order-09032015-115 of 2014
DESCRIPTION
This is order of MERC Order document.TRANSCRIPT
-
MERC Order Case No. 115 of 2014 Page 1 of 99
Before the
MAHARASHTRA ELECTRICITY REGULATORY COMMISSION
World Trade Centre, Centre No.1, 13th Floor, Cuffe Parade, Mumbai 400 005 Email: [email protected]
Website: www.mercindia.org.in/ www.merc.gov.in
Case No. 115 of 2014
In the matter of
Petition of Vidarbha Industries Power Ltd. for determination of Capital Cost and Final
Tariff for FY 2014-15 and FY 2015-2016 for its Generating Station at Butibori, Distt.
Nagpur
Smt Chandra Iyengar, Chairperson
Shri. Azeez M. Khan, Member
Shri. Deepak Lad, Member
ORDER
Date: 09 March, 2015
M/s. Vidarbha Industries Power Limited (VIPL) filed a Petition on 30 May, 2014 for
approval of capital cost and final Tariff of its 2 x 300 MW generating station located at the
Maharashtra Industrial Development Corporation (MIDC)s Butibori Industrial Area, Distt.
Nagpur, in the second Control Period of the Multi Year Tariff (MYT), i.e. FY 2014-15 and
FY 2015-16. The Petition has been filed under the provisions of Section 61, 62, and 86(1) (a)
and (b) of the Electricity Act (EA), 2003 and as per Parts A to C, E, F and K of the MERC
(MYT) Regulations, 2011. The Commission, in exercise of the powers vested in it under
Sections 61 and 62 of EA, 2003 and all other powers enabling it in this behalf, and after
taking into consideration the submissions of VIPL, issues raised during the Public Hearing
and all other relevant material, approves the capital cost and determines the final Tariff for
VIPLs 2 x 300 MW generating station at Butibori for FY 2014-15 and FY 2015-16 as
follows.
-
MERC Order Case No. 115 of 2014 Page 2 of 99
TABLE OF CONTENTS
1. BACKGROUND .............................................................................................................. 9
1.1. BACKGROUND OF THE CASE ....................................................................................... 9
1.2. ADMISSION OF THE PETITION AND PUBLIC PROCESS ................................................. 10
1.3. ORGANISATION OF THE ORDER ................................................................................. 11
2. PUBLIC HEARING ...................................................................................................... 12
2.1. PUBLIC HEARING AND SUGGESTIONS/OBJECTIONS FROM THE PUBLIC/STAKEHOLDERS
12
3. APPROVAL OF CAPITAL COST .............................................................................. 13
3.1. PROJECT COMMISSIONING AND TIME-LINES.............................................................. 13
3.2. SUBMISSION OF VIPL ON CAPITAL COST .................................................................. 29
3.3. LAND ........................................................................................................................ 34
3.4. EPC CONTRACT ........................................................................................................ 35
3.5. INITIAL SPARES AS PART OF THE CAPITAL COST AS ON COD .................................... 39
3.6. OUTSIDE BOUNDARY LIMITS (OSBL) ....................................................................... 40
3.7. OVERHEADS .............................................................................................................. 40
3.8. INTEREST DURING CONSTRUCTION (IDC) ................................................................. 44
3.9. FOREIGN EXCHANGE RATE VARIATION .................................................................... 48
3.10. APPROVED CAPITAL COST ........................................................................................ 50
3.11. MEANS OF FINANCE .................................................................................................. 51
4. DETERMINATION OF TARIFF FOR FY 2014-15 AND 2015-16 .......................... 53
4.1. CAPITAL COST FOR DETERMINATION OF TARIFF ........................................................ 53
4.2. ADDITIONAL CAPITALISATION .................................................................................. 55
4.3. DEPRECIATION .......................................................................................................... 59
4.4. INTEREST ON LONG TERM LOAN ............................................................................... 61
4.5. RETURN ON EQUITY .................................................................................................. 66
4.6. INCOME TAX ............................................................................................................. 69
4.7. OPERATION AND MAINTENANCE (O&M) EXPENSES ................................................. 71
4.8. NON- TARIFF INCOME................................................................................................ 73
-
MERC Order Case No. 115 of 2014 Page 3 of 99
4.9. INTEREST ON WORKING CAPITAL ............................................................................. 73
4.10. ANNUAL FIXED CHARGES ......................................................................................... 75
4.11. FUEL SUPPLY AGREEMENT ....................................................................................... 77
4.12. CALORIFIC VALUE AND PRICE OF FUEL .................................................................... 79
4.13. OPERATIONAL PARAMETERS ..................................................................................... 81
4.14. ENERGY CHARGES .................................................................................................... 87
4.15. SUMMARY OF TARIFF ................................................................................................ 89
5. COMPLIANCE OF DIRECTIVES ............................................................................. 90
5.1. RISK OF FERV .......................................................................................................... 90
5.2. FUEL SUPPLY AGREEMENT ....................................................................................... 90
5.3. PERFORMANCE GUARANTEE TEST ............................................................................ 91
5.4. AUXILIARY CONSUMPTION ....................................................................................... 91
6. APPLICABILITY OF ORDER AND TARIFF .......................................................... 93
7. RULINGS OF THE COMMISSION ........................................................................... 94
APPENDIX-I .......................................................................................................................... 98
APPENDIX-II ........................................................................................................................ 99
-
MERC Order Case No. 115 of 2014 Page 4 of 99
LIST OF TABLES
TABLE 1 - PROJECT TIME-LINES AND SCHEDULE AS SUBMITTED BY VIPL ................................. 13
TABLE 2 - CHRONOLOGY OF EVENTS FOR RAILWAY LAND LICENSING FOR SIDING ................... 15
TABLE 3 - CHRONOLOGY OF EVENTS REGARDING SICOM LAND FOR RAILWAY SIDING ........... 16
TABLE 4 - SCHEDULE OF KEY MILESTONES, AS SUBMITTED BY VIPL ........................................ 20
TABLE 5 - PROJECT COST HAD COD BEEN AS PER MYT NORMS, AS SUBMITTED BY VIPL (RS.
CRORE) .............................................................................................................................. 27
TABLE 6 - UNIT-WISE ACTUAL PROJECT COST AS ON COD, AS SUBMITTED BY VIPL (RS.
CRORE) .............................................................................................................................. 28
TABLE 7 - PROJECT COST AS ON COD, AS SUBMITTED BY VIPL (RS. CRORE) ........................... 29
TABLE 8 - ADDITIONAL FEATURES OF THE PLANT, AS SUBMITTED BY VIPL .............................. 30
TABLE 9 - COST OF LAND, AS SUBMITTED BY VIPL .................................................................. 34
TABLE 10 - DETAILS OF COST OF MIDC LAND, AS SUBMITTED BY VIPL ................................. 35
TABLE 11 - BTG AND BOP COST, AS SUBMITTED BY VIPL (RS. CRORE) ................................. 36
TABLE 12 - BENCHMARKING OF CAPITAL COST, AS SUBMITTED BY VIPL ................................ 37
TABLE 13 - BENCHMARKING OF PER MW COST, AS SUBMITTED BY VIPL ................................. 38
TABLE 14 - DETAILS OF OVERHEADS, AS SUBMITTED BY VIPL ................................................ 41
TABLE 15 OVERHEAD COST APPROVED BY THE COMMISSION (RS. CRORE) ........................... 44
TABLE 16 - DETAILS OF IDC AND FINANCING CHARGES AS SUBMITTED BY VIPL (RS. CRORE) 46
TABLE 17 - IDC AND FINANCING CHARGES, AS SUBMITTED BY VIPL ....................................... 47
TABLE 18 - IDC APPROVED BY THE COMMISSION (RS. CRORE) ................................................ 47
TABLE 19 - DETAILS OF FERV, AS SUBMITTED BY VIPL .......................................................... 48
TABLE 20 - FERV APPROVED BY THE COMMISSION (RS. CRORE) ............................................. 50
TABLE 21 - CAPITAL COST APPROVED BY THE COMMISSION (RS. CRORE) ................................ 50
TABLE 22 - MEANS OF FINANCE AS APPROVED BY THE COMMISSION (RS. CRORE) ................... 52
TABLE 23 - CAPITAL COST FOR DETERMINATION OF TARIFF, AS SUBMITTED BY VIPL .............. 53
TABLE 24 - CAPITAL COST FOR DETERMINATION OF TARIFF APPROVED BY THE COMMISSION (RS.
