S. No. ..............................

APPLICATION FORM

WALFARE SOCIETY

Re

sid

ency W

el f a

re Society

Location : GR. NOIDA WEST, SEC. 16

RESIDENCYPhase - II

ABOUT SOCIETY

Residency Welfare Society is a government society, registered under “SR Act 1860”. The main objective of the society is to provide

modern dwelling units in prime locations to Government/Public Sector & MNC employees. The society is managed by serving and retired Government/Public Sector and the established corporate officers

from MNCs. The principle objective of the society is to operate in a conducive and trust worthy environment; so as to fulfill the needs of

modern society in the best possible manner.

Re

sid

ency We

lf are

Society

2

If life is meant to be joy, then (Residency Welfare Society is an ode to it. For it is here that you will find your dreams answered in every way. The goodness of Residency Welfare Society lies not in its size spanning 5 acres of lush land, nor in its ambition to be a mega enclave hub for 250 families to live in. Its greatness is, in fact, in the little things that add up to make it an irresistible choice of home for you. Because, here, it is not just good homes that we seek to provide, it is a whole lifestyle - a way of life in the future, built around you and your family.

(Residency Welfare Society) is first and foremost defined by its place value. Being situated where it is (Adjacent to Gaur City Chowk & Crossing Republic), after all, has its privileges. It puts you within fifteen minutes drive from the heart of the city and over 100 top essential destinations for everyday living fall within a radius of 2 kms from RWS. All, while being sheltered in the peace and quiet of an elite residential locality.

And then there's the space aspect. (Residency Welfare Society) is inspired by the idea of luxury of space. Hence everything about it breathes ample space, made possible by our adherence to the 70:30 principles. Meaning, only 70% built up area and 30% free space and beautifully landscaped too! On offer are 1, 2 & 3 bedroom apartments in a choice of sizes ranging from 550SFT to 1125 SFT.

(Residency Welfare Society) comprises of two distinct apartment blocks, each rising to 4th& 6th storeys. The elegant structure is a tribute to architectural excellence and incorporates the most contemporary concepts in living space. Features such as wide open spaces, scope for abundant flow of natural light and ventilation, intricate planning and well engineered construction using the best materials and brands make this a quality proposition too.

Add to this, facilities like jogging track, community hall and you have the opening for a complete community life at (Residency Welfare Society) your choice for your future life. It's a decision you'll enjoy for the rest of your life

Two elements define modern living: Atmosphere and environment. At Maurishka Palace, we've paid attention to both these to lend it an aura of excellence that's both impressive and compelling. With world class aesthetics and a wide array of facilities to match, the expansive enclave Residency Welfare Society is a tribute to the modern living at its best.

Even as you enter the enclave you will be greeted with the abundant greenery, thanks to variety of exotic and decorative plants and tress a landscaping coup and a gardener's delight. The architecture blends the contemporary concepts with functionality to make it a haven for you to live in. The appealing external appearance is complemented with matching interior features, making it a happy conclave for futuristic living.

RESIDENCY WELFARE SOCIETY OVERVIEW

BENEFITS OF SOCIETY

Membership of Society.

Proper Legal Procedures.

Assurance of Legitimate Possession.

Welfare Services even after Possession.

Regular cultural events for the members of society.

Special grievance cell for addressing the issues of society.

Cost benefit in comparison to other projects at the same location.

Re

sid

ency We

lf are

Society

3

ELIGIBILITY CRITERIAS

Serving & Retired employees of Central, State and UT Governments.

Serving & Retired Doctors, Teachers, engineers, Chartered Accountants, Bank Employees, ICWAs, Armed/Paramilitary forces and their clo se

family members.

Serving & Retired employees of PSUs, BSNL, MTNL, BHEL, BFSIS, ONGC, NTPC, GAIL, NHPC, ESI, IOB, MMTC, STC, FCI, FRI, AAIB, EML, PFC, SBI,

NMDC, SAIL, IOC, Railways.

Self Employed, Serving & Retired employees of Listed Companies.

