गा�र्डे�न री�च शिपबि ल्डर्स� एण्र्डे इं�जी�बिनयर्स� लि�मि�टे�र्डे(भा�रीत र्सरीका�री का� उपक्र�)

GARDEN REACH SHIPBUILDERS & ENGINEERS LTD(A Government of India Undertaking)

(Ministry of Defence)

INVITATION TO TENDER Date: 18.04.2011

ENQUIRY NO.

Please quote this in all correspondence.

Please quote in duplicate for the following on delivered free to Garden Reach Shipbuilders & Engineers Ltd. or F.O.R. despatching Station Based, as per terms/ conditions detailed hereunder.

Item No.

Description Unit Quantity

01GRSE intends to carry out modification of the existing motivation hall and develop the entrance area of Corporate Building of Main Yard. You are requested to send your best offer on the basis of NIT in Annexure – I, Scope of Work in Annexure – II,

Encl: Annexure – I and II.

As per Annexure - II

As per Annexure - II

For गा�र्डे�न री�च शिपबि ल्डर्स� एण्र्डे इं�जी�बिनयर्स� शि�मि�टे�र्डे

अपरी �हा�प्र �धक (ई एर्स)/AGM (ES)

43/46 Garden Reach Road, Kolkata – 700 024, Ph: - 033 2469 8100 – 15 (15 lines),Fax No.: - 033 2469 2233, 8150, e-mail: - es.agm@grse.co.in

Annexure - I

Due Date & Time of Submission: 05-05-2011 at 13:30 hoursDue Date & Time of Opening: 05-05-2011 at 14:00 hours If the Due Date happens to be a Holiday or a Bandh then the next working day shall be taken as the Due Date of Submission and Due Date of Opening with the Timings of both remaining the same.

AGM (ES)/143/TE-2288/11

1. Garden Reach Shipbuilders & Engineers Limited (GRSE Ltd.) invites bids to carry out modification of the existing motivation hall and develop the entrance area of Corporate Building of Main Yard including design, manufacture, supply, erection, installation, commissioning and handing over to GRSE on turn key basis. You are hereby requested to submit sealed quotation for the above work as detailed in subsequent paragraphs.

2. Time of Completion: The work shall be started within 7 (Seven) days from the date of this order and completed within 90 days from the date of order or date of handing over of site whichever is later.

3. The bids will be obtained in three separate envelops as referred to herein below:-Part-I: This envelope shall contain technical parameters, commercial Terms and Conditions and unpriced bid (without any mention of price) interalia containing an undertaking that the bid does not contain any amendment, modification or change of any type whatsoever with respect to the bid document.

Part- II: This envelope shall contain only the priced BOQ only giving the unit price and amount against each item with grand total including Taxes & Duties at the end in figures and in words.

Part – III: The EMD.

These three separate sealed envelopes are to be put together in another sealed envelope. All the envelopes should be super scribed in bold letters with enquiry number, due date of submission and the contains therein and shall be sent directly to the Additional General Manager (ES), GRSE Ltd., 43/46 Garden Reach Road, Kolkata – 700 024.

4. No Tender Bid shall be considered without Earnest Money Deposit of Rs. 30,000.00 (Rupees Thirty Thousand only), which is to be submitted in the form of crossed Account Payee Bankers Cheque or Demand Draft payable at Kolkata. Bidder may also consider submission of EMD in the form of Bank Guarantee issued by any scheduled banks (other than Cooperative Banks) in favour of Garden Reach Shipbuilders & Engineers Limited, Kolkata. BG, if submitted, should be Valid for a period of 6 months from the date of Tender Bid Submission i.e. opening of Part –1 of the tender. The amount submitted towards EMD shall not carry any interest. Tender without Earnest Money Deposit strictly in the form and style as stated above may be rejected without further reference.

EMD of unsuccessful bidders shall be returned/refunded to the vendor without any interest after expiry of the bid validity or finalization/placement of the contract/order/LOI. EMD of successful bidder will be returned on successful completion of entire work to the satisfaction of GRSE.