CRORE) ............................................................................................................................. 55
TABLE 25 - ADDITIONAL CAPITALISATION, AS SUBMITTED BY VIPL (RS. CRORE) ................... 55
TABLE 26 - ADDITIONAL CAPITALISATION, AS SUBMITTED BY VIPL (RS. CRORE) ................... 56
TABLE 27 - DETAILS OF RAILWAY SIDING COST, AS SUBMITTED BY VIPL (RS. CRORE) ........... 57
TABLE 28 - ADDITIONAL CAPITALISATION AS APPROVED BY THE COMMISSION ....................... 59
-
MERC Order Case No. 115 of 2014 Page 5 of 99
TABLE 29 DEPRECIATION, AS SUBMITTED BY VIPL (RS. CRORE) .......................................... 60
TABLE 30 - DEPRECIATION AS APPROVED BY THE COMMISSION (RS. CRORE) ........................... 61
TABLE 31 - COMPUTATION OF INTEREST RATE, AS SUBMITTED BY VIPL ................................. 61
TABLE 32 - INTEREST EXPENSES, AS SUBMITTED BY VIPL (RS. CRORE) ................................... 62
TABLE 33 - SCENARIOS FOR HEDGING COST, AS SUBMITTED BY VIPL (RS. CRORE) .................. 62
TABLE 34 - IMPACT OF HEDGING ON ARR HEADS, AS SUBMITTED BY VIPL (RS. CRORE) ......... 64
TABLE 35 - INTEREST EXPENSES AS APPROVED BY THE COMMISSION (RS. CRORE) ................... 66
TABLE 36 - RETURN ON EQUITY, AS SUBMITTED BY VIPL (RS. CRORE) ................................... 67
TABLE 37 - TIME SCHEDULE FOR COMMISSIONING COMPUTED BY THE COMMISSION ................ 68
TABLE 38 RETURN ON EQUITY APPROVED BY COMMISSION (RS. CRORE)................................. 69
TABLE 39 - INCOME TAX AS SUBMITTED BY VIPL (RS. CRORE) ............................................... 70
TABLE 40 - O&M EXPENSES AS SUBMITTED BY VIPL .............................................................. 72
TABLE 41 - O&M EXPENSES AS APPROVED BY THE COMMISSION (RS. CRORE) ........................ 73
TABLE 42 - INTEREST ON WORKING CAPITAL, AS SUBMITTED BY VIPL (RS. CRORE) ............... 73
TABLE 43 - INTEREST ON WORKING CAPITAL AS APPROVED BY THE COMMISSION (RS. CRORE)
.......................................................................................................................................... 75
TABLE 44 - ANNUAL FIXED COST AS SUBMITTED BY VIPL (RS. CRORE) .................................. 75
TABLE 45 - ANNUAL FIXED CHARGES AS APPROVED BY THE COMMISSION (RS. CRORE) .......... 76
TABLE 46 - CALORIFIC VALUE AND PRICE OF FUEL, AS SUBMITTED BY VIPL .......................... 80
TABLE 47 - CALORIFIC VALUE AND PRICE OF FUEL CONSIDERED BY THE COMMISSION ........... 81
TABLE 48 - OPERATIONAL PARAMETERS, AS SUBMITTED BY VIPL ........................................... 81
TABLE 49 - OPERATIONAL PARAMETERS FOR UNIT 1 FROM COD TILL FY 2013-14 ................. 84
TABLE 50 - STATION HEAT RATE ALLOWED BY THE COMMISSION............................................ 85
TABLE 51 OPERATIONAL PARAMETERS APPROVED BY THE COMMISSION ................................. 86
TABLE 52 - ANNUAL ENERGY CHARGES, AS SUBMITTED BY VIPL (RS. CRORE) ...................... 87
TABLE 53 - FUEL COST AS APPROVED BY THE COMMISSION (RS. CRORE) ................................ 87
TABLE 54 COST OF WATER AS SUBMITTED BY VIPL (RS. CRORE)............................................ 87
TABLE 55 - ENERGY CHARGES AS APPROVED BY THE COMMISSION .......................................... 88
TABLE 56 - TARIFF APPROVED BY THE COMMISSION FOR FY 2014-15 AND FY 2015-16 .......... 89
-
MERC Order Case No. 115 of 2014 Page 6 of 99
List of Abbreviations
ACQ Annual Contracted Quantity
ACW Auxiliary Cooling Water
AFC Annual Fixed Charges
AHP Ash Handling Plant
ARR Aggregate Revenue Requirement
AS Accounting Standards
ATE Appellate Tribunal for Electricity
BC Buyers Credit
BoP Balance of Plant
BFP Boiler Feed Pump
BTG Boiler Turbine Generator
CA Chartered Accountant
CAPEX/Capex Capital Expenditure
CCEA Cabinet Committee on Economic Affairs
CCI Competition Commission of India
CEA Central Electricity Authority
CERC Central Electricity Regulatory Commission
CFBC Circulating Fluidised Bed Circulation
CHP Coal Handling Plant
CIL Coal India Limited
COC Cycles of Concentration
COD Commercial Date of Operation
CW Cooling Water
CWIP Capital Work In Progress
DCS Digital Control System
DM De-mineralisation
EAC Expert Advisory Committee
ECB External Commercial Borrowings
EPC Engineering, Procurement and Construction
ERP Enterprise Resource Planning
ESP Engineering Scale Plan
FBSM Final Balancing and Settlement Mechanism
FERV Foreign Exchange Rate Variation
FO Furnace Oil
FSA Fuel Supply Agreement
-
MERC Order Case No. 115 of 2014 Page 7 of 99
FY Financial Year
GCPP Group Captive Power Project
GCV Gross Calorific Value
GFA Gross Fixed Assets
GoM Government of Maharashtra
ICAI Institute of Chartered Accountants of India
IDC Interest During Construction
IPP Independent Power Producer
Kcal kilo calories
Kcal/kWh kilo calories per kilowatt hour
Kg Kilogram
kV kilo Volt
KW kilo Watt
kWh Kilo Watt hour
LoA Letter of Assurance
LD Liquidated Damages
LDO Light Diesel Oil
LIBOR London Interbank Offered Rate
MAT Minimum Alternate Tax
MERC Maharashtra Electricity Regulatory Commission
MIDC Maharashtra Industrial Development Corporation
MLD Million Litres per Day
MMT Million Metric Tonnes
MMTPA Million Metric Tonnes per Annum
MoC Ministry of Coal
MoEF Ministry of Environment and Forests
MoP Ministry of Power
MoPNG Ministry of Petroleum and Natural Gas
MPCB Maharashtra Pollution Control Board
MSPGCL Maharashtra State Power Generation Company Ltd.
MSLDC/SLDC Maharashtra State Load Despatch Centre
MT Metric Tonnes
MU Million Units
MW Megawatt
MYT Multi Year Tariff
NA Non-Agriculture
NTP Notice to Proceed
-
MERC Order Case No. 115 of 2014 Page 8 of 99
NTI Non Tariff Income
NOC No Objection Certificate
OEM Original Equipment Manufacturer
OSBL Outside Boundary Limits
O&M Operation & Maintenance
P&L Profit and Loss account
PLF Plant Load Factor
PPA Power Purchase Agreement
P&G Test Performance & Guarantee Test
PPM Parts per million
RBI Reserve Bank of India
RCC Roller Compacted Concrete
RH Relative Humidity
RHT Re-Heat Temperature
RInfra-D Reliance Infrastructure Limited-Mumbai Distribution
RO Reverse Osmosis
RoE Return on Equity
RPL Reliance Power Limited
SBAR State Bank Advance Rate
SECL South Eastern Coalfields Limited
SFOC Secondary Fuel Oil Consumption
SHR Station Heat Rate
SHT Super Heat Temperature
SICOM State Industrial & Investment Corporation Of Maharashtra
SLC(LT) Standing Linkage Committee (Long Term)
TMCR Turbine Maximum Continuous Rating
TVS Technical Validation Session
USD United States Dollar
VAM Vapour Absorption Machine
VAT Value Added Tax
WCL Western Coalfields Limited
-
MERC Order Case No. 115 of 2014 Page 9 of 99
1. BACKGROUND
1.1. Background of the Case
1.1.1. VIPL is a Generating Company which has developed a 600 MW (2 x 300 MW)
Power Plant at MIDC Butibori, District Nagpur in Maharashtra. The power from the
generating station is being supplied to Reliance Infrastructure Ltd. (Distribution
Business) (RInfra-D), which is a Distribution Licensee in parts of Mumbai.
1.1.2. VIPL has submitted that the Commission, vide Order dated 20 February, 2013 in
Case No. 2 of 2013 and Order dated 19 July, 2013 in Case No. 76 of 2013, had
accorded in-principle approval to the Power Purchase Agreement (PPA) between
RInfra-D and VIPL for procurement of power from the latters generating Unit 2 and
Unit 1 respectively on long term basis, and the Consolidation Agreement dated 4
June, 2013 executed between RInfra-D and VIPL for supply under the two PPAs for
Unit 1 and Unit 2 to be treated as supply from the Power Plant as a whole for Tariff
and regulatory purposes.
1.1.3. Vide Order dated 17 January, 2014 in Case No. 91 of 2013, the Commission had
approved the provisional Tariff for FY 2014-15 and FY 2015-16, and directed VIPL
to submit the capital cost based on audited accounts post the date of Commercial
Operation (COD).
1.1.4. VIPL has filed the present Petition for approval of capital cost and final Tariff for its
600 MW (2 x 300 MW) generation station at Butibori for the Second MYT Control
period FY 2014-15 and FY 2015-16 under the provisions of the MERC MYT
Regulations, 2011.
1.1.5. VIPLs prayers are as under:
(a) Admit the present Petition;
(b) Approve the capital cost and final tariff of the station for FY 2014-15 and FY
2015-16 based on the rationale submitted by VIPL.
-
MERC Order Case No. 115 of 2014 Page 10 of 99
(c) Approve the performance parameters as submitted in this petition.
(d) Provide directives on the identified options for treatment of FERV/hedging.
(e) Condone any shortcomings in the petition and allow the Petitioner to submit
additional information as may be required by the Commission at a later stage;
(f) Allow VIPL to recover the difference in current tariff /provisional tariff vis--
vis the final tariff to be approved in this petition from the date of issue of order.
(g)Pass any such order as deemed appropriate in the circumstance of this case.
