CLASSIFIEDS 701-857-1920 Wednesday, October 14, 2020, Minot (N.D.) Daily News C7

ADVERTISEMENT FOR BIDSFOR THE CONSTRUCTION OF

NAWS BIOTA WATERTREATMENT PLANT PHASE I

(CONTRACT 7-2A/4-1A)FOR THE NORTH DAKOTA STATE

WATER COMMISSIONNOTICE IS HEREBY GIVEN thatthe State of North Dakota, actingthrough the State Water Commis-sion, invites and will receive sealedproposals (bids) up to the hour of1:30 p.m., local time, on October29, 2020, for the furnishing to theState of North Dakota of all transpor-tation, labor, materials, tools, equip-ment, services, permits, utilities, andother items necessary to constructsaid work, in accordance with thedrawings and contract documentson file in the office the North DakotaState Water Commission. At saidtime, said proposals will be publiclyopened and read aloud in the NorthDakota State Water Commission lo-cated at:

North Dakota State WaterCommission

State Office Building900 East Boulevard Avenue

Bismarck, North Dakota 58505-0850Bids shall conform to and be respon-sive to the Contract Documents forthe work. The electronic reproduc-tions of the Contract Documents willbe available after September 28,2020. Copies of the Original versionof the Contract Documents will beon file and may be examined duringnormal office hours after October 2,2020 in the office of the North Dako-ta State Water Commission and atthe following locations:

Houston Engineering, Inc.3712 Lockport Street, Suite ABismarck, ND 58503701-323-0200 Phone701-323-0300 Fax

Houston Engineering, Inc.18 3rd St SE, Suite 101Minot, ND 58701701-852-7931 Phone701-858-5655 Fax

In accordance with the North DakotaCentury Code Chapter 48, the pro-ject shall be comprised of multiplebids. There are four (4) contracts:Contract No. 1 - General Construc-tion; Contract No. 2 - MechanicalConstruction; and Contract No. 3 -Electrical Construction; which maybe bid separately. A combined con-struction Contract, Contract No. 4 -Combined General, Mechanical, andElectrical Construction, which in-cludes all Work may also be Bid.The contract(s) shall be awarded tothe lowest responsive and responsi-ble bidder(s). The sum of Contracts1, 2, and 3 will be compared to Con-tract 4 to determine the lowest bid. IfContracts 1, 2, and 3 are awarded,the General Construction Contractorwill assume responsibility for coordi-nating the work of the prime contrac-tors responsible for Contracts 2 and3. The scope of Work for each Con-tract generally consists of the follow-ing:

CONTRACT NO.1 -GENERAL CONSTRUCTION

Construction work includes: Sitedemolition; construction of new con-crete, steel, and precast Biota WaterTreatment Plant, two (2) DissolvedAir Floatation (DAF) basins with in-cluding pre-procured DAF equip-ment, four (4) dual-media filters, in-stallation of two (2) pre-procured ul-traviolet (UV) disinfection reactors,clearwell, equalization basin, two (2)freeze-thaw lagoons, chemical feedand storage, laboratory, break room,other associated facilities, masonry,site piping, site work, BWTP Shop,paving, landscaping, miscellaneousmetalwork, doors, windows, flooring,and coatings; and other miscellane-ous Work.

CONTRACT NO.2 -MECHANICAL CONSTRUCTION

Construction work includes: Con-struction of new process piping insizes ranging from 1-inch to 42-inch, valves, actuators, meters, sup-ports, pump and surge control sys-tems, sump pumps, plumbing, filtra-tion equipment and appurtenances,HVAC; and other miscellaneousWork.

CONTRACT NO.3 -ELECTRICAL CONSTRUCTION

Construction work includes: Con-struction of new PLC/PC based pro-cess control systems, control con-soles, MCCs, VFDs, starters, buriedcable, general building and processcontrol electrical Work; and othermiscellaneous Work.CONTRACT NO.4 - COMBINEDGENERAL, MECHANICAL, &ELECTRICAL CONSTRUCTION

Construction work includes: All workassociated with Contracts 1, 2, and3 combined. The Contractor will notperform work or permit the perfor-mance of Work by subcontractorsoutside regular dusk to dawn work-ing hours or on Saturdays, Sundays,or legal State holidays without pro-viding written notice of proposedwork to the Engineer a minimum of5 days in advance and contingent onthe Owner’s written consent.Copies of plans and specificationsmay be obtained after October 2,2020 following receipt of payment of$1,500.00 per set, non-refundable,or a CD may be obtained with thedocuments in electronic (pdf) formatfollowing receipt of payment of $40per set, nonrefundable, from thefollowing:

Houston Engineering, Inc.3712 Lockport StreetBismarck, ND 58503-5535

The electronic reproductions of theContract Documents may also be

viewed free of charge online atwww.houstoneng.com, or down-loaded for a fee of $25.00 after Sep-tember 28, 2020. Please contactHouston Engineering at701-323-0200 if you have any ques-tions about viewing or downloadingthe documents. The Advertisementfor Bids, Planholders List, Adden-dums, and Bid Results will be avail-able from the “Bid Info” link locatedon the Houston Engineering, Inc.web site.In accordance with the current Ener-gy and Water Development Ap-propriations Act, to the greatest ex-tent practical, all equipment and pro-ducts purchased for use in this con-tract shall be Americanmade.A virtual pre-Bid conference will beheld on October 15, 2020 at 9:00a.m. The conference will be held viaMicrosoft Teams and also be acces-sible via call-in conference line.Representatives of the Owner andEngineer will be present to discussthe Project. Prospective primeBidders are required to attend andparticipate in the conference. Allbidders planning on attending themeeting shall send an invite request,via email, with the subject “NAWSBWTP: Pre-Bid Conference” to AlanKemmet at akkemmet@houstoneng.com prior to 12:00 p.m(noon) on October 14, 2020. In-vites shall be sent to the sendingemail address of the request. Atten-dance will be taken only once by theEngineer at the beginning of themeeting. All prime bidders listed onthe attendance sheet will be eligibleto bid the project. Bidders that arenot listed on the attendance sheetshall not be eligible to bid the projectas prime Bidders.Each bid shall be submitted on aform furnished as part of the con-tract documents and must be ac-companied by a separate envelopecontaining a Bidder’s Bond withAcknowledgement of Surety in anamount not less than 5% of the fullamount of the bid made payable tothe order of or for the benefit of theNorth Dakota State Water Commis-sion. The bid bond shall be executedby the bidder as principal and by asurety company authorized to dobusiness in the State of North Dako-ta, conditioned that if the principal’sBid be accepted and the contractawarded to the principal, within ten(10) days after Notice of Award, thePrincipal shall execute a contract inaccordance with the terms of the bidand contractor’s performance andpayment bonds as required by lawand the regulations and determina-tions of the North Dakota State Wa-ter Commission. A bid submittedwithout this information properly en-closed in the bid bond envelopeshall not be read nor considered andthe envelope shall be resealed andbid returned to the bidder immedi-ately. Each bid shall be sealed anddelivered to the North Dakota StateWater Commission at the locationdesignated in this notice for theopening of proposals at or before thetime in this notice provided.Anyone wishing to hand deliver bidsor attend the bid opening in personwill need to call (701) 328-2750 atthe entrance to the Water Commis-sion building and will be permittedaccess to the building.Anyone entering the building will bescreened, will be escorted to theconference room to deliver the bid,attend the bid opening and escortedout of the building after the bid open-ing. Masks are required. The bidopening shall also be accessible forvirtual attendance via the samemeans as the pre-bid conference. Allwho plan on attending the bid open-ing virtually shall send an invite re-quest via email, with the subject“NAWS BWTP: Bid Opening”, toAlan Kemmet atakemmet@houstoneng.com prior to12:00p.m. (noon) on October 28,2020. Invites shall be sent to thesending email address of the re-quest.Unless a bidder obtains acontractor’s license for the fullamount of its bid within twenty daysafter it is determined the bidder isthe lowest responsive and responsi-ble bidder, the bid must be rejectedand the contract awarded to the nextlowest, responsive, responsible, andLICENSED bidder.Completion for WORK for Mile-stone 1 shall be December 17,2021. Substantial Completion forall WORK shall be September 29,2023. Final Completion for allWORK shall be December 15,2023.The State of North Dakota, actingthrough the State Water Commis-sion, reserves the right to select theschedule(s) under which the bidsare to be compared and contract(s)awarded, to reject any and all bids,to determine whether a bidder isresponsive and responsible, and towaive any and all irregularities inany bid.BY THE ORDER OF THE NORTHDAKOTA STATE WATER COM-MISSION.Dated: September 24, 2020John Paczkowski, Secretary(September 30; October 7-14, 2020)

IMPOUNDED VEHICLE06 Acura TLVin: 19UUA66246A060989Impounded by NoDak Towing Sept.22nd 2020 Failure to claim vehiclewithin 30 days of this notice willresult in forfeit of all rights to saidmotor vehicle pursuant ND CenturyCode 39-26-08.