Earnest Money / Bid Security will be forfeited if:-

a) The bidder withdraws the bid after bid opening during the period of validity, or before the supply or execution of work order.

b) The bidder does not accept the correction of bid price. c) The successful bidder fails within the specified time limit to:

(i) Sign the Agreement. (ii) Furnish the required performance security.

5. Rate quoted must cover all items of incidents, transport, conveyance, taxes, octroi etc. for the completion of work. All rates shall be quoted on the tender schedule both in figures as well as in words. In case of any discrepancy found between the rate/amounts quoted in figures and words, the rate/amounts quoted in words will be considered for acceptance. Tenderer shall initial all correction and sign with date on each page of the tender. In case of any discrepancy the rate/total value written in words shall be accepted. If there is any conflict between the Tender Notice in English and those in any other language or languages, the English version shall prevail and be followed. 6. The quotation shall be valid for acceptance for a period of 120 days from the date of submission. Tenderers are advised to inspect and examine the local & site conditions and its surroundings means of access to site as well as nature of work before submitting the tender. No extra charges/claims subsequent of any misunderstanding or otherwise shall be allowed.

7. Payment terms:

The contractor shall submit the bills in triplicate along with measurement book, material reconciliation statement with supporting SIRs/Challan for the materials issued from GRSE, if any.

90% payment will be made on satisfactory completion of the work in progressive stages within 30 day of submission of clear and complete bill duly certified by HR Department on compliance of statutory obligations by the contractor, in Finance Department, through ECS mode after deduction of cost of materials, if any, issued by GRSE on recovery basis as per certificate of Engineer In-charge.

Balance 10% of the order value shall be released after satisfactory completion of Defect Liability Period; alternatively this 10% of the order value shall be payable against submission of a bank guarantee of equivalent amount valid till expiry of defect liability period as stated in clause no 8 below.

8. Defect Liability Period: The defect liability period for entire work shall be 12 (twelve) months from the date of Engineer In-Charge’s Completion Certificate.

9. No claim for idle charge due to non-supply of any materials or services or work fronts by GRSE or for any other reasons will be entertained. No claim will be entertained due to sudden fluctuations of rates of labour and materials, freights, taxes and duties etc. at any stage.

10. GRSE do not bind them to accept the lowest or any tender or to assign any reason(s) thereof.

11. Materials and workmanship shall conform to relevant IS Specification and drawings, if any, issued for the work, Instruction of Engineer-in charge are to be followed in absence of IS Specifications for any item.

12. Contractor shall abide by the security regulations of GRSE for safe custody and movement of men and materials as applicable. Photo passes in prescribed proforma shall be arranged by the contractor for the men working more than a fortnight at a time.13. Safety measures such as using safety belts etc are to be adopted while working overhead. Contractor will be responsible for any damage caused by them to GRSE property.

14. Fire Prevention: The contractor shall take all reasonable precautions to prevent fire of any nature in the general vicinity of his operations and shall be held responsible for all damages from fire directly or indirectly for his own activities or his employees.

15. Force Majeure: Standard Force Majeure condition at the contractor’s own work / establishment shall only be accepted. However, the failure of the Subcontractors of the vendor’s shall not be accepted as a Force Majeure Condition.

16. Terms of Price: Prices are on the basis of free delivery to GRSE site and are inclusive of all taxes, duties etc. Price shall remain firm and final for the total actual duration of the contract period with no escalation whatsoever. Financial and other commercial obligation shall be with contractor in case any GRSE material is required to be taken out of GRSE’s premises for necessary reworking.

17. GRSE will not entertain any claim from the contractor for any idle time compensation.

18. During pendency of this order, the contractor shall not employ any officer of GRSE without GRSE’s written consent. GRSE reserves the right to terminate the order in case of breach of this stipulation.

19. Work has to be carried out in a site along with other agencies without affecting normal activities of GRSE. One full time responsible and qualified supervisor / representative has to be posted at site during progress of the work.