1.2. Admission of the Petition and Public Process
1.2.1. Technical Validation Session: Vide Notice dated 11 June, 2014, the Commission
scheduled a Technical Validation Session (TVS) on the Petition on 19 June, 2014 in
the presence of institutional Consumer Representatives authorised under Section
94(3) of the EA, 2003. During the TVS held on 19 June, 2014, VIPL made a
presentation focusing on the salient features of the Petition. The list of persons who
participated in the TVS is at Appendix-I.
1.2.2. Admission of the Petition: The Commission admitted the Petition on 13 October,
2014. In accordance with Section 64 of the EA, 2003, VIPL was directed to publish a
Notice to solicit suggestions and objections from the public. In accordance with
Regulation 90 of the MERC (Conduct of Business) Regulations, 2004, the
Commission also directed VIPL to publish the Notice in at least two local Marathi
and English daily newspapers with wide circulation in Maharashtra, and to reply
expeditiously to all the suggestions and objections received.
1.2.3. Public Notice: VIPL published the Notice on 3 November, 2014 in two English
newspapers, viz. Indian Express and Hindustan Times, and two Marathi newspapers,
viz. Loksatta and Samana, inviting suggestions and objections. Copies of the Petition
and its summary were made available at the Companys offices for inspection/
purchase, and also on VIPLs website www.reliancepower.co.in. A copy of the
Public Notice and the executive summary of the Petition were also made available on
the website of the Commission (www.mercindia.org.in / www.merc.gov.in) in a
downloadable format.
-
MERC Order Case No. 115 of 2014 Page 11 of 99
1.2.4. Public Hearing: The Public Hearing on the Petition was held on 9 December, 2014
at the office of the Commission at World Trade Centre, Centre No.1, 13th
Floor,
Cuffe Parade, Mumbai. The list of objectors, responders and other persons who
participated in the Hearing is at Appendix II. The due process contemplated under
law was followed by the Commission at every stage to ensure transparency and
public participation and to provide adequate opportunity to all those who wanted to
express their opinion in this matter.
1.3. Organisation of the Order
1.3.1. This Order is organised in the following Sections:
Section 1 provides a brief history of the quasi-judicial regulatory process
undertaken by the Commission.
Section 2 discusses the suggestions raised by the stakeholders/public in writing as
well as during the Public Hearing before the Commission.
Section 3 deals with the approval of capital cost of VIPLs Butibori generating
station.
Section 4 deals with the determination of final Tariff of the generating station for
FY 2014-15 and FY 2015-16.
Section 5 deals with the compliance of directives contained in the provisional
Tariff Orders of the Commission
Section 6 deals with the applicability of the Order.
Section 7 sets out the Rulings of the Commission.
-
MERC Order Case No. 115 of 2014 Page 12 of 99
2. PUBLIC HEARING
2.1. Public Hearing and suggestions/objections from the public/stakeholders
2.1.1. Neither the Commission nor VIPL received any suggestions/objections from
stakeholders or other members of the public on the Petition.
2.1.2. The Public Hearing was held on 9 December, 2014, at the start of which VIPL made
a brief presentation.
2.1.3. During the hearing, the Commission inquired if any members of the
public/stakeholders wished to make any suggestions/comments on the Petition.
However, no suggestions/objections/comments were made by any of those present.
2.1.4. The list of persons who participated in the Public Hearing is at Appendix-II.
-
MERC Order Case No. 115 of 2014 Page 13 of 99
3. APPROVAL OF CAPITAL COST
3.1. Project Commissioning and Time-lines
3.1.1. VIPL is a Special Purpose Vehicle (SPV) originally established for implementation
of a Group Captive Power Project (GCPP) through a Competitive Bidding Process
conducted by the MIDC.
3.1.2. Vide its Order dated 20 February, 2013 in Case No. 2 of 2013, the Commission
accorded in-principle approval to the PPA between VIPL and RInfra-D for supply of
300 MW from Unit 2. Vide Order dated 19 July, 2013 in Case No. 76 of 2013, it
accorded in-principle approval to the PPA between VIPL and RInfra-D for supply of
300 MW from Unit 1.
3.1.3. VIPL submitted that it had awarded three separate Engineering, Procurement &
Construction (EPC) contracts to RInfra for Unit 1, Unit 2 and Railway siding works.
3.1.4. VIPL further submitted that Unit 1 has achieved COD on 4 April, 2013 and Unit 2 on
28 March, 2014.
Commissions Analysis
3.1.5. Based on the Project zero date as submitted by VIPL, the time overrun considering
the scheduled COD of Units I & II vis--vis their actual COD are as under:
Table 1 - Project time-lines and schedule as submitted by VIPL
Particulars Start Date Scheduled
COD
Actual Full
Load Test
Actual
COD
Time Over-
run
Unit 1 27.02.2010 27.09.2012 17.08.2012 4.04.2013 189 days
Unit 2 30.4.2010 31.01.2013 19.03.2013 28.03.2014 421days
3.1.6. The Commission asked VIPL to explain the reasons for the delay in COD. In reply,
VIPL has cited two major reasons:
-
MERC Order Case No. 115 of 2014 Page 14 of 99
(i) Non-availability of land from SICOM and Railways In order to complete
the railway siding, a few pockets of land were required to be procured from
the State Industrial & Investment Corporation of Maharashtra (SICOM) and
Central Railways (CR). In case of SICOM land, an application for transfer of
the identified land to VIPL was made in January, 2009. Based on the demand
note given by SICOM, VIPL paid 50% advance amount in May 2011.
However, for the final transfer of land, SICOM was required to take
clearance from the Industries, Revenue, Law and Judiciary Departments of
Govt. of Maharashtra (GoM), and these clearances have taken more time than
could be anticipated.
In case of Railway land, similar application for transfer was made to Central
Railways in August, 2010. The detailed Engineering Scale Plan (ESP) was
approved by the relevant authorities in June, 2011 enabling the further
Railway Land Licensing approval process. Railway Land Licensing has been
completed in January, 2014.
VIPL added that it has made significant efforts to speed up the process of
clearances and followed up with more than forty letters.
(ii) Delay in execution of Fuel Supply Agreement (FSA) VIPL submitted that
Unit 1 was demonstrated by achievement of full load operation on 17 August,
2012, but its COD was delayed on account of non-availability of Carpet Coal
required for commissioning purposes from Western Coalfields Limited
(WCL). Despite the Central Electricity Authority (CEA)s recommendation
and valid Letter of Assurance (LoA) approved by the Standing Linkage
Committee - Long Term (SLC (LT)), WCL did not supply it in time. VIPL
has followed up with more than 90 letters.
3.1.7. VIPL has submitted the following chronology of events with regard to Railway Land
Licensing for the Railway siding:
-
MERC Order Case No. 115 of 2014 Page 15 of 99
Table 2 - Chronology of events for Railway Land Licensing for siding
Sr.
No.
Activity Date
1 Application to railways for land licensing 01-Aug-10
2 CR, Nagpur after verification forwarded the plan to Chief
Engineer (CE(G)), CR, Mumbai
23-Feb-11
3 Engineering Scale Plan (ESP) approved by Railways 04-Jun-11
4 CR (Finance Department) forwarded the land proposal to
CE(G), CR Mumbai
14-Jun-11
5 CE(G), CR Mumbai raised queries to Sr. DEN (Co.) CR
Nagpur
07-Jul-11
6 DEN(HQ) forwarded their reply to CE(G), Mumbai 26-Aug-11
7 CE(G), CR Mumbai sent file back to Nagpur with observation
that land licensing has to be done from (-) 800 chainage while
Nagpur Division has approved +95 chainage
30-Sep-11
8 Dy. CE incorporated the additional area and forwarded file to
CE(G), CR, Mumbai
05-Dec-11
9 Follow up letter from VIPL to GM, CR for land licensing 23-Dec-11
10 VIPL to Sr DOM, CR, Nagpur for alteration of ESP 26-Dec-11
11 New Railway Board Circular No. 99/TC (FM)/26/1/Pt-II
dated 30 January, 2012 in connection with railway siding. The
relevant clause is No licence fees will be charged on the common user traffic facilities at the station from the siding
owner.
30-Jan-12
12 VIPL to Chief Transportation Planning Manager, CR,
Mumbai modification in approved ESP 02-Feb-12
13 RCC (Consultant of VIPL) to DEN (HQ) CR, Nagpur Revision of proposal due to change in Railways rules and
requesting to send old land licensing drawing to make
necessary corrections
21-Feb-12
14 CE(G), CR, Mumbai sent drawing back to Nagpur division
for required alterations in line with New Railway Board
Circular
01-Mar-12
15 VIPL to GM, CR follow up letter 07-Mar-12
16 Dy. CE to Sr. DEN/CO, Nagpur Communication to obtain requisite documents from VIPL
The documents required are;
1) Undertaking that party shall bear the cost of yard
remodeling and cost of additional land
2) Undertaking by competent authority to enter into financial
commitment
20-Nov-12
17 VIPL to CE (Genl.) Regarding bearing additional charges of land
27-Nov-12
-
MERC Order Case No. 115 of 2014 Page 16 of 99
Sr.
No.
Activity Date
18 VIPL to Sr. DEN Acceptance of land licence fees and requesting to process the case to PHOD Committee and GM's
approval
20-Dec-12
19 VIPL to CIPM, CR, Mumbai Acceptance of following additional clause in land licensing agreement
In future railway is authorised to take out more routes from the VIPL siding for other siding.
