resolving construction disputes through arbitration - an overview of tanzanian legal framework
DESCRIPTION
Resolving Construction Disputes Through Arbitration: An Overview Of Tanzanian Legal FrameworkTRANSCRIPT
University of Strathclyde
Law School
RESOLVING CONSTRUCTION DISPUTES THROUGH ARBITRATION:
AN OVERVIEW OF TANZANIAN LEGAL FRAMEWORK
By
George Mandepo
Reg. No. 200957963
Supervisor: Dr. Bryan Clark
Dissertation Submitted for the Degree of LLM in Construction Law, September 2010
George Mandepo Reg. 200957963
i
DECLARATION AND COPYRIGHT
This thesis is the result of the author’s original research. It has been composed by
the author and has not been previously submitted for examination which has led to
the award of a degree.
The copyright of this thesis belongs to the author under the terms of the United
Kingdom Copyright Acts as qualified by University of Strathclyde Regulation 3.50.
Due acknowledgement must always be made of the use of any material contained in,
or derived from, this thesis.
Signed………………………………….
(George Mandepo)
Date:…………………………………….
George Mandepo Reg. 200957963
ii
DEDICATION
This dissertation is dedicated to my parents, my wife Veronica and to
my children Hans and Renée.
George Mandepo Reg. 200957963
iii
ACKNOWLEDGEMENT
I would like to express my gratitude and appreciation to my supervisor, Mr. Bryan
Clark for your useful guidance, suggestion and encouragement that enabled me to
accomplish this study successfully.
Thanks to my employer, the Permanent Secretary, Ministry of Agriculture Food
Security and Cooperative of the United Republic of Tanzania for sponsoring my
studies. To Dr. A. P. Rutabanzibwa and my officemates, I am most grateful for your
support and encouragements during my studies.
My special gratitude to my beloved parents, brothers, sisters and all relatives whose
love and affection is the source of inspiration and support for my studies. Finally yet
importantly, I would like to thank my friend and fellow classmate Donald Sheedy for
your invaluable assistance and encouragement throughout my time at Strathclyde
University.
George Mandepo Reg. 200957963
iv
ABSTRACT
The complex nature of projects in the construction industry has made disputes
unavoidable. Arbitration as an alternative to litigation has been widely acceptable as
an effective dispute resolution method especially in domestic and international trade
transactions including construction industry.
The main purpose of the study was to examine the effectiveness of arbitration legal
framework in Tanzania in resolving construction disputes. The study involved a
thorough review of the existing legal and institutional framework for arbitration in
Tanzania in comparison with the international arbitration agreements and arbitration
laws of the other common law countries including the UK.
The study has revealed that the resolution of construction disputes through
arbitration in Tanzania is governed by the Arbitration Act, Cap. 15, Civil Procedure
Code and the National Construction Arbitration Rules 2001. However the principal
arbitration law i.e. Arbitration Act is out-dated and not compliant with the
requirements of various International arbitration agreements including the
UNICITRAL Model Law and New York Convention.
It has been observed that there are several inconsistencies in the procedures with
the current arbitration legislation that cannot afford effective resolution of
construction disputes between the parties. The observed shortcomings in the law
include too much power of the courts over the arbitration proceedings, which can
affect parties’ autonomy in the arbitration process and distort the general purpose of
arbitration. In addition, the study has observed that the arbitration system in
Tanzania lacks active and competent arbitration institutions and practitioners to
facilitate arbitration process for the construction disputes.
Based on the findings, the study recommends for the review of the legal and
institutional framework for arbitration in Tanzania with a view of making arbitration
more effective method in resolving of construction disputes in line with requirements
of the international arbitration agreements.
George Mandepo Reg. 200957963
v
TABLE OF CONTENTS
DECLARATION AND COPYRIGHT ............................................................................ i
DEDICATION .............................................................................................................. ii
ACKNOWLEDGEMENT ............................................................................................. iii
ABSTRACT ................................................................................................................ iv
ABBREVIATIONS .................................................................................................... viii
TABLE OF CASES ...................................................................................................... i
LIST OF STATUTES .................................................................................................. xi
CHAPTER ONE ......................................................................................................... 1
INTRODUCTION TO RESEARCH ............................................................................. 1
1.0 BACKGROUND ................................................................................................... 1
1.2 PROBLEM STATEMENT ..................................................................................... 2
1.3 AIM AND PURPOSE ............................................................................................ 3
1.4 RATIONALE AND OBJECTIVE ........................................................................... 3
1.5 SIGNIFICANCE OF THE STUDY ........................................................................ 4
1.6 LITERATURE REVIEW ........................................................................................ 4
1.7 HYPOTHESES ..................................................................................................... 6
1.8 RESEARCH METHODOLOGY ............................................................................ 6
1.9 ORGANISANISATION OF STUDY ...................................................................... 7
CHAPTER TWO ......................................................................................................... 8
CONSTRUCTION DISPUTES AND RESOLUTION TECHINIQUES ......................... 8
2.0 INTRODUCTION .................................................................................................. 8
2.1 CONSTRUCTION DISPUTES ............................................................................. 8
2.1.1 Dispute Defined ............................................................................................. 8
2.1.2 Cause of Disputes .......................................................................................... 9
2.1.3 Effects of Disputes in Construction .............................................................. 10
2.2 DISPUTE RESOLUTION METHODS................................................................. 10
CHAPTER THREE ................................................................................................... 13
ARBITRATION IN PRACTICE ................................................................................. 13
3.0 INTRODUCTION ................................................................................................ 13
3.1 ARBITRATION DEFINED .................................................................................. 13
3.2 HISTORICAL PERSPECTIVE ............................................................................ 13
3.3 PRINCIPLES OF ARBITRATION ....................................................................... 14
George Mandepo Reg. 200957963
vi
3.4 ADVANTAGES AND DISADVANTAGES OF ARBITRATION ............................ 14
3.5 STARTING AN ARBITRATION .......................................................................... 15
3.5.1 Genuine dispute or difference ...................................................................... 16
3.5.2 Arbitration agreement................................................................................... 18
3.5.3 Submission or reference of a specific dispute .............................................. 19
3.6 SEVERABILITY OF ARBITRATION AGREEMENT ........................................... 19
3.7 APPLICABLE LAW AND SEAT OF THE ARBITRATION................................... 20
3.8DUTIES AND POWERS OF ARBITRAL TRIBUNAL........................................... 20
3.9 ENFORCEMENT OF AWARD ........................................................................... 22
3.10 CHALLENGING AN AWARD ........................................................................... 23
3.11 COURTS’ POWERS ON ARBITRATION ......................................................... 23
CHAPTER FOUR ..................................................................................................... 25
LEGAL FRAMEWORK FOR ARBITRATION IN TANZANIA .................................... 25
4.0 INTRODUCTION ................................................................................................ 25
4.1 ARBITRATION ACT (CAP. 15) .......................................................................... 25
4.1.1 Applicability .................................................................................................. 26
4.1.2 Reference to arbitration ................................................................................ 26
4.1.3 Powers of an arbitrator ................................................................................. 27
4.1.4 Effect of arbitration agreement ..................................................................... 27
4.1.5 Court powers in support of arbitral proceedings ........................................... 30
4.1.6 Extension of time for commencement of arbitration ..................................... 31
4.1.7 Appointment of an arbitrator or umpire......................................................... 33
4.1.8 Removal of arbitrator.................................................................................... 33
4.1.9 Procedural and evidential matters ................................................................ 34
4.1.10 Powers of the Arbitrator or Umpire ............................................................. 34
4.1.11 Confidentiality ............................................................................................ 35
4.1.12 The arbitral award ...................................................................................... 35
4.1.13 Challenging an award ................................................................................ 37
4.1.14 Recognition and enforcement of domestic award ...................................... 39
4.1.15 Enforcement of Foreign Arbitral Awards .................................................... 40
4.2 ARBITRATION UNDER THE CIVIL PROCEDURE CODE ................................ 42
4.2.1 Arbitration by order of Court ......................................................................... 42
4.2.2 Agreement to refer to the arbitration ............................................................ 44
4.2.3 Arbitration without the intervention of court .................................................. 44
4.3 COMPARING ARBITRATION UNDER THE ARBITRATION ACT AND CPC .... 44
4.4 ARBITRATION UNDER THE NATIONAL CONSTRUCTION COUNCIL ............ 45
4.4.1 Scope of application ..................................................................................... 46
4.4.2 General principles ........................................................................................ 46
4.4.3 Jurisdiction and powers of the arbitrator ...................................................... 47
George Mandepo Reg. 200957963
vii
4.4.4 Arbitration costs ........................................................................................... 48 4.4.5 Procedures for enforcement and challenging an award ............................... 48
4.5 ARBITRATION UNDER THE PUBLIC PROCUREMENT .................................. 48
CHAPTER FIVE ....................................................................................................... 51
INSTITUTIONAL CHALLENGES FACING ARBITRATION IN TANZANIA ............... 51
5.0 INTRODUCTION ................................................................................................ 51
5.1 ARBITRATION INSTITUTIONS ......................................................................... 51
5.1.1 Arbitration in Commercial Courts of Tanzania .............................................. 52
5.1.2 Arbitration under NCC .................................................................................. 52
5.1.3 Tanzania Institute of Arbitrators ................................................................... 53
5.1.4 Arbitration Professionals .............................................................................. 54
CHAPTER SIX ......................................................................................................... 55
FINDINGS, CONCLUSION AND RECOMMENDATIONS........................................ 55
6.1 FINDINGS AND CONCLUSION ......................................................................... 55
6.2 RECOMMENDATION ........................................................................................ 57
BIBLIOGRAPHY ...................................................................................................... 58
George Mandepo Reg. 200957963
viii
ABBREVIATIONS
A.C - Appeals Cases
ADR - Alternative Dispute Resolution
ALL MR - All Maharashtra Law Reporter
BLR - Building Law Reports
CA - Court of Appeal
Cap. - Chapter
CPC - Civil Procedure Code
DRB - Dispute Resolution Board
EWHC - High Court of England and Wales
G.N - Government Notice
GCC - General Conditions of Contract
HGCRA - Housing Grants Construction and Regeneration Act
ICE - Institution of Civil Engineers
ICSID - International Centre for Settlement of Investment Disputes
JCT - Joint Contract Tribunal
K.B - Kings Bench
Lloyd’s Rep - Lloyd Law Reports
NCC - National Construction Council
PPRA - Public Procurement Regulatory Authority
R.E - Revised Edition
R.I.B.A. - Royal Institute of British Architects
SCC - Special Conditions of Contract
SLT/S.L.T - Scots Law Times
TCC - Technology and Construction
TIA - Tanzania Institute of Arbitrators
George Mandepo Reg. 200957963
ix
TLR - Tanzania Law Reports
UK - United Kingdom
UNICITRAL - United Nations Commission on International Trade Law
WLR - Weekly Law Reports
George Mandepo Reg. 200957963
x
TABLE OF CASES
AMEC Civil Engineering Ltd v The Secretary of State for Transport [2005] 1 WLR 2339
Azov Shipping Co. v Baltic Shipping Co. 2 Lloyd’s Rep. (1999)159
Bilta (UK) Ltd v Nazir [2010] EWHC 1086 (Ch)
Biwater Gauff (Tanzania) Ltd. V. United Republic of Tanzania ICSID Case No. ARB/05/22
Construction Engineers and Builders Ltd V. Sugar Development Corporation (1983) TLR 13 (CA)
Crow Estate Commissioner v Mowlew (1994) 70 B.L.R 1
Earl of Malmesbury v Strutt and Parker [2008] EWHC 424 (QB)
Edmund Nuttall Ltd v R.G. Carter Ltd [2002] EWHC 400 (TCC)
Farrans (Construction) Ltd. -v- Dunfermline District Council, 1991 SLT 365
Fastrack Contractors Ltd v Morrison Construction Ltd & Imreglio UK Ltd [2000] 1 BLR 168
Ford's Hotel Co Ltd v Bartlett [1896] AC 1
Halki Shipping Corporation v. Sopex Oils Ltd [1998] 1 Lloyd’s Rep. 465 (CA)
Halsey v Milton Keys NHS Trust [2004] EWCA (Civ) 576
Hamlyn & Co. v Talisker Distillery (1894) 21 R (H.L.) 21 at 27
Heyman v Darwins Ltd [1942] A.C. 356
John G. McGregor (Contractors) Limited -v- Grampian Regional Council 1988 S.L.T. 466
Patel v Patel [1999] BLR 227
Robert Lawrence Co. v. Devonshire Fabrics, Inc, 271 F.2d 402, 411 (C. A. 2d Cir. 1959)
RS Jiwani v Ircon International Ltd 2010(1) ALL MR 605 (F.B.)
SAB Miller Africa v East African Breweries [2010] 1 Lloyd's Rep. 392
SAB Miller Africa v East African Breweries [2010] EWCA Civ 1564
Sanderson v Armour & Company 1922 S.C. (H.L.) 117 at 126
Smith v. Martin [1925] 1 K.B 754
Tanzania Cotton Marketing Board v Cogecot Cotton Company SA (1997) TLR 165
Tanzania Cotton Marketing Board vs Cogecot Cotton Company S.A, Civil App. No 60 of 1998) [2002] TZCA 4 (unreported)
Tanzania Motor Services Ltd and Others v Mehar Singh t/a Thaker Singh (Civil Appeal No. 115 of 2005) [2006] TZCA 5 (21 July 2006) (unreported)
George Mandepo Reg. 200957963
xi
LIST OF STATUTES
Tanzania
1. Appellate Jurisdiction Act, 1979 (Cap 141 RE 2002)
2. Arbitration Act, 1931 (Cap 15 RE 2002)
3. Arbitration Rules 1957 (G.N. No.427)
4. Civil Procedures Code (Cap. 33 of R.E 2002)
5. Disposal of Public assets by Tender) (GN NO. 97/2005)
6. Employment and Labour Relations Act, No. 6 of 2004
7. Government Proceedings Act, 1967 (Cap. 5 RE 2002)
8. High Court Registries (Amendment) Rules, 1999
9. Judicature and Application of Laws, Cap. 358
10. Law of Evidence Act 1967 (Cap. 6 R.E 2002)
11. Law of Limitation Act, 1971 (Cap 89 RE 2002)
12. National Construction Arbitration Rules 2001 Edition
13. Public procurement (Goods, Works, Non-consultant services and
14. Public Procurement Act No. 21 of 2004
15. Tanganyika Order In Council, 1920
Other countries
1. Arbitration and Conciliation Act, 2000 (Uganda)
2. Arbitration (Scotland) Act 2010 asp 1 (Scotland)
3. Arbitration Act No. 4 of 1995 (Kenya)
4. Arbitration Act, 1996 (England & Wales)
5. Arbitration and Conciliation Act, 1996 (India)
6. Housing Grants, Construction and Regeneration Act 1996 (UK)
7. Indian Arbitration Act 1899(India)
George Mandepo Reg. 200957963
xii
International Conventions
1. The Convention on the Settlement of Investment Dispute between States and
Nationals of Others States, 1965
2. The Geneva Convention on the Execution of Foreign Arbitral Awards, 1927
3. The Geneva Protocol of Arbitration Clauses, 1923
4. The New York Convention on the Recognition and Enforcement of the Foreign
Arbitral Awards, as adopted by the United Nations Conference on International
Trade Law on 21 June 1985 (as amended in June 2006).1958.
5. UNICITRAL Model law on International Commercial Arbitration as adopted by
the United Nations Commission of the International Trade Law on 21 June 1985
(as amended in June 2006)
George Mandepo Reg. 200957963
Page | 1
CHAPTER ONE
INTRODUCTION TO RESEARCH
1.0 BACKGROUND
The construction industry worldwide is dispute-prone due to the complex and
fragmented nature of the industry and the adversarial relationships that traditionally
exist between project participants. In construction, dispute often arise when parties
to a contract cannot agree on the interpretation and implementation of contractual
clauses during execution of contract (Oladapo and Onabanjo, 2009).
