tender for s / i / t / c of air conditioning system & all ... · works (electrical items) 201...
TRANSCRIPT
नाबार्ड, महाराष्ट्र क्षेत्रिय कायाडलय इमारत, त्रिवाजी नगर, पुणे में एयर कंत्रर्िननंग और सभी आपेत्रक्षत
त्रसत्रवल और संबद्ध कायो की आपूर्तड, स्थापना, पररक्षण एवं कत्रमिननंग' का कायड के त्रलये त्रनत्रवधा.
TENDER FOR S / I / T / C OF AIR CONDITIONING SYSTEM & ALL
REQUIRED CIVIL & ALLIED WORKS, FOR NABARD, MAHARASHTRA
REGIONAL OFFICE, 54 WELLESLEY ROAD, SHIVAJI NAGAR, PUNE -411
005.
सदंर्भ स.ं एनबी.एमआरओ.डीपीएसपी/ 972 / कायाडलय ए सी/2017-18
RFQ Ref. No. NB:MRO.DPSP./ 972 /Office AC /2017-18
ननविदा जारी करने की तारीख: 22/05/2017 DATE OF ISSUE OF TENDER: - 22/05/2017
बोली पिूभ बठैक की तारीख नाबाडभ मके्षका, पणेु में 29/05/2017 को अपराह्न 3.00 बजे
DATE OF PRE-BID MEETING: - ON 29/05/2017 AT 3:00 P.M. AT NABARD, MRO, PUNE
ननविदा प्रस् ततु करने की तारीख 09/06/2017 या उससे पहले अपराह्न 2.00 बजे तक
DATE OF SUBMISSION OF TENDER: - ON OR BEFORE 09/06/2017 UPTO 2:00 P.M.
ननविदा खोलने की तारीख 09/06/2017 को अपराह्न 3.00 बजे तक
DATE OF OPENING OF TENDER: - ON 09/06/2017 AT 3.00 P.M.
बोली की सरुक्षा की िलै् य(ूबयबयाना रान रु. 8,20,000/- EARNEST MONEY DEPOSIT (EMD) Rs.8,20,000/-
CLIENT: क् लाइंट:
मुख् य महाप्रबंकक, THE CHIEF GENERAL MANAGER,
राष्ट रीय कऔ व ्र मीणामीण विकास ब क NATIONAL BANK FOR AGRICULTURE AND RURAL DEVELOPMENT,
महाराष्ट र क्षेीीय कायाभलय MAHARASHTRA REGIONAL OFFICE,
54, िेलेस् ली रोड, न िाजीनगर 54, WELLESLEY ROAD, ,SHIVAJI NAGAR,
पुणे- 411 005 PUNE – 411 005. 020-25500118, 25500285, [email protected]
बोलीदाता के हस् ताक्षर
Signature of Bidder
Page 1
TENDER FOR
S / I / T / C AIR CONDITIONING
SYSTEM & ALL REQUIRED CIVIL &
ALLIED WORKS
TAKING RURAL INDIA >>FORWARD
MAHARASHTRA REGIONAL OFFICE, PUNE 54, WELLESLEY ROAD, SHIVAJI NAGAR, PUNE - 411005
MEP CONSULTANTS
M/s. TARUN G BARAI CONSULTANT
303 FLYOVER APT, 12 A TELI GALI, ANDHERI (E), MUMBAI – 400 069.
WWW.TBCMEP.COM
TENDER SCHEDULE
Pre-bid meeting : 29 May 2017 AT 3:00 P.M
Last date for submission of Sealed Tender : 09 June 2017 BY 2.00 P.M
Opening of Technical Bids : 09 June 2017 AT 3.00 P.M
Name of the Contractor to whom issued : ______________________
Address : ______________________
______________________
Client:
CHIEF GENERAL MANAGER
NABARD, MAHARSHTRA REGIONAL OFFICE 54, WELLESLEY ROAD, SHIVAJI NAGAR
PUNE - 411005
Page 2
BLANK PAGE
TABLE OF CONTENTS
Page 3
SI.NO.
PARTICULARS
PAGE
FROM TO
PART 1 - TECHNICAL BID
1. NOTICE INVITING TENDER 5 8
2. INTEGRITY PACT (to be submitted separately in sealed envelope)
9 15
3. FORM OF TENDER 17 18
4. ARTICLES OF AGREEMENT 19 22
5. GENERAL INSTRUCTION 23 25
6. GENERAL CONDITIONS OF CONTRACT 26 49
7.
.
SPECIAL CONDITIONS OF CONTRACT 50 72
8. GENERAL DISCRIPTION OF WORKS 73 76
9. TECHNICAL SPECIFICATION OF AIR CONDITIONING WORK
77 86
10. SHEET METAL WORK 87 92
11. INSULATION WORK 93 93
12.
REFRIGERANT PIPING 94 96
13. ELECTRICAL WORK (HVAC) 97 110
14. TECHNICAL SPECIFICATION OF ELECTRICAL WORK
111 183
15. TECHNICAL DATA SHEET 184 200
16. METHOD OF MEASUREMENT FOR WORKS (Electrical Items)
201 202
17. APPENDIX 203 203 18. DECLARATION 204 204
19. APPROVED MAKES OF EQUIPMENT & MATERIALS
205 207
20. FORMAT OF BANK GUARANTEE FOR EMD (to be submitted in separate envelope alongwith Technical Bid)
209 211
21. DRAWINGS 213 223
PART 2 - FINANCIAL BID
22. BOQ – HVAC WORK 227 232
23. BOQ – ELECTRICAL WORK 233 243
24. BOQ – FLASE CEILING WORK 245 246
Page 4
TENDER FOR
S / I / T / C AIR CONDITIONING
SYSTEM & ALL REQUIRED CIVIL &
ALLIED WORKS
PART - 1
TECHNICAL BID
Page 5
1. NOTICE INVITING TENDER
M/s Date: 19 May 2017
Dear Sir
TENDER FOR S / I / T / C OF AIR CONDITIONING SYSTEM & ALL REQUIRED
CIVIL & ALLIED WORKS, FOR NABARD, MAHARASHTRA REGIONAL OFFICE,
54 WELLESLEY ROAD, SHIVAJI NAGAR, PUNE -411 005.
1. National Bank for Agriculture and Rural Development (NABARD) invites you to
tender for the aforesaid work. National Bank for Agriculture and Rural Development (NABARD) intends to setup supply, installation, testing &
commissioning of Air Conditioning system and all required civil & allied works at NABARD, Maharashtra Regional Office, Pune. You are requested to submit your Bids in sealed envelope for the aforesaid work as per detailed specifications and
other requirements as mentioned more specifically elsewhere in this tender document.
2. Sealed Bids in THREE separate sealed Envelopes indicating clearly
‘Envelope No.1 – Integrity Pact', 'Envelop-2 - Technical bid' and 'Envelope No.3 – Financial/Price bid', should be addressed by name to CHIEF GENERAL MANAGER, NABARD, MAHARASHTRA REGIONAL OFFICE, 54 WELLESLEY
ROAD, SHIVAJI NAGAR, PUNE – 411005 and Envelops should also be super scribed “TENDER FOR S / I / T / C OF AIR CONDITIONING SYSTEM & ALL REQUIRED CIVIL & ALLIED WORKS”. The tender should be submitted not later
than 09 June 2017 by 2.00 P.M.
3. This NIT (tender document) can be downloaded from our website at https://www.nabard.org/English/Tenders.aspx. The tender document will be available on the website, till the date of submission. Tender fee of Rs 1,500/-
(Rupees One Thousand Five Hundred Only) in the form of Demand Draft drawn in favour of NABARD and payable at Pune to be submitted at the time of collection of Tender document in physical form. If, tenderer wish to download the tender
document from our website, he has to submit tender fee separately at the time of submission of tender. No tender will be received without Tender fee. Tenderers
must submit tender in either downloaded document or physically purchased document from NABARD Pune Office.
4. Envelope No.1 shall contain Integrity Pact (IP) as per format given, duly signed and stamped by the bidder. Tenders submitted without IP will summarily be
rejected and their subsequent envelops will not be opened. Envelope No.1 will be opened on the last day of submission of tender at 15.00 hrs. in presence of the
bidders’ representative, should they choose to be present.
Page 6
5. Envelope no. 2 shall contain:
a. “Technical bid” of tender with every page signed and stamped.
b. Bar Chart indicating the program for the execution of the work.
c. An initial part amount of Rs 8,20,000/- (Rupees Eight lakh twenty thousand only) towards Earnest Money Deposit (EMD) by way of a Bank Guarantee from Nationalised/Scheduled Bank as per format given in this tender, to be submitted alongwith “Technical Bid” in a separate envelop. EMD envelop shall be super scribed as EMD towards S/I/T/C of AC work Tender. The Tender without EMD shall be rejected out rightly. No interest shall be paid on the EMD.
d. The Initial Security deposit(ISD), which will be 2% of the accepted value of the tender minus initial part payment i.e. EMD, will be submitted by the successful tenderer in form of bank draft from a scheduled bank within 15 days of intimation to him of acceptance of his tender. No interest shall be paid on the ISD
e. Power of attorney authorizing the person to sign the tender.
f. Technical bids of only those bidders will be opened, whose Integrity Pact (IP) found eligible. Technical bids be opened immediately after opening of IPs.
6. Envelope No.3 shall contain
a. Financial / Price Bid and addressed by name to CHIEF GENERAL
MANAGER, NABARD, MAHARASHTRA REGIONAL OFFICE, 54 WELLESLEY ROAD, SHIVAJI NAGAR, PUNE - 411005.
b. Envelope No.3 shall not contain any condition whatsoever and any
conditional bids shall be rejected. c. Envelope No.3 will be opened on some suitable date, which will be
communicated later on, after scrutiny of the documents submitted by tenderers. Financial/price Bid envelopes shall be opened only in respect of those tenderers who have complied with all the requirements in tender
document.
7. If the last date of receipt or opening of the tenders happens to be a holiday for NABARD, then the receipt and opening of the tenders shall be shifted to next
working day without change of time and venue.