25-Feb-13
20 VIPL to CIPM, CR, Mumbai Informing about the construction facilities as per ESP
25-Feb-13
21 File put up for approval before PHOD Committee Apr-13
22 VIPL to CIPM, CR, Mumbai Follow up letter with for expediting land licensing as plant is already operational
11-Jun-13
23 File approved by PHOD Committee Sep-13
24 Meeting of VIPL with General Manager, CR regarding the
proposal. It was decided to verify the feasibility of reducing
the usage of railway land at site.
20-Sep-13
25 VIPL to CIPM, CR, Mumbai Informing about the feasibility reducing railway land requirement
11-Oct-13
26 VIPL to CIPM, CR, Mumbai Follow up letter for approval of land licensing
21-Nov-13
27 Final Land licensing approval by CR 01-Jan-14
3.1.8. VIPL has submitted the following chronology of events for approval of SICOM land
for Railway siding:
Table 3 - Chronology of events regarding SICOM land for Railway siding
Sr.
No.
Activity Date
1. Application to SICOM for purchase of land for Railway siding
16-Jan-09
2. VIPLs email to SICOM for requesting for encumbrance free possession of land at Rs. 8 lakh per acre
15-Dec-09
3. SICOMs email to VIPL- Informing final offer of Rs. 11 Lakh per acre and other charges payable
16-Dec-09
4. Meeting between SICOM and VIPL on finalisation of way forward
07-Jun-10
5. VIPL to SICOM - A note has been sent for applying to Industries Department
16-Jun-10
-
MERC Order Case No. 115 of 2014 Page 17 of 99
Sr.
No.
Activity Date
6. SICOM applied to Industries Deptt. (GoM) for NOC 02-Jul-10
7. NOC from Industries Deptt. GoM. Further, Industries Deptt. GoM suggested that approval of Revenue Department, GoM
also be taken for sale of land
06-Sep-10
8. VIPL made an application for additional land of 450 acre in addition to 47 acres applied earlier
21-Sep-10
9. Meeting between SICOM and VIPL regarding commitment letter for purchase of land
16-Feb-11
10. Commitment letter to SICOM for purchase of encumbrance free land of :
a) 47 acres @ Rs. 11 Lakh per acre and 3% to SICOM Realty
Pvt. Ltd.
b) 453 acres @ 9.6 Lakh per acre including Rs. 1.6 Lakh per
acre to SICOM Realty Pvt. Ltd.
12-Mar-11
11. SICOM demand for 50% advance payment 30-Mar-11
12. VIPL acceptance letter to demand of advance 31-Mar-11
13. SICOM letter to Principal Secretary, Industries Deptt. requesting assistance in getting NOC from Revenue Deptt.
12-May-11
14. SICOM invoices for payment of 50% advance for 47 acre and 453 acre of land
19-May-11
15. Payment of professional fees to SICOM (Rs. 3.7 Crore) (credited on 15 July, 2011)
19-May-11
16. VIPL letter to SICOM requesting to allow start of site enabling work
11-Jun-11
17. SICOM letter to request Revenue Deptt. GoM for permission for outright sale of 47 acres of land
16-Jun-11
18. Account statement for payment of 50% advance to SICOM 15-Jul-11
19. SICOM letter to Collector, Wardha for non attachment of assets and setting aside levy of NA tax on SICOM
10-Oct-11
20. Petition filed by SICOM against Collector of Wardha regarding recovery of charges
17-Dec-11
21. Collector, Wardha letter to Pr. Secretary (Revenue) informing about the encumbrances on SICOM land requested by VIPL
on conditions :
1) Pending dues (Non Agriculture (NA) Tax assessment of
Rs. 1.01 Crore) may be either be deposited or waived by GoM
2) High Court Order in Appeal No. 248/04 filed against Court
order by SICOM regarding additional compensation shall be
binding on SICOM
22-Dec-11
22. SICOM to Minister, Revenue for his intervention 23-Jan-12
23. VIPL letter to Revenue Minister for his intervention 03-Sep-12
24. High Level Committee called by Revenue Deptt. for fast tracking the case. VIPL, Revenue, and Law & Judiciary
Deptts. were present. High Level Committee recommends
29-Oct-12
-
MERC Order Case No. 115 of 2014 Page 18 of 99
Sr.
No.
Activity Date
that:
1) Revenue Deptt. shall make available all relevant documents
and terms and conditions applicable while handing over the
land to SICOM to Law & Judiciary Deptt.
2) Law & Judiciary Deptt. to give opinion on whether the
SICOM can sell the land, which was handed over to it by
Government, to VIPL without their permission.
3) Law & Judiciary Deptt. to give opinion on whether the land
handed over to SICOM can be further handed over to MIDC
with due compensation to SICOM for future use/purpose 25. VIPL to SICOM- follow up letter 06-Mar-13
26. File forwarded to Revenue Department from Law & Judiciary Department after giving legal opinion (no documentary
evidence provided)
May-13
27. SICOM to VIPL - Proposal sent for consent for grant of land on long term lease
05-Jun-13
28. VIPL to SICOM- follow up letter including chronology of communications from the beginning
06-Jun-13
29. VIPL to SICOM- Confirmation of land lease instead of outright sale
19-Jun-13
30. SICOM to Collector, Wardha informing the status of 24 cases for enhanced compensation with no pending case in respect of
enhanced compensation in the High Court
03-Sep-13
31. SICOM to Collector, Wardha requesting removal of encumbrances on SICOM land
03-Sep-13
32. VIPL to Minister, Revenue for his intervention as land is not handed over yet
03-Oct-13
33. Collector, Wardha to Revenue Department-Status report of land sought by VIPL
15-Oct-13
34. VIPL to SICOM- Seeking intervention for getting approval from Revenue/Finance Department
22-Nov-13
35. VIPL to SICOM- Informing about starting of power plant without railway siding and requesting for execution of lease
deed
03-Jan-14
36. Final approval by GoM for transfer of land on lease to extent of 46.73 acres for 30 years
23-Apr-14
37. Collector, Wardha to VIPL-Approval of lease and directing to deposit Rs. 84.65 Lakh pertaining to enhanced compensation
17-May-14
38. Collector, Wardha to Revenue Deptt. - Suggesting changes in lease agreement, i.e. that the matter is pending before the
Hon'ble High Court for 18.29 acre land and the responsibility
for complying with the High Court Order for the said land
will lie with VIPL.
11-Jun-14
39. Lease deed signed 15-Jul-14
-
MERC Order Case No. 115 of 2014 Page 19 of 99
Sr.
No.
Activity Date
40. SICOM-VIPL-Consent for creation of charge on land 24-Jul-14
41. Placement of subordinate debt with SICOM 24-Jul-14
3.1.9 For transporting coal from the mines to its power plant at Butibori by rail, VIPL
planned a Railway siding off Sindhi Station, which is the nearest railway station on
the Wardha-Nagpur line of Central Railways. As per the rail alignment plan, this
Railway siding will take off from the Sindhi Station and be connected to the Butibori
plant. Considering the proposed rail alignment route, the siding project required 47
acres of SICOM land in some villages of Tehsil Selu Tehsil in Wardha District.The
Commission notes that VIPL had started the process of arranging for SICOM land for
the Railway siding before the start of work. For Railway Land Licensing also, VIPL
had initiated the process early. For obtaining the land from SICOM, clearances were
required from the Industries and Revenue Departments, GoM, and legal opinions were
also taken within Govt. Clearance from Revenue Department took substantial time
because of pending issues of levy of Non Agricultural Tax assessment on land held by
SICOM and liability of SICOM to pay for additional compensation for one patch of
land. Revenue Department also sought legal opinion as to whether the land could be
sold by SICOM to VIPL since it had been handed over to SICOM by GoM. Further,
SICOM sent a proposal to VIPL for consent for grant of the land on long term lease,
to which VIPL consented. GoM gave the final approval for transfer of land of 46.73
acre to VIPL on long term lease for 30 years.
3.1.9. With regard to Railway land, the Commission observes that VIPL had applied in
August, 2010 but considerable time was taken in the internal approval process of
Railways, including modification in number of chainage from +95 chainage to (-)
800 chainage, change in Railway rules regarding the land licence fee, etc.
3.1.10. VIPL has asserted that this delay by external agencies was beyond its control, and
that the time overrun in completion of Railway siding work by the scheduled date
could not be attributed to it.
-
MERC Order Case No. 115 of 2014 Page 20 of 99
3.1.11. The Commission asked VIPL how COD of Unit 1 was declared without resolving the
issues such as SICOM/Railway land availability, non-supply of linkage coal, etc.
VIPL submitted as follows:
(i) There was no delay in achieving the readiness of the plant to commence COD as
far as construction was concerned. It achieved COD readiness by synchronising
the Unit and achieving the full load within the committed EPC contract schedule.
The key milestones are as under:
Table 4 - Schedule of key milestones, as submitted by VIPL
Sr. No. Particulars Unit 1 Unit 2
1 Scheduled COD as per
EPC Contract 27 September, 2012 31 January, 2013
2 Synchronisation date 25 June, 2012 1 January, 2013
3 Full load test Completed 17 August, 2012 19 March, 2013
4 Time taken in attaining
full load/COD readiness 30 months 36 months
5 COD as per MERC MYT
Regulations, 2011 33 months 37 months
(ii) VIPL had signed a Medium Term PPA for supply of 134 MW power to RInfra-D
through competitive bidding in September, 2009. VIPL considered that, by
declaring early COD, it could build pressure on the Ministry of Coal
(MoC)/CIL/WCL to execute the FSA for meeting its obligation under the PPA.