According to Murdoch and Hughes (2008), disputes if not dealt with swiftly and
equitably, can ruin the success of the project objectives. Disputes can consume
many resources which could otherwise be used in a more productive manner and
they can lead into poor performance of construction project (Cheung and Yiu, 2007;
Elis and Baiden, 2008).
In today’s complex construction projects, resolving dispute has become an inevitable
part of a project manager's work (Cheung, 1999). The use of Alternative Dispute
Resolution (ADR) techniques has gained great momentum during recent years in
various common law jurisdictions as part of managing construction disputes. These
alternative methods embody a range of processes, the most common of which are
mediation, arbitration and adjudication.
In order to promote and encourage the use of ADR, there have been several legal
and institutional reforms in various countries to make the techniques user-friendly.
For instance in the UK, besides its Arbitration Act, 1996 (for England and Wales),
following the recommendations of The Latham Report1, the Government enacted the
Housing Grants, Construction and Regeneration Act 1996 (HGCRA) to formalise
adjudication in construction contracts by giving parties to the contract a right to refer
the dispute to adjudication based on the procedures set out under the Act as a
matter of the parties’ right2.
HGCRA culminated in the review of the standard forms construction contracts such
as JTC to incorporate statutory requirements for the adjudication process whose
1 The Latham Report, “Constructing the Team” 1994.
2 See section 108 of HGCRA.
George Mandepo Reg. 200957963
Page | 2
decision is binding upon the parties until the dispute if finally resolved through
arbitration or litigation3. Further, to the HGCRA, the UK government introduced the
Civil Procedure Rules, 1999 based on the Lord Woolf Reforms to transform the Civil
Justice landscape in England and Wales in order to improve access to justice4. The
reform encourages the early settlement of disputes through a combination of pre-
action protocols, active case management by the courts, and cost penalties for
parties who unreasonably refused to attempt negotiation or consider ADR5.
In Scotland where the use of mediation is patchy, the Scottish Parliament passed the
Arbitration (Scotland) Act 2010 to regulate arbitration proceedings. The new Act
reforms and codifies the Scots law of arbitration, which was mainly based on
common law and precedents6. At the international level, the reforms involve
modernization of arbitration procedures in order to promote international trade by
making the arbitration process more effective and quicker method of dispute
resolution as alternative to litigation. Through international instrument such as
UNICITARL Model law, various countries of the world have harmonized their national
arbitration procedures to standardize their arbitration systems in compliance with the
international requirements.
1.2 PROBLEM STATEMENT
Effective implementation of any dispute resolution approach mainly depends on the
legal framework of a particular country where it is subjected. Apart from having the
law to govern the procedures of allowing the parties to access justice machineries to
assert their rights, the institutional framework also plays a great role in considering
what the system can deliver to its stakeholders.
In most developing countries of which Tanzania is, ADR techniques such as
mediation and adjudication are not very familiar in use for the resolving of
construction disputes. However, in Tanzania, arbitration is one of ADR technique
that has been legally recognised since the colonial time. The statutory regulation of
law relating to arbitration in Tanzania is contained in Arbitration Act Cap.15 of R.E
2002.
3 Section 108(3).
4 See. Access to Justice Final Report, by The Right Honourable the Lord Woolf, Master of the Rolls,
July 1996, Final Report to the Lord Chancellor on the civil justice system in England and Wales. 5 See Halsey v Milton Keys NHS Trust [2004] EWCA (Civ) 576 and Earl of Malmesbury v Strutt and
Parker [2008] EWHC 424 (QB). 6 Came into force on 7
th June 2010.
George Mandepo Reg. 200957963
Page | 3
Apart from the arbitration Act, the Civil Procedure Code for Tanzania7 provides also
for arbitration under the supervision of the court. The Code was amended in 19948
to incorporate court annexed ADR wherein the Courts were empowered to
encourage early settlement of disputes through use of ADR mechanisms including
arbitration, negotiations and mediation procedures. Arbitration is also recognised
through industrial law under the Employment and Labour Relations Act9 which
regulates conciliation, arbitration an adjudication of labour disputes.
Despite the presence of the legislative framework to govern settlement of disputes
through arbitration, there is still an issue to be raised as to how the existing legal
framework is effective in facilitating disputes resolution. This study is designed to
examine and reveal the effectiveness of the system from evidence on the ground.
1.3 AIM AND PURPOSE
The main aim of this study is to examine the current legal and institutional
frameworks for the arbitration in Tanzania in order to determine their adequacy and
effectiveness in facilitating resolution of construction disputes.
1.4 RATIONALE AND OBJECTIVE
For over a decade, the use of arbitration as a method of dispute settlement has been
established as a part of the world agenda to promote trade and commerce. As
pointed out by Murdoch and Hughes (2008),arbitration is one form of dispute
settlement which is mostly under the control of the parties. However, if a party to the
dispute wishes to take the matter to arbitration or further to a court of law, he will be
bound to comply with certain set procedures under the arbitration agreement or
governing legislation.
The resolution of disputes in the construction industry must of necessity be within the
legal framework of national legislation and applicable international protocol and
conventions (Oladapo and Onabanjo, 2009). However, it is important that the law
should be clear and certain in both procedures and substantive issues. Therefore,
the main objective of the study is to determine the effectiveness of the arbitration
system in Tanzania in resolution of construction disputes.
7 Cap. 33 of R.E, 2002
8 Government Notice No. 422 of 1994
9 NO. 6 of 2004
George Mandepo Reg. 200957963
Page | 4
1.5 SIGNIFICANCE OF THE STUDY
The past practices of arbitration as an informal and non-judicial process has received
great challenge through on-going legal reforms taking place all over the world with
the view to institutionalise the arbitration system. Though arbitration is not the only
form of dispute settlement amongst ADR techniques, it is widely acceptable as a
consensual, cost effective and binding method of resolving contract disputes with
fewer procedures and techniques compared to the cumbersome court processes.
Given all its inherent problems, the reforms of arbitration procedures through
governing laws is expected to make arbitration a more effective way of resolving
disputes in the construction industry. The basic area of concern is to identify and
examine any potential gaps or weaknesses in the existing legal and institutional
frameworks for resolving construction disputes in Tanzania through arbitration and
thereby to suggest appropriate recommendations which will yield improvement of the
arbitration system in order to ensure effectiveness in disputes resolution.
1.6 LITERATURE REVIEW
Although several researchers have established various problems facing construction
industry including disputes and their resolution techniques, there is no any literature
existing in respect to the arbitration of construction disputes in the Tanzania.
Samson (1992) discusses the views, difficulties and considerations of African
governments and African lawyers in dealing with international commercial arbitration
and their search for new universally applicable principles and rules. He argues that
the challenge in Africa with regard to the evolution of the international arbitral
process would appear unique and time and need revision to accommodate new
developments and enable Africa to comply with the rapid expansion of international
commercial arbitration.
The author urges the African States to establish regional arbitration centres in a
single formulating approach to service arbitration in Africa, in line with international
legal instruments such UNCITRAL Model Law. Although the whole study does not
relate to Tanzania, it covers various African countries having ineffective arbitration
laws including Tanzania.
George Mandepo Reg. 200957963
Page | 5
Chau (2007) explains various issues relating to arbitration in practice with particular
reference to the Hong Kong construction industry. The author describes the
importance of arbitration in its traditional nature as an informal, fair, and non-
adversarial way of resolving disputes. However, Chau (2007) challenges modern
arbitration in respect of the use of litigation techniques including involvement of
trained lawyers, who sometimes are not interested in assisting the parties to reach to
an amicable solution to the extent of making the arbitration an excessively
complicated process. The author concludes that although the modern arbitration
process appears to be adversarial in the form of procedures, it can still be used
alongside other forms of ADR techniques in resolving construction disputes. Despite
the fact that this work was meant for the Hong Kong construction industry, it
represents a substantial input and justification for the reform of arbitration to
accommodate modern techniques.
Andrew (2005) examines and discusses the merits and popularity of both
adjudication and arbitration processes as it has been in use in the UK construction
Industry. His work elaborates the historical background of arbitration from medieval
times and its development in European international trade and commerce.
The author makes an account of the use of arbitration in Scotland as evidenced from
domestic arbitration case law dating back at least to 1207. Though the author
considers the possibility of arbitration declining following adoption of statutory
adjudication, through HGRCA 1996, he admits the reforms in arbitration procedures
will eradicate its main problems and accommodate its use as an effective form of
dispute resolution in the construction industry parallel with the adjudication process.
This study is important, as it provides a clear background of arbitration and
elaborates its benefits despite the rise of other forms of ADR such as adjudication.
Further, the study is helpful in considering various important issues pertaining to the
review of the arbitration system in Tanzania in line with reforms taking place in other
countries.
Smith (2004) critically analyses the problems of disputes in the construction industry
and the relationship between arbitration and adjudication as two forms of disputes
recognised in the Scottish construction industry. The work is mainly concerned with
the Arbitration (Scotland Bill) which is now the Arbitration (Scotland) Act 2010.
Comparing the two forms of dispute resolution, the author is of the view that the
George Mandepo Reg. 200957963
Page | 6
adjudication is a rough and ready process that is unsuitable for certain types of
dispute,. The process provides no means of appeal, therefore, the courts have no
option but to enforce decisions even when they are clearly wrong. The author
comments that the new arbitration Act for Scotland will provide a viable alternative to
adjudication especially in dealing with complex cases while providing the arbitrator
with the power to control the process. Like other previous studies, this study though
is not relevant to Tanzania it contains very useful information to show experience of
the use and benefits of the modern arbitration.
Daele (2010) reports on the current system of arbitration in Tanzania, the work
highlights among others, the legal framework and arbitral institutions; the constitution
of the arbitral tribunal, its jurisdiction, arbitral proceedings, awards, on what grounds
an award could be challenged, and recognition and enforcement of awards. The
study tries to review the arbitration system in Tanzania by identifying some
shortcomings in the existing legislation. However, the review is not sufficiently
exhaustive to cover a detailed comparative analysis of the current arbitration system
in practice vis-à-vis other jurisdictions. Also, as the purposes of this work was to
identify the arbitration landscape in Tanzania, it lacks a thorough analysis of all
issues pertaining to the actual practice of arbitration including case laws which will
be examined in this study.
1.7 HYPOTHESES
This study has been written based on the following proposed assumptions, namely:-
(i) The legal and institutional frameworks for Tanzanian arbitration are not
sufficiently effective to promote resolution of construction disputes;
(ii) The existing arbitration laws are too out-dated to accommodate
modern arbitration techniques; and
(iii) Parties to construction disputes cannot resolve their disputes without
delay and unnecessary costs.
1.8 RESEARCH METHODOLOGY
In order to achieve the aim, the author gathered and analysed data from the
following sources:
Relevant previous academic literature
Relevant case laws and statutes relating to the topic
George Mandepo Reg. 200957963
Page | 7
Technical and academic journals and text books
The internet, Westlaw and Lexis Library websites
Reports from government and other bodies
Materials/ Course Handouts on the subject
The author adopted a qualitative methodology involving a comprehensive literature
review and analysis of gathered information to present the work. The study may by
no means be exhaustive due to the words, time and monetary restraints to undertake
an extensive and detailed field survey. It is merely designed to present some ideas
for the contraction industry in order to improve the existing arbitration system in
Tanzania.
1.9 ORGANISANISATION OF STUDY
This study is organised into six chapters.
Chapter One covers an introduction to the research. It deals with the background,
aim, objective and rationale of the research. It also explains the methodology used,
and literature review. Chapter Two provides for an examination of root causes and
effects of the disputes on construction projects based on various literatures. It also
gives an overview of various dispute resolution techniques commonly used in the
construction industry.
Chapter Three discusses arbitration in practice by highlighting its contextual legal
meaning, advantages and disadvantages and the governing principles of the
method. Chapter Four examines the legislative framework and arbitration institutions
in Tanzania in order to establish their effectiveness in facilitating resolution of
construction disputes. Chapter Five discusses challenges on arbitration the
institutional framework in Tanzania and Chapter Six provides for the findings,
conclusion and recommendations of the study.
George Mandepo Reg. 200957963
Page | 8
CHAPTER TWO
CONSTRUCTION DISPUTES AND RESOLUTION TECHINIQUES
2.0 INTRODUCTION
This chapter examines root-causes and effects of disputes on construction projects
based on the literature. It also gives an overview of various dispute resolutions
techniques which are commonly used in the industry. Due to the word limitation,
detailed examination will only be done on arbitration.
2.1 CONSTRUCTION DISPUTES
Disputes between parties to construction contracts have become an inherent feature
of the construction industry. They may arise in projects due to the number of factors
which are within and outside the control of the parties. As argued by Cheung et al.
(2000), disputes are a common occurrence in construction and their resolution is
now among routine management functions of the project actors. There has been
considerable research undertaken that has sought to determine the causes of
disputes (Love, et al., 2008).
2.1.1 Dispute Defined
A review of the literature reveals that the term “dispute” has no fixed or definite
meaning. There are a number of literatures that try to define what constitutes a
dispute in the construction industry and the word has been used interchangeably or
in pair with the term “conflict” (Love et al., 2008).
The study by Langford et al., (1996) reveals that a dispute is one of the effects of
conflicts. In the work, the authors defined ‘disputes’ as events which resulted in
some form of formal contractual notice and which could be resolved by the
recognisable contractual resolution process whereas a conflict cannot be resolved by
contractual means without becoming a dispute. They suggest that a conflict could
mutate into a dispute if its severity escalated.
Love et al.,(2008) have adopted the legal meaning of dispute from the principle
derived in the case of Halki Shipping Corporation v Sopex Oils Ltd10, in which the
court held that a dispute does not exist until a claim or request for compensation for
George Mandepo Reg. 200957963
Page | 9
damages incurred by any party to the contract has been submitted and rejected by
the other. From a contextual point of view, disputes can arise because of
disagreement, misunderstanding, poor relationships or escalated conflicts between
the parties. Disputes arise not just because people enter into contracts but because
of a wide variety of interactions between diverse people and the failure of one party
to the contract to keep their promise (Murdoch and Hughes, 2008).
2.1.2 Cause of Disputes
It is a matter of fact that at the time of entering into a contract, parties are often
motivated by different objectives, which guide the entire construction process. As
pointed out by Sir John Egan in the “Rethink Construction, 1998”, clients need better
value from their projects and their main objective normally is to see that the project
is be delivered on time, within budget and to the standards of quality expected.
However, on the other hand, construction companies need reasonable profits to
assure their long-term future the success of the project. In construction, disputes
may arise due to the failure to achieve the perceived objectives by each of the
parties to the contract.
In addition, disputes can arise because of the failure of one party to the contract to
perform his/her obligation(s) or seeking to exploit the other party (Murdoch and
Hughes, 2008). Disputes in construction contracts are generally rooted in fact that
while the client on one hand usually aims to optimize quality and functionality at
minimum cost, the contractor on the other hand strives to satisfy the client and
achieve maximum profit at the same times using minimum resources (Howard et al.,
1997).
Levy (2007) identifies common causes of disputes in construction projects to include
poor or ineffective communication; inadequate finance to support the project; errors
in planning and coordination; problems with site conditions which occur during
contract execution; unforeseen events beyond the contemplation of the parties;
increase in scope of works or variations; breach of contracts and disruption or delays
ending up in costs overruns.
Sharing the similar views, Yates (2003); Walton (2005), Hall (2002) and Langford et
al., (1996) identify the cause of construction disputes to include unfair allocation of
risks; multiple contracts; unrealistic expectations and schedules; poorly drafted or
George Mandepo Reg. 200957963
Page | 10
inadequate contract documents; design omissions, tighter funding; the lack of
experienced personnel, communication problems; complexity of construction
projects; poor choice of the method of procurement; and failure to identify and deal
timely and properly with problems when they arise.
Generally, the root cause of disputes can well be described as the failure of one
party to the contract to honour his/her obligation which in the legal context is
considered as the breach of the contract giving an affected party a right to redress.
As such, disputes in the construction project can occur at any time of the project’s
life. Therefore, in anticipating that disputes may arise, most of the modern standard
form construction contracts contain provisions on how disputes should be dealt with.