8. A pre-bid meeting will be held at NABARD, MAHARASHTRA REGIONAL OFFICE,
54 WELLESLEY ROAD, SHIVAJI NAGAR, PUNE – 411005 at 3.00 P.M on 29 May 2017 with the prospective bidders to clarify any issues pertaining to the tender. The bidders are expected to thoroughly read the tender document before
being present for the pre-bid meeting, so as to understand all aspects of the work.
9. Before filling up the tenders, the bidders may note the following:
a. The bids shall remain valid and open for acceptance for 3 months from the date of opening of Envelope No.1. If the tenderer withdraws his tender before the expiry of the said period or makes any modifications in terms and
condition of the tender which are not acceptable to the Bank, then the bank
Page 7
without prejudice to any other right or remedy will be at liberty to forfeit the earnest money.
b. Time of Completion: Time is the essence of the contract. The Contractor
shall be allowed to execute the work after working hours, in nights & on
holidays, with the prior permission from NABARD authority. No extra
payments will be made for the work being done during the odd hours. Date of
commencement shall be either one-week, from the date of issue work
order to the contractor or day on which the contractor will take
possession of site whichever is earlier. The work shall be completed
within 10 Weeks from the date of commencement. The successful Contractor
will have to give bar/activity chart of various activities of works to be done so
that the work gets completed within the stipulated time. The chart shall be
submitted at the time of commencement of work.
c. Liquidated damages for delay in completion of the works will be levied at
0.25% of the value of the accepted tender for every week of delay or part
thereof, subject to maximum of 5% of the value of the accepted tender.
d. The contractors should quote the rate in figures as well as in the words, and
amount tendered by them. The rate for each item should be worked out and
the requisite total amount shall be calculated accordingly. Rates quoted by
the contractor in item rate tender in figures and words shall be accurately
filled in so that there is no discrepancy in the rates, figures and words.
However, if a discrepancy is found in the rates in words and figures, the rates
which correspond to the total amount worked out by the contractor shall be
taken as correct. In case, the rate assessed does not work out by the amount
of an item or it does not correspond with the rate written either in figure or in
words, then the rates quoted by the contractor in words shall be taken as
correct. Where the rates quoted by the contractor in figures and in words
tally but the amount is not worked out correctly the rates quoted by the
contractor will be taken as correct and not the amount.
e. The tender document must be filled in English and all the entries must be
hand written or neatly typed. If any of the documents are missing or un-
signed in financial/price bid, the tender shall be considered invalid. In case
of technical bid, the details of incomplete or missing documents will be
intimated to contractors verbally/writing and the contractor has to submit all
those documents within 2 days after opening of the technical bid, otherwise
the tender will be rejected.
f. NABARD reserves the right to accept or reject any /all tender/s in part or whole of any firm / firms without assigning any reasons for doing so.
g. Canvassing in connection with tenders is strictly prohibited and the tenders submitted by the contractors who resort to canvassing will be liable to
rejection.
h. All taxes including Service tax, works contract tax, VAT, turnover tax, Sales Tax or any other payable/ prevailing tax on material or on finished works etc,
in respect of this contract shall be payable by contractor and the Bank will not entertain any claim whatsoever in this respect over the quoted price.
Page 8
i. The tenderer, apart from being a competent contractor must co-ordinate
himself with all the agencies as and when required.
j. The tenderer should visit the site to ascertain the working conditions and local authority regulations / restrictions if any and other information required
for the proper execution of the work.
k. The quantities of various items given in the schedule of quantities are approximate. The quantities of work may vary at time of allotment / execution of work. Bank reserves the right to omit / delete any item(s) of work
from the schedule at the time of allotment / before. Contractor will be paid for the actual work done at the site duly verified by the consultant and concerned
official of the bank.
l. If the rate quoted by the contractor for any item / items are not workable or abnormally lower than the market rate, the full and final payment of the contractor will be settled after the satisfactory execution of
these item.
m. NABARD does not bind itself to accept the lowest or any tender at all. NABARD also reserves the right to negotiate or partly accept any tender
or all tenders received without assigning any reasons thereof.
n. Any discrepancies, omissions, ambiguities in the tender documents, if any, or any doubt as to their meaning should be reported in writing to CHIEF GENERAL MANAGER, NABARD, MAHARASHTRA REGIONAL OFFICE, 54
WELLESLEY ROAD, SHIVAJI NAGAR, PUNE, 411005 who will review the questions and if information sought is not clearly indicated or specified,
NABARD will issue clarifications to all the tenderers which will become part of the Tender Document. NABARD will not be responsible if the discrepancies, omissions, ambiguities in the tender documents or any doubts as to their
meaning are not brought to the notice of NABARD before three working days prior to the last date of submission of the tender.
o. NABARD also reserves the right to divide and distribute the work to more than
one tenderer at its sole discretion.
p. The successful bidder shall execute an agreement on non-judicial stamp paper with NABARD in accordance with the standard format enclosed (Articles of Agreement) within 14 days from date of issue of work order failing which the days bidder’s EMD may stand forfeited.
(Dr. R.N Kulkarni) CHIEF GENERAL MANAGER
Page 9
2. INTEGRITY PACT
1. General
This pre-bid pre-contract Agreement (hereinafter called the Integrity Pact) is made on
______________ day of the month of __________ between, on one hand, National Bank for
Agriculture and Rural Development (NABARD), represented by Shri
________________________________ (hereinafter called the “BUYER”, which expression shall
mean and include, unless the context otherwise requires, his successors in office and
assigns) of the First Part and M/s _______________________ represented by Shri
_______________________, Chief Executive Officer (hereinafter called “BIDDER/Seller”
which expression shall mean and include, unless the context otherwise requires, his
successors and permitted assigns) of the Second Part.
WHEREAS the BUYER proposes to getting executed the work of Supply, Installation,
Testing and Commissioning of Air conditioning work and all required civil and allied works
at NABARD, MAHARASHTRA REGIONAL OFFICE, 54, WELLESLEY ROAD, SHIVAJI
NAGAR, PUNE - 411005 and the BIDDER is willing to offer/ has offered the work and
WHEREAS THE BIDDER is a private company/ public company/ Government
undertaking/ partnership/ registered agency, constituted in accordance with the relevant
law in the matter and the BUYER is a body corporate established under NABARD Act,
1981 having its Head Office at Plot No. C-24, Block ‘G’, Bandra-Kurla Complex,
Bandra(East), Mumbai.
NOW, THEREFORE,
To avoid all forms of corruption by following a system that is fair, transparent and free
from any influence/ prejudiced dealings prior to, during and subsequent to the currency
of the contract to be entered into with a view to :-
Enabling the BUYER to obtain the desired said work at a competitive price in conformity
with the defined specifications by avoiding the high cost and the distortionary impact of
corruption on public procurement and
Enabling BIDDERs to abstain from bribing or indulging in any corrupt practice in order
to secure the contract by providing assurance to them that their competitors will also
abstain from bribing and other corrupt practices and the BUYER will commit to prevent
corruption, in any form, by its officials by following transparent procedures.
The parties hereto hereby agree to enter into this Integrity Pact and agree as follows:
2. Commitments of the BUYER
The BUYER undertakes that no official of the BUYER, connected directly or indirectly
with the contract, will demand, take a promise for or accept, directly or through
intermediaries, any bribe, consideration, gift, reward, favour or any material or
immaterial benefit of any other advantage from the BIDDER, either for themselves or for
any person, organization or third party related to the contract in exchange for an
advantage in the bidding process, bid evaluation, contracting or implementation process
related to the contract.
Page 10
The BUYER will, during the pre-contract stage, treat all BIDDERs alike and will provide to
all BIDDERs the same information and will not provide any such information to any
particular BIDDER which could afford an advantage to that particular BIDDER in
comparison to other BIDDERs.
All the officials of the BUYER will report to the appropriate Government office any
attempted or completed breaches of the above commitments as well as any substantial
suspicion of such a breach.
In case any such preceding misconduct on the part of such official(s) is reported by the
BIDDER to the BUYER with full and verifiable facts and the same is prima facie found to
the correct by the BUYER, necessary disciplinary proceedings, or any other action as
deemed fit including criminal proceedings may be initiated by the BUYER and such a
person shall be debarred from further dealings related to the contract process. In such a
case while an enquiry in being conducted by the BUYER the proceedings under the
contract would not be stalled.
3. Commitments of BIDDERs
The BIDDER commits itself to take all measures to prevent corrupt practices, unfair
means and illegal activities during any stage of its bid or during an pre-contract or post-
contract stage in order to secure the contract or in furtherance to secure it and in
particular commit itself to the following :-
The BIDDER will not offer, directly or through intermediaries, any bribe, gift,
consideration, reward, favour, any material immaterial benefit or other advantage,
commission, fees, brokerage or inducement to any official of the BUYER, connected
directly or indirectly with the bidding process, or to any person, organization or third
party related to the contract in exchange for any advantage in the bidding, evaluation,
contracting and implementation of the contract.
The BIDDER further undertakes that it has not given, offered or promised to give, directly
or indirectly any bribe, gift, consideration, reward, favour, any material or immaterial
benefit or other advantage, commission, fees, brokerage or inducement to any official of
the BUYER or otherwise in procuring the Contract or forbearing to do or having done any
act in relation to the obtaining or execution of the contract or any other contract with the
Bank for showing or forbearing to show favour or disfavor to any person in relation to the
contract or any other contract with the Bank.
BIDDERs shall disclose the name and address of agents and representatives and Indian
BIDDERs shall disclose their foreign principles or associates.
BIDDERs shall disclose the payments to be made by them to agents/ brokers or any
other intermediary, in connection with this bid/ contract.
The BIDDER further confirms and declares to the BUYER that the BIDDER is the original
manufacturer/ integrator/ authorized government sponsored export entity of the defence
stores and has not engaged any individual or firm or company whether Indian or foreign
to intercede, facilitate or in any way to recommend to the BUYER or any of its
functionaries, whether officially or unofficially to the award of the contract to the
BIDDER, nor has any amount been paid, promised or intended to be paid to any such
Page 11
individual, firm or company in respect of any such intercession, facilitation or
recommendation.