(October 14, 2020)

INVITATION TO BID

PROJECT. Souris HeightsBIDS CLOSE. Tuesday, November10, 2020, 2 PM

EAPC PROJECT #. 20201550DATE OF ISSUE. October 14, 2020BY. EAPC Architects Engineers300 3rd Ave SW, Suite AMinot, ND 58701PHONE: (701) 839 – 4547

OUTLINE OF PROJECT. The pro-ject is a three-story 54 unit apart-ment building with two attached onestory parking garages for BeyondShelter Inc.. The project located atthe intersection of 35th Avenue NWand Kodiak Street in Minot, ND, willbe wood framed, with asphalt shin-gle sloped roof, metal siding andbrick veneer. Interior finishes will beprimarily carpet, luxury vinyl tile,painted gypsum, and ceramic tile inlocations. The project is federallyfunded and part of the NDR pro-gram.TYPE OF BIDS. Bids will be re-ceived from qualified Bidders at thesame time on the following portionsof the work, separately as listed orcombined at the Bidder’s option:

General ContractMechanical ContractElectrical Contract

THE OWNER.Beyond Shelter, Inc.3320 Westrac Dr. S.Suite GFargo, ND 58103

BID PLACE.EAPC Architects Engineers300 3rd Avenue SW, Suite AMinot, ND 58701

Bids received after the designatedtime will not be accepted. All in-terested parties are invited to attend.Bids will be opened and publiclyread aloud. It is the Bidder’s respon-sibility to see that mailed ordelivered Bids are in the hands ofthe Owner prior to the time of theBid opening.OBTAINING DOCUMENTS. Draw-ings and Specifications may be ex-amined at the Architect/Engineer’soffice, and the Owner’s office at theaddress shown above and:

QuestCDN (www.questcdn.com)CMD (Construction Market Data)Dodge Plan Room and SCAN inMinneapolis.Minnesota Builders Exchanges atDuluth, St. Cloud, Minnesota Build-ers Exchange in Minneapolis.North Dakota Builders Exchanges atBismarck, Dickinson, Fargo, GrandForks, Minot, Williston.South Dakota Builders Exchanges atAberdeen, Plains Builders in SiouxFalls, Rapid City,Sioux Falls Builders Exchange.Montana Builders Exchange at Bil-lings.

If Contractor receives the biddingdocuments from a plans exchange,it is the Contractors responsibility tocontact EAPC Architects Engineersto be added to the plan holders list.Complete digital project bidding do-cuments are available atwww.questcdn.com. You maydownload the digital plan documentsfor $15.00 by inputting Quest project# 7360608 on the website’s ProjectSearch page. Please contactQuestCDN.com at 952-233-1632 orinfo@questcdn.com for assistancein free membership registration,downloading, and working with thisdigital project information.An optional paper set of project do-cuments is also available for a re-fundable price of $150 per set fromEAPC Architects Engineers, 300 3rdAve SW, Suite A, Minot, ND 58701.If the Bidder returns the set of docu-ments, in good condition, within 10days following the Bid Date, thedeposit will be refunded. If theBidder does not return the set of do-cuments within the designated time,none of the deposit will be refunded.Please allow 2 days for printing.Partial or complete sets of prints andspecifications may be obtained fromEAPC by other than the above. Thesets or partial sets will be distributedupon receipt of payment for the in-formation charged at the currentreproduction rate. None of this pay-ment will be refunded. Complete-ness and adequacy of the list of do-cuments requested shall be theresponsibility of the person makingthe request.FEDERAL REGULATIONS. Thiscontract is Federally assisted. TheContractor must comply with theDavis- Bacon Act, the Anti- KickbackAct, and the Contract Work HoursStandards. Contracts for work underthis bid will obligate the Contractorand Subcontractors not to discrim-inate in employment practices.Bidders must submit a compliancereport in conformity with thePresident’s Executive Order No.11246.BID SECURITY. Bid Security in theamount of five (5%) percent of theBid including all add alternates, mustaccompany each Bid in accord with00 1000 - Instructions to Bidders.Bidders Bond, cashier’s checks orcertified checks will be accepted.NORTH DAKOTA LAW. All biddersmust be licensed for the highestamount of their bids, as provided byNorth Dakota Century Code Section43-07-05; and no bid will be read orconsidered which does not fullycomply with the above provisions asto bond and licenses, and any biddeficient in these respects submittedwill be re-sealed and returned to thebidder immediately.BID SUBMISSION: Bids shall besubmitted to the person and place,and by the time indicated in the In-structions to Bidders. Bids shall bepackaged in accordance with 001000 - Instructions to Bidders.THE OWNER reserves the right to

waive irregularities, to reject Bidsand to hold all Bids for a period of 30days after the date fixed for theopening thereof.By order of: Dan Madler, CEO