2.1.3 Effects of Disputes in Construction
Like any other business transactions, the achievements of the objectives in the
construction project invariably depend upon a good relationship between the parties.
Therefore, when a dispute arises at any point in the execution of the project it can
ruin both the objectives and the relationship between the parties to the project
(Murdoch and Hughes, 2008).
Disputes in construction are detrimental and if not properly managed, they may
cause project delays, undermine team spirit, increase project costs, and, above all,
damage continuing business relationships (Cheung et al., 2002).
Wahi (2008) has attempted to review various literatures regarding the effect of
disputes in the construction industry. The summary from the study suggest that there
are several effects of construction disputes ranging from contractual to social
relationships. Among identified effects, include increase in project costs because of
project overruns or litigation; deterioration of the quality of product to be delivered;
loss of productivity due to untimely utilization of labour, equipment and other
resources at site; reduction in investment profits and loss of trust among parties to
the dispute.
2.2 DISPUTE RESOLUTION METHODS
Cheung and Wing (2006) point out that dispute form part of the portfolio of
engineering managers and that, managing construction disputes is akin to conflict
resolution. Once a dispute occurs, it requires resolution approach which addresses
the problem between the parties for the betterment of the project.
George Mandepo Reg. 200957963
Page | 11
Epling (1987) adds that in the hope of avoiding the long delays, skyrocketing costs
and expenses, enormous legal fees, and other disadvantages attendant upon court
adjudication, the parties to construction contracts look to substitute for quicker,
easier, less costly determination of claims and disputes. In today’s world, there are
several methods of dispute resolution techniques ranging from litigation to
consensual or mutual agreement between the parties. The recognised form of
dispute resolution in the construction industry apart form litigation include,
adjudication, negotiations, conciliation, mediation, private enquiry, mini-trial, Dispute
Resolution Board (DRB) and arbitration.
The following are the main factors which can influence disputants in the selection of
resolution methods:
(i) how fast to get the dispute resolved;
(ii) need to preserve commercial relationships;
(iii) cost effectiveness (fee for tribunal/lawyers etc ) ;
(iv) quality of decision in terms of reaching the expected results;
(v) recoverability of expenses incurred;
(vi) privacy of the procedure;
(vii) finding a creative solution to suit all parties; and
(viii) finality of decision (without further possible challenges or appeals).
It is worth noting that the dispute resolution method whether is based on consensual
or adversarial approach, has several of its requirements in both procedural and
substantive matters. In addition, each resolution method has both advantages and
disadvantages.
Despite the fact that there are several dispute resolution techniques, in most of sub-
Sahara African countries like Tanzania, the only popular methods in use for
settlement of construction disputes are adjudication and arbitration. It is not the
intention of this study to cover much on the other forms of dispute settlement apart
from arbitration which is now gaining popularity for use in construction industry in
various developing countries, including Tanzania.
George Mandepo Reg. 200957963
Page | 12
Although adjudication is a dispute resolution method which recognised within
Tanzanian construction industry and can be found in most of the public procurement
construction contracts, its applicability is not well preferred as compared to the UK
whereby the method is legally recognised through HGCRA, 1996 upon extensive
research to determine its efficacy and adequacy in the resolving of construction
disputes. Therefore, the author finds that as it was in the UK before the enactment
of the HGCRA, there is a need for a separate and in-depth study on adjudication for
Tanzania which cannot be addressed well in this work due to the limitation factors
indicated under paragraph 1.8 above.
George Mandepo Reg. 200957963
Page | 13
CHAPTER THREE
ARBITRATION IN PRACTICE
3.0 INTRODUCTION
Arbitration was originally devised as an alternative to litigation but is prone to many
of the problems that beset litigation (Murdoch and Hughes, 2008). However, the
method is still accepted worldwide as one of the best forms of dispute settlement and
thus there are several reforms in various jurisdictions to make the method more
user-friendly by eliminating some of its shortcomings. This chapter discusses
arbitration in practice by highlighting its contextual legal meaning, advantages and
disadvantages and the governing principles of the method.
3.1 ARBITRATION DEFINED
Commenting on UK arbitration, Uff (2009) argues that there is no agreed definition of
the word “arbitration”. However, for its popular usage in commercial disputes, the
term “arbitration” denotes the placing of a dispute before a third party to obtain a fair
or equitable resolution based on discretion rather than on fixed rules.
Arbitration as a form of ADR is a voluntary process based on the agreement
between the parties who wish to resolve their dispute outside the court by referring
the same to the tribunal or person of their choice for making a decision that is legally
binding for both sides.
3.2 HISTORICAL PERSPECTIVE
Arbitration as a dispute resolution technique has been in use since time immemorial
(Andrew, 2005). The use of the arbitration in private disputes started to be
sanctioned through law by various states as an alternative to what was perceived to
be shortcomings of litigation, with its concomitant escalation in costs, delays and
adversarial relationship (Oladapo and Onabanjo, 2009). In recent years, the use of
arbitration in the construction industry, has been preferred through incorporation of
procedures in the standard form contracts as a voluntary approach by the parties to
arbitrate in case a dispute arises which they cannot resolve by their own initiatives.
Smith (2004) describes arbitration as a dispute settlement approach which has its
foundation in medieval times. It is a procedure for resolving disputes whereby the
George Mandepo Reg. 200957963
Page | 14
parties put their dispute to an independent person for a decision that is binding on
them. Smith refers also to the court’s position on arbitration including the decisions of
Lord Watson on the origin of arbitration where it was held that ‘The law has, from the
earliest time, permitted private parties to exclude the merits of any dispute between
them from consideration of the court by simply naming their Arbiter’11. As regards
enforceability of the arbitration agreement, the courts have held that ‘If the Parties
have contracted to arbitrate, to arbitration they must go’12.
3.3 PRINCIPLES OF ARBITRATION
Arbitration as mechanism of dispute resolution is based on its founding principles
which intend at giving the parties autonomy to decide on the rules of the game while
maintaining fairness based on the relevant laws. The modern arbitration statutes
such as the English and Scottish Arbitration laws have attempted to incorporate the
principle expressly in the body of statutes. For instance, section 1 of the Arbitration
(Scotland) Act, provides for the principles as follows:-
(i) that the object of arbitration is to resolve disputes fairly, impartially and
without unnecessary delay or expense,
(ii) that parties should be free to agree how to resolve disputes subject only to
such safeguards as are necessary in the public interest,
(iii) that the court should not intervene in an arbitration except as provided by
the law for smooth and effective administration of the arbitration
proceedings.
The arbitration principles are covenants by the parties to the arbitration agreement
and provides for guidance to the tribunal or court in determining the matter between
the parties in order to ensure that the clear purposes of arbitration are not distorted.
3.4 ADVANTAGES AND DISADVANTAGES OF ARBITRATION
From its founding principles, arbitration being a creature of contract and a method
which can be fashioned by parties in many ways, has several major advantages to
offer in comparison with other disputes resolution techniques such as adjudication
and litigation. However, the method also has its own disadvantages that need to be
taken into account.
11
Hamlyn & Co. v Talisker Distillery (1894) 21 R (H.L.) 21 at 27. 12
Sanderson v Armour & Company 1922 S.C. (H.L.) 117 at 126.
George Mandepo Reg. 200957963
Page | 15
According to Smith (1998) and Mazirow (2008), among the advantages of arbitration,
include time and cost savings, convenient process to the parties, limited discovery
and smaller attorney's fees. The process is also faster than the court procedures
unless there are multiple parties. The parties are also free to choose a dispute
resolver according to their preference. The process is private, confidential and
usually final. It also provides easy way to enforce an international arbitral award in
another country as opposed to the decisions of the courts.
The perceived disadvantages of arbitration include very limited possibilities of appeal
even if the arbitrator makes a mistake of fact or law. In addition, the process lacks
precedents and often no explanation for the reasoning behind the award (Mazirow,
(2008). The other disadvantages is that, unless there is an agreement to the
contrary, it is impossible for the arbitrator to consolidate actions or dispute between
the same parties and also on the basis of privity, he cannot order the joinder of a
party who is not a signatory to the arbitration agreement (Sherwin,Vermal and
Figueira, 2007).
3.5 STARTING AN ARBITRATION
Murdoch and Hughes, (2008) submit that whereas there is normally an automatic
right to take a dispute to court, the right to go to the arbitration is by its nature more
restricted. There are three prerequisite conditions to be met before an arbitration
proceeding can be commenced. The conditions are as follows:-
(i) First, there must be a genuine dispute or difference between the parties
capable of being arbitrated and determined through an award by the
arbitrator which can be enforced as a judgment of the court.
(ii) Secondly, there must be a binding contractual agreement to arbitrate
which allows a party to such agreement to submit a dispute or difference
between them to arbitration by a chosen third party or one appointed in
accordance with their instruction. The agreement to arbitrate can be
made when the dispute has already arisen or can be provided from the
outset in the construction contract document.
(iii) Thirdly, there must be a submission or reference of a specific dispute to
the arbitrator or tribunal in accordance with the procedures set out in the
George Mandepo Reg. 200957963
Page | 16
arbitration agreement. The procedure mainly includes a “notice to refer
the dispute to arbitration”13.
The above prerequisite conditions for arbitration are important to make the arbitration
proceedings valid. Otherwise, a party who wishes not to go to arbitration may
challenge the proceedings.
3.5.1 Genuine dispute or difference
Reid and Ellis (2007) argue that it is a prerequisite on both adjudication and
arbitration that a dispute must exist before such proceedings can commence. If there
were no dispute, then an appointed adjudicator or arbitrator would have no
jurisdiction to decide the matters referred and any decision reached in the absence
of a valid appointment can result in challenge of enforcement of that decision due to
the lack of jurisdiction or breach of natural justice.
The question of whether or not there is a dispute that must be referred to arbitration
arises with great frequency in many different contracts and has produced a large
number of cases. Construing what the “dispute” means in arbitration or adjudication,
Reid and Ellis (2007) are of the views that there is no definitive meaning of the word
“dispute”. The authors reviewed the decision of Halki Shipping Corporation v. Sopex
Oils Ltd14 in which upon construction of section 9 of the English Arbitration Act 1996
and the arguments by the parties in respect to the application for stay of the
proceedings, the Court of Appeal held that there is a dispute once money is claimed
unless and until the defendants admit that the sum is due and payable.
Accordingly, Reid and Ellis (2007), submit that in determining whether a dispute
exists or not, it is necessary for the arbitrator or the court to take into account the
circumstances and facts existing in each particular case based on the common
sense approach and having cognisance of time-related issues i.e. what transpired
before the matter was referred to the arbitration or adjudication.
13
For example, clause 66C (1) of ICE 7 Standard form contract as amended in 2004, requires “a notice to refer” has to be served not later than 3 months after the decisions of an adjudicator. 14
[1998] 1 Lloyd’s Rep. 465 (CA).
George Mandepo Reg. 200957963
Page | 17
In Fastrack Contractors Ltd v Morrison Construction Ltd & Imreglio UK Ltd15, upon
considering various cases including that of Halki (supra), HHJ Thornton QC derived
the following principle at paragraph 27 to define the word “dispute”:
“A dispute can only arise once the subject-matter of the claim, issue or other
matter has been brought to the attention of the opposing party and that party
has had an opportunity of considering and admitting, modifying or rejecting the
claim or assertion”.
In another case of Edmund Nuttall Ltd v R.G. Carter Ltd16 His Honour Judge
Seymour QC considered that while a "dispute" can be about a "claim", there is rather
more to a "dispute" than simply a "claim" which has not been accepted. The decision
of this case suggests that for there to be a "dispute" there must have been an
opportunity for the protagonists to each consider the position adopted by the other
and to formulate arguments of a reasoned kind.
The current settled principle on what constitutes a dispute in both arbitration and
adjudication is derived from the decision of the Court of Appeal in the case of AMEC
Civil Engineering Ltd v The Secretary of State for Transport17. In the case the main
issue which the court was invited to consider is whether there was existence of a
‘dispute’ for the purposes of ICE (5th) Clause 66. In the case, the Court of Appeal
endorsed the decision of Jackson J at first instance in which the judge had the
following views under part 68 of the decisions:
“…1. The word ʺdisputeʺ which occurs in many arbitration clauses and also in
section 108 of the Housing Grants Act should be given its normal meaning. It
does not have some special or unusual meaning conferred upon it by lawyers.
“…3.The mere fact that one party (whom I shall call "the claimant") notifies the
other party (whom I shall call "the respondent") of a claim does not
automatically and immediately give rise to a dispute. It is clear, both as a
matter of language and from judicial decisions, that a dispute does not arise
unless and until it emerges that the claim is not admitted”.
15
[2000] 1 BLR 168. 16
[2002] EWHC 400 (TCC). 17
[2005] 1 WLR 2339.
George Mandepo Reg. 200957963
Page | 18
According to Jackson J, in order to determine whether there is a failure on part of the
defendant to admit the claim, it is upon the court to review and make an appropriate
conclusion based on the circumstances or facts of a particular case. It is interesting
to note that some of the modern arbitration statutes such as the Arbitration
(Scotland) Act 2010 provides for the clear definition of a “dispute” based on the
judicial findings. For instance, section 2 of the Act defined the word “disputes” as
follows:
“dispute” includes –
(a) any refusal to accept a claim, and
(b) any other deference (whether contractual or not)”.
3.5.2 Arbitration agreement
Application of arbitration in the construction industry and other areas of commercial
law is regarded as a consensual process for which a party cannot be forced to go to
arbitration unless he agrees to do so through an arbitration agreement.
The requirement for “arbitration agreement” can distinguish arbitration from the
adjudication process as applicable in the UK construction industry, in which the
adjudication is regarded as a statutory right irrespective of whether the contract so
provides (Uff, 2009). As it is required under the law of contracts, every arbitration
agreement needs to have an element of consent for the arbitration to have legal
force. Lack of consent can invalidate the arbitration process.
In Azov Shipping Co. v Baltic Shipping Co18, the court set aside an award on the
ground that the plaintiff never agreed to be bound by the underlying contract or the
arbitration agreement contained in it. As opposed to the normal agreements
recognised under law of contract regimes, various arbitration statutes such as the
English and Scottish Arbitration laws require the agreement to be in writing19.
Section 5(2) – (6) of the English Arbitration Act, 1996 is more elaborative and
constitutes “an agreement in writing” for validity of arbitration proceedings. Under the
provision, any writing or exchange of communications in respect to the arbitration
18
2 Lloyd’s Rep. (1999)159 19
See section 5 of the Arbitration Act 1996 (English) and section 4 of the Arbitration (Scotland) Act, 2010.
George Mandepo Reg. 200957963
Page | 19
can be deemed as evidence of an agreement, and need not be signed by the
parties.
3.5.3 Submission or reference of a specific dispute
Submission or reference of a dispute to the arbitration can be in any form. However,
it is important to note that this step is crucial, as it is an essential formal step without
which no dispute may be held to have occurred. For instance, Rule 1 of the Scottish
Arbitration Rules, 2010 provides that “An arbitration begins when a party to an
arbitration agreement (or any person claiming through or under such a party) gives
the other party notice submitting a dispute to arbitration in accordance with the
agreement”.
In the most usual way, unless otherwise specified, reference to the arbitration is
deemed to be to a single arbitrator who is either named in the arbitration agreement
or selected/appointed thereafter by the nomination or appointment body (Uff, 2009).
Most of the arbitration legislation requires the parties to agree on the appointment of
the arbitrator in advance or prior to the occurrence of a dispute. If the Arbitrator is not
named in the contract, the nominating body will select and send a list of arbitrators
from whom the parties will choose their arbitrator in accordance to their preference.
Normally arbitrators are required to be individuals with extensive experience in
alternative dispute resolution apart from their professional background.
3.6 SEVERABILITY OF ARBITRATION AGREEMENT
Generally, an arbitration agreement is not distinguished from the main contract
between the parties and is always governed by the law that governs the main
contract (Uff, 2009). Although the arbitration agreement can be incorporated in the
main agreement, it is considered separate and independent from the main contract.
An arbitration agreement is not void, voidable or otherwise unenforceable only
because the agreement of which it forms part is void, voidable or otherwise
unenforceable20.