The BIDDER, either while presenting the bid or during pre-contract negotiations or before
signing the contract, shall disclose any payments he has made, is committed to or
intends to make to officials of the BUYER or their family members, agents, brokers or any
other intermediaries in connection with the contract and the details of services agreed
upon for such payments.
The BIDDER will not collude with other parties interested in the contract to impair the
transparency, fairness and progress of the bidding process, bid evaluation, contracting
and implementation of the contract.
The BIDDER will not accept any advantage in exchange for any corrupt practice, unfair
means and illegal activities.
The BIDDER shall not use improperly for purposes of competition or personal gain or
pass on to others, any information provided by the BUYER as part of the business
relationship regarding plans, technical proposals and business details, including
information contained in any electronic data carrier. The BIDDER also undertakes to
exercise due and adequate care lest any such information is divulged.
The BIDDER commits to refrain from giving any complaint directly or through any other
manner without supporting it with full and verifiable facts.
The BIDDER shall not instigate or cause to instigate any third person to commit any of
the actions mentioned above.
If the BIDDER or any employee of the BIDDER or any person acting on behalf of the
BIDDER either directly or indirectly is a relative of any of the officers of the BUYER, or
alternatively if any relative of an officer of the BUYER has financial interest/ stake in the
BIDDER’s firm, the same shall be disclosed by the BIDDER at the time of filling of tender.
The term ‘relative’ for this purpose would be as defined in Section 6 of the Companies Act
1986.
The BIDDER shall not lend to or borrow any money from or enter into any monetary
dealings or transactions, directly or indirectly, with any employee of the BUYER.
4. Previous Transgression
4.1 The BIDDER declares that no previous transgression occurred in the last three
years immediately before signing of this Integrity Pact, with any other company in any
country in respect of any corrupt practices envisaged hereunder or with any Public Sector
Enterprises in India or any Government Department in India that could justify BIDDER’s
exclusion from the tender process.
Page 12
4.2 The BIDDER agrees that if it makes incorrect statement on this subject, BIDDER
can be disqualified from the tender process or the contract, if already awarded, can be
terminated for such reason.
5. Earnest Money Deposit (EMD)/ Initial Security Deposit (ISD)
5.1 While submitting Technical bid, the BIDDER shall deposit an amount Rs.8,20,000/-
as EMD in the form of Bank Guarantee. Initial Security Deposit (ISD), which will be 2%
of the accepted value of the tender minus initial part payment i.e. EMD, will be
submitted by the successful tenderer in the form of bank draft from a scheduled bank
within 15 days of intimation to him of acceptance of his tender. EMD shall be deposited
with the BUYER through bank guarantee of equal amount by an Indian Nationalised
Bank, promising payment of the guaranteed sum to the BUYER on demand within three
working days without any demur whatsoever and without any reasons whatsoever. The
demand for payment by the BUYER shall be treated as conclusive proof of payment. Any
other mode or through any other instrument (as specified in the tender document)
5.2 The Earnest Money/Initial Security Deposit shall be valid for contract period or the
complete conclusion of the contractual obligations to the complete satisfaction of both the
BIDDER and the BUYER, including warranty period, whichever is later.
5.3 In case of the successful BIDDER a clause would also be incorporated in the Article
pertaining to Performance Bond in the Purchase Contract that the provisions of Sanctions
for Violation shall be applicable for forfeiture of Performance Bond in case of a decision by
the BUYER to forfeit the same without assigning any reason for imposing sanction for
violation of this Pact.
5.4 No interest shall be payable by the BUYER to the BIDDER on Earnest Money/ Initial Security Deposit for the period of its currency.
6. Sanctions for Violations
6.1 Any breach of the aforesaid provisions by the BIDDER or any one employed by it or
acting on its behalf (whether with or without the knowledge of the BIDDER) shall entitle
the BUYER to take all or any one of the following actions, wherever required:-
i. To immediately call off the pre-contract negotiations without assigning any reason or
giving any compensation to the BIDDER. However, the proceedings with the other BIDDER(s) would continue.
ii. The Earnest Money Deposit (in pre-contract stage) and/ or Security Deposit/
Performance Bond (after the contract is signed) shall stand forfeited either fully or partially as decided by the BUYER and the BUYER shall not be required to assign any
reason therefore. iii. To immediately cancel the contract, if already signed, without giving any compensation
to the BIDDER.
iv. To recover all sums already paid by the BUYER, and in case of an Indian BIDDER with interest thereon at 2% higher than the prevailing Prime Lending Rate of State Bank of India, while in case of a BIDDER from a country other than India with interest thereon
at 2%, higher than the LIBOR. If any outstanding payment is due to the BIDDER from the BUYER in connection with another contract for any other stores, such
outstanding payment could also be utilized to recover the aforesaid sum and interest.
Page 13
v. To encash the advance bank guarantee and performance bond/ warranty bond, if furnished by the BIDDER, in order to recover the payments, already made by the BUYER, along with interest.
vi. To cancel all or any other contracts with BIDDER. The BIDDER shall be liable to pay compensation for any loss or damage to the BUYER resulting from such cancellation/
rescission and the BUYER shall be entitled to deduct the amount so payable from the money(s) due to the BIDDER.
vii. To debar the BIDDER from participating in future bidding processes of the
Government of India for a minimum period of five years, which may be further extended at the discretion of the BUYER.
viii. To recover all sums paid in violation of this Pact by BIDDER(S) to any middleman or agent or broker with a view to securing the contract.
ix. In cases where irrevocable Letters of Credit have been received in respect of any
contract signed by the BUYER with the BIDDER, the same shall not be opened. x. Forfeiture of Performance Bond in case of a decision by the BUYER to forfeit the same
without assigning any reason for imposing sanction for violation of this Pact.
6.2 The BUYER will be entitled to take all or any of the actions mentioned at para 6.1(i)
to (x) of this Pact also on the Commission by the BIDDER or any one employed by it or
acting on its behalf (whether with or without the knowledge of the BIDDER), of an offence
as defined in Chapter IX of the Indian Penal code, 1860 or Prevention of Corruption Act,
1988 or any other statute enacted for prevention of corruption.
6.3 The decision of the BUYER to the effect that a breach of the provisions of the Pact
has been committed by the BIDDER shall be final and conclusive on the BIDDER.
However, the BIDDER can approach the Independent Monitor(s) appointed for the
purposes of this Pact.
7. Fall Clause
7.1 The BIDDER undertakes that it has not supplied/s not supplying similar product/
systems or subsystems at a price lower than that offered in the present bid in respect of
any other Ministry/ Department of the Government of India or PSU and it is found at any
stage that similar product/ systems or sub systems was supplied by the BIDDER to any
other Ministry/ Department of the Government of India or a PSU at a lower price, then
that very price, with due allowance for elapsed time, will be applicable to the present case
and the difference in the cost would be refunded by the BIDDER to the BUYER, if the
contract has already been concluded.
8. Independent Monitors
8.1 The BUYER has appointed Independent Monitor Shri Debabrata Sarkar (hereinafter
referred to as Monitor) for this Pact in consultation with the Central Vigilance
Commission.
8.2 The task of the Monitor shall be to review independently and objectively, whether
and to what extent the parties comply with the obligations under this Pact.
Page 14
8.3 The Monitor shall not be subject to instructions by the representatives of the parties
and perform their functions neutrally and independently.
8.4 Both the parties accept that the Monitors have the right to access all the documents
relating to the project/ procurement, including minutes of meetings.
8.5 As soon as the Monitor notices or has reason to believe, a violation of this Pact, he
will so inform the Authority designated by the BUYER.
8.6 The BIDDER(s) accepts that the Monitor has the right to access without restriction
to all Project documentation of the BUYER including that provided by the BIDDER.
The BIDDER will also grant the Monitor, upon his request and demonstration of a
valid interest, unrestricted and unconditional access to his project documentation.
The same is applicable to Subcontractors. The Monitor shall be under contractual
obligation to treat the information and documents of the BIDDER/ Subcontractor(s)
with confidentiality.
8.7 The BUYER will provide to the Monitor sufficient information about all meetings
among the parties related to the Project provided such meetings could have an
impact on the contractual relations between the parties. The parties will offer to the
Monitor the option to participate in such meetings.
8.8 The Monitor will submit a written report to the designated Authority of BUYER
within 8 to 10 weeks from the date of reference or intimation to him by the BUYER/
BIDDER and should the occasion arise submit proposals for correcting problematic
situations.
9. Facilitation of Investigation
In case of any allegation of violation of any provisions of this Pact or payment of
commission, the BUYER or its agencies shall be entitled to examine all the
documents including the Books of Accounts of the BIDDER and the BIDDER shall
provide necessary information and documents in English and shall extend all
possible help for the purpose of such examination.
10 Law and Place of Jurisdiction
This Pact is subject to Indian Law. The place of performance and jurisdiction is the
seat of the BUYER.
11. Other Legal Actions
The actions stipulated in this Integrity Pact are without prejudice to any other legal
action that may follow in accordance with the provisions of the extant law in force
relating to any civil or criminal proceedings.
Page 15
12. Validity
12.1 The validity of this Integrity Pact shall be from date of its signing and extend up to 5
years or the complete execution of the contract to the satisfaction of both the
BUYER and the BIDDER/ Seller, including warranty period, whichever is later in
case BIDDER is unsuccessful, this Integrity Pact shall expire after six months from
the date of the signing of the contract.
12.2 Should one or several provisions of this Pact turn out to be invalid, the remainder of
this Pact shall remain valid. In this case, the parties will strive to come to an
agreement to their original intentions.
13. The parties hereby sign this Integrity Pact at _____________________ on -
____________________.
BUYER BIDDER
Name of the Officer Chief Executive Officer
Designation
NABARD
Witness Witness
1_______________________ 1 _______________________
2_______________________ 2_______________________
Page 16
BLANK PAGE
Page 17
3. FORM OF TENDER
The Chief General Manager NABARD, Maharashtra Regional Office 54 Wellesley road, Shivaji Nagar
Pune, 411005
Dear Sir
TENDER FOR S / I / T/ C OF AIR CONDITIONING SYSTEM & ALL REQUIRED
CIVIL & ALLIED WORKS, FOR NABARD, MAHARASHTRA REGIONAL OFFICE,
SHIVAJI NAGAR, PUNE.