(October 14-21-28, 2020)

NORTH DAKOTA DEPARTMENTOF ENVIRONMENTAL QUALITY

PUBLIC NOTICE OFOPPORTUNITY TO COMMENT ON

DRAFT PERMITFOR A SOLID WASTE

MANAGEMENT FACILITY UNDERTHE NORTH DAKOTA SOLIDWASTE MANAGEMENT RULES

FACILITY NAME: Stanley InertWaste Landfill – Permit 0126APPLICANT: City of StanleyPO Box 249Stanley, ND 58784BACKGROUND:On August 8, 2019, the North Dako-ta Department of EnvironmentalQuality (Department) received a per-mit application for a renewal of theCity of Stanley’s inert waste landfillfacility.The City of Stanley currently ownsand operates an inert waste landfill,regulated under Permit 0126 locatedin the NE1/4 of the NW1/4 of Sec-tion 27, Township 156 North, Range91 West in Mountrail County, ND.The City of Stanley is proposing torenew their permit. The Inert WasteLandfill facility was first permitted in1991.The facility operates an existing inertwaste landfill area, a yard wastecomposting area, a recyclable me-tals pile (including white goods), aconcrete and asphalt concrete pilefor reuse or disposal, a woodstorage area for conducting openburning, and soil stockpiles for futurecovering operations. According tothe application, waste will be accept-ed from residents within the City ofStanley and residents from MountrailCounty that are generally locatedwithin 20 miles of Stanley.The Department believes that a per-mit which meets the requirements ofthe North Dakota Solid WasteManagement Rules and is protectiveof human health and the environ-ment can be issued to the City ofStanley and has prepared a DraftPermit for public review and com-ment.PUBLIC COMMENTS AND HEAR-INGAs required by Section33.1-20-03.1-03 of the North DakotaAdministrative Code, the Draft Per-mit will be available for public reviewand comment for thirty (30) days fol-lowing publication of the Public No-tice. The public comment period be-gins October 14, 2020 and ends No-vember 12, 2020. During thatperiod, any interested person maysubmit written comments and re-quest a public hearing by stating thenature of the specific issues to beraised. A fifteen (15) day notice willbe provided before any hearing isscheduled. The North DakotaDepartment of Environmental Quali-ty will consider all comments prior totaking any action on the permit.Comments, questions and writtencommunication should be directedto:

Charles R. Hyatt, DirectorNorth Dakota Department of

Environmental QualityDivision of Waste Management

918 East Divide Avenue, 3rd FloorBismarck, ND 58501-1947

Comments may also be sent viae-mail to solidwaste@nd.gov.The Draft Permit and Permit Appli-cation are available for review duringthe hours of 8:30 a.m. to 4:00 p.m.,Monday through Friday, at the NorthDakota Department of Environmen-tal Quality, Division of WasteManagement, 918 East Divide Ave-nue, 3rd Floor, Bismarck, ND. Acopy of this Public Notice is also onthe Department’s website at:https://deq.nd.gov/PublicNotice.aspxAnyone requiring special access oraccommodations to review the DraftPermit may contact the Departmentat 701-328-5166.

(October 14, 2020)

**NOTICE OF RESCHEDULE**NORTH DAKOTA DEPARTMENT

OF TRUST LANDSFALL SURFACE LEASE ONLINE

AUCTIONThe Board of University and SchoolLands will conduct an online surfacelease auction for one thousand forty(1040) tracts in Adams, Barnes,Benson, Billings, Bowman, Burke,Burleigh, Divide, Dunn, Eddy, Em-mons, Golden Valley, Grant, Het-tinger, Kidder, Lamoure, Logan,McHenry, McIntosh, McKenzie,McLean, Mercer, Morton, Mountrail,Oliver, Pierce, Rolette, Sheridan,Sioux, Slope, Stark, Stutsman,Towner, Ward, Wells, and WilliamsCounties, ND. Tracts will be avail-able to view on September 1, 2020.Bidding will commence October 12,2020 at 8:00 a.m. CST and endstaggered from October 20-23, 2020starting in alphabetical order withAdams Co. The link to view the of-fered tracts and participate in theauction is:

https://www.energynet.com/govt_listing.pl

The Board of University and SchoolLands reserves the right to rejectany and all bids.Anyone needing auxiliary aids andservices should call the Departmentat (701) 328-2800 by 10/20/2020.9/24/2020 /s/ Jodi Smith