The analytical rationale of severability or separability doctrine is to accord with the
original intention of the parties to the arbitration agreement whereby mutual promises
to arbitrate would form the quid pro quo of one another and constitute a separable
20
See for instance Section 5 of Arbitration (Scotland) Act.
George Mandepo Reg. 200957963
Page | 20
and enforceable part of the agreement21. In arbitration proceedings, under the
principle of severability, the matter submitted to arbitration can be separated from
one not submitted, the court may set aside that part of the arbitral award alone which
is not submitted to arbitration.
In RS Jiwani v Ircon International Ltd22 a full bench of the High Court of Bombay held
that an arbitration award is severable and if a part of it is illegal and incapable of
enforcement the other part that is valid and legal can still be enforced. In that case,
the court was invited to decide on whether the Court could set aside an award
partially under Section 34 of the Arbitration and Conciliation Act, 1996 of India. The
court held that once an award attains finality and vests a legal right in one of the
parties, it would be unjust to deny such a party the vested right on the grounds that
other portions of the award are invalid.
3.7 APPLICABLE LAW AND SEAT OF THE ARBITRATION
Most of jurisdictions recognize and put a mandatory requirement for the applicability
of a particular law to the arbitration agreement and also for the geographical and
legal jurisdiction to which the arbitration is tied. For example, section 6 of the
Arbitration (Scotland Act) 2010 provides that where the parties to an arbitration
agreement agree that an arbitration is to be seated in Scotland, but the agreement
does not specify the governing law, that unless the parties otherwise agree, the
arbitration will be governed by Scots law.
It is important to note that the governing law and seat normally determine the
procedural rules of arbitration to be followed, and the courts which will exercise
jurisdiction in the matter.
3.8 DUTIES AND POWERS OF ARBITRAL TRIBUNAL
Though there is great flexibility in arbitration, the arbitrator or arbitral tribunal is
required to act in accordance with the agreement of the parties and the law. The
tribunal is bound to observe principles governing administration of justice as it is for
the courts of law. Subject to the agreement by the parties and applicable law, among
the duties of the arbitral tribunals are-
21
See Robert Lawrence Co. v. Devonshire Fabrics, Inc, 271 F.2d 402, 411 (C. A. 2d Cir. 1959) 22 2010(1) ALL MR 605 (F.B.)
George Mandepo Reg. 200957963
Page | 21
(i) to act fairly and impartially as between the parties, giving each party a
reasonable opportunity to present and defend the case;
(ii) to ensure that the adopted procedures to deal with the case do not
cause unnecessary delays or expenses to the parties; and
(iii) to decide all evidential matter, including whether to apply the strict rules
of evidence as to the admissibility, relevance or weight of any materials
on any matters of fact or opinion.
Although the arbitration is considered as a flexible method in which an arbitrator can
have wider powers, in some countries, the arbitrator has limited jurisdiction in
determining some issues in the disputes. In the UK, it was formerly the case that an
arbitrator did not have power to decide whether or not the contract is void23 or if his
jurisdiction is challenged, whether or not he himself has jurisdiction upon any
question24. These points were reserved to the exclusive determination of the courts.
Section 30 of the English Arbitration Act 1996 has altered the position whereby,
unless parties agree otherwise, the arbitrator may have jurisdiction to decide on the
validity of the arbitration agreement, proper constitution of the tribunal and legality of
reference to the arbitration.
Accordingly, pursuant to Section 31 of the Act a party who wishes to challenge the
jurisdiction of the arbitrator must do so at the outset, before taking any step to
answer the case on merit (Murdoch and Hughes, 2008).In Scotland, among powers
vested to the arbitrator under the Scottish Arbitration Rules, 2010 is to decide the
dispute in accordance with the law chosen by the parties as applicable to the dispute
and not on the basis of general considerations of justice, fairness or equality, unless
such matters form part of the law chosen by the parties or an agreement of the
parties25.
In reaching its decision, the tribunal has to take into account among other factors,
the provisions of contract relating to the dispute, normal trade or commercial
customs or practices and other matters which the parties have agreed26. As for the
23
See Heyman v. Darwins Ltd [1942] A.C. 356 24
Smith v. Martin [1925] 1 K.B 754 25
Rule 47 (1) and (2). 26
Rule 47(3).
George Mandepo Reg. 200957963
Page | 22
orders which the arbitral tribunal can issue in Scotland pursuant to Rules 48-47,
include the following:-
(i) order as to the payment of damages;
(ii) declaratory or injunctive orders;
(iii) order of rectification or reduction of any deed or document other than a
decree of court; and
(iv) order of interest to be paid in whole or in part of any amount
claimed in respect of any period up to the date of award and or up
to the date of payment.
The arbitral tribunal power to award interest as provided for in the Arbitration
(Scotland) Act, has altered a common law position as it was considered in the case
of Farrans (Construction) Ltd. -v- Dunfermline District Council27 in which it was a
matter for the parties to the arbitration agreement to ensure that any issue relating to
interest is put before the arbiter for his decision. Otherwise, as it was also held in
John G. McGregor (Contractors) Limited -v- Grampian Regional Council28, the arbiter
could not have any implied power at common law to award interest before the date
of his final decree.
3.9 ENFORCEMENT OF AWARD
As noted before, the main advantage of arbitration as opposed to other forms of
ADR is that the decision of the arbitral tribunal is final and binding on the parties and
any person claiming through or under them (except a third party)29. Either of the
parties to the arbitral award can apply to the Court for enforcement of the decision of
the arbitrator as if it were a judgment or order of the court. In some countries,
enforcement of either domestic or foreign arbitral awards is made through bringing
an action to the court of competent jurisdiction, though approaches may differ from
country to country. However, most of the common law countries have adopted
quicker mechanisms, in the form of summary enforcements.
27
1988 S.L.T. 466. 28
1991 SLT 365 29
See also section 11 of Arbitration (Scotland) Act.
George Mandepo Reg. 200957963
Page | 23
Under the Arbitration (Scotland) Act, the arbitral award may be enforced as if it is an
extract registered decree bearing a warrant for the execution granted by the court30.
Under section 66 of the English Arbitration Act, a party wishing to enforce the award
has to seek leave of the court so as a judgment may be entered in terms of such an
award. Further, the Act provides that leave to enforce an award shall not be given
where, or to the extent that, the person against whom it is sought to be enforced
shows that the tribunal lacked substantive jurisdiction to make the award.
3.10 CHALLENGING AN AWARD
The finality of the award does not affect the right of a person to challenge the award
by any available arbitral process including appeal or review to the competent court of
law on jurisdictional or procedural grounds or on the basis of an error of law31. Under
the English Arbitration Act, 1996, an arbitration award is incapable of direct
enforcement by the successful party in case that there is a challenge to it on the
grounds of serious irregularity or a question of law arising out of an award made in
the proceedings32.
It should be noted that an appeal process under the Act is very complex and or
restrictive; it requires either consent of the parties to the arbitration or leave of the
court. The party in the arbitration who seeks to challenge an award on grounds of
lack of jurisdiction or serious irregularities has first to exhaust the appeal or reviewing
process provided by the arbitration agreement itself (Murdoch and Hughes, 2008).
3.11 COURTS’ POWERS ON ARBITRATION
In contrast to the old practice where courts had traditionally used to exercise wide
range of powers in the arbitration process, in recent years, arbitration is regarded as
a private process of resolving disputes with very limited interferences by either the
administrators or the courts. Therefore, the determination of the dispute has been left
to the parties’ autonomy. In most jurisdictions, there have been gradual changes of
laws to reduce powers of court to intervene in the arbitration process. For instance,
under the English and Scottish arbitration Acts, the courts can only exercise
supportive powers in order to ensure that there is fairness and justice in the
arbitration process. Such powers include appointment and removal of the arbitrator;
30
Section 12. 31
See also section 58 of English Arbitration Act 1996. 32
Section 67, 68 and 69 (ibid)
George Mandepo Reg. 200957963
Page | 24
extension of time and stay of proceedings; supportive powers to the process and
enforcement or challenges to awards33. Both the English and Scottish Arbitration
Acts have adopted the requirements of UNCITRAL Model law to restrict courts
interferences on arbitration by incorporating a provision in their laws stating that the
court should not intervene in the arbitration except provided expressly by the Act34.
33
See sections 17, 18, 24, 44, 45, 68 and 69 of English Arbitration Act, 1996. 34
Section 1 of the Arbitration (Scotland) Act, 2010.
George Mandepo Reg. 200957963
Page | 25
CHAPTER FOUR
LEGAL FRAMEWORK FOR ARBITRATION IN TANZANIA
4.0 INTRODUCTION
Depending on the form of the arbitration process which the parties choose to resolve
their dispute, the laws and institution governing a particular process are very
important in determining the effectiveness of any outcome from the process. This
Chapter examines the legislative framework in Tanzania in order to establish their
effectiveness in facilitating resolution of construction disputes.
4.1 ARBITRATION ACT (CAP. 15)
The Arbitration Act35 is the principal legislation regulation arbitration in Tanzania. It
is a replica of the English Arbitration Act 1889 and amongst the oldest pieces of
legislation in the Tanzanian statute books enacted in 1931. The Arbitration Act
regulates both domestic arbitral proceedings and enforcement of foreign arbitral
awards. It also gives effect to the two international measures, viz. the Geneva
Protocol on Arbitration Clauses of 1923 and the Geneva Convention on the
Execution of Foreign Arbitral Awards of 1927 appended to the Act as 3rd and 4th
Schedules.
Since the last amendments to the Act were made in 1971, the Arbitration Act does
not incorporate requirements of most important international arbitration agreement
entered into force or ratified by Tanzania after that period. The agreements include
the Convention on the Settlement of Investment Dispute between States and
Nationals of Other States (ICSID), 196536 and the Multilateral Investment Guarantee
Agency of 198537.
As pointed out by Mkono et al., (2007), to date, Tanzania has entered into four
bilateral agreements relating to arbitration with Switzerland, Germany, Netherlands
and UK for the purposes of the investment treaty. On the other hand, UNCITRAL
Model Law of 1985 has no influence on the Tanzanian Arbitration Act. Besides the
35
Cap 15 R.E 2002. 36
Ratified on 17 June 1992. 37
Ratified 19 June 1992.
George Mandepo Reg. 200957963
Page | 26
Act, there are also Arbitration Rules of 195738 which are made under section 20 of
the Act to provide for arbitration procedures. However, the Rules contain thirteen
provisions which cover very few matters on arbitration procedures.
It is also worth noting that by virtue of sections 17 (2) Tanganyika Order In Council39
and sections 2(3), 14, 16 and 17 of Judicature and Application of Laws40
respectively, the English common law, doctrine of equity and statutes of general
application and Indian Law in force as by 22nd July 1920 (in England) and 1st
December 1920 (in India) was made applicable in Tanganyika (now Tanzania
mainland) with such modification and so far as the circumstances of Tanzania and its
inhabitants permit.
4.1.1 Applicability
The Tanzanian Arbitration Act is applicable to any arbitration dispute which, if the
matter submitted to arbitration formed the subject of a suit, only the High court would
have competence to try41.
4.1.2 Reference to arbitration
Pursuant to section 4 of the Arbitration Act read together with the First Schedule,
unless there is any agreement to the contrary, a submission to the arbitration is
deemed to be irrevocable except by leave of the court.
Section 5 of the Act allows parties to the arbitration agreement to agree on the name
of an arbitrator(s) to be appointed by a third person or appointment body designated
therein.
The arbitrator(s) are bound under the Act to make an award in writing within three
months after entering on the reference, or after having called on to act by notice in
writing from any party to the submission or on or before any later day to which the
arbitrator(s) may, from time to time, extend the time for making the award42.
Under the Act, the umpire may forthwith enter on the reference in lieu of the
arbitrators if the arbitrators have allowed the time to be extended or expire without
38
G.N. No. 427 of 1957 39
1920 40
Cap. 358 R.E 2002 41
Section 3 42
Clause 3 of the First Schedule to the Act.
George Mandepo Reg. 200957963
Page | 27
making an award or have shown an indication in writing that they cannot agree43.
Once the umpire enters on the reference, he will be bound to make his award within
one month after the original or extended time appointed for making the award of the
arbitrators has expired, or on or before any later day to which the umpire, in writing
signed by him may, from time to time, extend the time for making his award44.
Pursuant to section 14, the law empowers the High court to extend the time for
making an award by the arbitrator or umpire.
4.1.3 Powers of an arbitrator
Under the law, the arbitrator or umpire has power to examine any document to be
relied upon by the parties to the arbitration proceedings, to examine witnesses on
oath, to issue an award which is final and binding on the parties and the persons
claiming under them respectively, to determine and direct which party to the dispute
has to pay the costs of the proceedings and may tax such costs45.
4.1.4 Effect of arbitration agreement
Though there are few reported cases in Tanzania in respect to the courts power to
enforce arbitration agreement, the application of common law cases has been of
great significance to the Tanzanian legal system in which the courts have shown a
keen interest to compel the parties to respect their arbitration agreement.
Where there is an arbitration agreement, by virtue of section 6 of the Act, a party to
a submission, or a person claiming under him, has a right to apply to the court to
have any legal proceeding barred/ stayed so as the dispute may be determined
through arbitration. An application under section 6 must be made by the defendant
before filing a written statement or taking any other steps in the proceedings.
Further to section 6, rule 11 of the Arbitration Rules 1957 reads as follows:
“11. A judge may stay proceedings on such terms as he thinks fit, but not without
notice to the opposite party except where it appears that the object of granting the
stay would be defeated by the delay occasioned by the notice”.
Arguably, as the law provides, the court’s power to stay arbitration proceedings in
Tanzania is a matter of the discretion of the presiding judge. It should also be noted
43
Clause 4 of the First Schedule. 44
Clause 5 of the First Schedule. 45 Section 11.
George Mandepo Reg. 200957963
Page | 28
that contrary to the other arbitration statutes in the common law, there is no any
conditions to guide the court on the circumstances for which stay should or should
not be allowed. In Kenya for example, through section 6 of the Kenya Arbitration
Act46 , for the order of stay to be issues by the court, the applicant must prove
existence of an arbitration agreement which is valid and enforceable, and that he/she
is a party to the arbitration agreement or at least a person claiming through a party
e.g. a personal representative or trustee in bankruptcy and that the dispute in
question has arisen fall within the scope of the Arbitration Clause (Muigua,2008).
The decisions of Construction Engineers and Builders Ltd V. Sugar Development
Corporation47 provides for the authority in Tanzania regarding the circumstances in
which the court can order stay of proceedings pursuant to section 6 of Tanzania
Arbitration Act. This case involved termination of a building contract contained an
arbitration clause based on R.I.B.A. The Court of Appeal of Tanzania held that
where it is clear that the parties to a contract have agreed to submit all their disputes
or differences arising "under" the contract to an arbitrator, the dispute must go to
arbitration unless there is good reason to justify the court to override the agreement
of the parties.
In arriving to the decision in the above case, the Court of Appeal was highly
persuaded by the decision of the House of Lords in the English case of Heyman v
Darwins Ltd48 in which upon construing the true nature and function of the
arbitration agreement and the wording of the arbitration clause in the contract
between the parties, the House of Lords concluded for the order of stay pursuant to
section 4 of the Arbitration Act 1889 was proper to allow the matters in dispute
between the parties to be dealt with under the arbitration clause.
The above referred English case was later considered by the Court of Appeal of
Tanzania in another case of Tanzania Motor Services Ltd and Others v Mehar Singh
t/a Thaker Singh49. In this case, the parties entered into a building contract contained
an arbitration clause whereby the parties agreed to refer any dispute or difference
arising between them to arbitration. A dispute having arisen between the parties, the
respondent instituted a civil case in the High court seeking to recover from the
46
Act No. 4 of 1995, Laws of Kenya. 47
(1983) TLR 13 (CA) 48
[1942] A.C. 356. 49 (Civil Appeal No. 115 of 2005) [2006] TZCA 5 (21 July 2006) (unreported).