LOCATION ADVANTAGES

Delhi -------------------- 20 Minutes

Ghaziabad ------------- 20 minutes

Noida City Center --- 10 minutes

Kissan Chowk --------- 5 minutes

Knowledge Park V --- 5 minutes

Railway Station ------ 15 minutes

Metro Station --- 5 minutes

NH 24 ------------------- 5 minutes

NH 91 ------------------- 5 minutes

Re

sid

ency We

lf are

Society

4

Gated & Walled Society

Front Entrance with 24x7 Security

Main Road (150 feet wide)

Internal Roads (45 feet wide)

Park & Green Belt Development

G+4 Floors (1 Lift in Each Tower)

Water Supply

Street Lights

Drainage System & Sewage System

Water Harvesting

FACILITIES PROVIDED BY SOCIETY

Re

sid

ency We

lf are

Society

5

UNIT DETAILS

UNITS AREA (SQ. FEET ) AREA (SQ. METERS)

550 51.096

800

1 BHK

74.3222 BHK

1125 104.5533 BHK

IMPORTANT DATES

Scheme Opening th: 17 January, 2015

Scheme Closing th: 26 February, 2015

Draw Date th: 28 February 2015

Note: Validity of mentioned dates is subjected to the avaliability of forms.

Re

sid

ency We

lf are

Society

6

SPECIFICATION1) Fully R.C.C. Framed structure.

2) Laterite 9” outer walls & 4” solid block inner walls.

3) Double coat exterior plastering with water proof treatment.

4) Smooth finish interior wall plastering.

5) Inter lock paving for parking & open area.

6) Steel gate with surround compound wall as per architect's design.

7) Front elevation as per architect's design.

8) Hard wood door frames with Flush door.

9) Mortise lock for all the bed rooms.

10) Teak wood door frames with Flush door.

11) Brass fittings & lock for front door.

12) Fibroteck door for toilets with baby lock.

13) 2'0”x2'0” vetrified flooring with premium quality.

14) Good quality glazed tiles for toilet walls up to ceiling.

15) Anti skid 1'0”x1'0” ceramic tiles for toilet flooring.

16) White colored commodes & wash basins in all toilets (Parry ware / Hindware/ RAK).

17) Over head water tank & under ground sump tank with required pumps.

18) Electrical points as per specifications.

19) T.V. & Call bell points & Telephone.

20) Pastel colour below counter type wash basin for dining with black granite slab with nosing.

21) Split A/C Provision for living.

22) Bed Rooms

23) Split A.C. provision for all bedrooms.

24) T.V. points in all bed rooms.

25) Kitchen and Work Area

26) Black Granite platform with bullnozing.

27) Stainless steel sink 36” with drain board.

28) Adequate power points & exhaust fan provision.

29) Provision for fixing water purifier near the sink.

30) Provision for washing machine in work area.

31) Reticulated gas connections.

32) Provision for exhaust fan.

33) Bath Rooms

34) Water proof treatment done for sunken.

35) Pressure checked plumbing and drainage lines to ensure total leak proof toilets.

36) Flush valves for commodes.

37) Wall mount commodes in all toilets.

38) Bison Panel ventilators with exhaust fan provision.

39) Health faucet in all the bath rooms.

LIVING & DINING FURNISHED

UNIT LAYOUT PLAN

Re

sid

ency We

lf are

Society

1BHKAREA = 51.096 SQ MT.

OR 550 SQ FT.

8

2BHKAREA = 74.322 SQ MT.

OR 800 SQ FT.

Re

sid

ency We

lf are

Society

9

UNIT LAYOUT PLAN

UNIT LAYOUT PLAN

Re

sid

ency We

lf are

Society

3 BHKAREA = 104.553 SQ MT.

OR 1125 SQ FT.

8

PAYMENT PLAN (Phase-II)

No.