Commissioner(September 30; October 7-14, 2020)

NOTICE TO CREDITORS

Probate No. 51-2020-PR-00134

IN DISTRICT COURT, WARD

COUNTY, STATE OF NORTHDAKOTA

In the Matter of the Estate ofLori M. King, Deceased.

NOTICE IS HEREBY GIVEN thatthe undersigned has been appointedPersonal Representative of theabove estate. All persons havingclaims against the deceased are re-quired to present their claims withinthree months, 90 days, after the dateof the first publication or mailing ofthis notice or the claims will be for-ever barred. Claims must either bepresented to Norman F. King, Jr.,Personal Representative of theEstate of Lori M. King, in care ofLaura Wheeles of Boppre Law Firm,PLLC, 2151 36th Ave SW, Suite B,Minot, North Dakota 58701, or filedwith the Court.Dated this 25th day of September,2020.

/s/Norman F. King, Jr.Norman F. King, Jr.,Personal Representative

/s/Laura WheelesLaura Wheeles (ID #09319)Boppre Law Firm, PLLC2151 36th Ave SW, Suite BMinot, ND 58701701-852-5224lwheeles@bopprelawfirm.comAttorney for PersonalRepresentative(September 30; October 7-14, 2020)

NOTICE TO CREDITORS

Probate No. 51-2020-PR-00174

IN THE DISTRICT COURT OFWARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate ofGayle Farris Stafford, Deceased.

NOTICE IS HEREBY GIVENthatBrigitte Funk has been appointedPersonal Representative of theestate of Gayle Farris Stafford. Allpersons having claims against thedecedent are required to presenttheir claims within three months afterthe date of the first publication of thisnotice or their claims will be foreverbarred. Claims must either bepresented to Brigitte Funk at PO Box1057, Minot, ND 58702, PersonalRepresentative of the estate, or filedwith the Court.Dated this 8th day of October, 2020.

/s/Bridgitte FunkBridgitte FunkPersonal Representative

Paul A. Temanson (04468)Temanson Law FirmPO Box 1057Minot, ND 58702Attorney for the Personal Represen-tative

(October 14-21-28, 2020)

NOTICE TO CREDITORS

Probate No. 51-2020-PR-00186

IN DISTRICT COURT, WARDCOUNTY, STATE OF NORTH

DAKOTA

In the Matter of the Estate ofRamona G. Schaan, Deceased.

NOTICE IS HEREBY GIVEN thatthe undersigned has been appointedPersonal Representative of theabove estate. All persons havingclaims against the deceased are re-quired to present their claims withinthree months, 90 days, after the dateof the first publication or mailing ofthis notice or the claims will be for-ever barred. Claims must either bepresented to Brenda Weber, Per-sonal Representative of the Estateof Ramona G. Schaan, in care ofBrian Boppre of Boppre Law Firm,PLLC, 2151 36th Ave SW, Suite B,Minot, North Dakota 58701, or filedwith the Court.Dated this 8th day of October, 2020.

/s/Brenda WeberBrenda Weber,Personal Representative

/s/Brian W. BoppreBrian W. Boppe (ID #07482)Boppre Law Firm, PLLC2151 36th Ave SW, Suite BMinot, ND 58701701-852-5224bboppre@bopprelawfirm.comAttorney for PersonalRepresentative

(October 14-21-28, 2020)

STATE OF NORTH DAKOTAPUBLIC SERVICE COMMISSIONNorthern States Power CompanyTransmission Facility CostRecovery (2021)Rates