20. The quantities given in the schedule are approximate and may vary as per actual requirement at site. Payment shall be made on the basis of actual measurement of the work to be certified by the Engineer-in-Charge. Measurement shall be made as per the relevant IS Code, except wherever otherwise mentioned.

21. P.F. Clause: The Contractor has to indicate PF Code No. as possessed and enclose deposit Challans to GRSE with the bills for processing them.

In case the firm is not having PF and ESI Code then a declaration in prescribed format will have to be undertaken by the firm that they will timely deposit PF under Code No WB/301(Un-exempted) of GRSE and ESI Code No 41-3771 of GRSE and produce acknowledged copies of challans by the authorities concerned to the Retainer/HR Department for verification of compliance in each month.

In case of failure on the part of the contractor in this respect the bills payable to the contractor will be withheld till the challan depositing PF and ESI are produced by the contractor to the Retainer or to the respective HR officer of the Unit.

However in case such deposits are not made available by the contractor even after repeated instructions to the contractor to this effect, GRSE will be at liberty to exercise the right to deduct and adjust bill amount against deposit of statutory dues with the respective authorities. 22. As per the Official Secret Act 1923 of Ministry of Home Affairs, Govt. of India, Police Verification Certificate of character antecedents in respect of all employees of Contractors/Subcontractors operating in GRSE Ltd., is required to be submitted by the concerned contractors/subcontract before processing any gate pass for their employees, failing which gate pass may not be issued.

23. Arbitration: (i) If at any time before, during or after the contract period, any unsettled claim, question, dispute or difference arises between the parties, upon or in relation to or in

connection with or in any way touching or concerning this tender / agreement /supply order (retain whichever is applicable) the same shall bereferred to the Chairman & Managing director (‘CMD’ in short) or the Managing Director (‘MD’in short); as the case may be of Garden Reach Shipbuilders & Engineers Ltd. (‘GRSE Ltd’ in short) for adjudication of the said disputes or differences as sole Arbitrator, in accordance with the provisions of the Arbitration and Conciliation Act, 1996.(ii) If the CMD or MD of GRSE Ltd so desires, may nominate/ appoint another officer of GRSE Ltd. or a person, whom he thinks fit and competent for adjudication of the disputes or differences; referred to him as the sole Arbitrator.

(iii) Such Arbitration shall, in all respects, be conducted in accordance with the provisions of the Arbitration and conciliation Act, 1996 and the rules framed there under or any statutory modification or re-enactment thereof for the time being in force.(iv) The Award of the sole Arbitrator shall be final, conclusive and binding upon the parties. (v) In the event of the death or resignation for any reason whatsoever of the said sole Arbitrator, appointed by the said CMD or MD of GRSE Ltd, on an application form either of the parties in this behalf, shall act himself as the sole Arbitration or nominate / appoint, in place of outgoing Arbitration, another officer of GRSE Ltd. Or a person whom he thinks fit and competent to adjudicate the said disputes and differences in accordance with law.

(vi) Also in the event of an arbitration award is set aside by a competent court on an application form either party and unless otherwise ordered by the said court, the CMD or MD of GRSE Ltd; on an application form either party, shall himself act as sole Arbitrator or nominate / appoint another officer of GRSE Ltd. or a person whom he thinks fit and competent to adjudication the disputes and differences in accordance with law.

(vii) The cost of the arbitration, fees of the arbitrator, remuneration of the stenographer and clerk, stamp paper etc; as shall be decided by the sole Arbitrator, shall be shared equally by the parties. The venue of Arbitration, unless otherwise decided by the parties or by the sole Arbitrator himself, shall be the premises of Garden Reach Shipbuilders & Engineers Ltd. located at 43/46 Garden Reach Road, Kolkata - 700 024.

24. The bidder who is not enlisted with GRSE yet, should furnish the details of similar work executed in last one year, like Purchase Order No., date, value, completion of certificate, contact details like name, address, telephone no. of the person under whose direct jurisdiction the work was executed of similar work executed in last one year, details of infrastructures including human resources available etc.25. The quantities indicated against each item are tentative only. Actual requirements shall be estimated by the vendor from the site requirements and will be binding on the vendor for execution.