However, CIL/ MoC introduced a condition that, to execute FSAs and commence
coal supply, a generating plant should have a Long Term PPA with a Distribution
Licensee.
(iii) VIPL made arrangements to buy coal from e-auction and obtained the
Maharashtra Pollution Control Board (MPCB) permission in March, 2013 for
transporting the coal by road in the absence of Railway siding as an interim
arrangement. Thereafter, it declared COD immediately to fulfil its Medium Term
PPA commitment and maintaining power supply to Mumbai. The early
-
MERC Order Case No. 115 of 2014 Page 21 of 99
declaration has helped to reduce the Interest During Contruction (IDC) by Rs.
84.45 Crore, which was transferred to the Profit and Loss account post-COD.
3.1.12. The Commission observes that full load test of Unit 2 was undertaken on 19 March,
2013 and VIPL declared the COD of Unit 2 on 28 March, 2014 i.e., after nearly a
year. The Commission asked VIPL to submit the justification for not declaring the
COD of Unit 2 immediately after achieving full load/COD Readiness. In reply, VIPL
submitted that the possibility of getting linkage coal for operating Unit 2 diminished
for want of assurance from CIL/WCL on commencement of coal supply without a
Long Term PPA and WCLs refusal to release initial carpet/ commissioning coal.
Further, there was very limited availability of e-auction coal and this small window
of opportunity was leveraged to secure coal for Unit 1 only. Moreover, the
connectivity of the plant with the State Transmission Utility (STU) made it even
more unattractive to offer the power outside Maharashtra as the Wheeling cost plus
losses amounted to around Rs 0.50/ kWh. VIPL made several attempts to sell power
in the market through short term bidding, but these were unsuccessful. Therefore, in
the absence of viable off-take from Unit 2, VIPL could not declare Unit 2 COD
immediately after achieving Full Load/ COD readiness.
3.1.13. As regards Unit 1, the Commission observes that VIPL declared its COD also
without resolving the above issues, and asked VIPL to submit the justification. VIPL
submitted that it declared the COD of Unit 2 to fulfil its commitment under the Long
Term PPA with RInfra-D which required commencement of supply from 1 April,
2014, and securing the FSA with WCL. VIPL declared the COD of Unit 2 only after
securing Railway land in January, 2014 and receiving assurance from GoM in March,
2014 on leasing of SICOM land required for completing the Railway siding.
3.1.14. As regards the impact of delay on Project cost, the Commission asked VIPL for the
details of cost overrun from the original estimates to the day of readiness of the
Project. VIPL submitted that, as the Project is implemented based on firm price lump
sum Turnkey EPC contract without escalation clause, there was no overrun in the
hard costs on account of delay in the Project.
-
MERC Order Case No. 115 of 2014 Page 22 of 99
3.1.15. The Commission asked VIPL to submit reasons for declaring COD of Unit 1 and
Unit 2 18 months and 6 months prior to the commissioning of Railway siding,
respectively. VIPL submitted that:
(i) Unit 1 was commissioned by considering that coal transportation can be handled
by road as a temporary solution, Unit 1 could be made operational to fulfil the
Medium term PPA, and to meet debt service obligation and reduce the effective
capital cost of the Unit when Long Term PPA takes effect from 1 April, 2014.
(ii) Unit 2 could not have been commissioned without certainty of Railway siding and
based on movement of coal by road transport, which would have involved around
430 truck trips per day, along several highways, village roads, and railway
crossings. Hence, Unit 2 was commissioned after there was certainty on
availability of pending land parcels for completion of Railway siding just before
March, 2014, and considering that a stock of coal of 1.5 Lakh tonnes had been
stocked at the plant site to deal with any shortfall in coal movement by road for 3-
4 months to meet Long Term PPA obligations.
3.1.16. The Commission observes that, despite delays and difficulties in obtaining SICOM
and Railway land for Railway siding, VIPL was able to achieve the COD, and that it
had declared the COD considering its commitment to supply power to RInfra-D
under Medium and Long Term agreements. The Commission notes VIPLs
submission that it would not have been able to tie up the power supply had the COD
been declared based only on the availability of e-auction coal. The Commission
observes that, on the day of readiness for declaring COD for Unit 1, VIPL had an
existing Medium Term PPA for which it could have supplied energy by declaring
COD. Further, VIPL has submitted that the COD was declared to meet its PPA
obligation and in order to reduce the effective capital cost. However, had VIPL
declared COD on the date of readiness of the Plant, the effective capital cost would
have been further reduced, which VIPL had done at a later stage inspite of
unresolved issues remaining the same.
-
MERC Order Case No. 115 of 2014 Page 23 of 99
3.1.17. The Commission notes that Unit 1 has achieved COD on 4 April, 2013 and Unit 2 on
28 March, 2014. There is a delay in the commissioning of the Project with respect to
the scheduled dates. With regard to such delay, the Appellate Tribunal for Electricity
(ATE), in its Judgement dated 27 April, 2011 in Appeal No. 72 of 2010, has held as
under:
7.4. The delay in execution of a generating project could occur due to
following reasons:
i) due to factors entirely attributable to the generating company, e.g.,
imprudence in selecting the contractors/suppliers and in executing contractual
agreements including terms and conditions of the contract, delay in award of
contract, delay in providing inputs like making land available to the
contractors, delay in payments to contractors/suppliers as per the terms of
contract, mismanagement of finances, slackness in project management like
improper co-ordination between the various contractors, etc.
ii) due to factors beyond the control of the generating company e.g. delay
caused due to force majeure like natural calamity or any other reasons which
clearly establish, beyond any doubt, that there has been no imprudence on the
part of the generating company in executing the project.
iii) situation not covered by (i) & (ii) above.
In our opinion in the first case the entire cost due to time overrun has to be
borne by the generating company. However, the Liquidated Damages (LDs)
and insurance proceeds on account of delay, if any, received by the generating
company could be retained by the generating company. In the second case the
generating company could be given benefit of the additional cost incurred due
to time over-run. However, the consumers should get full benefit of the LDs
recovered from the contractors/suppliers of the generating company and the
insurance proceeds, if any, to reduce the capital cost. In the third case the
additional cost due to time overrun including the LDs and insurance proceeds
could be shared between the generating company and the consumer. It would
also be prudent to consider the delay with respect to some benchmarks rather
than depending on the provisions of the contract between the generating
company and its contractors/suppliers. If the time schedule is taken as per the
terms of the contract, this may result in imprudent time schedule not in
accordance with good industry practices.
7.5. In our opinion, the above principles will be in consonance with the
provisions of Section 61(d) of the Act, safeguarding the consumers interest
-
MERC Order Case No. 115 of 2014 Page 24 of 99
and at the same time, ensuring recovery of cost of electricity in a reasonable
manner.
3.1.18. The ATE Judgement categorises the reasons for delay as controllable, uncontrollable
and neither controllable nor uncontrollable, and specifies the treatment of the impact
of such delays while approving the Project cost.
3.1.19. The Commission observes that the reasons cited by VIPL for the delay in the
commissioning of the Project from the scheduled COD were mainly on account of
delay in the availability of land from SICOM and Railways for the Railway siding,
and delay in execution of FSA.
3.1.20. The Commission notes that, considering the general uncertainty in availability of fuel
in the country, VIPL was not the only party subjected to delay in execution of FSA.
However, the responsibility of arranging for fuel lies with the Generating Company,
and VIPL must or should have accounted for the risk relating to fuel availability at
the outset of the Project. Being aware of issues regarding fuel availability, VIPL
declared COD of the Project to meet its Medium Term PPA commitment by using
coal obtained from e-auction. VIPL has submitted the difficulties in the sustained
operation of the plant as a whole with the transportation of coal by road. Hence,
ultimately the commissioning of the Railway siding was essential.
3.1.21. The Commission notes that VIPL has achieved COD readiness/ completion of full
load for Unit 1 on 17 August, 2012 and for Unit 2 on 19 March, 2013. There was no
delay in the execution of the Project as COD readiness and completion of full load
test for Unit 1 were achieved in 30 months and 36 months, respectively, from the
date of NTP, i.e. earlier than the MERC MYT Regulations, 2011 norms of 33 months
and 37 months, respectively. The Commission observes that the delay was only in the
the declaration of COD of the Project because of the reasons set out above.
3.1.22. The Commission notes that VIPL has declared COD of Unit 1 to fulfil the Medium
Term PPA obligations. The supply delivery date in the Medium Term PPA was 1
April, 2012. However, VIPL has declared COD of Unit 1 on 4 April, 2013, i.e. with a
-
MERC Order Case No. 115 of 2014 Page 25 of 99
delay of more than a year. COD readiness/completion of full load for Unit 1 was
achieved on 17 August, 2012 and COD on 4 April, 2013 without commissioning of
Railway siding and execution of FSAs. Hence, the decision not to declare the COD
of Unit 1 even after completion of the full load test was a decision taken by VIPL in
its own interest. According to VIPL, the COD of Unit 1 was declared to meet its PPA
obligation and to reduce the effective capital cost. However, had VIPL declared COD
on the date of readiness, the effective capital cost would have reduced further.