George Mandepo Reg. 200957963
Page | 29
appellants outstanding monies under the contract. Instead of filing a written
statement of defence, the appellants applied by way of petition for a stay of the
proceedings in terms of Section 6 of the Arbitration Act. The learned judge dismissed
the petition, hence the Appellant decided to appeal to the Court of Appeal.
However, at the commencement of hearing the appeal, the respondent raised a
preliminary objection challenging the competence of the appeal by reason of Section
5(2) (d) of the Appellate Jurisdiction Act 1979, on the ground that the decision in
question was interlocutory and it did not finally determine the case between the
parties in the trial court, therefore was not appealable50. Dismissing the respondent’s
objection, the Court of Appeal held that the decision of the learned judge refusing to
stay the proceedings in the case instituted by the appellant had a final determination
of the petition by barring the parties from going to arbitration. Accordingly, the Court
of Appeal considered that the decision by the trial judge closed the door to arbitration
thus rendering provisions in contract for arbitration meaningless.
It should be noted that the wording of Section 6 of the Arbitration Act for Tanzania
is in pari materia with section 4 of the old English Arbitration Act, 1889. Under the
English law, the defendants sometimes inadvertently lost their rights of stay when
taking some fair trivial procedural step in response to the legal proceedings against
them. For instance, as held in Ford’s Hotel Co Ltd v Bartlett51, the defendants who
took out a summons seeking an order for an extension of time would have precluded
from applying for a stay unless there was an express reservation of rights.
Before the 1996 Arbitration Act, the judges in English courts would have refused stay
in the case involving more than two parties with consideration that such kind of
disputes could be easily handled up by the court than in arbitration. Relying on the
discretion of court to refuse to grant stay, it was possible under the old law to bring a
multi-party proceeding. However, under the new Act, all multi-party arbitration
proceedings must be based on consent (Uff, 2009).
Murdoch and Hughes (2008) comment that section 9 of the English Arbitration Act
1996 has revised the old law whereby, in interpreting the section, the English
50
Section 5(2) (d) of the Appellate Jurisdiction Act, 1979 as amended by Act No. 25 of 2002 bars appeals against preliminary or interlocutory decision or order unless such decision or order has the effect of finally determining the suit. 51
[1896] AC 1.
George Mandepo Reg. 200957963
Page | 30
Courts have been unwilling to deprive defendant’s rights of stay on technical
grounds. Under section 9, the court must order a stay of proceedings unless satisfied
that the arbitration agreement is null and void, inoperative or incapable of being
performed.
Based on the strict interpretation of section 9 of the English Arbitration Act, 1996, the
judges have applied the law to favour arbitration. For instance, a party applying to
set aside a default judgment with associated leave to defend cannot thereby be
regarded to take any substantial step in proceedings which would debar him from
insisting that the matter be stayed pending a referral to arbitration52.
Similarly, it was held in Bilta (UK) Ltd v Nazir53 that an application for an extension
of time to serve a defence will not amount to a waiver of the right to seek a stay of
proceedings pending arbitration if a party has expressly reserved its rights. In that
case, Sale J. reviewed previous decisions including that of Patel v Patel (supra.),
and approved the principle that "the right to apply for a stay will be lost if the
Defendant in the judicial proceedings has expressly or impliedly represented that he
does not intend to refer the dispute to arbitration".
In contrast to English arbitration law, section 6 of Tanzanian Arbitration Act can
deprive the defendants’ right of stay of proceedings just by mere filing a written
statement of defence or by making an application for adjournment of the proceeding.
The technicalities on right to stay under section 6 appear not to favour the intention
of arbitration agreement and contradict requirements of the international conventions
such as the New York Convection 1958, which require each Contracting party to
recognize and or respect an arbitration agreement54.
4.1.5 Court powers in support of arbitral proceedings
Under the English Arbitration Act 1996, courts have inherent power to support
arbitration proceedings whereby pursuant to Section 44, the courts can issue an
injunctive order where it is appropriate to preserve the status quo and the greater
risk of potentially irremediable injustice lay in refusing injunctive relief. In the case of
SAB Miller Africa v East African Breweries55, Justice Christopher Clarke of the High
52
Patel v Patel [1999] BLR 227. 53
[2010] EWHC 1086 (Ch). 54
See Article I(1). 55
[2010] 1 Lloyd's Rep. 392.
George Mandepo Reg. 200957963
Page | 31
Court of Justice, Queens Bench Division granted such an injunctive relief pending
further order of the arbitral tribunal, which at the time of hearing was yet to be
appointed in order to determine the disputes between the parties.
The application for the leave to appeal made against such an injunctive order
against the respondent was later refused by the Court of Appeal as the court found
that it had no power to grant permission to appeal for the order made under section
4456. Under the Tanzania Arbitration Act, such an inherent power by the court to
honour the arbitration agreement is not specifically provided. Therefore, if there is no
any agreement to the contrary, the parties have to rely upon the common law if they
wish to preserve the status quo on their case.
4.1.6 Extension of time for commencement of arbitration
Section 7 of the Tanzania Arbitration Act empowers the court to extend time for
commencement of the arbitration proceedings, if it is of the opinion that in the
circumstances of the case ‘hardship would otherwise be caused’ and
notwithstanding that the time so fixed in the arbitration agreement has expired. In
that provision, the court’s power to extend time is without prejudice to any written law
limiting the time for the commencement of arbitration proceedings57.
Under the Law of Limitation Act58 which governs limitation of claims in Tanzania the
word “arbitration" is defined to mean arbitration on a submission or under any written
law59. Section 40 of the Law of Limitation provides that the Act apply to arbitrations in
the same manner as it applies to other proceedings.
For the purpose of limitation, the law considers that where a submission contains a
term that no cause of action shall accrue in respect of a matter, the cause of action
shall accrue in respect of any such matter at the time when it would have accrued
but for the term in the submission. The Law of Limitation provides further under
section 40(3) as follows:-
“(3) For the purposes of this Act, an arbitration shall be taken to have
commenced when one party to the arbitration serves on the other party a
notice requiring him to appoint an arbitrator or, where the submission provides
56
SAB Miller Africa v East African Breweries [2010] EWCA Civ 1564. 57
Sub-section (2). 58
Cap. 89. 59
Ibid. section 2.
George Mandepo Reg. 200957963
Page | 32
that the reference shall be to the person named or designated in the
submission, requiring him to submit the dispute to the person so named or
designated”.
Usually, a construction contract may contain certain provisions which trigger
commencement of claims. For instance, under the standard construction contracts
such as clause 66 of ICE Conditions and clause 30.9 of JTC 98 respectively, the
engineer or architect decision on the certificate is final and binding unless
challenged by a notice of arbitration. In one English case of Crow Estate
Commissioner v Mowlew60, the employer sought to rely upon the power of the court
to extend time for commencing arbitration proceedings in order to avoid the binding
effect of the final certificate under the JCT 80 form of contract. The court held that
the power to extend time for arbitration could override the binding effect of the final
certificate as agreed upon in construction contract by the parties.
Based on the old English Arbitration law, the courts could not avoid the effect of
time-bar and binding effect of the decisions by the engineer or contract administrator
in respect of the final certificate. However, the position has now been revised by
section 12 of the Arbitration Act 1996 in which the court can on discretion extend the
time only if the claimant proves that –
(i) the circumstance which barred or extinguished the claimant’s rights to
begin the arbitral proceedings or other dispute resolution are such as were
outside the reasonable contemplation of the parties when they agreed the
provisions in question, and that it would be just to extend the time; and
(ii) the conduct of one party makes it unjust to hold the other party to the strict
terms of the provision in question.
As opposed to the above-referred English position, section 7 of Tanzania Arbitration
Act gives a wider discretion to the judge to determine extensions of time by importing
the word “hardship” without further clarification.
60
(1994) 70 B.L.R 1.
George Mandepo Reg. 200957963
Page | 33
4.1.7 Appointment of an arbitrator or umpire
The Tanzania Arbitration Act also empowers the court to intervene in the arbitration
proceeding by the appointment of an arbitrator or umpire61. This power can only be
exercised by the court under the following situation:
(i) where the parties fail to agree on an appointment of an arbitrator;
(ii) where the appointed arbitrator (s) or umpire neglects or refuses to act or
is incapable of performing or dies or is removed; and
(iii) where parties or two appointed arbitrators fail to appoint an umpire or third
arbitrator (if they were to do so).
One party to the arbitration agreement could seek the intervention of the court if the
other party has not decided on the appointment of an arbitrator or umpire within
seven clear days after the service of the notice of appointment62.
However, it is not provided under either Arbitration Act or Rules if in appointing the
said arbitrator, umpire or third arbitrator, the court is bound to consider any factors,
which will ensure effective determination of dispute among the parties such as the
nature of the subject matter, qualification, age or competency of a particular
arbitrator or umpire. In other jurisdiction such Scotland, the law excludes persons
under 16 years old and any incapable adult from becoming arbitrators63
4.1.8 Removal of arbitrator
Sections 9(a) and 10(1) (a) of the Arbitration Act allow the arbitrator who is appointed
by one party to become a sole arbitrator in case the other party has failed to appoint
or replace his own arbitrator within seven clear days upon being served with a
written notice to make the appointment. Under section 9(b) and 10(2), the court can
set aside the appointment made by one party but it is not clear on what specific
grounds the court can set aside such an appointment before the end of arbitration
proceedings.
It should be noted that the only ground provided for in the Act in which the court can
remove an arbitrator or umpire is when the said arbitrator or umpire has committed
61
Section 8 (1). 62
Section 8(2). 63
See Rule 4 of the Scottish Arbitration Rules, 2010.
George Mandepo Reg. 200957963
Page | 34
misconduct64. Nonetheless, the word “misconduct” is not defined or elaborated in the
Act or Rules, something which may make difficult for the court to remove an
arbitrator from office. In addition, as opposed to Scottish Arbitration Rules in which
the arbitrator can be removed from office at any time by the parties who appointed
him/her65, the Tanzanian Arbitration Act or Rules does not provide such right to the
parties to remove the arbitrator at their wishes.
4.1.9 Procedural and evidential matters
In contrast to the English and Scottish arbitration laws66, in Tanzania, neither the
Arbitration Act nor the Rules provide specifically on what form of procedures should
be adopted by the arbitrator or umpire. Although the Tanzanian Law of Evidence
Act67 excludes strict application of evidentiary rules to the arbitration proceedings68,
sometimes, it is upon the parties to agree on the specific powers to be vested to the
tribunal including evidential matters to guide the tribunal.
Otherwise, if an arbitration agreement by the parties lacks detailed information,
then the whole procedure of administering the dispute before tribunal including filing
of pleadings, calling of witnesses, examination of evidence etc., will largely depend
upon the experience of a particular arbitrator handling the matter and legal counsels
of the parties to the dispute (if at all represented).
4.1.10 Powers of the Arbitrator or Umpire
Section 11 of the Arbitration Act read together with the First Schedule provide for the
specific powers of the arbitrator as follows–
(i) to determine cost of reference and award
(ii) to administer oaths to the parties and witnesses appearing;
(iii) to state a special case for the opinion of the court on any question of law
involved;
(iv) to correct in an award any clerical mistake or error arising from any accidental
slip or omission.
64
Section 18. 65
Rule 10 -12 of Scottish Arbitration Rules 66
See also section 33(b) of the English Arbitration Act 1996 and Rule 28 of the Scottish Arbitration Rules, 2010. 67
Cap. 6 of the Laws of Tanzania (R.E 2002) 68
Section 2
George Mandepo Reg. 200957963
Page | 35
As opposed to the arbitration laws of other countries including that of its neighbour
Kenya69, the Tanzanian legislation does not specifically empower the arbitral tribunal
to determine its own jurisdiction/ competence or order interim measures such as
injunction, prohibition or security for costs70.
Although under the Tanzania Arbitration Act the arbitrator has powers to award
costs, such powers are limited to the costs relating to what is in the submission by
the parties. The arbitrator can award costs within his discretion if satisfied that the
arbitration agreement is silent on cost and the governing legal provision empowers
him to do so. However, there is nowhere in the Arbitration Act empowering the
arbitrator to award interest on costs in whatever form. In Kenya, under section 32C
the of Kenya Arbitration Act, where there is no any agreement to the contrary, an
arbitral award may include provision for the payment of simple or compound interest
calculated from such date, at such rate and with such rests as may be specified in
the award.
4.1.11 Confidentiality
As opposed to the arbitration laws of other countries such as Scottish Arbitration
Rules, which provide for confidentiality of arbitration proceedings71, in Tanzania, both
the arbitration Act and its Rules do not provide specifically whether the arbitration is
a confidential process. Therefore, the parties will only consider the issue of
confidentially of proceedings in the arbitration process as a matter of practices or
agreement.
4.1.12 The arbitral award
Pursuant to section 12 of the Arbitration Act, the arbitrator is entitled to make and
sign an award and thereof notify the parties to the dispute of the delivered award
together with any fees and charges payable in respect of arbitration and award.
Unlike section 52 of the English Arbitration Act 1996 and Rule 51 of the Scottish
Arbitration Rules, the Tanzanian Arbitration law does not provide for any mandatory
form or conditions that the tribunal should take into account in the award.
69
The Arbitration Act No. 4 of 1995, Laws of Kenya as amended in 2009. 70
Ibid, section 17 and 18 (1)(a)-(c). 71
See Rule 26 of Scottish Arbitration Rules, 2010.
George Mandepo Reg. 200957963
Page | 36
The only requirement under the law is for the arbitrator to make an award on the
format provided for in Form 5 to the Second Schedule to the Act. Notwithstanding
that requirement, the Act does not provide any fate or remedy if an award has not
complied with Form 5 of the Second Schedule.
As for the judgment of the court, an arbitral award is just a determination and
declaration of the rights and obligations of the parties in a case. Under section 12(2)
of the Act, once the arbitrator or umpire has made his award and notified the parties
thereto, he will only file the award or cause it to be filed in court upon a request by
any of the parties to the submission or any person claiming under such party. The
filing of the award shall be after payment of all fees, charges and all costs in respect
to the arbitration and award and the costs of filing it in court.
In order to file an award to the High court, rule 4 of the Arbitration Rules requires that
the arbitrator or umpire to forward the award or certified true copy with all
accompanying documents to the Registrar of the High court by a registered post and
in a sealed envelope. In Tanzania Cotton Marketing Board v Cogecot Cotton
Company SA72 the Court of Appeal of Tanzania provided clear guidance on the
procedure for filling an award pursuant to section 12(2) and rule 4.
In that case a dispute arose between the appellant and the respondent which
resulted in the matter being referred to arbitration before the Liverpool Cotton
Association Limited. An award granted in favour of the respondent and confirmed by
the Technical Appeal Committee of the Arbitrators was filed in the High Court of
Tanzania through the service of one local law firm in Tanzania having being
forwarded by DHL courier and not by registered post as required by rule 4 of the
Arbitration Rules, 1957.
The appellant objected to the award on the ground that the proper procedure as
required under the Arbitration Act was not followed. The court held that there was no
reason for a restrictive interpretation of the provisions of section 11(2) of Arbitration
Act73 which allowed the arbitrator to `cause the award, or a signed copy of it to be
filed in the court'. The import of this was that the arbitrator either could file the award
himself in court or could cause the award to be filed by instructing somebody else to
do it on his behalf. The court went on to consider that:-
72
1997 TLR 165 73
[now section 12(2)]
George Mandepo Reg. 200957963
Page | 37
“ the words `registered post' had to be interpreted widely enough in order to
take into account the current development in communication technology, such
as courier postal services, that had taken place since 1957 when the rules were
enacted. In the circumstances the award had been properly filed”.
The court was of the views that also rule 4 of the Arbitration rule, 1957 is more
restrictive than the principal legislation. Therefore, it should be interpreted widely in
order to accord to it a more meaningful and practical interpretation which is in line
with the spirit behind the principal Act. As guidance on what happens after the award
has been filed, the court also upon considering various arbitration decisions by the
Supreme Court of India in light of the Indian Arbitration Act 189974, was of the view
that from the date of filing, the award is capable of being enforced as though it were
a decree. The court as well challenged the practise in the enforcement of an award
through the Arbitration Act Cap. 15 of Tanzania as follows:-
“So far in our country the practice in matters of arbitration awards is that the
court is moved by an application for an order for filing which is then followed by
proceedings. On the basis of the Indian decisions we are persuaded to take the
view that as a matter of law it is not necessary to conduct proceedings before
an order for filing is made. In our view, the receipt of the award by the Court
Registry constitutes the filing of the award. Thereafter, the court is required to
notify the parties who may wish to challenge or to enforce the award in terms of
the law”.