I / We the undersigned have carefully gone through and clearly understood, after
visiting the site, the tender drawings and tender documents comprising of the tender
form, Notice of Tender, General terms and conditions of tender, Special Conditions,
Specifications and Schedule of Quantities prepared by your Consultant, M/s. Tarun G
Barai, Consultant, 303 Flyover Apt, 12 A, Teli Gali, Andheri (E), Mumbai – 400 069.
I/We hereby offer to execute the works specified in the said Memorandum within the
time specified, at the rates mentioned in the financial/ price Bid and in accordance
With all respects of the tender and with such materials as are provided for, by
and in all other respects in accordance with such conditions so far as they may be
applicable.
I / we do here by undertake to execute and complete the whole or part of the work (as
desired by you) at the respective rates quoted.
In the event of this Tender being accepted I / we agree to enter into an agreement as
and when required and executed the contract according to your form of Agreement, in
default whereof, I/we do hereby bind my-self / ourselves to forfeit the aforesaid deposit.
I / we further agree to complete the work included in the said schedule of quantities
within 10 weeks from the date of commencement. Date of commencement shall be
either one-week, from the date, the acceptance letter is issued to the contractor or day
on which the contractor is instructed to take possession of site whichever is later.
I / we agree to employ only those sub-contractors; approved by Consultants /
Employer.
I/we agree to provide the list of all the sub-contractors in the beginning or at least one
week prior to commencement of the work by the said sub-contractor. In case of non-
compliance, I/ we authorize consultant/ bank engineer to stop the work at site.
I / We agree to pay Government, Service tax, General and Sales Tax (State and
Central), Excise and Octroi duties etc. for insurance and all other taxes including
works contract extra, turnover tax, VAT etc. as prevailing foretime to time, on such
items for whom same is to be levies, and the rates quoted by me / us are inclusive of
the same.
MEMORANDUM
Page 18
a) Description of work: Tender for S/I/T/C Air Conditioning System & all
required civil & allied works for, NABARD, Maharashtra Regional Office, Shivaji
nagar, Pune.
b) Earnest Money Deposit: Rs.8,20,000/-
c) Time allowed for completion: 10 Weeks from the date of commencement which
shall be either one-week, from the date of issue of work order to the contractor or
day on which the contractor will take possession of site whichever is earlier.
d) Retention Money Deposit (RMD): 5% from every R.A. Bill.
We understand that the time for completion shown above shall be reckoned form the
date of commencement of the work.
Should this tender be accepted, I/We hereby agree to abide by and fulfill the terms and
provisions or the said Conditions of the tender annexed hereto so far as they may be
applicable or in default thereof to forfeit the EMD and pay to the National Bank for
Agriculture and Rural Development, the amount mentioned in the said tender
conditions.
Our Banker’s are:
i)
ii)
The names of partners of our firm are:
ii)
iii)
Name of the partner of the firm
Authorized to sign:
OR
Name or person having Power of Attorney
to sign the contract (certified copy of the
Power of Attorney should be attached):
Yours faithfully,
Signature of Tenderer
Page 19 SEAL AND SIGN OF BIDDER
4. ARTICLES OF AGRREMENT
करार के य ेअनुच्छेद............. माह के............वें
ददन एक पक्ष के रूप में राष्ट्रीय कृषि और ग्रामीण
षवकास बैंक (षिस े इसके पश्चात "षनयोक्ता" कहा
िाएगा) और दसूरे पक्ष के रूप में............... (षिस े
इसके पश्चात् ''षनषवदाकताा'' कहा िाएगा) के बीच
षनष्पाददत दकए िात ेहैं.
ARTICLES OF AGREEMENT made this
_____________ day of __________ between
the National Bank for Agriculture and
Rural Development (hereinafter called
“the Employer”) of the one part and
__________________(hereinafter called
“the Tenderer”) of the other part.
यत: षनयोक्ता नाबार्ा, महाराष्ट्र क्षेषिय कायाालयइमारत, षिवािी नगर, पुणे में एयर कंषर्िननंगऔर
सभीआपेषक्षत षसषवलऔरसंबद्धकायो कीआपूर्ता, स्थापना, पररक्षणएवंकषमिननंग' का काया षनष्पाददत करवाना चाहता ह.ै
तथायत:, षनषवदाकताा मूल्य षबर् में दी गई ितों और
इस करार में आगे ददए िा रही ितों (इन सभी को
इसके पश्चात ्''उक्तिततें'' कहा िाएगा) के अधीन उक्त
तकनीकी षवषनदिेनों, और मूल्य षबर् में िाषमल
संबंषधत दरों इसमें आगे षनधााररत की िाने वाली राषि
अथवा कोई अन्य दयेराषि (इस राषि को इसके पश्चात
''उक्तठेका राषि'' कहा िाएगा) पर उक्त कायो को
षनष्पाददत करना स्वीकार करता ह.ै
WHEREAS the Employer is desirous
of getting executed the work of S / I /
T/ C OF AIR CONDITIONING
SYSTEM & ALL REQUIRED CIVIL &
ALLIED WORKS, FOR NABARD,
MAHARASHTRA REGIONAL OFFICE
, SHIVAJI NAGAR, PUNE.
AND WHEREAS the Tenderer has
agreed to execute upon and subject to
the conditions set forth in the Price Bid
and Conditions of Contract (all of which
are collectively hereinafter referred to
as “the said Conditions”) the work
shown upon the said technical
specifications, and included in the Price
Bid at the respective rates therein set
forth amounting the sum as therein
arrived or such other sum as shall
become payable there under
(hereinafter referred to as “the said
contract amount”).
अब एतद्द्वारा षनम्नानुसार स्वीकार दकया िाता ह:ै- NOW IT IS HEREBY AGREED AS
FOLLOWS :-
1. इसमें आगे उल्लेख क दकए िाने वाले रतिषत ल पर
षनषवदाकताा, अनुबंधमेंदीिारहीितोंकेअधीनकाया
करेगाऔरसंषवदामेंदिााएगए, मािाओंकीअनुसूची
औरउक्तितोंमेंवर्णातअथवाषन्दाष् कायोंकोपूरा
करेगा.
1. In consideration hereinafter
mentioned, the Tenderer will upon and
subject to the conditions annexed,
carry out and complete the works
shown in the contract, described by or
referred to in the Schedule of
Quantities and in the said conditions.
2. षनयोक्ता षनषवदाकताा को उक्त षनषवदा राषि
अथवासमय-समयपरदयेहानेवालीराषिकाउक्त
ितोंमेंषवषन्दाष् तरीकेसेभुगतानकरेगा.
2. The Employer shall pay the Tenderer
the said contract amount or such sum
as shall become payable at the times
and in the manner specified in the said
conditions.
Page 20 SEAL AND SIGN OF BIDDER
3. उक्तितोंऔरउनके साथ केअनुबंधों तथा इसके
साथलगेदस्तावेों ोंको इसकरार केहीएकभाग के
रूप में पढा िाएगाऔर उसका अथा भी उसी रतिकार
षनकालािाएगातथादोनोंपक्षउक्तितोंकाससम्मान
पालनकरेंगेऔरतथाउक्तितोंऔरइसकेसाथलगे
दस्तावेों ोंकोस्वीकारकरेंगेऔरउनकेअनुसारअपनी-
अपनीओरसेइसकरारकाषनष्पादनकरेंगे.
3. The said Conditions and Appendix
thereto and the documents attached
hereto shall be read and construed as
forming part of this Agreement and the
parties hereto shall be respectively
abide by, submit themselves to the said
Conditions and the correspondence and
perform the agreements on their part
respectively in the said conditions and
the documents contained herein.
4. यह करार और इसमें उषल्लषख कत दस्तावेों इस
संषवदाकाआधारबनेंगे.
4. This Agreement and documents
mentioned herein shall form the basis
of this contract.
5. यहसंषवदापूरेकायाहतेुमददरसंषवदाहैषिसके
अंतगातदरोंकीअनसुूचीमेंदीगईदरपरअथवाउक्त
ितोंमें ददएगएरतिावधानों केअनुसारकाया स्थलपर
आवश्यकइन्स् ालेिनकरनेपरभुगतानदकयािाताह.ै
5. This contract is an item rate contract
for the complete work to be paid for
according to necessary installation
carried out at site, at the rate contained
in the Schedule of Rates or as provided
in the said conditions.
6. षनषवदाकताा षनयोक्ता द्वारा षनयुक्त अन्य
ठेकेदारों के सभी कायोंमें सहयोग रतिदान करेगा तथा
ऐसे काया समाप्त होन े के पश्चात दीवारों, िों
इत्यादद को हुई दकसी भी हाषन को ठीक करेगा.
6. The Tenderer shall afford every
reasonable facility for carrying out of all
works of other Contractors employed by
the Employer and shall make good any
damage done to walls, floors, etc. after
the completion of such works.
7. इस संषवदा पर षबना रतिषतकूल रतिभाव र्ाले नया काया िोड़कर अथवा काया की कोई मदें ह ाकर अथवा इसी काया को भागों में करवाने द्वारा इस कायाकी रतिकृषत को बदलने का अषधकार षनयोक्ता अपने पास सुरषक्षत रख कता ह.ै
7. The Employer reserves to itself the
right of altering the nature of work by
adding to or omitting any items of
works or having portions of the same
carried out without prejudice to this
contract.
8. समय इस संषवदा का सवााषधक महत्वपूणा तत्व होगा, तथा षनषवदा कताा एत द्द्वारा यह स्वीकार करता ह ैदक वह कायाादिे षमलने के दसवें ददन के भीतर उक्त ितों में ददए गए अनुसार काया/ काम िुरू कर दगेा और कायाादिे रतिाप्त दकए िाने की तारीख क से गणना करते हुए समय को बढाए िाने का रतिावधान होते हुए भी नीचे षवषन्दाष् समय सीमा के भीतर पूरा काया ख कत्म कर दगेा.
8. Time shall be considered as the
essence of this contract, and the
Tenderer hereby agrees to commence
the work/ job within the tenth day of
receipt of the work order as provided for
in the said conditions and to complete
the entire work within the time period
prescribed below reckoned from the
date of receipt of such work order
subject nevertheless to the provision for
extension of time.