Instead, COD was declared later despite the unresolved issues remaining the same.
The Commission also notes that VIPL has been operating Unit 1 by using coal
transported by road. It was, therefore, possible to do so even without completion of
Railway siding work.
3.1.23. The Commission observes that the delay in acquisition of SICOM land was because
of procedural delays in resolving certain issues between the GoM and SICOM which
which were beyond VIPLs control. Inspite of this, VIPL declared the COD of Unit 2
without commissioning of the Railway siding so as to meet its obligation of supply of
power to RInfra-D. The Commission notes VIPLs submission that it declared the
COD of Unit 2 only when it got clarity on the acquisition of the land for Railway
siding (in January, 2014) and after ensuring sufficient stock of coal for running the
plant till the commissioning of the siding.
3.1.24. VIPL-G issued Letter of Intent (LoI) on 6 July, 2010 to the EPC contractor for
completion of the Railway siding work by 5 July, 2012 (within 24 months), i.e.
before the scheduled COD (27 September, 2012) of Unit-1. However, the work was
completed 27 months late (in October, 2014) mainly because of delay in acquisition
of land and related clearances from SICOM and Central Railways, the details of
which may be seen in the chronology set out earlier. The Commission notes that
VIPL initiated the process of acquiring SICOM land in January, 2009, long before
issuing the EPC contract LoI. After clearance from the Industries Department,
SICOM approached the Revenue Deptt., GoM in June, 2011, but GoM permission
was finally received nearly 3 years later, in April, 2014. This delay was beyond the
control of VIPL, and inspite of its efforts, since matters relating mostly to GoM and
SICOM such as additional compensation to erstwhile land owners, liability of Non-
-
MERC Order Case No. 115 of 2014 Page 26 of 99
Agriculture tax on SICOM, legal consultations regarding mode of allotment of land,
change in mode of land allotment from sale to lease, etc. had to be resolved. The
Commission also notes that VIPL initiated the process for land licensing approval
from Central Railways in August, 2010, just after issuing the EPC LoI. The delay in
obtaining that approval was also beyond VIPLs control, involving issues of revision
in assessment of chainage, modifications in assessments of different offices, changes
norms for licence fee, additional undertakings required from VIPL, delays in internal
approval process, etc.
3.1.25. Unit-2 COD was declared on 28 March, 2014 after assurance regarding availability
of pending land parcels for completion of the Railway siding. From that time till
commissioning of the siding in October, 2014, VIPL was running both Units by
transporting coal by road. This was possible because VIPL was able to stock 1.5
Lakh tonnes of coal to meet any shortfall in the movement of coal. However,
operation of both Units with transport of coal by road is unsustainable because of
cost and the fact that the road infrastructure cannot support movement of as many as
430 trucks per day continuously for a long time. Hence, the railway siding was
essential for combined operation of both Units.
3.1.26. As the Project developer, VIPL had a responsibility to declare COD as scheduled, if
necessary by making alternative arrangements for transportation of coal. The
Commission notes that VIPL was able to run Unit 1 by bringing coal by road, and
hence that it was feasible to operate it for some time without the siding. However, the
Railway siding was an integral component for sustained operation of the Project and
was delayed for reasons beyond VIPLs control. Therefore, the Commission is of the
view that the delay in commissioning Unit-1 was neither fully controllable nor fully
uncontrollable. In line with the ATE Judgment dated 27 April, 2011 and in order to
protect the interests of the consumers, the additional Project cost due to time overrun
of Unit 1 should be equally shared by VIPL and the consumers.
3.1.27. While Unit 1 could be operated for some time in this manner, the Commission notes
the genuine difficulty in combined operation of both the Units on the basis of road
-
MERC Order Case No. 115 of 2014 Page 27 of 99
transport of coal and without the Railway siding on a sustained basis. The
Commission is of the opinion that the reasons for delay, set out in earlier paragraphs,
in the commissioning of Unit 2 cannot be attributed to VIPL and must be treated as
uncontrollable. Hence, in line with the ATE Judgement dated 27 April, 2011 cited
earlier, the Commission allows the additional Project cost due to time overrun of Unit
2 on actual basis.
3.1.28. The Commission considers it prudent to consider the delay with respect to some
benchmarks rather than solely on the time-lines provided in the contract for execution
of the Project. VIPL has also referred to the MERC MYT Regulations, 2011
regarding the project completion period. The Commission has considered the
benchmark in accordance with those Regulations, which provide as under:
A. Thermal Power Projects: Coal/Lignite Power Plant: Unit size
200/210/250/300/330 MW and 125 MW CFBC technologies:
(a) 33 months for first Unit of green field projects. Subsequent Units at an
interval of 4 months each.
(b) 31 months for first Unit of extension projects. Subsequent Units at an
interval of 4 months each.
3.1.29. The Commission directed VIPL to submit the impact of the delay in commissioning
on the Overheads, IDC and Foreign Exchange Rate Variation (FERV) as compared
to the norms specified under the Regulations. VIPL submitted that, had the project
been commissioned as per those norms, Overheads, IDC and FERV would be as
under:
Table 5 - Project cost had COD been as per MYT Norms, as submitted by VIPL (Rs.
crore)
Sr.
No. Particulars
Cost for
Unit 1
Cost for
Unit 2 Project Cost
1 Hard Cost 1544.50 1264.22 2808.72
2 Pre-operative and
commissioning expenses 132.69 108.37 240.76
-
MERC Order Case No. 115 of 2014 Page 28 of 99
Sr.
No. Particulars
Cost for
Unit 1
Cost for
Unit 2 Project Cost
3 IDC 176.82 224.83 401.65
4 FERV 104.48 112.53 217.01
5 Total Project Cost 1958.19 1709.95 3668.13
3.1.30. As directed by the Commission, VIPL submitted details of actual Overheads, IDC
and FERV of Units 1 and 2 as under:
Table 6 - Unit-wise Actual Project cost as on COD, as submitted by VIPL (Rs. crore)
Sr.
No. Particulars
Cost for
Unit 1
Cost for
Unit 2 Project Cost
1 Hard Cost 1544.50 1264.22 2808.72
2 Pre-operative and
commissioning expenses 144.97 136.86 281.83
3 IDC 254.90 308.95 563.85
4 FERV 143.92 206.83 350.75
5 Total Project Cost 2088.29 1916.86 4005.15
3.1.31. In view of the above, the Commission observes that the delay in Commissioning
of Unit 1 cannot be categorized either fully controllable or uncontrollable. In
light of the forgoing, the Commission, for approving the project cost, has
considered equal sharing of impact of delay of Unit 1 on overheads, IDC and
FERV (i.e. difference between the actual cost for Unit 1 and estimated cost for
Unit 1 considering COD as per MYT norms) between VIPL and consumers. The
Commission has considered the actual cost of Unit 2, treating delay in the
commissioning of Unit 2 as uncontrollable.
3.1.32. The Commission has considered the approval of costs under each head in subsequent
sections of this Order.
-
MERC Order Case No. 115 of 2014 Page 29 of 99
3.2. Submission of VIPL on Capital Cost
3.2.1. Regulation 38.5 of the MERC MYT Regulations, 2011 provides that a Generating
Company has to approach the Commission for approval of capital cost and
determination of final Tariff as follows:
38.5 A Generating Company shall make a fresh Petition in accordance with
these Regulations, for determination of final tariff based on actual capital
expenditure incurred up to the date of commercial operation of the Generating
Station duly certified by the statutory auditors based on Annual Audited
Accounts.
3.2.2. Along with Chartered Accountant (CA)s certificate, VIPL submitted that the overall
capital cost of the generating station as on COD of Unit 2 (28 March, 2014) is Rs.
4005.15 Crore, based on the audited accounts as on that date.
3.2.3. The break-up of the capital cost as on COD, as submitted by VIPL, is as under:
Table 7 - Project Cost as on COD, as submitted by VIPL (Rs. crore)
Sr. No. Particulars Actual Cost as on COD
1 Land 85.36
2 BTG 790.12*
3 BOP 1695.87
4 Initial Spares 22.34
5 Taxes and duties 179.00
6 Overheads 281.83
7 OSBL 36.03
8 IDC & FC 563.85
9 Total Capital Cost 3654.40
10 Impact of FERV 350.75
11 Total Project cost as on COD 4005.15
*BTG Cost in 170.48 MUSD
3.2.4. VIPL submitted that the benchmark capital cost provided by the Central Electricity
Regulatory Commission (CERC) in Order dated 4 June, 2012 in Case No. L-
-
MERC Order Case No. 115 of 2014 Page 30 of 99
1/103/CERC/2012 for a thermal power station with coal as fuel for a single 500 MW
Unit is Rs. 5.08 Crore per MW as on December, 2011. The actual hard cost
(including additional capitalisation) excluding land cost, infirm power and Railway
siding, of Rs. 5.16 Crore per MW for the generating station at Butibori is competitive
considering the comparable CERC benchmark of Rs. 5.39 Crore after considering
3% escalation for two years.
3.2.5. VIPL submitted that it had opted for the following additional features in order to
meet Project- specific requirements:
Table 8 - Additional features of the plant, as submitted by VIPL
Sr.
No.