GRSE reserves the right to: -a) Add/cancel items in scope of this order.b) Increase/decrease in the quantities of items involved in the scope of this order,c) Add/cancel items of erection work involved in the order,d) The unit rate for supply and erection shall be applicable for any increase/decrease in quantities and calculating the extra price /price reduction on account of variation,e) The price for new items shall be negotiable.

26. One full responsible and qualified Site In charge has to be posted at the site during progress of work.

27. Inspection: The work shall be inspected and certified as completed in totality with desired quality by AGM (ES) or the nominated representative of shipyard.

28. All tools, tackles, staging etc. are to be arranged by the contractor.

29. No living accommodation inside GRSE premises will be allowed Safety measures, such as safety belts etc. are to be adopted while working is overhead. The contractor will be responsible for any damage caused by him to GRSE property arising out of his executing this Work.

30. GRSE reserves the right to split up the work to various contractors, if found necessary and to restrict the items of the quantum of work as per requirement and no claim on this account will be admitted.

31. Liquidated Damages: If the contractor fails to complete the work within the stipulated time, the contractor shall be liable to pay GRSE as penalty @ 1 % of the order value for every week of delay or part thereof, subject to a maximum of 10 % of the order value.

32. GRSE reserves the right to cancel the works in case of poor materiel supply, poor workmanship/progress and get the work completed at risk and cost of the contractor. GRSE reserves the rights to cancel this work order in case of poor workmanship /progress of work and get the work done through any other agency at the risk responsibility and cost of the contractor.

33. Contractor has to submit gate entry challans with quantities duly certified by Gate Office for materials procedure for this work.

34. Working Hours: Contractor’s men will be allowed to work normally during working hours of GRSE. If work is required beyond normal working hours of GRSE including Sundays/Holidays special permission has to be taken by contractor for each day. GRSE may or may not give permission for work beyond working hours for security reasons. No claim of extension of time will be granted on this ground.

35. It will be considered that the bidder has inspected, examined and understood the local & site conditions and its surroundings means of access to site as well as nature, details of work to be executed while submitting the tender. No extra charges/claims subsequent of any misunderstanding or otherwise shall be allowed.

36. Jurisdiction: All disputes arising out of the contract if required to be referred to a court of law, the jurisdiction of the case would be under Kolkata Court irrespective of the location of the vendor.

अपरी �हा�प्र �धक (ई एर्स)/AGM (ES)

Annexure – II

(An enclosure to tender document no AGM (ES)/143/TE-2288/11 dated 18.04.2011)

Sl No

Description Unit Qty Rate (`)

Amount (`)

           1 Dismantling        

 

Dismantling / removal of windows, doors, glass panels, granite slabs, marbonite floors, existing plastering, P.C.C. floors, all other materials / structures as necessary to facilitate construction /completion of the project etc.

- LS    

         

2  Site Cleaning      

General site cleaning and removal of debris and ensuring cleanliness of site through out the duration of works including housekeeping services till handover of the project.

- LS

 3 Foundation work        

  

Digging below up to 3 ft from the present floor level, providing all requisite material and laying 10" brick walls with well burnt good quality of first class designation 75 in cement mortar 1:4 (1 cement : 4 coarse sand) around the extension area up to the plinth level of the existing building to match with the flooring. The trough is then to be completely filled with Silver Sand, compacted and rough soling to be done on top of that.

Sft  1250    

           4 Screed Concreting        

 

Providing all requisite material and laying concrete mix of 75mm average thickness in cement concrete M15 grade (1:2:4 nominal mix) with 6 mm and down graded stone chips and medium coarse sand with proper leveled surface. Rate to include necessary material handling and complete work at all levels.

Sft  1160    

           5 Brick Work        

Providing all requisite material and laying 125 mm thick brick masonry work with well burnt good quality of first class designation 75 in cement-sand mortar 1:4 (1 cement:4 coarse sand) duly finished including scaffolding, curing, rubbing the surface, racking out the joints etc., complete as directed and specified for walls, parapet, platform supports etc. at all floor heights & levels. Rates to include 2 no 6 mm MS bar at every 3rd course and chicken wire mesh laying at junction of any other material.