Page 21 SEAL AND SIGN OF BIDDER
9. षनयोक्ता द्वारा इस सषंवदा के तहत दकए िान ेवाल ेसभी भुगतान षस ा पुणेमें ही दकए िाएगं.े
9. All payments by the Employer under
this contract will be made only at Pune.
10. इसकरार केसंबंधमें उठने वालेअथवा इससे
दकसीभीरतिकारसेसंबंषधतसभीषववादपुणेमेंहीउठे
षववादमानेिाएगंेऔर पुणे षस्थत न्यायालयोंकोही
उक्तकेसंबंधमेंषनणायलेनेकाक्षेिाषधकारहोगा.
10. All disputes arising out of or in any
way connected with this agreement
shall be deemed to have arisen at Pune
and only Courts in Pune shall have the
jurisdiction to determine the same to
the exclusion of all other courts.
11. दक षनषवदाकताा द्वारा काया स्थलकोदखे क षलयागया हैऔरकाया षनष्पादन स्थलकी वतामान षस्थषत
कोपूरीतरहसमझषलयागयाहै.
11. That the tenderer has visited the
site and fully understood the existing
conditions of site for execution of work.
12. दक षनषवदाकताा द्वारा इस संषवदा के षवषभन्न
भागोंकोपढाऔरषनषवदाकतााद्वारापूरीतरहसमझ
षलयागयाह.ै
12. That the several parts of this
contract have been read by the tenderer
and fully understood by the tenderer.
इसके साक्ष्य के रूप में षनयोक्ता ने अपने षवषधवत
रतिाषधकृत अषधकाररयों के माध्यम से इन षवलेख कों पर
हस्ताक्षर दकए तथा षनषवदाकताा ने इन षवलेख कों और
उक्त दो रू्प्लीके रतिषतयों पर इस दस्तावेों में सबसे
पहलेषलख केगएस्थानऔरविावतारीख ककेददनअपने
हस्ताक्षर दकएऔरअपनीकॉमनसीललागाई. (यदद
षनषवदाकतााकोईकंपनीहैतो).
IN WITNESS WHEREOF the Employer
has set its hands to these presents
through its duly authorized officials
and the Tenderer has caused its
common seal to be affixed hereunto
and the said two duplicates/ has
caused these presents and the said two
duplicates here of to be executed on its
behalf, the day and year first herein
above written. (If the Tenderer is a
company).
हस्ताक्षरख कंर् Signature Clause
राष्रीय कृषि और ग्रामीण षवकास बैंक की ओर से
अधोषलषख कतकेहाथोंहस्ताक्षररतऔरसपापागया
श्री
(नामवपदनाम)
SIGNED AND DELIVERED by the
National Bank for Agriculture and
Rural Development by the hand of
Shri
(Name & Designation)
ठेकेदर की ओर से अधोषलषख कत के हाथों हस्ताक्षररत
औरसपापागया श्री (नामवपदनाम)
SIGNED AND DELIVERED by the
Bidder by the hand of
Shri
Page 22 SEAL AND SIGN OF BIDDER
गवाहस.ं1
हस्ताक्षर:
नाम:
पता:
गवाहस.ं2
हस्ताक्षर:
नाम:
पता :
(Name & Designation)
Witness #1
Signature:
Name:
Address
Witness #2
Signature:
Name:
Address
Page 23 SEAL AND SIGN OF BIDDER
5. GENERAL INSTRUCTIONS
1. PROCEDURE OF FILLING AND SUBMISSION OF TENDER
i) The tenderers should quote their rates in figures and words where the
quantities have been indicated in the relevant items of the schedule of
quantities, failures to do so may invalidate the tender. Erasing or over
writing shall not be allowed. Corrections in the tender should be avoided if
this becomes unavoidable, the entire rate (and not a portion only) shall be
scored out and signed (not simply initiated) by the tenderer as token of such
cancellation. A fresh rate in specified manner shall then be correctly written.
ii) In the event of the tender being submitted by a firm, it must be signed by a
member or members of the firm having legal authority to do so, and if called
for, the legal documents in support thereof must be produced for inspection
and the same in the case of the firm carried out by one member of a joint
family.
iii) All corrections are to be initialed.
iv) The tenderer is to quote this rate in ink/type both in words and figures in
English. The tender shall be clearly and legibly written and whole writing
must be by the hand of the person signing the tender and with the same pen
and ink/type.
v) The employer reserves to itself the right to accept the lowest or split up and
distribute any items of work to any specialist firm or firms without assigning
any reason. The employer reserves the right to split up and distribute the
work to more than one tenderer, if necessary. Signature/initial with
company seal on each page will be deemed to be the acceptance of the
contents of this tender paper by the tenderer.
vi) Tenderer shall note that their tenders shall remain open for acceptance for a
minimum period of 03 months from the date of opening the technical bid.
The tender must be unconditional. Conditional tenders may be summarily
rejected.
2. RATES TO INCLUDE:
While quoting their rates the tenderer should include the following also if
otherwise not stated herein before.
a) Necessary cost of taking samples of materials supplied by them for construction including cement and steel, wood/tiles etc, testing of the same at govt. approved laboratory including transportation, cost of the samples, as and when required.
b) Submission of test reports of other materials as may be specified by
Consultants or Bank’s Engineer.
Page 24 SEAL AND SIGN OF BIDDER
c) Rates should include all prevailing applicable taxes (like service tax, VAT, work contract tax, income tax, etc) Duties, Octroi, Levies, Wages as per Act, etc. and should be firm for the entire Contract period. No escalation of rates will be allowed for the entire contract period on any account.
d) NABARD will provide Electric power and water at one point in the building for
proper execution of the work. The Contractor will however have to pay for the
electric power and water consumed by him at the rates chargeable by the local
authorities.
e) The basic rate of the item means prevailing market rate including VAT, works
contract tax and all other taxes as applicable during the period of the
contract.
f) The quoted rate shall include the cost of all minor/sundry items to make it
functional
3. WORKING HOURS:
Since the site is a Working Department, if the Contractor has to execute the
work after working hours, nights & on holidays. No extra payments will be
made to the contractor on account of carrying out the works during odd hours.
4. STORAGE OF MATERIALS:
On-site storage space will be provided to the Contractor subject to availability.
However, the Contractor may erect temporary sheds for storage purposes at his
cost with the permission of NABARD. NABARD will not be responsible for
Contractor's materials. The Contractor may be required to vacate the storage
space and sheds as per exigency without any extra cost to NABARD
5. LABOUR HUTMENT:
Shelter or stay for the labourers has to be arranged by the contractor outside NABARD office premises at his own expense and responsibility.
6. IDLE LABOUR AND EXTENSION OF TIME:
In case the construction work is held up for any site conditions not attributable
to the contractors or for any decisions instructions / want of details from
Employer / Consultants or for any of the conditions as per General conditions
of contract at S.No: 30 and 31, the contractor shall be allowed reasonable
extension of time by the employer but any additional/ extra claim for payment
to idle labour/tools/establishment/plant etc. during this period shall not be
the liability of the employer. Contractor’s quoted rates should include for all
such contingencies.
Page 25 SEAL AND SIGN OF BIDDER
The Contractor or his authorized representative should visit the site frequently as required by NABARD and meet NABARD’s Engineer with prior appointment for any clarifications and to receive instructions, take measurements, etc. at the site. The work should not suffer due to lack of supervision, manpower and materials.
The Contractor is required to co-ordinate his works along with other agencies
working at site. He has to reimburse for any of the damage made by him
or any of his representatives to any other agency or the Employer at site.
Nothing extra will be paid for making any cut-out / opening for electrical wiring / fitting in any of false ceiling, partition, Paneling, masonry work etc. contractor’s quoted rates should include for all such works.
The contractor is required to fabricate a sample where required, or any item so installed for approved. Any changes made by the Consultant/Employers, in the sample to the specifications as mentioned in the tender, shall not be deducted or paid extra. The bulk production of the furniture can only be taken up after the final approval of the sample of the item.
The partitions shall be so fixed that all joinery work is in plumb and true in line. The partition frame shall be firmly fixed to the floor and ceiling by using suitable wall plugs and screws.
The contractor shall check all dimensions before fabricating and fixing the
partitions or ceiling in position at site.
All measurements given in the schedule hereunder are for the purpose of tender
only. Payment will be made on actual measurement of the work done.
All measurements shall be as per relevant I.S.I. standards and Materials used
should conform to relevant National Codes.
Except where provided for in the description of the individual items in the
schedule of quantities and in the specifications and conditions laid down
hereinafter and in the drawings, the work shall be carried out as per standard
specifications and under the direction of Employer / Consultant.
Page 26 SEAL AND SIGN OF BIDDER
6. GENERAL CONDITIONS OF CONTRACT
1. TECHNICAL AUDIT
The work is liable to be technically audited by the chief technical examiner of the
Central Vigilance Commission, Govt. of India from Time to Time. Any defects,
improvements or testing etc. pointed out by the Chief Technical Examiner should
be carried out by the contractor at his own cost and deduction suggested by the
CTE will be borne by the contractor. The employer shall have a right to cause a
technical examination and audit of works and the final bills of the contractor
including all supporting vouchers, abstracts etc. to be made at the time of payment
of the final bills. If as a results of this examination or otherwise any sum found to
have been overpaid in respect of any work done by the contractor under the
contract , the contractor shall be liable to return an amount of overpayment and it
will be lawful for the employer to recover the same from any sum of sums due to
him and in any other manner legally permissible and it is found that the contractor
was paid than what was due to him under the contract in respect of any work
executed by him under the contract , the amount of such underpayment shall be
duly paid by the employer . Any sum of money due and payable to the contractor
(including security deposit returnable to him) under this contract may be
appropriated by NABARD and set off against any claim of NABARD for the payment
of sum of money arising out of or under any other contract made by the contractor
with NABARD.