The observation by the Court of Appeal in the above case would support for the
reform of Tanzanian arbitration law in order to accommodate new developments in
the arbitration procedures taking place elsewhere in the world.
4.1.13 Challenging an award
While under the English and Scots laws it is required that a party first exhausts any
available review or appeal process under the arbitration agreement before going to
the court, in Tanzania, the decision of the arbitrator or umpire under the Arbitration
Act is not appealable; instead an aggrieved party can make an application/petition to
the court for the same to be set aside or remitted back to the arbitrator or umpire for
reconsideration.
74
The Indian legislation was in pari materia with Arbitration Act Cap 15 of Tanzania,
George Mandepo Reg. 200957963
Page | 38
The court may set aside the award only when it is satisfied that there are elements of
misconduct or improper procurement of an award by the arbitrator or umpire75. Once
an award is remitted back for reconsideration, the arbitrator or umpire shall, unless
the court direct otherwise, make a fresh award within three months76. As noted
before, pursuant to section 12 (1) of the Arbitration Act, when and arbitrator or
umpire makes his award, is required to give a notice to the parties in that effect.
It was considered in the case of Tanzania Cotton Marketing Board v Cogecot Cotton
Company SA, (supra), that a party to the arbitration can apply for the enforcement or
changing an award once it has been filed in court and upon being notified such filing
by the Registrar of the High Court.
In the circumstances, should there be a time limitation to apply for the enforcement
or challenging the award, the time has to be counted starting from the date when a
party has received a notice of the filing of an award by the arbitrator from the
Registrar but not from the date when the award has been filed in court.
In Tanzania Cotton Marketing Board Vs Cogecot Cotton Company S.A77, the Court
of Appeal was to consider what form of pleading should be filed in the court to
challenge an award and time limit for taking such action. In that case, the appellant
petitioned to the High Court to impeach an award under section 15 of the Arbitration
Act and Rules 5 and 6 of the Arbitration Rules.
The matter was dismissed by High Court on the ground that it was time-barred
pursuant to Item 21 of Part III of the First Schedule to the Law of Limitation Act that
provides for the limitation period of 60 days. The Appellant then appealed against
that decision contending that the High court erred in holding the time of limitation to
be 60 days. The Appellant contended that a petition was a suit founded on a
judgment, namely the award and therefore, the time of limitation under the Law of
Limitation Act is 12 years reckoned from the date the notice of filing the award was
served on the appellant. In its judgment, the Court of Appeal held that a petition
under rules 5 and 6 of the Arbitration Rules is an application rather than a suit and
that all applications under the Arbitration Act fall under Item 21 of Part III of the First
75
Section 15 and 16 of the Act read together with Rule 5 and 6 of the Arbitration Rules 1957. 76
Section 15(2). 77 60 of 1998) [2002] TZCA 4 (1 January 2002) http://www.saflii.org/tz/cases/TZCA/2002/4.html (accessed on 4 August 2010).
George Mandepo Reg. 200957963
Page | 39
Schedule to the Law of Limitation Act, and the period is 60 days78. On the contrary,
as we will see later on, the same Law of Limitation Act provides for the time limit of
30days for making an application to set aside an award under the Civil Procedure
Code79. In furtherance to the above, the Law of Limitation Act is silent on when the
right of action accrues as far as application/petition for the challenging of an award is
concerned.
Section 6(j) of the Law of Limitation Act provides for when a right of action accrues in
respect to the “appeals” This section provides that time starts to run on the date
when the judgment, decision, award, decree or order appealed against was
delivered, passed or made. Section 2 of the Law of Limitation defines “appeal” to
mean an appeal against a decree, order, award, judgment or decision passed,
delivered or made in a proceeding of a civil nature. The word “award” is defined to
mean an “award of an arbitrator”.
Section 19 (4) of the Law of Limitation Act provides further that in computing the
period of limitation prescribed for an application to set aside an award, the time
requisite for obtaining a copy of the award shall be excluded. Interpretation of section
6 and 19 of the Law of Limitation Act can cause confusion in determining an
appropriate way of challenging the award and the time limit for doing so. As a matter
of law according decisions of the court of appeal in the case of Tanzania Cotton
Marketing Board vs. Cogecot Cotton Company S.A, an award under the Arbitration
Act can only be challenged by way of application referred as “petition” instead of
“appeal”. Therefore, the whole procedure under the Law of Limitation for challenging
an award does not involve an award made under the Arbitration Act.
4.1.14 Recognition and enforcement of domestic award
Under the Tanzania Arbitration Act the award upon being filed in the court, unless
the court remits it to the consideration to the arbitrator(s) or umpire(s) or sets it aside,
is enforceable as if it were a decree of the court80. An award can be enforced by filing
78
Note: The Arbitration Act does not provide for the period of limitation but refers to the limitation period under the Law of Limitation Act. 79
Under Part III, item 2 of the First Schedule. 80
Section 17.
George Mandepo Reg. 200957963
Page | 40
a petition in the High Court in the manner set out in the Arbitration Rules81, to which
a copy of the submission (or arbitration clause) have to be attached.
Under Part I, item 9 of the First Schedule to the Law of Limitation Act, the award can
also be enforced as a “suit” to be filed in court within 6 years.
Contrary to the English Arbitration law where an award can be enforced through an
application for the leave of court or an action for a summary judgment on the sum
awarded82, in Tanzania, a party who wishes to enforce the award under the Act has
to follow the normal procedures for the enforcement of the decrees of the court as
provided for under the Civil Procedure Code. This is a subject which may involve a
lot of other legal complications which may end up in justice delayed if not denied.
Twaib (2009), challenges the civil justice system of Tanzania as far as process of
enforcement of decree is concerned. The author argues that even when the litigation
ends, another problem usually arises that of enforcing whatever decree or order a
person might have obtained from the Court. The execution process is full of
procedural complications, especially where, as in most cases, the losing party is not
willing to comply with the court order.
4.1.15 Enforcement of Foreign Arbitral Awards
In Tanzania, the enforcement of foreign arbitral award is governed by sections 29 to
32 of the Arbitration Act. A foreign award is enforceable either by action or through a
petition made to the High Court upon the award being filed. Although the law does
not define what “action” means, it can be construed to imply a formal suit. A party to
the foreign award may rely upon it in any legal proceedings by way of defence, set-
off or otherwise83. Pursuant to section 32, in order that a foreign award to be
enforceable under the Act, it must–
(i) have been made in pursuance of an agreement for arbitration which was valid
under the law by which it was governed;
(ii) have been made by the tribunal provided for in the agreement or constituted
in manner agreed upon by the parties;
81
Rule 5, 6 and 7. 82
Section 66 of Arbitration Act 1996. 83
Section 29.
George Mandepo Reg. 200957963
Page | 41
(iii) have been made in conformity with the law governing the arbitration
procedure;
(iv) have become final in the country in which it was made (there is no any
proceedings for contesting its validity in the country in which was made).
(v) have been in respect of a matter which may lawfully be referred to arbitration
under the law of Tanzania, and its enforcement must not be contrary to the
public policy or the law of Tanzania.
The foreign award cannot be enforced if the court is satisfied that-
(i) the award has been annulled in the country in which it was made; or
(ii) the party against whom it is sought to enforce the award was not given notice
of the arbitration proceedings in sufficient time to enable him to present his
case or was under some legal incapacity and was not properly represented;
or
(iii) the award does not deal with all the questions referred or contains decisions
on matters beyond the scope of the agreement for arbitration.
Section 31 of the law requires that a party seeking to enforce a foreign award must
prove the existence of a particular award by producing–
(i) the original award or its copy duly authenticated in the manner required by the
law of the country in which it was made;
(ii) evidence proving that the award has become final; and
(iii) such evidence as may be necessary to prove that the award is a foreign
award including certified translation of any of document if it is in the foreign
language.
Recognition and enforcement of a foreign award in Tanzania is based on the
Convention on the Execution of the Foreign Arbitral Awards of 1923 and The
Protocol on Arbitration Clauses of 1923 for which Tanzania is a member. The two
international agreements are incorporated in 3dr and 4th Schedules to the Arbitration
Act. Unlike Scots Arbitration Law which incorporates the international agreements in
its national law84 , the Arbitration Act for Tanzania does not make any reference to
84
Arbitration Act (Scotland) Act 2010 expressly recognises these two agreements through Sections 18 – 22 and 26 respectively.
George Mandepo Reg. 200957963
Page | 42
the New York Convention or and UNICITRAL Model Law though the United Republic
of Tanzania is a member to such agreements.
Lack of recognition of international agreement through its national arbitration law has
made most of the arbitration cases involving the government of United Republic of
Tanzania and some international companies to be referred to the international
arbitrators even if the companies are registered and have their place of business in
Tanzania.
Among recent cases referred to the international arbitration tribunal (ICSID) is that of
Biwater Gauff (Tanzania) Ltd. V. United Republic of Tanzania85 which involved a
dispute on the termination of the World Bank funded project for the management and
operation of the water and sewerage services in Tanzania. In that case, though the
implementation of agreement involved a locally incorporated company in Tanzania,
named City Water Services Limited, the seat of arbitration was in Paris. In the
circumstances, it was very expensive for a poor country like Tanzania to handle the
case abroad. The costs that are incurred in submitting the dispute to the international
centres for disputes resolution could be avoided by having strong national arbitration
institutions and competent arbitration practitioners.
4.2 ARBITRATION UNDER THE CIVIL PROCEDURE CODE
The Civil Procedure Code provides for its own unique arbitration through the Rules
incorporated in the Second Schedule made under Section 80 to the Code. The Rules
governs both arbitration by the order of the court and that without an intervention of
the court.
4.2.1 Arbitration by order of Court
The Arbitration by order of Court requires that the parties in the proceedings who
wish to settle the dispute through arbitration, to apply in writing for the order of the
court that the matter be referred to arbitration before judgment has been
pronounced. In that circumstance, the arbitrator will be appointed by the court in
such manner as may be agreed upon between the parties and be required to make
an award within a specified time86. As for the Arbitration Act, the court may as well
85
ICSID Case No. ARB/05/22 86
Rules 2 – 3 of the Second Schedule
George Mandepo Reg. 200957963
Page | 43
assist the proceedings by compel attendance of witness and extend time for making
an award by an arbitrator87.
Once the arbitrator has made an award in the suit will then cause it to be filed in
court. The court is empowered under Rules 12 and 14 to order modification,
correction or reconsideration of only if:
(i) it appears that a part of the award contains matters which were not
referred to the arbitration;
(ii) the award is imperfect in form, or contains an obvious error which can be
amended without affecting such decision; or
(iii) the award contains a clerical mistake or an error arising from an
accidental slip or omission.
The court can also interfere with the award by making such order as it thinks fit
respecting the costs of the arbitration if the award contains no sufficient provision
regarding the cost. Pursuant to Rule 15(1), the court cannot set aside the award
except on one of the following grounds, namely-
(i) corruption or misconduct of the arbitrator or umpire;
(ii) fraudulent concealment or misleading of any matter which ought to have
been disclosed to the arbitrator or umpire; and
(iii) the award having been made after the issue of an order by the court
superseding the arbitration or after the expiration of the period allowed by the
court or being otherwise invalid.
The rule 15 provide further that if the court sees no cause to remit the award for re-
consideration in whatever manner and no application has been made to set aside
the award or the court has refused such application, the court shall, after the time for
making such application has expired, proceed to pronounce judgment according to
the award which then shall be followed by a decree. A party to the proceedings is
allowed to challenge the decree only if it is in excess of, or not in accordance with
the award.
87
Rules 7 and 8
George Mandepo Reg. 200957963
Page | 44
4.2.2 Agreement to refer to the arbitration
By virtue of Rule 17(1), any persons who agree in writing that any difference
between them shall be referred to arbitration, may make a written application to any
court having jurisdiction in the matter to which the agreement relates, that the
agreement be filed in court.
The application in this nature shall be accepted and registered as a suit between the
parties. Then the court will direct a notice thereof to be given to all the parties to the
agreement, requiring such parties to show cause within the time specified in the
notice, why the agreement should not be filed. In the absence of any objection
against the agreement, the court will order the agreement to be filed in court and the
arbitrator be appointed in accordance with the agreement. In line with section 6 of
the Arbitration Act, the court can stay any legal proceeding pending arbitration on
application by any party to the proceeding88.
4.2.3 Arbitration without the intervention of court
By virtue of rule 20 of the Second Schedule of CPC, where any matter has been
referred to arbitration without the intervention of a court and an award has been
made thereon, any person interested in the award shall make an application in
writing to the court that the award be filed in court. The application made in this
manner shall be registered as a suit between the parties and the court shall direct
notice to be given to the parties to show cause as to why the award should not be
filed in court.
If there is no any objection as regard to the filling, setting aside or remitting of the
award, the court will pronounce judgment according to the award. Upon the
judgment, so pronounced a decree shall follow and no appeal shall lie from such
decree except insofar as the decree is in excess of or not in accordance with the
award89.
4.3 COMPARING ARBITRATION UNDER THE ARBITRATION ACT AND CPC
It is submitted that, in contrast to the Arbitration Act, the CPC provides for two
procedures of arbitration i.e. arbitration which can or cannot involve intervention of
the court. However, both the proceedings require existence of an arbitration
88
Rule 18 89
Rule 21.
George Mandepo Reg. 200957963
Page | 45
agreement between the parties. Under the CPC, the procedure of filing, enforcement
or challenging an arbitral award is different from that provided for in the Arbitration
Act. While in the Arbitration Act an award can be challenged by way of petition to
High court upon the award being filed by the arbitrator pursuant to section 12 of the
Arbitration Act, under CPC an award without intervention of the court can be
enforced by way of an action or a suit in which a judgment and a decree can be
pronounced straight forward.
The remedy for any of the parties who is aggrieved by the decree under the CPC
arbitration is to file an appeal against the decree whereas under the Arbitration Act
recourse of an aggrieved party is to challenge the award so as it should not be
treated as a judgment or decree of the court. As noted before, the Law of Limitation
Act provides under Part III, item 2 of the First Schedule that an application to set
aside an award “under the CPC is within thirty days (30) this is different from 60
days for challenging an award under the Arbitration Act .
Another contradiction in the arbitration procedures is that, while the Arbitration Act
requires all applications to be made in court by way of petition and that suit cannot
be recognized as “an application”, under the CPC, a party can use an action known
as a “suit” to enforce an award and the time limitation provided under the Law of
Limitation Act is six (6) years90. On the other hand, while the Arbitration Act does not
provide when an award has to be filed in the High court for the enforcement or
challenge, the Law of Limitation Act requires that an application under the CPC for
the filing an award in a suit made in any matter referred to arbitration by order of the
court or without the intervention of a court be made within six (6) months91.
Unless the laws are harmonized, it can be confusing if a party to an award decides to
quote both the provisions of CPC and the Arbitration Act on making his application
for the challenging or enforcement of an arbitral award.
4.4 ARBITRATION UNDER THE NATIONAL CONSTRUCTION COUNCIL
The National Construction Council (NCC) is a statutory body that was established in
1979 through the National Construction Act 1979. Cap 162, as amended in 200792.
Pursuant to section 4 of its Act, among functions of NCC include promoting and
90
Part I, item 9 of the Schedule to the Law of Limitation Act. Cap. 89. 91
Part III, item 18 of the First Schedule of the Limitation Act. 92
No. 20 of 1979, Cap. 162.