Equipment /
Services
Convention
al thermal
power plant
Additional features of
VIPL plant Remarks
1 Land
Normally
the plants
are located
in remote
areas where
cost of land
is low
Land is located near
Nagpur city and in
industrial area where
land cost is high
Location being in industrial
area has reduced the need to
acquire agricultural land,
thereby helping the
environment
2
Cooling
Water(CW)
/Auxiliary
Cooling
Water
(ACW) Pump
Single Pump
House for
both Units,
with
common
standby
pump for
both Units.
Dedicated CW/ACW
pump house for each
Unit with Standby CW
pump for each Unit.
Electric Overhead
Crane (EOT) crane for
each pump house.
Ventilation for each
CW pump house.
Dedicated CW
treatment system for
In the available layout it was
not possible to accommodate
two cooling towers with
common forebay and
CW/ACW pump house.
-
MERC Order Case No. 115 of 2014 Page 31 of 99
Sr.
No.
Equipment /
Services
Convention
al thermal
power plant
Additional features of
VIPL plant Remarks
each Unit.
3 Raw Water
Storage
Earthen
reservoir
Roller-compacted
concrete (RCC)
reservoir
For Unit-I, the clarified
quality water is made
available by MIDC. RCC
reservoir was found to be
necessary to maintain the
better water quality of the
water supplied by MIDC.
Raw water reservoir of
required capacity with
earthen embankment could
not be accommodated in
available space
4
Coal
Handling
Plant (CHP)
Coal Receipt
only by
Railway
In addition to Wagon
Tippler Arrangement,
dedicated coal
unloading & crushing
system for coal receipt
by road is provided.
Facility to receive the coal
by truck is incorporated in
the system so that blending
of market coal can be done.
5 Ash handling
Plant (AHP)
Lean Phase
Ash Slurry
disposal
System.
High Concentration
Slurry Disposal System
for fly ash disposal
To meet MoEF clearance
requirement
6 Ash Pond Earthen Ash
Pond RCC Ash Pond
Ash Pond of required
capacity with earthen
embankment could not be
accommodated in available
space. Therefore Ash Pond is
constructed out of Plum
-
MERC Order Case No. 115 of 2014 Page 32 of 99
Sr.
No.
Equipment /
Services
Convention
al thermal
power plant
Additional features of
VIPL plant Remarks
concrete as against
conventional earthen Ash
Pond.
7
Demineralisa
tion Plant
(DM Plant)
Ion
exchange
vessels
without
Ultra
filtration
system
In addition to Ion
exchange vessels, Ultra
filtration System is used
Butibori water contains
higher colloidal silica (6 ppm
against less than 1 ppm).
Colloidal silica cannot be
removed by conventional ion
exchange process, but only
by Ultra filtration process.
Therefore Ultra filtration
system has been considered
for removal of colloidal
silica present in
dematerialized water.
8
Cooling
Water
Treatment
Chemical
dosing
system
without Side
Stream
Filtration
system
Side Stream Filtration
system
Higher Cycles of
Concentration (COC)
adopted as per MOEF
Clearance for conservation
of water. Due to higher
COC, suspended particles in
the CW water exceed
permissible limit
recommended by Cooling
Tower fill manufacturer. To
maintain suspended solids
below permissible limit, side
stream filter is used in CW
circuit to remove suspended
-
MERC Order Case No. 115 of 2014 Page 33 of 99
Sr.
No.
Equipment /
Services
Convention
al thermal
power plant
Additional features of
VIPL plant Remarks
solids.
9 Air
Conditioning
Screw
Chillers are
used
Vapour Absorption
Machines (VAM)
Chiller is provided
which will be in the
operation & screw
chiller will be in
standby mode.
Due to its low operating cost,
VAM Chiller is provided in
centralized air conditioning
system in addition to
conventional screw chiller.
10
Mill Reject
Handling
System
Pneumatic
Mill Reject
Handling
System,
common for
two units.
Mechanical Redder
conveyor operated mill
reject handling system
is provided.
Mechanical conveyor will
ensure uninterrupted
operation of the mill even if
rejects are more than
designed quantity, i.e. output
of the unit will not be
affected in case of receipt of
poor quality coal.
11
Reverse
Osmosis
(RO) System
No RO Plant RO Plant envisaged To meet MPCB requirement.
12
Widening of
External
Drain
Widening of external
drain required to be
included
Widening of external drain
Culverts was carried out as
per recommendation of M/s
WAPCOS pursuant to the
requirement of MoEF.
13 Raw Water
System
Pipeline of 18 Kms
implemented requiring
road and railway
crossing
VIPL constructed a pipeline
of around 18 km as against a
nominal requirement of
around 5 km for other
conventional power plants.
-
MERC Order Case No. 115 of 2014 Page 34 of 99
Sr.
No.
Equipment /
Services
Convention
al thermal
power plant
Additional features of
VIPL plant Remarks
MIDC had asked VIPL to
make alternate arrangements
to get the water supply for
the station. Further, VIPL
encountered Railway
crossing and State &
National Highways and in
order to avoid disruption of
traffic, Push through
technology had to be adopted
for laying the pipeline.
3.3. Land
3.3.1. VIPL submitted that the actual cost of land incurred as on COD was Rs. 85.36 Crore.
Commissions Analysis
3.3.2. The Commission asked VIPL for a statement of land acquired from all sources along
with the acquisition rate. VIPL mentioned that the rates of MIDC land had increased
from Rs. 4 Lakh/acre to Rs. 19 Lakh/acre, and the Commission asked for supporting
documents. VIPL submitted summary statement of land acquired along with average
acquisition rates as below:
Table 9 - Cost of Land, as submitted by VIPL
Sr.
No.
Source/Type of
Land Acquired
Area (In
Acres)
Total Cost
(In Rs. Lakh)
Avg. Acquisition
Rate (Rs.
Lakh/Acre)
1 MIDC Land 298 2384.00 8.00
2 Private Land 257 6137.00 23.88
-
MERC Order Case No. 115 of 2014 Page 35 of 99
The following Table gives the details of land acquired from MIDC at rates varying
from Rs. 4 Lakh to Rs. 19 Lakh/Acre:
Table 10 - Details of Cost of MIDC Land, as submitted by VIPL
MIDC Land Area Cost of Land Rate
In Sq. Mtr In Acres Rs. Crore Rs. Crore/Acre
D-3 700000 173.00 7.00 0.04
D-3/Part 200000 49.00 3.45 0.07
D-3/Part 1 205099 51.00 8.20 0.16
RS-1 101175 25.00 4.05 0.16
P-81 1250 0.31 0.06 0.19
P-82 1440 0.36 0.07 0.19
3.3.3. The Commission referred to the land lease agreements and other documentary
evidence submitted by VIPL.
3.3.4. The Commission notes that the land cost claimed by VIPL is the actual cost incurred by
it. Hence, the Commission has considered the actual cost incurred for land as on COD.
3.4. EPC Contract
3.4.1. VIPL submitted that the development of project was undertaken through EPC
contracts, and that it has awarded the turnkey EPC contract to RInfra on fixed price
basis. VIPL stated that it gave Notice to Proceed (NTP) for Unit 1 on 27 February,
2010 and for Unit 2 on 30 April, 2010, with a commissioning schedule of 31 months
for Unit 1 and 34 months for Unit 2 from the respective dates of NTP.
3.4.2. VIPL also submitted that there has been no price variation in the domestic cost
component. The cost of the main equipment of the plant, i.e., Boiler, turbine and
generator, civil works and Commissioning and Installation (C & I) package, is
competitive in comparison to similar Projects, and that VIPL had ensured due
diligence as regards the scope of work in the EPC contract.
3.4.3. VIPL submitted that it has incurred the following BTG and BOP costs as on COD:
-
MERC Order Case No. 115 of 2014 Page 36 of 99
Table 11 - BTG and BOP Cost, as submitted by VIPL (Rs. Crore)
Sr.
No. Particulars
Cost
1 BTG (plant and equipment) 790.12
2 Design and engineering 42.68
3 BOP Mechanical 595.12
4 BOP Electrical 329.60
5 Commissioning and Installation package 54.16
6 BTG Erection Services 143.24
7 Civil Works 531.07
8 Taxes and duties 179.00
Total BTG and BOP 2664.99
Commissions Analysis
The Commission had directed VIPL to show how least cost principles and
competitive bidding route have been followed while awarding the EPC contract.
VIPL submitted that the Butibori project was originally conceived as one Unit of 300
MW to be developed as GCPP. This was awarded by MIDC through competitive
bidding process. Originally, 51% of the power was required to be sold to industrial
consumers with their equity participation so as to qualify as a GCPP. Subsequently,
an additional capacity of 300 MW was undertaken at the same site. Ensuring its
competitiveness of the Project has been at the core of its development. The Project is
being executed by awarding EPC contract whereby the entire responsibility of
construction is with the contractor. The EPC contract price offered by RInfra was
compared with cost benchmarks for similar projects at that point of time, and with
BTG supply awarded to Reliance Infra Projects (UK) Ltd. VIPL submitted further
that, for competiveness of procurement, it had also undertaken due diligence on the
market dynamics prevalent at the time of contract award. There are two types of
packages for the construction of a power plant, viz. mandatory packages (BTG, BOP,
Civil, etc,), and Project-specific additional packages (township, transmission line and
Railway siding). A comparison was undertaken with mandatory packages. In early
2008, similar Units (2 x 270 MW) were ordered by M/s GVK for a Project in Punjab.
-
MERC Order Case No. 115 of 2014 Page 37 of 99
GVK awarded the main packages through a competitive bidding process. The GVK
contracts are understood to have standard price escalation clauses. The other
precedent was from Maharashtra, where the Maharashtra State Power Generation Co.