2. INTERPRETATION
In constructing these conditions, the specifications, the schedule of quantities,
tender and agreement, the following words shall have the meaning herein
assigned to them except where the subject or context otherwise requires.
i. Employer: The term employer shall denote NABARD with their Regional office at 54, WELLESLEY ROAD, SHIVAJI NAGAR, PUNE, 411005 and any of its
employees representative authorized on their behalf. ii. Consultants: The term Consultant shall mean M/s. Tarun G Barai
Consultant, 303 Flyover Apt, 12 A, Teli Gali, Andheri (E),Mumbai –
400 069 or in the event of his / their ceasing to be the Consultant for the purpose of this contract such other persons as the employer shall
nominate for the purpose. iii. Contractor: The term contractor shall mean
(Name and address of the contractor) and his / their heirs, legal
representatives, assigns & successors.
Page 27 SEAL AND SIGN OF BIDDER
iv. Site: The site shall mean the site where the works are to be executed as shown within boundary in red border on the site plan including any building and erection thereon, allotted by the employer for the contractors
use. v. Bank Engineer: Any Engineer appointed from time to time by the employer
shall act as Engineer for the said Contract at the said site. vi. Drawings: The work is to be carried out in accordance with drawings,
specifications, the schedule of quantities and any further drawings, which
may be supplied, or any other instruction, which may be given by the Employer during the execution of the work.
All drawings relating to work given to the contractor together with a copy
of schedule of quantities are to be kept at site and the contractor will
made them available to the employer / consultant whenever necessary.
In case any detailed Working Drawings are necessary contractor shall
prepare such detailed drawings and / or dimensional sketches therefore
and have it confirmed by the Employer / Consultants as case may be
prior to taking up such work.
The contractor shall ask in writing for all clarifications on matters
occurring anywhere in drawings, specifications and schedule of
quantities or to additional instructions at least
10 days ahead from the time when it is required for implementation so
that the Employer may be able to give decision thereon.
vii. “The Works” shall mean the work or works to be executed or done under
this contract.
viii. “Act of Insolvency” shall mean any act as such as defined by the Presidency Towns Insolvency Act or in Provincial Insolvency act or any
amending status. ix. “The Schedule of Quantities” shall mean the schedule of quantities as
specified and forming part of this contract. x. “Priced Schedule of Qu an t i t i e s ” shall mean the schedule of quantities
duly priced with the accepted quoted rates of the contractor. xi. “Contract” shall mean the Articles of Agreement, the general conditions
special conditions, the appendix, the schedule of quantities, specifications and drawings attached here to and duly signed.
xii. “Contract Price” shall mean the sum named in the Tender subject to such additions thereto or deductions there from as may be made under the provisions hereafter contained.
xiii. “Notice in Writing” or written notice shall mean a notice in writing, type or printed characters sent (unless delivered personally or otherwise provided to have been received) by registered post to the last known private or business address or registered office of the addressee and shall
Page 28 SEAL AND SIGN OF BIDDER
be deemed to have been received when in the ordinary course of post it would have been delivered.
xiv. “Net Prices” any arriving at the Contract amount the Contractor shall have added to or deducted from the total of the items if the Tender any sum, either as a percentage or otherwise, then the net price of any item in the tender shall be the sum arrived at by adding to or deducting from the actual figure appearing in the tender as the price of that item a similar percentage or proportionate sum. Providing always that in determining the percentage or proportion of the sum so added or deducted by the contractor, the total amount of any Prime Cost items and provisional sums of money shall be deducted from the total amount of the tender. The expression “net rates” or “net prices” when used with reference to the contract or account shall be hold to mean rates or prices so arrived at.
xv. “Virtual Completion” shall mean the site is in the opinion of the Consultant and Employer fit for occupation.
xvi. “Date of commencement” shall be either one-week, from the date of issue work order to the contractor or day on which the contractor will take possession of site whichever is earlier
3. SCOPE OF WORK:
The Contractor shall carry out and complete the said work in every respect in
accordance with this Contract and with the directions of and to the satisfaction
of the Consultant and Employer. The Consultant with approval of Employer
issue further drawings and / or written instructions, details directions and
explanations which hereafter collectively referred to as “Consultant’s
Instructions” In regard to:
a. The variation or modification of the design quality or quantity of works or the addition or omission or substitution of any work.
b. Any discrepancy in the drawings or between the schedule of
quantities and / or drawings and / or specification. c. The removal from the site of any defective material brought thereon
by the contractor and the substitution of any other material thereof.
d. The demolition removal and / or re-execution of any work executed by the contractor/s.
e. The dismissal from the work of any persons employed there upon.
f. The opening up for inspection of any work covered up.
g. The rectification and making good of any defects under clauses
hereinafter mentioned and those arising during the maintenance period (Defect Liability Period).
Page 29 SEAL AND SIGN OF BIDDER
The contractor shall forthwith comply with and duly execute any work comprised
in such Employer’s or his agent / Consultant’s instructions, provided always
that verbal instructions, directions and explanations given to the contractor’s or
his representative upon the works by the Employer’s or his agent /
Consultants shall, if involving a variation, be confirmed in writing to the
contractor/s within seven days. No works, for which rates are not specifically
mentioned in the priced schedule of quantities, shall be taken up without written
permission of the Employer or his agent / Consultants. The employer in
consultation with the Consultants as provided in clause “variation” shall fix rates
of items not mentioned in the priced schedule of quantities.
Regarding all factory made products for which ISI marked products are
available, only products bearing ISI marking shall be used in the work.
4. TENDERERS SHALL VISIT THE SITE
Intending tenderer shall visit the site and make himself thoroughly acquainted
with the local site condition, nature and requirements of the works, facilities of
transport conditions, effective labour and materials, access and storage for
materials and removal of rubbish. The tenderer shall include the cost of these
items in the quoted rates like carriage, freight and other charges as also for
any special difficulties and including police restriction for transport etc., for
proper execution of work as indicated in the drawings. The successful tenderer
will not be entitled to any claim of compensation for difficulties faced or losses
incurred on account of any site condition which existed before the
commencement of the work or which in the opinion of the employer or his agent
/ Consultant might be deemed to have reasonably been inferred to be so
existing before commencement of work.
5. TENDERS
The entire set of tender paper issued to the tenderer should be submitted and
also signed on the last page together with initials on every page. Initial /
signature will indicate the acceptance of the tender papers by the tenderer.
(Also see general rules and instructions for the guidance of Tenderers)
Page 30 SEAL AND SIGN OF BIDDER
The schedule of quantities shall be filled in as follows:
i. The “Rate” column to be legibly filled in ink in both English figures and
English words. ii. Amount column to be filled in for each item and the amount for each
sub head as detailed in the “Schedule/ Bill of Quantities”. iii. All corrections are to be initialed. iv. In case of any errors / omissions in the quoted rates, the rates given in
the tender marked “original” shall be taken as correct rates.
No modifications, writings or corrections can be made in the tender
papers by the tenderer, but may at his option offer his comments or
modifications in a separate sheet of paper attached to the original tender paper.
The Employer reserves the right to reject the lowest or any tender and also to
discharge any or all of the tenders of each section or to split up and distribute
any item of work to any specialist firm or firms, without assigning reasons.
The tenderers should note that the tender is strictly on the item rate basis and
their attention is drawn to the fact that the rates for each and every item should
be correct, workable and self-supporting. If called upon by the Employer /
Consultants detailed analysis of any or all the rates shall be submitted. The
Employer / Consultants shall not be bound to recognize the contractor’s
analysis. All corrections are to be initialed.
The works will be paid for as “measured work” on the basis of actual work done and not as “lumpsum” contract, unless otherwise specified.
All items of work described in the schedule of quantities are to be deemed and
paid as complete works in all respects and details including preparatory and
finishing works involved, directly related to and reasonably detectable from the
drawings, specifications and schedule of quantities and no further extra charges
will be allowed in this connection. In the case of lump-sum charges in the
tender in respect of any items of work will be made for the actual work done
on the basis of lumpsum charges as will be assessed to be payable by the
Employer / Consultants.
The employer has power to add to, omit from any work as shown in
drawings or described in specifications or include in schedule of quantities and
intimate the same in writing but no addition, omission or variation shall be
made by the contractor without authorization from the Employer. No variation
shall vitiate the contract.
The tenderer shall note that his tender shall remain open for consideration for a
period of three months from the date of opening of the tender.
Page 31 SEAL AND SIGN OF BIDDER
6. AGREEMENT
The successful contractor will be required to sign agreement in accordance with
the draft agreement enclosed and the schedule conditions. The contractor shall
pay for all stamps and legal expenses, incidental thereto. However the written
acceptance by the employer of a tender will constitute a binding contract
between the employer and the person so tendering whether such formal
agreement is or is not subsequently executed.
7. AUTHORITIES, NOTICES, PATENT RIGHTS AND ROYALTIES:
The Contractor shall confirm to the provisions of the statutes relating to the
works, and so to the regulation and bylaws of local authority, and of any water,
lighting and other companies on authorities with whose systems the structures
are proposed to be connected and shall before making any variation from the
drawings or specifications, that may be necessitated by so conforming given
to the Consultant’s written notice, specifying the variations proposed to be
made and the reason for making it apply for instruction thereon.
In case, the Contractor shall not within the 10 days receive such instruction, he
shall proceed with the work conforming to the provisions, regulations or bylaws
in questions.
The Contractor shall bring to the attention of the Consultant all notices required
by the said acts, regulations or bylaws to be given to any Authority, and pay to
such authority or to any Public Officer all fees that may be properly chargeable
in respect of the works, and lodge the receipts with the Consultant /Employer.
The Contractor shall identify the Employer against all claims in respect of
patent rights, designs, trademarks or name or the protected rights in respect
of any constructional plant, machine, work or material used for or in
connection with the works or temporary works and from and against all claims,
demands, proceedings, damages, costs, charges, and expenses whatsoever in
respect thereof or in relation thereto. The Contractor shall defend all actions
arising from such claims, unless he has informed the Consultants, before any
such infringement and received their permission to proceed and shall himself
pay all royalties, license fees, damages, coat and charges of all and every sort
that may be legally incurred in respect thereof.
Page 32 SEAL AND SIGN OF BIDDER
8. TAXES AND DUTIES
The tenderers must include in their tender prices quoted for all duties royalties,
cess and sales tax, works contract tax or any other taxes or local charges if
applicable. No extra claim on this account will in any case be entertained.