George Mandepo Reg. 200957963
Page | 46
providing strategic leadership to the stakeholders for the development of the
construction industry as well as advice the government on all matters relating to the
construction industry in Tanzania. Apart from its main statutory mandates in the Act
of establishment, the Council is also engaged in facilitating construction dispute
settlements through adjudication and arbitration under the National Construction
Council arbitration rules. The current Rules applicable in the arbitration are the
Arbitration Rules 2001 Edition, which replaced the old Rules of 1984. The Rules are
in the form of guiding procedures for regulating arbitration between parties who seek
to resolve their construction dispute through NCC.
4.4.1 Scope of application
By virtue of its preamble, the NCC Rules are applicable to both domestic and
international arbitration. For the international arbitration, the Rules take recognizance
of the UNCITRAL Model Law. It is provided under the preamble that the parties who
wish to have their construction disputes determined through the Rules, they should
insert an arbitration clause in their contract to provide that any dispute or difference
of any kind whatsoever which may arise in relation to any matter in connection with
the agreement shall be referred to the arbitration under the Rules of NCC.
If there is no any prior agreement to arbitrate, the Rules allows the parties to enter
into “an agreement to refer” the dispute through the NCC Rules at the time of
occurrence of such dispute.
The NCC Rules state that any matters, which are not covered therein, shall be
governed by the agreement between the parties and the laws of Tanzania in case of
disputes under domestic contract or in accordance with the law agreed by the parties
in case of dispute arising out of, or in connection with international contract.
However, the word “domestic” or “international” contacts are not defined in the
Rules, neither is there any clause in the Rules defining words used therein.
4.4.2 General principles
Unlike the Arbitration Act Cap. 15, the NCC Rules contains a provision for the
general principles regarding the objective of arbitration. In addition, they provide
clear duties of the arbitrator and parties to the arbitration proceedings93. Generally,
93
Rule 1.0 - 3.0.
George Mandepo Reg. 200957963
Page | 47
the object of arbitration is considered as an approach to obtain fair resolution of
dispute by an impartial tribunal without unnecessary delay or expense.
The arbitrator on his part is required to act fairly and impartially between the parties
and to adopt procedures suitable to the circumstances of the case to avoid
unnecessary delay or expenses to the parties. Likewise, parties to the disputes are
also required to do whatever possible for the proper an expeditious conduct of the
proceedings. Under Rule 3.2 Parties may agree to confer any other power to the
arbitrator apart from those in the rules or their arbitration agreement.
As a matter of procedure, pursuant to Rule 4, a party who wishes to commence
arbitration shall send to the NCC a written request to that effect. A request shall
contain particulars of the parties, brief statement of the dispute, copies of agreement
and a separate submission with a copy sent to the other party. On receipt of the
request, NCC shall then submit to the claimant a list of approved arbitrators and the
claimant shall select three names and send back the names to NCC and NCC shall
thereafter upon checking the availability of the arbitrators, request the Respondent to
select one with 14 days, otherwise if there is a disagreement on the name, parties
may request NCC to appoint an arbitrator who shall not be from the list proposed by
the claimant.
The procedure involving two arbitrators and umpire is only applicable on complicated
arbitration whereby NCC is the one, which appoints the umpire after each party has
appointed his own arbitrator94.
4.4.3 Jurisdiction and powers of the arbitrator
The jurisdiction and powers of the Arbitrator under NCC Rules are provided for under
Rule 7.0 in which the arbitrator is required to exercise his powers and discretion so
far as Tanzanian law allows. Among the powers of the arbitrators under the Rules
include to determine validity and enforceability of contract by the parties, to order
correction or amendment to such contract, to determine any question of law arising
in the arbitration, to determine validity of arbitration agreement, to determine any
question as to his jurisdiction, to order a joining of any party by consent and make
single award, to make any interim orders and to award interest on any sum from and
to any date as such as he determines to be appropriate etc.
94
Rule 5.0
George Mandepo Reg. 200957963
Page | 48
As it has been noted above, most of the referred powers in the NCC Rules are not in
the principal arbitration law, thus Arbitration Act Cap.. 15 and Rules of 1957.
4.4.4 Arbitration costs
As opposed to the Arbitration Act which does not stipulate how costs are to be
allocated at the end of the proceedings and or interest thereof, NCC Rules require
parties to pay in equal contribution all costs and fees relating to arbitration in
advance.
The said contributions, which are deposited with the NCC before or during the
arbitration proceedings, will probably differ from the costs at the end of the
arbitration, the entire costs of the arbitration are usually ordered to be borne by the
unsuccessful party95. The arbitration expenses are payable to cover for the
arbitrator’s fees, and all facilitation costs to be incurred by the NCC.
4.4.5 Procedures for enforcement and challenging an award
The procedure for making an award under the NCC Rules is completely different
from that provided in the Arbitration Act and CPC. Under Rule 12 of NCC it is
provided that the arbitrator will make his reasoned award in writing and then send his
award to NCC within 14 days after the conclusion of the hearing. NCC will then notify
the parties for collecting of the award upon payment of any outstanding fee and
costs. Rules 15.1 provides that if the award is not taken within one month of
notification , NCC may by action recover all outstanding costs of the arbitration from
any or all the parties. Nonetheless, NCC Rules do not specify what follows a party
had taken the award. In the other hand, rule 12 of the NCC Rules contradicts with
section 12 of the Arbitration Act, which requires the arbitrator to file or cause to be
filed an award in court upon being requested by any party to the arbitration to do so.
4.5 ARBITRATION UNDER THE PUBLIC PROCUREMENT
Amongst mandatory conditions in the procurement of public works or services in
Tanzania is a requirement that all Public Procurement Entities (PE) make use of an
appropriate standard model tender document and contract form prepared by the
PPRA96. As far as dispute settlement is concerned, the procedures are provided for
95
Rule 14 96
Sections 63(1) and 70(3) of the Public Procurement Act No. 21 of 2004 read together with Regulations 77 (4) and 83 (3) and (4) of the of the Public procurement (Goods, Works, Non-consultant services and Disposal of Public assets by Tender) (GN NO. 97/2005)
George Mandepo Reg. 200957963
Page | 49
under clause 27 and 28 of under the Clause of the General Conditions of Contract
(GCC) in the current standard form tender documents approved by PPRA.
The conditions require that a dispute in a public project between the contractor and
the Project Manager should be determined by the Adjudicator whereby the
contractor who is aggrieved by the decision of the Project Manager has to refer the
matter to the Adjudicator within 14 days of the notification of the Project Manager’s
decision. The Adjudicator is bound to give a decision in writing within 28 days of
receipt of a notification of a dispute and if either is aggrieved with the decisions of the
Adjudicator, he may refer the matter to an Arbitrator within 28 days of the
Adjudicator’s written decision. Otherwise, the Adjudicator’s decision becomes final
and binding.
Pursuant to the said GCC, the Adjudicator is the person appointed jointly by the
Employer and the Contractor to resolve disputes in the first instance and such
appointment needs to be done through Special Conditions of Contract (SCC) within
the same standard tender documents. It is provided further under Clause 28(3) of the
said GCC that “The arbitration shall be conducted in accordance with the arbitration
procedure published by the institution named and in the place shown in the Special
Conditions of Contract”.
In the circumstances, parties have to nominate through SCC both the adjudicator
and the rules of an arbitration institution of which their dispute will be determined in
case it is unresolved through adjudication.
Apart from the fact that the standard tender documents (GCC) lack the procedure on
how the dispute can be referred to the adjudication or arbitration as it is under JTC,
2005 as commonly in use for the UK construction Industry97, it is the settled position
that in Tanzania, the adjudication process is the first step for the settlement of
disputes relating to public procurement and that the arbitration can only be instituted
as an appeal or review of the adjudicator’s decision.
However, the position is unclear as what should be the approach in a case where the
dispute between the parties does not involve the decision of the Project Manager.
97
Section 9.2 – 9.8
George Mandepo Reg. 200957963
Page | 50
Similarly, the GCC does not make clear what will be an implication if the decision of
the adjudicator is unchallenged within 28 day, because the finality of the decision
does not always carry the same weight as a “binding decision” which renders the
decision enforceable before the court of law as it is for the adjudicator’s decision in
the UK under the HGCRA 1996.
George Mandepo Reg. 200957963
Page | 51
CHAPTER FIVE
INSTITUTIONAL CHALLENGES FACING ARBITRATION IN TANZANIA
5.0 INTRODUCTION
An attempt has been made in the preceding chapter to review the legal aspects of
arbitration in Tanzania. As noted, there are various weaknesses to the existing
arbitration legislation which cannot assist the parties to the arbitration proceedings to
resolve their dispute more effectively and enjoy all the benefits attached to arbitration
as one method of dispute resolution in the modern world. On the institutional aspect,
the arbitration is a form of dispute resolution method, which requires a workable
institutional framework to facilitate disputes resolution without causing unnecessary
delay or costs to the parties. This chapter examines and all the challenges facing
arbitration as far as the institutional aspect is concerned.
5.1 ARBITRATION INSTITUTIONS
Though Tanzanian courts have traditionally adopted a favourable attitude towards
arbitration, there are less private institutions for arbitration in the country. As it has
been observed, arbitration construction disputes proceedings in Tanzania can be
commenced directly in specialist arbitration tribunals or upon start of the proceedings
in the court if parties thereto agree to arbitrate.
Tanzanian legal system is based on the English common law in terms of substantive
law and procedures. Depending on jurisdiction issue and subject matter, apart from
arbitration, that requires a different approach, normal construction disputes can also
be adjudicated in the ordinary courts of law. About arbitration, pursuant to section 3
of the Arbitration Act, the only court having jurisdiction on arbitration cases is the
High Court of Tanzania whose decisions can be appealed to the Court of Appeal.
Currently, the High Court has three specialized divisions that are Commercial, Land,
and Labour divisions.
The Commercial Court shares jurisdiction over commercial matters concurrently with
the general division of the High Court and can act as a court of law as well as an
arbitral tribunal.
George Mandepo Reg. 200957963
Page | 52
5.1.1 Arbitration in Commercial Courts of Tanzania
The Commercial division commonly known as the Commercial Court was
established under the High Court Registries (Amendment) Rules, 199998. The Rules
empower the Court to determine all civil cases of a commercial nature including
arbitration proceedings99. The Commercial division of the High Court of Tanzania
was established with the express purpose of improving the efficiency and fairness of
commercial dispute resolution.
The division was established in order to solve the problem of poor case
management, delays and backlog of cases in the general registries of the High
Court. However, access to the commercial court can be very difficult for poor litigants
due to the higher case filing fees and pecuniary jurisdiction of the court. The
statutory minimum fee in 2002 was at least Tanzanian shillings 100 million (about
US$94,250). This has reduced the number of cases that are being brought before
the Commercial Court (Finnegan, 2005). In the other hand, though arbitration of
commercial dispute is part of the role of the court, this study has failed to find any
case determine through arbitration by the commercial court of Tanzania.
Also, as opposed to the UK where construction disputes are determined by the
Technology and Construction Court, in Tanzania neither the Commercial court nor
the ordinary High Court registries have such a specialized section to deal with
construction disputes. Therefore, all construction cases be it normal litigation or an
arbitration case, can be dealt either as a “commercial case” or normal disputes
depending on the registry where the matter has been filed. In that regard, as for
other cases, if the matter is taken to the court, the same problem of delays in
decision will be suffered by the litigants in the construction disputes.
5.1.2 Arbitration under NCC
As noted before, currently NCC is the only semi-government institution facilitating
arbitration of construction disputes in Tanzania. Under the NCC Arbitration Rules,
2001, NCC role regarding arbitration, is only to facilitate appointment of arbitrators
and coordination of all proceedings as the parties may agree.
98
. G.N. No 141 of 1999 99
Rule 2(a) (xi).
George Mandepo Reg. 200957963
Page | 53
In the process, NCC has been charging facilitation costs referred in the NCC Rules
as “administrative costs” imposed as part of the arbitration costs calculated by NCC
based on the estimated time required by the arbitrator to arrive at an award100 (not
the time required by Arbitration Act). NCC is empowered under the Rules to
determine the arbitration fees of the arbitrator based on the work done, his special
qualification, and complexity of a particular case to be determined.
Pursuant to Rules 14.3 and 4, the arbitration fees include the administrative costs of
NCC but do not cover other specific expenses incurred by NCC or arbitrator such as
travel costs, fees for venues, subsistence allowances, report of experts and any
advisory services which are charged at cost. Rule 14.1 of the NCC Rules state
categorically that from the commencement of the arbitration, all parties shall be
jointly and severally liable to the NCC for arbitration cost until they are fully paid.
NCC has a right to enforce payment of arbitration costs by filing an action in the
court to recover all unpaid costs of arbitration against any party101. In such
circumstances, sometimes, arbitration under NCC Rules may be an expensive
process for the parties as opposed to litigation in which the only required costs are
court fess for filling the case but not costs of adjudicating their matters.
Being a public-owned entity, NCC operations depend upon funds from the central
government. Due to the lack of financial and human resources, sometimes it can be
difficult for the NCC to undertake effectively the role of facilitating arbitration. The
other challenge to the arbitration under NCC is that, currently NCC has no offices
only in Dar es Salaam region despite the fact that Tanzania has more than 25
regions. Due to the lack of branch offices in other regions of the country, it is difficult
for all stakeholders in the construction industry outside Dar es Salaam to have their
arbitration disputes resolved through facilitation of NCC without incurring
unnecessary cost and delays.
5.1.3 Tanzania Institute of Arbitrators
The Tanzania Institute of Arbitrators (TIA) is another registered private NGO in
Tanzania whose main objective is to deal with arbitration. The Institution has been
collaborating with NCC in training of construction professionals and lawyers to
100
Rule 14.2 101
Rule 15.2
George Mandepo Reg. 200957963
Page | 54
become arbitrators. However, there is no record to show that the activeness of the
Institute in facilitating arbitration as it is for the neighbouring countries such as Kenya
and Uganda where private arbitration institutions are well organised and active102.
With increased pace in the use of ADR for commercial disputes, TIA can be
empowered to work effectively as a trusted institution for the promotion and
determination of disputes through arbitration and other forms of ADR in Tanzania.
It appears that lack of effective arbitration institutions in Tanzania compel the parties
in construction disputes to opt for litigation through traditional courts.
5.1.4 Arbitration Professionals
Apart from institutions, the success of arbitration also depends on the quality of
arbitrators. Concurrently with competent arbitration institutions to facilitate arbitration,
the need to have skilled arbitrators who are knowledgeable of arbitration procedures
and other forms of ADR is very important in the arbitration process.
As already pointed out, under the NCC Rules for instance, the appointment is made
from the list of arbitrators who are enrolled under NCC panel of arbitrators For a
person to be enrolled as an arbitrator under NCC he/she has to attend training
courses administered by NCC in collaboration with TIA and pass the relevant
examinations in procedures and practices of arbitration. The published list of
arbitrators by NCC103, as of July 2009, reveals that currently, there are only forty five
(45) approved arbitrators in Tanzania of which only 14 are lawyers and the rest are
engineers, quantity surveyors or architects.
This figure of 45 arbitrators is very small compared the to number of registered
contractors and the number of disputes occurring in the construction industry. As by
July 2010, there were about 2,527 local contractors, who constitute 96.41% of all
registered contractors in Tanzania104
102
In Kenya there is a Chartered Institute of Arbitrators Kenya Branch, established in 1984 and now has about 300 registered (http://www.ciarbkenya.org/about.html) and the Centre for Arbitration and Dispute Resolution of Uganda ( established by the Arbitration and Conciliation Act, 2000 of Uganda 103
http://www.ncc.or.tz/ArbitratorsListJuly09.pdf. 104
The Express News Paper of 07/29/2010 (Tanzania) http://theexpress.server295.com/node/894
George Mandepo Reg. 200957963
Page | 55
CHAPTER SIX
FINDINGS, CONCLUSION AND RECOMMENDATIONS
6.1 FINDINGS AND CONCLUSION
The complex nature of projects in the construction industry has made disputes
unavoidable. Disputes in construction can be caused by various factors mostly being
risk or uncertainties inherent in the project concerned or parties’ attitudes. As argued
by Brown and Marriot (1999), dissatisfaction with litigation as a form of dispute
resolution has led to the development of various alternative forms of dispute
resolution including arbitration.