01

Particulars

Re

sid

ency We

lf are

Society

10

1 BHK(550 Sq/Ft.)

2 BHK(800 Sq/Ft.)

3 BHK(1125 Sq/Ft.)

At the time of Submission of the Application form

After draw (Within 15 day)

After 1 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

After 3 months

`

`

`

`

`

`

`

`

`

`

`

`

`

10%

10%

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

89,763/-

` 31,000/-

Balance Service Tax

+

Registry Charges

` 11,50,000 + 1 Lac CCP

Total Cost (BSP `)

Balance Service Tax

+

Registry Charges

Balance Service Tax

+

Registry Charges

` 17,50,000+ 1 Lac CCP

Total Amount ` 12,50,000/-

02

03

04

05

06

07

08

09

10

11

12

13

14

At the time of Registry15

`

`

`

`

`

`

`

`

`

`

`

`

`

10%

10%

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

1,32,472/-

` 51,000/-

` 18,50,000/- ` 27,00,000/-

` 26,00,000+ 1 Lac CCP

`

`

`

`

`

`

`

`

`

`

`

`

`

10%

10%

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

1,93,590/-

` 71,000/-

TERMS AND CONDITIONS

Re

sid

ency We

lf are

Society

11

1. All Indian Citizens or NRIs are eligible to apply for the allotment of residential flat under proposed scheme.

2. The Applicant(s) must have attained the age of majority (18 years) as on the date of application. In case of minor Applicant(s), application shall be made by the

natural/appointed guardian on behalf of such minor.

3. Allotment of the Flats in the proposed residential scheme shall be made on the basis of first come first serve.

4. All payments to be made through Cheque/D.D. in favour of Villosa Developers Pvt. Ltd., payable at Delhi NCR.

5. All receipts shall be subject to realization of cheque/D.D. The date of receipt shall be considered as the date of payment in case the Cheque/D.D. is not

dishonoured.

6. The company does not offer any discount on BSP. If any representative/associate offers you discount on mentioned BSP, the company would not be responsible

for same. Furthermore the application would stand cancelled without any prior notice by company.

7. The mentioned BSP remains fixed till next price revision. The company does not authorise its representatives/associates to charge any premium apart from the

mentioned BSP.

8. If Applicant(s) opt for cancellation of his/her/their booking, refund of payment made shall be as follows: 20% of the payment made as on the date shall be

deducted if Applicant(s) opt for cancellation of his/her/their booking.

9. The Applicant(s) have agreed that in case of delayed installments on account of dishonour of a cheque, ̀ 500/- per instance will be debited to his/her account and

if there are three recurring instances of cheque dishonour then, the company reserves the right to cancel the booking without giving any notice to the

Applicant(s).

10. The installment due towards the payment of unit is to be paid as per the given payment schedule, no separate letter will be issued for any such installment, hence

it is obligatory on the part of Applicant(s) to pay installments on or before the due dates as mentioned in the payment schedule. It is made clear that timely

payment is the essence of this allotment.

11. The time of payment of installment shall be the essence of consent between the parties. It shall be incumbent upon the intending Applicant(s) to comply with the

terms of payment and other terms and conditions of allotment. In case the installment is delayed, the intending Applicant(s) shall pay interest calculated from the

due date of outstanding amount @18% per annum, compounded at the time of every succeeding installment even if the intending Applicant(s) fails to pay the

installment with interest the Developer has reserved the right to cancel registration of allotment.

12. The price of the Flat is tentative to the extent that any enhancement in the cost of scheduled land awarded by the Competent Authority under the relevant law

shall also be payable proportionately, as determined by the Authority, within 30 days or in such specific period of its demand. Simple Interest at the rate of 15%

per annum shall be payable on the delayed payment of enhancement.

13. Installments due towards payment of the Flat will be made at intervals as laid down by the Developer. In case payment is not received within the stipulated period

given above or in the event of breach of any of the terms and conditions of this allotment by the Applicant(s), the allotment will be cancelled and 25% of the basic

price of the Flat will be forfeited and balance amount will be refunded without any interest after six months.

14. The land shall continue to vest with the Developer until the entire consideration money together with interest and other amount, if any, due to the Developer on

account of the sale, of such Flat is paid. The transferee shall have not right to transfer by way of sale, gift, mortgage or otherwise the Flat or any right, title or

interest therein until the full price is paid to the Developer, except with the prior permission of the Developer.

15. Possession of the residential Flats shall be delivered to the Applicant(s) in about 3 years from the date of allotment subject to the grace period of 180 days.