Ltd. (MSPGCL), the State Generating Company, had awarded the EPC of Paras Unit
3 (250 MW) to M/s BHEL through competitive bidding. The contract, it had a price
escalation clause of 20%. The rationale for selection of these Projects for
benchmarking was the similarity of Unit size, similar time frame for contract award,
and since credible information on these Projects could be gathered from the public
domain. VIPL provided a broad comparison of these Projects as under:
Table 12 - Benchmarking of Capital Cost, as submitted by VIPL
Particulars
GVK
(2x270)MW
Paras 3
(1x250)MW
VIPL
(1x300) MW
Year of Award 2008 2007 2008
EPC Cost ( BTP, BOP & Civil) (Rs
Crore) 2221 1195 1390
Price Escalation factor#1 1.1 1.1 1 @
Total(Rs Crore) 2443 1315 1390
Removal of cost advantage for 2 Units
configuration for sharing of common
facilities #2 55% NA NA
Total Per Unit (Rs Crore) 1344 1315 1390
Per MW (Rs. Cr./MW) 4.98 5.26 4.63 # 1: Assumed to be equivalent to 10% over a 4 year tenure of Project construction period.
# 2 : Correction for cost advantage of 2 Unit configuration v/s single Unit. First Unit taken as
55% of total EPC Cost.
@ : VIPL awarded the EPC Contract on fixed price basis.
3.4.4. VIPL submitted that the average price of BTG, BOP and civil contract for these
similar Projects was between Rs 4.98 to Rs 5.26 Crore/MW. The variation was
perceived to be on account of the fact that the two Units of GVK would use certain
facilities in common and, therefore, the cost per MW would be lower in comparison
to Paras Unit -3, which was more like a greenfield Unit.
3.4.5. Since the initial intention idea was to develop a 300 MW Unit as a GCPP, the
ordering cost as in Paras Unit-3 was considered for comparison. Subsequently, when
it was decided to take up the second Unit , the cost of the GVK project was
-
MERC Order Case No. 115 of 2014 Page 38 of 99
considered relevant in view of the sharing of certain facilities by both Units.
Therefore, VIPL undertook exercise to optimise the cost of the second Unit. The
comparison of EPC award cost for the 2 units (600 MW) below is made to
substantiate its competitiveness.
Table 13 - Benchmarking of per MW cost, as submitted by VIPL
Particulars GVK VIPL
Capacity (MW) 540 600
EPC Cost ( BTG, BOP & Civil) (Rs Crore) 2221 2636
Price escalation factor # 1.1 1 @
Total (Rs Crore) 2443 2636
PER MW (Rs Crore/MW) 4.52 4.39 # : Assumed to be equivalent to 10% over a 4 year tenure of Project construction period.
@ : VIPL awarded the EPC Contract on fixed price basis.
3.4.6. The Commission notes VIPLs submission that the ordering cost for both its Units
compares well with that of the GVK Units. VIPL submitted that, with the addition of
Unit 2, the EPC cost was reduced considerably due to optimization in design,
efficient capacity utilization of the existing infrastructure and the common facilities.
The least cost principle was, therefore, ensured.
3.4.7. Subsequently, VIPL had compared the EPC cost of some other generating Stations
developed by Central and State Sector entities. The EPC cost for Central Sector
Projects was in the range of Rs. 5.04 Crore/MW to 5.48 Crore/MW, and between Rs.
5.13 Crore/MW to 5.93 Crore/MW for State Sector Projects.
3.4.8. The Commission notes that VIPL has endeavoured to follow the least cost approach
for award of the EPC contract for BOP and BTG. The EPC contract, popularly
known as Turnkey Contract, is awarded to a single contractor responsible for the
Supply, Erection and Commissioning of a project, to be completed within the time
period fixed, and based on agreed price and guaranteed performance.
3.4.9. The Commission notes that VIPL has followed the least cost approach while
awarding the EPC contract (including BTG, BOP and Civil works) and awarded the
-
MERC Order Case No. 115 of 2014 Page 39 of 99
contract on firm price basis. Further, the actual cost of EPC contract (including BTG,
BOP and civil works) is lower than its ordering cost.
3.4.10. For the purpose of approving the capital cost, the Commission has considered
the actual cost incurred for BTG package, BOP including civil works, and taxes
and duties paid for the Project.
3.5. Initial Spares as part of the Capital Cost as on COD
3.5.1. VIPL submitted that it has incurred an actual cost Rs.22.34 Crore, as on COD, for
initial spares.
Commissions Analysis
3.5.2. The Commission directed VIPL to furnish the list of initial spares included in capital
cost and documents justifying procurement of such spares. VIPL submitted that the
procurement of initial spares was based on general recommendations of Original
Equipment Manufacturers (OEM) to the EPC contractor, and submitted a list of
spares for Unit 1 and Unit 2 as provided to it.
3.5.3. As regards the cost of spares, Regulation 27.7 of the MERC MYT Regulations, 2011
specifies as under:
27.7 The capital cost may include capitalised initial spares for a maximum of
first five years of operation as follows:
(a) upto 2.5% of original capital cost in case of coal based/lignite fired
Generating Stations...
3.5.4. The Commission observes that the cost of initial spares capitalised till COD is
within 2.5% of Project cost as approved in this Order, as stipulated in
Regulation 27.7 of the MERC MYT Regulations, 2011. Accordingly, the
Commission has allowed the actual cost of initial spares amounting to Rs 22.34
Crore as on COD, being within the ceiling specified in the Regulations.
-
MERC Order Case No. 115 of 2014 Page 40 of 99
3.6. Outside Boundary Limits (OSBL)
3.6.1. VIPL submitted that it has incurred Rs. 36.03 Crore as cost of OSBL as on COD for
the Project, which pertains to the water conveyance system. The cost variation of the
water conveyance system compared to original estimates was because of finalisation
of the scope of work after the original estimates were made.
Commissions Analysis
3.6.2. The Commission notes that Railway siding, water conveyance system and
transmission lines were included in OSBL in the original estimates. After the change
in the nature of the Project from a GCPP to an Independent Power Plant (IPP), the
transmission lines have been separated from the generation and made a part of Intra
State Transmission System (InSTS). Further, because of the delay in its
commissioning, the Railway siding has been considered by VIPL in additional
capitalisation in FY 2014-15. The Commission notes that the cost incurred towards
OSBL pertains only to the water conveyance system.
3.6.3. The Commission notes that the amount claimed under OSBL by VIPL is the
actual cost incurred for the water conveyance system. The Commission has
accordingly considered a cost of Rs. 36.03 Crore for OSBL.
3.7. Overheads
3.7.1. VIPL submitted that the cost of actual overheads as on COD is Rs. 281.83 Crore as
against the estimate of Rs. 155 Crore. The increase is on account of higher than
anticipated expenditure on the following:
(i) Capital cost contribution paid to MIDC for water allocation: Against the total water
requirement of 22 MLD for a Unit, MIDC initially allotted 15 MLD without charging
capital cost contribution (one time payment to MIDC). For the balance 7 MLD, MIDC
charged fees as capital cost contribution.
(ii) Restoration charges paid to Irrigation Department for water allocation: As per MIDC
policy, water shall be provided by MIDC for the industries located in its MIDC area.
However, due to non-availability of water allocation to MIDC from the Irrigation Deptt.,
-
MERC Order Case No. 115 of 2014 Page 41 of 99
MIDC asked VIPL to arrange water from alternate sources. Vide letter
VIPL/NGP/IRRIG/09/001 dated 3 January, 2009, VIPL accordingly approached
Irrigation Department and obtained water allocation for the Project. The Irrigation
Department has levied restoration charges.
(iii)Start up expenses have increased primarily on account of higher than anticipated
expenditure on:
- Purchase of market coal (instead of linkage coal)
- Significantly reduced revenue from Infirm power considering MSEDCL's policy of
paying for infirm power only during peak hours
- Start up power from MSEDCL.
3.7.2. VIPL also submitted that the overheads for Railway siding and other systems which
are yet to be completed have not been considered.
Commissions Analysis
3.7.3. The Commission directed VIPL to submit details, with reasons and documents, of the
increase in each of the overhead costs vis-a-vis the original estimates. VIPL
submitted as under:
Table 14 - Details of Overheads, as submitted by VIPL
Particulars
Original
estimates
(Rs.
Crore)
Actual
Cost
(Rs.
Crore)
Reasons for variation
Charges to MIDC
for water supply
0 11.27 Capital cost contribution was paid in order to
get water allocated for the Project.
Charges to
Irrigation
Department for
water
supply
0 12.73 Due to non-availability of water allocation
from MIDC, VIPL was required to arrange
water from Irrigation Department, GoM.
Irrigation Department directed VIPL to pay
restoration charges for allocating water for the
Project.
Start up Expenses
- Fuel
30.00 44.78 As the linkage coal for start up and testing of
the Project was not made available by WCL in
the absence of FSA, VIPL had to procure
market coal. Also, there was an increase in
HFO / LDO prices which added to the costs.
-
MERC Order Case No. 115 of 2014 Page 42 of 99
Particulars
Original
estimates
(Rs.
Crore)
Actual
Cost
(Rs.
Crore)
Reasons for variation
Employee and
other
Administration /
establishment
Expenses
145.00 213.30 The power sector employment market scenario
had undergone a change du