Case No. PU-20-406NOTICE OF OPPORTUNITY FOR

HEARINGOctober 7, 2020

On September 23, 2020, NorthernStates Power Company (NSP), dbaXcel Energy, filed its 2021Transmission Cost Recovery Rider(TCR). The purpose this rider is torecover costs from NSP’s NorthDakota electric customers for 52previously approved transmissionprojects and six new transmissionprojects, as well as net expensesfrom the Midcontinent IndependentSystem Operator (MISO) billings.This proposal would increase theTCR rate from $0.003322 perkilowatt-hour (kWh) to $0.004133per kWh.The proposed 2020 TCR rate wouldbe applied to all energy billed toeach customer. As a result of theTCR change, a residential electricalcustomer consuming 750 kWh per

month would expect a $0.61 permonth billing increase.The issues to be considered in thisproceeding are:1. Whether the investments and as-sociated costs for the new or modi-fied electric transmission facilitiesqualify for recovery,2. Whether the incurred costs arereasonable and prudent, and3. Whether the rate adjustments areconsistent with the terms of NSP’stariff.Those interested are invited to com-ment on the application in writing.Persons desiring a hearing must filea written request identifying their in-terest in the proceeding and the rea-sons for requesting a hearing. Com-ments and requests for hearing mustbe received by November 21, 2020.If deemed appropriate, the Commis-sion can determine the matterwithout a hearing.For more information contact thePublic Service Commission, StateCapitol, Bismarck, North Dakota58505, 701-328-2400 or Relay NorthDakota 1-800-366-6888 TTY. If yourequire any auxiliary aids or ser-vices, such as readers, signers, orBraille materials, please notify theCommission 24 hours in advance.PUBLIC SERVICE COMMISSIONJulie Fedorchak, CommissionerBrian Kroshus, ChairmanRandy Christmann, Commissioner

(October 14, 2020)

SUMMONS

Civil No. 51-2020-CV-01439

STATE OF NORTH DAKOTA,COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRALJUDICIAL DISTRICT

ProCollect Services, LLC,Plaintiff,

vs.

Drew T. HansonDefendant.

THE STATE OF NORTH DAKOTATO THE ABOVE-NAMED DEFEN-DANT:YOU ARE HEREBY SUMMONEDand required to appear and defendagainst the Complaint in this action,which is herewith served upon you,by serving on the undersigned anAnswer or other proper responsewithin twenty-one days after serviceof this Summons upon you, ex-clusive of the day of service. If youfail to do so, judgment by default willbe taken against you for the reliefdemanded in the complaint.Dated October 8, 2020.

/s/Christopher A. CarlsonChistopher A. Carlson (ID #03378)PO Box 1097Bismarck, North Dakota 58502-1097701-258-4800carlsonlaw@qwestoffice.netAttorney for the Plaintiff

(October 14-21-28, 2020)

SUMMONS

CIVIL NUMBER: 51-2020-CV-01280

IN THE STATE OF NORTHDAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTHCENTRAL JUDICIAL DISTRICT

Lakeview Loan Servicing, LLC,Plaintiff,

v.

Shaun D. Welsch and Heirs andDevisees of the Estate of Shaun D.Welsch, and any person in posses-sion, and all persons unknown,claiming any estate or interest in, orlien or encumbrance upon, the realestate described in the complaint,Defendants.

1. To the above mentioned Defen-dants including all persons unk-nown, claiming any estate or interestin, or lien or encumbrance upon, thereal estate described in the com-plaint.2. You are hereby summoned to ap-pear and defend against the Com-plaint in thisaction, which has been filed with theClerk of Court and is herewithserved upon you, by servingupon the undersigned a copy of anAnswer or other proper responsewithin twenty-one (21) daysafter the service of this Summonsupon you, exclusive of the day ofservice. If you fail to do so,Judgment by default will be takenagainst you for the relief demandedin the Complaint. Theoriginal Complaint is filed with theClerk of the District Court in theCounty in which this actionis commenced.3. This action relates to the foreclo-sure of a mortgage upon the follow-ing described real property in theCounty of Ward, State of NorthDakota:Lot 15, Burlington Heights Addition

to the City of Burlington, WardCounty, North Dakota.

Property Address: 102 Soo Street,Burlington, ND 58722

4. The Plaintiff is not seeking a per-sonal judgment against theabove-named Defendants.Date: August 17, 2020

/s/ Benjamin J. MannBenjamin J. Mann376 East 400 South, Suite 300Salt Lake City, UT 84111Tel: 801-355-2886Fax: 801-328-9714Email: benjamin@hwmlawfirm.comBar Number: 08371HWM: ND10094

(October 7-14-21, 2020)

PPPP UUUU BBBB LLLL IIII CCCC NNNN OOOO TTTT IIII CCCC EEEE SSSS

Legal Notices run daily in the Classified Section of theMinot Daily News.

If you have a legal notice to be published, please call

857-1920 or 1-800-735-3119

classads@MinotDailyNews.com