However, possession may be given earlier, if the development of basic services in a scheme is completed before the above-mentioned period.

16. In case the possession of the Flat is not offered within the prescribed period of 3 years from the date of allotment, Developer will pay interest at the rate of 6% per

annum (or as may be fixed by the Developer from time to time) on the amount deposited by the intending Allottee after the expiry of 3 years until the date of offer

of possession. In such case, the intending Allottee will not be required to pay the further installments. The payment of balance installment will only start after the

possession of the Flat is offered to the intending Allottee.

17. If the proposed residential scheme fails to complete or deliver on account of force majeure reasons or any other reasons beyond the control of the Developer,

entire paid amount shall be refunded to the Allottee without any interest thereon. The Developer is working as per statutory rules and regulations and is making

all possible efforts to obtain all necessary permissions or sanctions from the competent authorities of the Government.

18. There can be a variation in the shape or size of Flat as per actual demarcation at the site, and intending Allottee shall be liable to accept the same subject to

payment or refund for the differential areas, as the case may be. The variation can be up to ±3% of the total Flat area allotted.

19. The Applicant(s) has/have seen and accepted the plans, designs, specifications, which are tentative, modifications in the layout plan/plans, designs as the

Developer may deem fit or as directed by any competent authority or authorities. Any alteration/modification resulting in ±3% in the area of the Flat, there will be

no extra charge/claim by the Developer/Applicant(s). However, any major alteration/modification resulting in more than ±3% change in area of the Flat, any time

prior to and upon the possession of the Flat, the Developer shall intimate to the Applicant(s) in writing the changes thereof and the resultant change, if any, in the

price of the Flat to be paid by him/her/them and the Applicant(s) agrees to inform the Developer in writing his/her/their consent or objections to the Developer

within 30 days from the date of such notice failing which the Applicant(s) shall be deemed to have given his/her/their full consent to all the

alterations/modifications. If the Applicant(s) give his/her/their non-consent/objections then the allotment shall be deemed to be cancelled and the Developer

shall refund the entire money received from the Applicant(s) without any deduction and the interest. The Applicant(s) agreed that any refundable/payable

amount (without any interest) would be at the rate per sq. yd, as mentioned in the application/booking/allotment letter.

Signature of the First/Sole Applicant Signature of the Second Applicant

Re

sid

ency We

lf are

Society

12

20. The development of the Project is likely to be completed as stipulated, subject to force majeure circumstances like regular and timely payment by the

Applicant(s), availability of development material etc. change of laws by Government/local authorities etc. No claim by way of damage or compensation shall be

maintainable against the Developer in case of delay in handing over of the Flat within stipulated time after exceeding the grace period 180 days subject to

aforesaid reasons the company will compensate the Applicant(s) for delayed period @ 3/- per sq feet per month.

21. The Allottee shall use the allotted residential unit for the residential purpose only. An Allottee undertakes not to make any illegal construction in the allotted unit

nor use the same for any illegal or commercial purpose. If an Allottee found to be in violation of this condition, the Company shall have exclusive right to cancel

the allotment of such Allottee.

22. In the event of furnishing any false information/affidavit in the allotment application, the Company shall have sole right to cancel the allotment of such Allottee

without giving him or her any opportunity. The cancellation of allotment of such Allottee shall be rendered even after the delivery of possession of the Flat and in

that event the company shall be competent to recover the possession of the Flat. If the process of allotment of a Flat to an Allottee could not be completed on

account of any mistake by such Allottee, the Company shall deduct 20% from the paid amount and remaining amount after such deductions shall be refunded

without any interest by way of account payee cheque in favour of the Allottee.

23. If the Allottee opts for home loan in respect of the allotted unit from any banks and financial institutions, eligibility and entitlement for such loan shall be decided

by the lending banks or financial institutions.

24. All applicants are require to furnish Identity Proof, Voting I-Card, Driving License or any documents bearing his or her photo along with their application, and one

of such documents shall be attested.

25. The address given in the application should be complete. Any change in the address should be notified to the Developer’s Officer by registered A. D. post.