Sft 576    

           6 Plastering Works        

 

Cement Sand Plaster: Providing all requisite materials and laying 20 mm thick plaster on both sides in cement mortar 1:5 (1 cement : 5 coarse sand) to all types of brick work (small or big)/RCC work surfaces including walls, tops, jambs and cills etc. at all levels in line, level and plumb as required, including smooth cement finish, providing necessary bands, drip moulds, tapak, grooves, including, chicken mesh at the junction of two different materials, raking the joints or roughening the RCC surfaces, necessary curing, scaffolding etc., complete as directed and specified.

Sft 5740    

           7 MS Structural Works    

(a)

Supply all requisite material, fabrication of MS structure for roofing using MS flats and tubular sections conforming to IS: 806-1957 and IS: 1161-1958 connected to one another with brackets, cleats etc. all complete including cutting to requisite size and fabrication with necessary metal arc wielding conforming to IS:816-1956 using electrode of make to be approved by GRSE. The top to be covered with Tata corrugated Bluescope corrugated GI sheets in grade G550 (minimum yield strength 550 MPa) with base metal thickness 0.80 mm. the various components of the truss to be fabricated will be as flows: Top Chord: 88.9 O/D tubular section, Bottom Chord: 101.6 O/D (M), Bottom Runner: 60.3 O/D (M), Purling: 88.9 O/D (M) square bar, Wind Tie: MS flat (60X12); Webs - 48.3 O/D (M). The job includes securing/fixing to the brick wall with necessary support system.

Sft 1350

(b) Supply all requisite material, fabrication of MS structure for column and beam structures supporting the roof using simple rolled structures of MS I-section (ISMB/ISMC) conforming to IS: 226, IS: 806 and SP (6)-1964, connected to one another with brackets, cleats etc. all complete including cutting to requisite size and fabrication with necessary metal arc wielding conforming to IS: 816-1956 using electrode of make to be approved by GRSE. The columns should comprise of 2 no ISMC 250 welded together face to face to make a perfect square bar of size 250 X 250 mm. These should be welded with 12mm thick MS base plate fixed to the floor with 25 mm thick and 600 mm long bolts grouted inside the RCC bed. The top of the column has to be welded with another base

MT 6.67

plate which in turn gets fixed with nut and bolts with the supporting base plate of the truss.

(c)

Supply all requisite material, fabrication and erection of 200 mm wide, 150 mm deep riding, rain gutter, eaves channel guttering by fixing aluminium plain sheet forming the component of the roof system with requisite nuts, bolts, screws to collect and divert rain water; arrangement should be made to pass out collected/accumulated water through a downspout (4” dia EPVC pipe of make to be approved by GRSE) from the roof edge to the base of the building and finally to the nearest drainage system.

Sft 352

 8 Structural Glazing        

 

Glazing on specially designed system to withstand wind pressure of 180 kg/M2 with pressure equalization, gasket barrier, drainage at all panel position, spandrel panel pressure release & condensation drainage, to accommodate building movements, thermal expansions and the seismic movements.

Sft 1820

        

        

Series: 34Alloy & Temper: 6063 T6Extruder: Alom/Hindalco/Century Surface Coatings: 15 micron Colour anodizing / 60 Micron Powder CoatingSectional Details:Mullion: 101 .00 mm x 52.00 mm x 2.00 mmTransome:63.00 mm x 52.00 mm x 2.00 mm

Accessories: GI Anchor fastener & galvanized bolts, GI screw, PVC Shim, Hot dipped Galvanized MS brackets, DOW CORNING Structural (995) / Equivalent.