9. NOTICES AND STATUTORY REGULATIONS:
The contractor shall give all notices and pay all fees and shall comply all Acts
and Regulations for the successful completion of the contract works. The whole
of the work is to be complied with as per the requirements and bylaws of the
relevant statutory authorities including contract labour (Regulation and
Abolition) Act 1970.
10. QUANTITY OF WORK TO BE EXECUTED
The Schedule of Quantities unless otherwise stated shall be deemed to
have been prepared in accordance with the Standard Procedure of the
Consultants shall be considered to be approximate and subject to variation. The
Employer reserves the right to execute only a part or the whole or any excess
thereof without assigning any reason therefore.
The Contractor shall be deemed to have satisfied himself before tendering to the
correctness and sufficiency of his tender for the works and of the prices stated
in the Schedule of Quantities and / or the Schedule of Rates and Prices, which
rates and prices shall cover all things necessary for the completion of the works.
11. OTHER PERSONS ENGAGED BY THE EMPLOYER
The Employer reserves the right to execute any part of the work included in this
contract or any work, which is not included in this contract by the other
Agency, or persons and contractor shall allow all reasonable facilities and
use of his scaffoldings for the execution of such work. The main contractor
shall extend all cooperation in his regard.
Page 33 SEAL AND SIGN OF BIDDER
12. EMD/ ISD/ RMD
An initial part amount of Rs 8,20,000/- ( Rupees eight lakh twenty
thousand only) towards Earnest Money Deposit (EMD) by way of a Bank
Guarantee from Nationalised/Scheduled Bank to be submitted alongwith
“Technical Bid”. The Tender without initial part amount of EMD shall
be rejected out rightly. No interest is allowed on the EMD.
The “Initial Security deposit”(ISD), which will be 2% of the accepted
value of the tender minus initial part payment i.e. EMD, will be
submitted by the successful tenderer in form of cash or bank draft from a
scheduled bank within 15 days of intimation to him of acceptance of his
tender. No interest is allowed on the ISD.
"Retention Money Deposit" (RMD) at the rate of 5% is recovered from
each on-account bill till the total recovery amounts to the figure
stipulated in the tender document at the time of invitation of tender.
This sum will be arrived at after adjusting the EMD/ISD. The EMD/ISD
together with RMD will constitute Security Deposit. While determining
the RMD, the EMD/ISD already with the Bank shall be taken into
account.
13. CONTRACTOR TO PROVIDE EVERYTHING NECESSARY
The Contractor shall provide everything necessary for the proper execution
of the work according to the intent and meaning of the drawings, schedule
of quantities and specifications taken together whether the same may or
may not be particularly shown or described therein provide that the same
can reasonably be inferred there from and if the contractor finds any
discrepancies therein he shall immediately and in writing, refer the same to
the Employer / Consultants whose decision shall be final and binding.
14. TIME OF COMPLETION, EXTENSION OF TIME & PROGRESS CHART
The Contractor shall be allowed admittance to the site on the „Date of Commencement‟ stated in the Appendix, and he shall thereupon and
Page 34 SEAL AND SIGN OF BIDDER
forthwith begin the works and shall regularly proceed with to complete the same (except such painting or other decorative work as the Employer may desire to delay). On or before the “Day of Completion” stated in the Appendix subject nevertheless the provision for the extension of time hereinafter contained.
If in the opinion of the Employer the works be delayed: By
a. force major, OR
b. By reason of any exceptionally inclement weather,
OR
c. By reason of proceedings taken or threatened by or dispute with
adjoining or neighboring Employers of public authorities arising,
than through the Contractor’s own default, OR
d. By the works or delays of the contractors tradesmen engaged or
nominated by the Employer / Consultant and not referred in the
Schedule of Quantities and / or specifications, OR
e. By reason of civil, commotion, local combination of workmen or
strike or lock-out effecting any of the buildings traders, OR
f. By reason of the Consultant’s instructions as per clause 2, OR
g. In consequence of the Contractor not having in due time,
necessary instructions from the Consultant for which he shall
have specifically applied in writing ahead of time, giving the
Consultant reasonable time to prepare such instructions, the
Employer/Consultants shall make a fair and reasonable
extension of time for completion of the Contract works.
In case of such strike or lock-out, the Contractor shall as soon as possible,
give written notice thereof to the Employer/Consultant, but the Contractor
shall nevertheless constantly use his endeavors to prevent delay and shall
do all they may reasonably be required, to the satisfaction of the Consultant
to proceed with the work.
The Contractor on starting the works shall furnish to the Employer /
Consultant a PERT / CPM Programme /Bar chart for carrying out the work
stage in the stipulated time for the approval of Consultant / Employer and
follow strictly the approved time schedule incorporating charges if any, to
ensure the completion of the work in stipulated time. A graph or chart on
Page 35 SEAL AND SIGN OF BIDDER
individual work shall be maintained showing the proportionate progress of
work week by week by Consultant a weekly progress report stating
the number of skilled and un skilled laborers employed on the work, working
hours done, place, type, and quantity of work done during the period.
The Contractor must inform the Consultant within 10 days in advance of all
drawings and detailed required by him from time to time. The Contractor
shall Adhere to the approved program and arrange for the materials and
labour etc accordingly. Despite repeated instructions, if the Contractor
fails to show proportionate progress of the work, the Consultant / Employer
may take suitable action and deemed fit without prejudice to any terms and
conditions of the contract.
15. Site Order Book
i. For issuing instructions to Contractors in the course of day-to-day supervision of works, Site Order Books shall be maintained in a prescribed form (format can be obtained from Employer). The pages shall be machine
numbered in triplicate, so that a copy each of the pages can be given to the Contractors and the Consultants/PMC for necessary action. While issuing such instructions, the Contractors'/his authorised representative's signature
shall be obtained in the Office copy.
ii. Instructions in the Site Order Book shall be recorded under the signature of the PMC/Bank's Engineer at the site or the Consultants' Resident Engineer. The Engineers of the PMC during their periodical inspection / visits
shall peruse and record their instructions, if any, in this book.
iii. All instructions to the Contractors which are at variance with tender provisions as also pointing out through Site Order Book by the Site Engineer as well as Senior Engineers visiting the site of construction for inspection.
iv. The Site Order Book shall be kept in the custody of the Bank's Engineer/PMC at site. This fact shall be made clear to the Contractors at the
beginning of work.
v. The Site Order Book shall be referred at the time of making final payments to the Contractors.
Page 36 SEAL AND SIGN OF BIDDER
16. Hindrance Register
In order to have a record of hindrances in the progress of work which may
result in delays and consequent claims from the contractors for extension of
time, a "Hindrance Register" shall be maintained at the construction site.
The details of the hindrances with time period shall be recorded by the
Bank's Engineer / PMC therein as and when these occur and all recordings
shall be signed jointly by the Bank's Engineer/ PMC and that genuine and
acceptable hindrances to their work recorded in this register will only be
considered for extension of time.
17. LIQUIDATED DAMAGES
Should the work be not completed to the satisfaction of the Employer within
the stipulated period, the contractor shall be bound to pay to the
Employer a sum calculated as given below by way of liquidated damages
and not as penalty during which the work remains uncommenced or
unfinished after the expiry of the completion date.
a. Liquidated damages : Time is the essence of the contract and Liquidated Damages" shall be
recovered from the contractor’s dues for delay in completion of the work on
his part, subject to force majeure clause. The quantum of liquidated
damages per week shall be calculated at 0.25% of the estimated cost put to
tender subject to a maximum 5% of the accepted tender amount.
18. NOTICE AND PATENTS OF APPROPRIATE AUTHORITY AND EMPLOYERS
The contractor shall conform to the provisions of any Acts of the Legislature
relating to the work, and to the Regulations and Bye-Laws of any
authorities, and / or any water, lighting and other companies, and / or
authorities with whose systems the structures were proposed to have
connection and shall before making any variations from the drawings or
specifications that may be associated to so conform, give the Employer /
Consultants written notices specifying the variations proposed to be made
and reasons for making them and apply for instruction thereon. The
Employer / Consultants written notices specifying the variations proposed to
Page 37 SEAL AND SIGN OF BIDDER
be made and reasons for making them and apply for instruction thereon.
The Employer / Consultants on receipt of such intimation, shall give a
decision within a reasonable time.
The contractor/s shall arrange to give all notices required for by the
said Acts, Regulations or Bye-laws to be given to any authority, and to pay
to such authority or to any public officer all fees that may be properly
chargeable in respect of the work and lodge the receipts with the Employer.
The contractor shall indemnify the Employer against all claims in respect of
patent rights, royalties, and damages to buildings, roads or members of
public in course of execution of work and shall defend all actions arising
from such claims and shall keep the Employer saved harmless and
indemnified in all respects from such actions, costs and expenses.
19. MATERIALS, WORKMANSHIP, SAMPLES, TESTING OF MATERIALS.
All the works specified and provided for in the specifications or which may
be required to be done in order to perform and complete any part thereof shall
be executed in the best and most workmanlike manner with materials of the
best and approved quality of the respective kinds in accordance with the
particulars contained in and implied by the specifications and as represented
by the drawings or according to such other additional particulars, and
instructions as may from time to time be given by the Employer /
Consultants during the execution of the work and to his entire satisfaction.
All mandatory tests shall be carried out as per CPWD specifications. If
required by the Employer / Consultants, the contractor shall have to
carry out tests on materials and workmanship in approved materials
testing laboratories or as prescribed by the Employer / Consultants at
his own cost to prove that the materials etc., under test conform to the
relevant I.S Standards or as specified in the specifications. The
necessary charges for preparation of mould (in case of concrete cube),
transporting, testing etc., shall have to be borne by the contractor. No extra
payment on this account should in any case be entertained.
All the materials (except where otherwise described) stores and equipment
required for the full performance of the work under the contract must be
provided through normal channels and must include charges for import
duties, sales tax, octroi and other charges and must be the best of their kind
available and the contractors must be entirely responsible for the proper and
Page 38 SEAL AND SIGN OF BIDDER
efficient carrying out of the work. The work must be done in the best
workmanlike manner. Samples of all materials to be used must be
submitted to the Employer / Consultants when so directed by the
Engineer / Consultants and written approval from Employer must be
obtained prior to placement of order.