26. Allotee(s) shall bear cost of consumption of electricity and water for his flat as well as the proportionate running cost (i;e., electricity, water, manpower &

consumables) for providing common services & facilities in the colony with effect from the date of offer of possession of flat by developer.

27. The cost and expenses of preparation, stamping and registering the legal documents and its copies and all other incidental charges including the stamp duty or

any other duty thereof or charge/processing charge that may be levied by any authority empowered in this behalf, in respect of the devised Flat shall be borne by

the Applicant(s).

28. Payment shall alone not accrue any right to the Applicant(s) unless supported by relevant documents issued by the Developer.

29. The intending Allottee(s) has/have full knowledge of that the demarcation and zoning plans may further be changed and substituted by other layout plan(s) as

and when sanctioned/approved by the Competent Authority in which event the number of the Said Flat, its location, size as allotted to the Intending Allottee(s)

may change and be substituted by a new number, location, size etc; to which the Intending Allottee(s) has/have confirmed that he/she/they shall have no

objection having been prior informed of this eventuality. The Intending Allottee(s) also agree(s) to abide by the terms and conditions of this Allotment including

those relating to payment of Sale Price, Govt. Charges including but not limited to External Development Charges, Infrastructure Development

Charges/Infrastructure Augmentation Charges and other charges.

30. The possession of the Flat shall be delivered to the Allottee after executing necessary documentation. The Allottee shall be liable to pay all taxes after taking over

the possession of his or her unit. If the Allottee fails to take the possession within 6 month from the date of delivery of possession, he or she shall be liable to pay

holding charges to the Company @ 5/- sq feet per month. After the lapse of 6 months from the date of possession, the Company shall cancel the allotment of such

Allottee and refund the paid amount after deducting 20% by way of account payee cheque.

31. It is abundantly made clear that in respect of all remittances, acquisition/ transfer of the Said Flat it shall be the sole responsibility of non-resident/foreign

national of Indian origin to comply with the provisions of Foreign Exchange Management Act (FEMA), 1999, and rules and regulations made there under or

statutory enactments or amendments thereof and the rules and regulations of the Reserve Bank of India or any other applicable law and provide the Company

with such permissions, approvals which would enable the Company to fulfill its obligations under this Agreement. Any refund, transfer of security if provided in

terms of this application shall be made in accordance with the provisions of FEMA, and rules and regulations made there under or statutory enactments or

amendments thereof and the rules and regulations of the Reserve Bank of India or any other applicable law. The Intending Allottee(s) understand(s) and agrees

that in the event of any failure on Intending Allottee(s) part to comply with the prevailing exchange control guidelines issued by the Reserve Bank of India,

Intending Allottee(s) shall be liable for any action under the FEMA, and rules and regulations made there under as amended from time to time. The Intending

Allottee(s) shall keep the Company fully indemnified and harmless in this regard. The Company accepts no responsibility in this regard.

32. This allotment shall be construed and the legal relations between the parties hereto shall be determined and governed according to the laws of India. The Courts

at Delhi alone and the High Court of Delhi alone shall have the jurisdiction in all matters arising out of/ touching and/or concerning this allotment. All or any

disputes arising out or touching upon or in relation to the terms of this allotment including the interpretation and validity of the terms thereof and the respective

rights and obligations of the parties shall be settled amicably by mutual discussion failing which the same shall be settled through arbitration. The arbitration

proceedings shall be governed by the Arbitration and Conciliation Act, 1996 or any statutory amendments/modifications thereof for the time being in force. The

Arbitration Proceedings shall be conducted by a Sole Arbitrator who shall be appointed by the Company. The Intending Allottee hereby gives his consent to the

appointment of the Sole Arbitrator as specified herein above and waives any objections that he may have to such appointment or to the award that may be given

by the Arbitrator. The venue of the Arbitration shall be at New Delhi, India and language of arbitration shall be English. The Intending Allottee(s) hereby confirms

that the Intending Allottee(s) shall have no objection to such appointment by the Company or have any doubts about the impartiality of the sole arbitrator,

appointed by the Company. It is hereby clarified that during the Arbitration Proceeding the Company and the Intending Allottee shall continue to perform their

respective rights and obligations under the Agreement.