    

    

Sealant: Weather (789) sealant / Equivalent.Gasket: Microwave cured EPDM gasket for air and water sealGlass: Saint Gobain 8mm Toughned Reflective

           9 Roof for Atrium

Providing all requisite materials, fabrication of atrium roof with MS structural framework of 88.9 O/D (M) square bar covered from top with Tata Bluescope GI corrugated sheet in grade G550 (minimum yield strength 550 MPa) with base metal thickness 0.80 mm; from below the roof to be cladded with aluminium composite paneling as per technical specification given in Sl no 8 below to give a smooth plain finish.

Sft 2020

10 ACP Cladding        

 

Fixing aluminium composite wall panel of with foil thickness on both sides cladded to shaped profile as per approved shade and specified design would confirm the following specifications:

Sft 889

      

      

Framing: Framing with 37 x 47 mm Aluminum TubeExtruder: Hindalco/Century/Alom

Sealant: Dow Corning 789 Silicon/Mccoy

Accessories: Anchor fastener, Galvanized Bracket, foam , & GI screws, Aluminum rivets, Aluminum corner clips, etc.Groove Size: The size of the groove between the panels would be 10-12 mm.

           11 Glass canopy

Providing all requisite materials, fabrication of glass canopy made of Saint Gobain make 12 mm thick toughened glass sheet fixed to brush finished stainless steel framing structure strong enough to bear the load, fixed to building wall on one side and hung from the wall with SS strings.

Sft 400

12 Wooden False Ceiling        

 

Ceiling framework to consist of 2'-0" x 2'-0" grid work of hardwood sections with sectional size as 11/2" x 3" fixed/secured to ceiling with bullet GI fasteners ready and firm to take the load duly finished by proper taping and jointing compound complete with all accessories like special adjusters, tees, cross tees having interlocking slots, wall angle, suspenders, treated with anti termite treatment, fixing pins etc. including supply of all requisite materials. Rate should include recess, cutouts/openings for light fittings, cove works in ceiling as per direction of GRSE. The tiles should be perforated wooden board finished with glossy melamine.

Sft 1325    

           

13 Single leaf glass door        

 

Fabricating and fixing single leaf 12 mm thk toughened glass door of size 1200 x 2100 mm with patch fittings as per details. All the door patch fittings should be Hafele/Savex make, floor spring - Dorma make, handles - Hafele make, glass - Saint-Gobain make, Door Handle (2 no) - Ozone/Haffele make, Door Lock (1 no) – Godrej make, Door Closure (1 no) – Godrej / Garnish make and Door Stopper.

Sft 56    

           

14 Double leaf glass door

Fabricating and fixing single leaf 12 mm thk toughened glass door of size 1800 x 2100 mm with patch fittings as per details. All the door patch fittings should be Hafele/Savex make, floor spring - Dorma make, handles - Hafele make, glass - Saint-Gobain make, Door Handle (2 no) - Ozone/Haffele make, Door Lock (1 no) – Godrej make, Door Closure (1 no) – Godrej / Garnish make and Door Stopper.

Sft 65

15 Vitrified Tile Flooring        

 

Providing & laying vitrified flooring with Johnson make 1st quality homogeneous vitrified tiles of shade, texture and design to be approved by GRSE, size 900mm x 900mm, set in 1:4 CM on epoxy cement-based backing mortar, including pointing with epoxy stain free (SP-100) grouting, curing, compound bedding in proper slope, lines, levels etc., finishing the joints with matching compound complete as required & directed by GRSE, protection with polythene sheet and POP overlay till hand-over.

Sft 1910    

           16 Kota Stone Flooring

Providing all requisite materials and laying 18-20 mm thick kota stone flooring at parking lot. The stone to be cut into even and equal pieces of size 300 X 300 mm, set in 1:4 CM, including pointing with Epoxy stain free (SP-100) grouting, properly cured, complete in all respects including polishing. The flowing at parking positions to be laid in a zigzag pattern so as to provide grip for the car tyres.