Arbitration as an alternative to litigation has been widely acceptable as an effective
dispute resolution method especially in domestic and international trade
transactions. This is evidenced by the worldwide reforms of arbitration systems in the
form of international harmonization of the procedures and substantive arbitration
laws.
The main focus of this study was to examine how the existing legal and institutional
framework for arbitration in Tanzania is effective in assisting the parties to the
construction dispute to resolve their dispute. The study was made by identifying gaps
and or inconsistencies with the existing Tanzanian laws and arbitration institutions.
The study has revealed that the resolving of construction disputes through arbitration
in Tanzania is governed by the Arbitration Act, Cap. 15, Civil Procedure Act Cap. 33
and the NCC Arbitration Act 2001 Edition. It has been also found that the main
arbitration law (Arbitration Act and its Rules) being a replica of the English
Arbitration Act 1889 contain various provisions which cannot assist in the facilitation
of resolution of commercial disputes in compliance with modern arbitration
requirements.
It has been observed that the procedure under the Arbitration Act is different from
that provided in the CPC and the NCC Rules. CPC provided for the arbitration that
can arise in the course of the court’s proceedings, whereas arbitration under the
Arbitration Act and NCC Rules are based on the arbitration agreement without an
intervention of the court. Though NCC Rules that deal with construction disputes are
George Mandepo Reg. 200957963
Page | 56
based on the UNICITRAL Model law, they are just as procedural rules in a form of
subsidiary legislation that cannot in any way supersede the main legislation i.e.
Arbitration Act (Cap. 15) and its Arbitration Rules, 1957 which are however out-
dated.
Among others, the following shortcomings have been identified in the arbitration
system for Tanzania, namely:-
(i) lack of founding principles in the legislation to guide arbitration as compared
with arbitration legislation of other countries such as the English and Scottish
Arbitration laws;
(ii) too much power vested to the court to control the arbitration proceedings
including discretion of judges to order stay of proceedings pending arbitration;
(iii) lack of powers of arbitrator(s) or umpires to determine their
competence/jurisdiction of tribunal, to issue interim orders, to award interest
on costs, to order joinder of proceedings or parties;
(iv) lack of details on procedural matters to guide the tribunals on the conduct of
arbitration proceedings such as filing of proceedings, discoveries and
administration of evidence;
(v) lack of provision to allow the parties to remove the arbitrator at their own
wishes;
(vi) inconsistencies in procedures for enforcement or challenging of an award
delivered by the arbitrators appointed under the Arbitration Act and those
appointed under CPC or NCC Rules;
(vii) lack of any provision in respect of mandatory issues which should be
covered in the arbitral award; and
(viii) lack of appropriate provision empowering the arbitrator to award interest on
costs of the matter.
The study also observed that as far as arbitration institutions in Tanzania are
concerned, NCC seems to be an active arbitration institution in dealing with
construction disputes. However, NCC as a public owned institution entrusted with
other core mandates in respect of the construction industry lacks enough competent
George Mandepo Reg. 200957963
Page | 57
enrolled arbitrators something that poses a great challenge to the institution for
effective resolution of construction disputes.
6.2 RECOMMENDATION
Although parties are free to determine the procedure applicable to their arbitration,
national laws also have a significant impact on arbitral proceedings. International
agreements such as UNICITRAL Model law, Geneva Convention and New York
Convention on Enforcement have played a major role in harmonization of
procedures and promotion of settlement of the international trade disputes through
consensual methods such as arbitration.
Several Contracting parties to the aforementioned international agreements have
enjoyed great support in developing their own national arbitration legal frameworks
so as to create better environment for the settlement of disputes through arbitration.
It is therefore recommended that Tanzania should modernize its arbitration law in the
light of the ratified multilateral and regional conventions so as to ensure
effectiveness in settlement of disputes.
Apart from compliance with the international conventions of arbitration, the revising
of its arbitration law will enable Tanzania to step on the same footing with her
neighbours and trading partners under the East Africa Community i.e. Kenya and
Uganda whose laws have been revised in line with the UNCITRAL Model law.
It is also recommended that the Tanzanian Government should promote the
establishment of private arbitration institutions so that they can work effectively in
facilitation and promotion of arbitration and other ADR forms of dispute resolution in
the construction industry.
George Mandepo Reg. 200957963
Page | 58
BIBLIOGRAPHY
American Arbitration Association (AAA) (1996b) Building Success for the 21st
Century: A Guide to Partnering in the Construction Industry [WWW doc.] URL
http://www.adr.org (visited, 2010, August 15).
Andrew, W. R. (2005) ‘The Demise of Adjudication and the Rise of Arbitration: Are
you sure? 2005 A Dispute Resolution Odyssey’ :( unpublished LLM
Dissertation, University of Strathclyde).
Brown, H.J and Marriot. A.L. (1999) ADR Principles and Practice, 2nd Ed.London:
Sweet and Maxwell.
Chan, E. H. W. (1997), 'Amicable dispute resolution in the People's Republic of
China and its implications for foreign-related construction disputes',
Construction Management and Economics, , pp 539-548.
Chau,K.W.(2007)’Insight into resolving construction disputes by
Mediation/Adjudication in Hong Kong, Journal of Professional Issues in
Engineering Education and Practice, ASCE, Vol. 133, No. 2, 2007, pp. 143-
147.
Cheung S. O (1999) ‘Critical factors affecting the use of alternative dispute resolution
processes in construction’ International Journal of Project Management
Volume 17, Issue 3, June 1999, Pages 189-194 Elsevier Science Ltd and
IPMA.
Cheung S. O and Wing Y. T (2006) ‘Are Construction Disputes Inevitable?’ in IEEE
Transactions on Engineering Management, Vol. 53, NO. 3, August 2006.
Cheung S.,Suen, H. C. H. and Lam., (2002) ‘Fundamentals of alternative dispute
resolution processes in construction’, Journal of construction Engineering and
Management, pp 28-294.
Cheung, S.,Tam, C. M., Ndekugri, I. and Harris, F. C. (2000), 'Factors affecting
clients' project dispute resolution satisfaction in Hong Kong', Construction
Management and Economics, pp 281-294.
Cheung, S.O. and Yiu, K.T.W. (2007) ‘A study of construction mediator tactics—Part
I: taxonomies of dispute sources, mediator tactics and mediation outcomes’,
Building and Environment, 752-761.
George Mandepo Reg. 200957963
Page | 59
COBRA (2008) ‘Proceedings of The construction and building research conference
of the Royal Institution of Chartered Surveyors: Held at Dublin Institute of
Technology, 4-5 September 2008 (WWW doc).URL:
http://www.rics.org/site/download_feed.aspx?fileID=3161&fileExtension=PDF
(Visited 2010, August 7).
Conlin, D.A. Langford, & P. Kennedy (1996)The Sources, Causes and Effects of
Construction Disputes: A Research Project. CIB Rpt. 02544083.
Conlin, J., Langford, D. and Kennedy, P. (1996), The relationship between
construction procurement strategies and construction contract disputes, in
Taylor, R.G. (Ed), CIB W92 'North meets South' Procurement Systems
Symposium, Durban, South Africa, 14- 17 January 1996, pp 66-82.
Daele, K. (2010). Arbitration Tanzania. In G. L. Review, Getting a deal Through
Arbitartion: Arbitration 2010 (p. 330.). London : Law Business Research Ltd.
Debrah, Y. A. and Ofori, G. (2005)'Emerging managerial competencies of
professionals in the Tanzanian construction industry', The International Journal
of Human Resource Management. London: Routledge.
Egan, J. (1998) Rethinking Construction, London, Department of Environment,
Transport and Regions (DETR).
Elis, F. and Baiden, B.K. (2008) ‘A conceptual model for conflict management in
construction firms, in Jin, X. and Doloi, H. (Eds), Proceedings of the
Construction and Building Research Conference of the Royal Institution of
Chartered Surveyors (COBRA 2008), RICS, Dublin, 4-5 September 2008,
[WWW. document] http://www.rics.org/NR/rdonlyres/D9156965-B8BD-4E1D-
9DD3-F0362F87756B/0/Baiden2.pdf, (visited 2010, Sept 15).
Epling, J. A. (1987) Resolving international construction disputes Vol. 5 No 4
Butterworth & Co (Publishers) Ltd 217.
Fauz, T. (2006) ‘Legal Empowerment of the Poor: Access to Justice and Rule of
Law’ in National Consultation on Legal Empowerment of the Poor in Tanzania,
National Conference November 29-30, 2006, Dar es Salaam, Tanzania
(Unpublished).
George Mandepo Reg. 200957963
Page | 60
Finnegan D. L (2005) Judicial Reform and Commercial Justice: The Experience Of
Tanzania’s Commercial Court: Background paper prepared for the World
Development Report (WWW document: URL:
http://siteresources.worldbank.org/INTWDR2005/Resources/finnegan_judicial_r
eform.pdf (Visited 2010, August 10).
Graffi D. L (2006) ‘Securing harmonized effects of Arbitration Agreements under the
New York Convention’ in Houston Journal of International Law, springs, [WWW
Document] URL http://www.highbeam.com/doc/1G1-147302386.html (visited
2010, August 24).
Hall, J. M. (2002) Ineffective communication: Common causes of construction
disputes. Alliance’s Advisory Council Legal Notes. Vol. 13, No.2.
Hellard, B.R. (1997) Preventing and solving construction contract disputes. Litton
Educational publishing company.
Kumaraswamy M. M. (1998) ‘Consequences of construction conflict: A Hong Kong
perspective", J. Manage. Eng., vol. 14, pp. 66 1998.
Kumaraswamy, M.M. (1998), Tracing the root causes of construction claims and
disputes, In Keeping, M. and Shiers, D. (Eds), Proceedings of the Construction
and Building Research Conference of the Royal Institution of Chartered
Surveyors (COBRA1998), RICS, Oxford, 2-3 September 1998, pp 26-35.
Kumaraswamy, M.M. and Chang, D.W.M (1998), ‘Contributors to construction
delays’, Construction Management and Economics, pp 17-29.
Latham, M. (1994), Constructing the Team, HMSO, London.
Levy, S.M. (2007) Project Management in construction, 5th Edition pages 261-
293.McGraw Hill companies.
Love, P E D, Davis, P, Kerry London, K and Jasper, T.(2008) Causal Modelling of
Construction Disputes. In Dainty, A (Ed) Procs 24th Annual ARCOM
Conference, 1-3 September 2008, Cardiff, UK, Association of Researchers in
Construction Management, 869-878.
Marks R. J., et al (1978) Aspect of Civil Engineering Contract Procedure, - 2nd Ed.
Robert Maxwell, and MC.
George Mandepo Reg. 200957963
Page | 61
Mazirow Arthur (2008) “ The Advantages and Disadvantages of Arbitration as
compared to Litigation” Paper presented to the Counsellors of Real Estate April
13, 2008 Chicago, Illinois (WWW document : URL:
http://www.cre.org/images/MY08/presentations/The_Advantages_And_Disadva
ntages_of_Arbitration_As_Compared_to_Litigation_2_Mazirow.pdf (visited
2010, August 11) .
Mkono, N. E, Kapinga, W. B and Daele K. (2007) ‘Arbitration Tanzania [WWW doc.]
URL http://www.mkono.com/pdf/Arbitration_getting_the_deal_through_2007.pdf
(visited, 2010, August 23).
Muigua, K.(2008) ‘The Arbitration Acts: A Review of Arbitration Act, 1995 of Kenya
Vis-a-Viz Arbitration Act 1996 of United Kingdom, 25-26 August 2008 A Lecture
Paper Delivered at the Chartered Institute of Arbitrators - Kenya Branch Entry
Course held at College of Insurance, Nairobi. [WWW.doc.]
http://www.kmco.co.ke/attachments/075_ARBITRATION_ACT_REVIEW.pdf
(visited 2010, Sept 19).
Murdoch, J. and Hughes, W. (2008) Construction Contracts. Law and Management.
4th ed., Taylor & Francis, London.
Oladapo, A and Onabanjo, B. (2009) ‘A study of the causes and resolution of
disputes in the Nigerian construction industry RICS COBRA Research
Conference, University of Cape Town, 10-11th September 2009.7-22 London,
RICS [WWW.doc.]
http://www.rics.org/site/download_feed.aspx?fileID=4943&fileExtension=PDF
(visited, 2010, Sept 18).
Onyema, E. (2008) Effective Utilization of Arbitrators and Arbitration Institutions in
Africa by Appointors. In: 4thInternational Arbitration & ADR in Africa Workshop,
29 - 31 July 2008, Conrad Hilton, Cairo, Egypt. (Unpublished).
Poh, K. C.(2005) ‘The causes of Construction Dispute on Client Organizations.
(Unpublished Masters thesis, Universiti Teknologi Malaysia. [WWW doc.] URL
http://eprints.utm.my/4437/1/KohCheoPohKPFKA2005TTT.pdf (Visited, 2010,
August 8).
Ravi Kumar, K., Kumar, V.S.S., and Rao, D.S.P.(2007)‘Alternative Dispute
Resolution in Construction Industry’ Proceedings of National Conference on
George Mandepo Reg. 200957963
Page | 62
Formulation of Construction Law in India, New Delhi, India. [WWW.doct]
http://iccindia.org/construction_law/K%20Ravi%20Kumar.pdf (visited 2010,
August 24).
Reid, A. and Ellis, R. (2007) ‘Common sense applied to the definition of a dispute’.
Structural Survey, 25(3), pp. 239-252.
Sakal, M. W. (2004) Constructing Projects in a Dynamic Environment: A Focus on
Relational Contracting, Master of engineering report, University of California
Berkeley, unpublished. [WWW doc.] URL www.leanconstructionjournal.org
(Visited, 2010, August 7).
Samson L. S (1992). ‘Obstacles to International Commercial Arbitration in African
Countries’, International & Comparative Law Quarterly, 41, pp 387-413.
Sherwin .P, Vermal A. and Figueira E, (2007) ‘Proskauer on International Litigation
and Arbitration: Managing, Resolving, and Avoiding Cross-Border Business or
Regulatory’ WWW doc] URL http://www.proskauerguide.com/arbitration/19/V
(visited, 2010, Sept 16).
Smith R M. (1998) ‘ADR for Financial Institutions’, West Group, 2nd ed. 1200 pp.)
[WWW doc.] URL:
http://www.robertmsmith.com/about_adr/arbitration_overview.asp (Visited 2010,
August 7).
Smith T. P.(2004) ‘Arbitration (Scotland) Bill 2002 v Adjudication’ (unpublished LL.M.
dissertation, University of Strathclyde).
Steen, R. H. (2002) Alternative dispute resolution in the Construction industry
[WWW.doc] http://www.njsba.com/activities/DRP-Steen-
Constrresolutioninconstructionwithinfomaster.pdf (visited 2010, August 13).
The Joint Contracts Tribunal Limited (JCT) (2005)’Construction Industry Model
Arbitration Rules, London, Sweet & Maxwell Limited.
Uff J. (2009) Construction Law – 10th Editions. London Sweet & Maxwell.
Wahi, N. (2008) ‘Minimising construction disputes’ (Unpublished Masters thesis,
Universiti Teknologi Malaysia [WWW.doc.]
http://eprints.utm.my/9576/1/NoraziahWahiMFKA2008.pdf(visited 2010,August
24).
George Mandepo Reg. 200957963
Page | 63
Walton, J. G. (2005) Avoiding construction disputes just a matter of price?
[WWW.doc] URL http://www.johnwalton.co.nz/bits/avoiddispute.pdf
Yates, D. (June 2003) ‘Can claims and disputes (in construction contracts) be
prevented or reduced?’ Building Journal Hong Kong China [WWW.Doc.] URL.
http://www.building.com.hk/forum/10_03canclaims.pdf (visited, 2010, Sept 19).
Yiu K.T.W. and Cheung S. O. (2006) ‘A catastrophe model of construction conflict
behavior’ Building and Environment. Volume 41, Issue 4.pages 438-447.
Yiu, K.T.W. and Cheung, S.O. (2007) Behavioural transition: a framework for
construction Conflict-tension relationships. IEEE Transactions on Engineering
Management, 498-505.