33. The price, terms and conditions mentioned in the information brochure are merely indicative and not exhaustive

I/we have gone through the details of the aforesaid terms and conditions and unequivocally undertake(s) to abide by the said terms and conditions and agreed to

accept the same.

Sole/First Applicant Application No.

1. Name (Mr./Ms./Mrs.)

2. Father’s/Husband’s Name

3. Date of Birth Occupation

4. Nationality Indian Other

5. Mailing Address

Pin Code Mobile Number Telephone Number

6. Email Id

7. Permanent Address

8. PAN Card No. Total Annual Income

9. Bank Account Details

Account Holder’s Name

Bank Name Branch

Account Number IFSC Code

Second Applicant

1. Name (Mr./Ms./Mrs.)

2. Father’s/Husband’s Name

3. Date of Birth Occupation

4. Nationality Indian Other

5. Mailing Address

Pin Code Mobile Number Telephone Number

6. Email Id

7. Permanent Address

8. PAN Card No. Total Annual Income

9. Bank Account Details

Account Holder’s Name

Bank Name Branch

Account Number IFSC Code

Application No.

ACKNOWLEDGMENTSole/First Applicant’s Name for the application of registration of Flat Unit Type

(Sq. feet / Sq. metre) along with the earnest money of (`) by Cheque/DD/Cash

Dated in favour of ‘VILLOSA DEVELOPERS PVT. LTD.’ payable at Delhi NCR.

*Please Note: The validation of this acknowledgment is subjected to the realization of payment.

Applicant’s Signature Representative’s Signature

APPLICATION FORM

Re

sid

ency We

lf are

Society

13

9. Unit Type

1 BHK (Sq. feet / Sq. metre) 2 BHK (Sq. feet / Sq. metre)

10. Payment Details:

Payment Mode Cheque DD Cash

Amount. Date

Demand Draft/Cheque No. Bank Name

12. Documents Required

a) Two passport size photographs

b) Address Proof c) Identity Proof

Driving Licence PAN Card

Passport Passport

Voter Id Aadhar Card

Aadhar Card Driving Licence

Ration Card Govt./Employee Id

13. Nominee Declaration

SN. Name Age Relation % age

1.

2.

Date Authorized Signatory

14. Declaration

a) The Cheque/Draft should be payable in the favour of ‘VILLOSA DEVELOPERS PVT. LTD.’ payable at Delhi NCR.

b) We have seen and understood the terms and conditions of the offer and have understood that the company has the sole

discretion and authority to accept and reject this application. In case of rejection by the company, the applicant shall be entitled

to get the refund of entire earnest amount of money paid, without interest.

Date

Sole/First Applicant’s Signature Second Applicant’s Signature

Re

sid

ency We

lf are

Society

VVILLOSA

14

3 BHK (Sq. feet / Sq. metre)

VILLOSA DEVELOPERS PVT. LTD.Address : A-23, 4th floor, Sector-2 Noida-201301.

Email : info@villosaestates.com

Tel.: 0120-4549523 Web : www.villosaestates.com

*M

ap N

ot

To S

cale

Noida City Centre Metro Station

JP Greens

Amity

Wish town

University

Golf Course

Botonical Garden

Supertech ECO-3

Ajnara

Noida - Gr. Noida express Way

DN

D F

lyw

ay

Kal

ind

i Ku

nj R

oad

Mah

amay

a Fl

yove

r

Kissan Chowk

Buddha Chowk

Pari Chowk

TO

WA

RD

S D

ELH

ITO

WA

RD

S N

OID

A

MAP

Re

sid

ency We

lf are

Society

Apollo Hospital

15

VictoryOne Amara

RESIDENCYWELFARE SOCIETY

Re

sid

ency We

lf are

Society

` 200/-

VVILLOSA

VILLOSA DEVELOPERS PVT. LTD.Address : A-23, 4th Floor, Sector-2 Noida-201301.

Email : info@villosaestates.comTel.: 0120-4549523 Web : www.villosaestates.com