Sft 360

17 Wooden Wall Paneling        

 

Wooden Wall Paneling with single layer of 12mm thick BWP plywood to be made on 50x35mm framework of hard wood, with tapered edge 12.5 mm screw at 610 mm center to centre as per framework finished on top with Green/Century make veneer and shade to be approved by GRSE duly finished with high gloss melamine polish. Necessary provision to be made to fix the skirting as required. Rate includes grooves in veneer and polished teak wood moulding if necessary.

Sft 1128    

           18 Push/Pull signage        

 Brushed steel finished with black embossed letters for push and pull singage in access controlled glass doors.

- LS    

           

19 Electrical works ( including light fixtures )        

 

Supply, installation, testing and commissioning of electrical system comprising with recessed type lighting at false ceiling with 20 no 2X36 Watt CFL (2’ X 2’) luminaire, 15 no recessed down lights suitable for use with High Pressure Metal Halide 150 Watt lamps Philips make type no MBS 205/150, 20 no 2X18W CFL down lighter, wires, FR cables, FRPVC conduits, wire ways, Circuit / point wiring, MCB, DB, Power outlets, switch boxes, modular switches & sockets and lamps, all complete as per design and direction of GRSE.

Sft 2125     

Make of luminaire - PhilipsMake of lamp - Osram / PhilipsMake of cable/wires - Polycab/Havells/FinolexMake of switch & socket - CrabtreeMake of MCB - Legrand

           20 Glass Mosaic Cladding        

 

Profiding and fixing Bisazza make glass mosaic over rough backing with glass mosaic adhesive so as to give a design pattern or any artwork, to be approved by GRSE, applied over the curved wall outside surface of the staircase well. Technical specification: no water absorption, resistant to

Sft 5500    

thermal shock, chemical attack, frost and colour fading. The mosaic pieces (tesserae) are of 20 mm x 20 mm size uniformly spaced by a regular interval of 4 mm finished with special coloured epoxy grout. Weight of glass mosaics: 7kg/Sq Mtr.

           21 Acrylic emulsion paint        

 

Providing and applying on wall Asian Paints / ICI make acrylic emulsion paint finish of shade and texture to be approved by GRSE. Existing wall surfaces to be prepared by scraping away of any loose particles, dust etc. by washing and scrubbing and 2 coats of water based primer to be applied to prepare the surface. The wall surfaces are then smoothened using putty as directed. Surfaces are then sandpapered to achieve a smooth finish and three coats of paint to be applied as directed.

Sft 1325    

           22 Enamel paint        

 

Providing and applying 3 coats of Asian Paints / ICI make Enamel Paint finish of shade to be approved by GRSE over two coats of red oxide paint after proper scrubbing of all the MS Structural works (joist, angles, tubes, etc.).

- LS    

           23 Roller Blinds        

 

Providing & fixing 100% blackout roller blinds Classic make, made with normal fabric; shade to be approved by GRSE. Roller Tube should be made of extruded Aluminium Alloy. Clutch shall be of wrap spring design and shall operate directionally; mechanism shall be crash proof, prevent slippage and shall rise and come down smoothly to any desired height. Bottom of the blind shall be provided with Aluminium Powder coated tube in matching colour with the selected fabric. The supply should be provided with aluminium frame, runner, chain, cord and control unit, all complete as approved by GRSE.

Sft 864    

24 Pest control or Anti-termite treatment: Prevention of the termite from reaching the superstructure of the building and its contents to be achieved by creating a chemical barrier between the ground and other contents of the building. Treatment of the soil beneath the building and around the foundation should be

Sft 2453     

made with appropriate insecticide. Chemicals like Chlorphriphos and / or Lindane emulsifiable concentrate of 20% to be used for this purpose.

25

Manufacture, supply and erect GRSE Name Board as per colour and design in the form of Glow Sign Board of base material P-III flex; lettering areas should have 3635 day/night vinyle including LEF (Light Enhancement Film) and LED and Philips true lighting inside arrangement.

No 2

Total `  Total in words  

The bidder is to specify the make, model, design, texture, colour and enclose catalogue against each item proposed to be offered/used for execution of the project in the technical bid document for approval of GRSE.

अपरी �हा�प्र �धक (ई एर्स)/AGM (ES)