Any damage (during constructions) to any part of the work for any reasons
due to rain, storm or neglect of contractor shall be rectified by the contractor
in an approved manner at no extra cost.
Should the work be suspended by reason of rain, strike, lockouts or any
other cause, the contractor shall take all precautions necessary for the
protection of work and at his own expenses shall make good any damage
arising from any of these causes.
The contractor shall cover up and protect from damage, from any cause, all
new work and supply all temporary doors, protection to windows, and any
other requisite protection for the execution of the work whether by himself or
special tradesmen or sub-contractor and any damage caused must be made
good by the contractor at his own expenses.
20. REMOVAL OF IMPROPER WORK
The Employer shall during the progress of the work have power to order in
writing from time to time the removal from the work within such reasonable
time or times as may be specified in the order of any materials which in the
opinion of the Employer are not in accordance with specification or
instructions, the substitution or proper re- execution of any work executed
with materials or workmanship not in accordance with the drawings and
specifications or instructions. In case the contractor refuses to comply with
the order the Employer shall have the power to employ and pay other
agencies to carry out the work and all expenses consequent thereon or
incidental thereto as certified by the Employer / Consultants shall be done
by the contractor or may be deducted from any money due to or that may
become due to the contractor. No certificate, which may be given by the
Consultants, shall relieve the contractor from his liability in respect of
unsound work or bad materials.
Page 39 SEAL AND SIGN OF BIDDER
21. SITE ENGINEER
The contractor shall afford the Employer’s representative every facility and assistance for examining the works and materials and checking the measuring time and materials. Neither the Employer’s representative nor any assistant to the Consultant shall have power to revoke, alter enlarge or relax the requirements of this Contract, or to Sanction any day- work, additions, alterations, deviations or omissions unless such an authority may be specially conferred by a written order of the Employer.
The Employer’s Representative shall have to give notice to the Contractor or his foremen about the non-approval of any work or materials and such works shall be suspended or the use of such material should be discontinued until the decision of the Consultant is obtained, the work will from time to time be examined by the Consultant or the Employer’s representative but such examinations shall not in any way exonerate the Contractor from the obligation to remedy defects which may be found to exist at any stage of the work of after the same is completed. Subject to the limitations of this cause, the Contractor shall take instruction from the Consultant / Employer.
22. CONTRACTOR’S EMPLOYEES
The Contractor shall employ technically qualified and competent
supervisors for the work who shall be available (by turn) throughout the
working hours to receive and comply with instructions of the Employer /
Consultants. The contractor shall engage at least one experienced
Engineer as site-in-charge for execution of the work. The contractor shall
employ in connection with the work persons having the appropriate skill or
ability to perform their job efficiently.
The contractor shall employ local laborers‟ on the work as far as possible. No
laborers below the age of sixteen years and who is not an Indian National
shall be employed on the work.
Any labourer supplied by the contractor to be engaged on the work on day
work basis shall be deemed to be a person employed by the contractor.
The contractor shall comply with the provisions of all labour legislation
including the requirements of
a) The payment of Wages Act.
b) Employer’s Liability Act.
c) Workmen’s Compensation Act.
Page 40 SEAL AND SIGN OF BIDDER
d) Contract Labour (Regulation & Abolition) Act. 1970 and Central Rules 1971
e) Apprentices Act 1961
f) Minimum Wages Act
g) Any other Act or enactment relating thereto and rules framed
there under from time to time.
The contractor shall keep the Employer saved harmless and indemnified
against claims if any of the workmen and all costs and expenses as may be
incurred by the Employer in connection with any claim that may be made by
any workmen.
The contractor shall comply at his own cost with the order for requirement of any Health Officer of the State or any local authority or of the Employer regarding the maintenance of proper environmental sanitation of the area where the contractor’s laborers are housed or accommodated, for the prevention of small pox, cholera, plague, typhoid, malaria and other contagious diseases. The contractor shall provide, maintain and keep in good sanitary condition adequate sanitary accommodation and provide facilities for pure drinking water at all times for the use of men engaged on the works and shall remove and clear away the same on completion of the works. Adequate precautions shall be taken by the contractor to prevent nuisance of any kind on the works or the lands adjoining the same.
The contractor shall arrange to provide first aid treatment to the laborers‟ engaged on the works. He shall within 24 hours of the occurrence of any
accident at or about the site or in connection with execution of the works
report such accident to the Employer and also to the competent Authority
where such report is required by law.
23. DISMISAL OF WORKMEN
The contractor shall on the request of the Employer immediately dismiss from
works any person employed thereon by him, who in the opinion of the
Employer be unsuitable or incompetent or who may misconduct him. Such
discharges shall not be the basis of any claim for compensation or damages
against the Employer or any of their officer or employee.
Page 41 SEAL AND SIGN OF BIDDER
24. ASSIGNMENT
The whole of the works included in the contract shall be executed by the
contractor and the contractor shall not directly or indirectly transfer, assign
or underlet the contract or any part, share or interest therein nor, shall take
a new partner, without written consent of the Employer and no subletting
shall relieve the contractor from the full and entire responsibility of the
contract or from active superintendence of the work during their progress.
25. DAMAGE TO PERSONS AND PROPERTY INSURANCE ETC
The contractor shall be responsible for all injury to the work or workmen to persons, animals or things and for all damages to the structural and / or decorative part of property which may arise from the operations or neglect of himself or of any sub-contractor or of any of his or a sub-contractor’s employees, whether such injury or damage arise from carelessness, accident or any other cause whatsoever in any way connected with the carrying out of this contract. The clause shall be held to include inter-alias, any damage to buildings whether immediately adjacent or otherwise, and any damage to roads, streets, foot paths or ways as well as damages caused to the buildings and the works forming the subject of this contract by rain, wind or other inclemency of the weather. The contractor shall indemnify the Employer and hold harmless in respect of all and any expenses arising from any such injury or damages to the person or property as aforesaid and also in respect of any claim made in respect of injury of damage under any acts on compensation or damage consequent upon such claim.
The contractor shall reinstate all damages of every sort mentioned in this
clause so as to deliver the whole of the contract works complete and perfect in
every respect and so as to make good or otherwise satisfy all claims for
damages to the property of third parties.
The contractor shall affect the insurance necessary and indemnify the Employer entirely from all responsibility in this respect. The original insurance policy will be with NABARD which will be jointly in the name of the Employer and contractor and the duplicate will be with the contractor. The scope of insurance is to include damage or loss to the contract itself till this is made over in a complete state, so contractor will take the CAR (Contractors All Risk Policy) for insurance equal to the amount of issued work order for this work. Insurance is compulsory and must be affected from the very initial stage. The contractor shall also be responsible for anything, which may be excluded from damage to any property arising out of incidents, negligence or defective carrying out of this contract.
Page 42 SEAL AND SIGN OF BIDDER
The Employer shall be at liberty and is hereby empowered to deduct the
amount of any damages, compensations, costs, charges and expenses arising
or accruing from or in respect of any such claim or damages from any sums
due to or to become due to the contractor.
26. MEASUREMENTS
As per CPWD guidelines. Before taking any measurement of any work the
contractor/ its representative deputed by him shall give reasonable notice to
the employer. The mode of measurement will depend upon the unit mentioned
in the Schedule of Quantities. If the contractor fails to attend at the
measurements after such notice or fails to countersign or to record the
difference within a week from the date of measurement in the manner required
by Site Engineer or by the subordinate deputed by him as the case may be is
final and binding on the contractor and contractor shall have no right to
dispute the same. The Measurement shall be jointly done with Consultant and
Accepted by the Client.
The Employer / Consultant shall issue a certificate after due scrutiny of the contractor’s bill stating the amount due to the contractor from the Employer and the contractor shall be entitled to payment thereof, within the period of honoring certificates named in
27. PAYMENTS
All bills shall be prepared by the contractor in the form prescribed by the Employer / Consultants. Normally one interim bill shall be prepared each month subject to minimum value of Rs 75 lakhs per month for interim certificate as stated in these documents. The bills in proper forms must be duly accompanied by detailed measurements in support of the qualities of work done and must show deductions for all previous payments, retention money, etc.
The Employer / Consultant shall issue a certificate after due scrutiny of the
contractor’s bill stating the amount due to the contractor from the Employer
and the contractor shall be entitled to payment thereof, within the period of
honoring certificates named in these documents.
The Employer will deduct retention money as described in clause 11 of these
conditions. The refund of retention money will be made as specified in the
said clause.
Page 43 SEAL AND SIGN OF BIDDER
If the Employer has supplied any materials or goods to the contractor, the
cost of any such materials or goods will be progressively deducted from the
amount due to the contractor in accordance with the quantities consumed in
the work.
All the interim payments shall be regarded as payments by way of advance
against the final payment only and not as payments for work actually done
and completed, and shall not preclude the requiring of bad, unsound,
and imperfect or unskilled work to be removal and taken away and
reconstructed, or re-erected or be considered as and admission of the due
performance of the contract, or any part thereof in any respect or the accruing
of any claim, nor shall, it conclude, determine or affect in any way the power
of the Employer under these conditions or any of them as to the final
settlement and adjustment of the accounts or otherwise or in any other way
vary or affect the contract. The final bill shall be submitted by the contractor
to the consultant within one week of the date fixed for completion of the work
or of the date of certificate of completion furnished by the Consultant. The
payment of final bill shall be made by the employer within 45days from the
date of receipt of bill from Consultant. All interim bills shall be supported with
necessary valid insurance covers, test certificates, measurement sheets of
work done duly certified by the consultant and accepted by the contractor,
any other documents as required by the consultant/employer.
Final Payment The final bill shall be accompanied by a certificate of completion from the Employer / Consultants, and other relevant documents such as ……….build drawings etc. Payments of final bill shall be made after deduction of Retention Money as specified in clause 11 of these conditions, which shall be refunded after the completion of the Defects Liability Period after receiving the Employer’s/Consultant’s certificate that the contractor has rectified all defects to the satisfaction of the Employer / Consultants. The acceptance of the payment of the final bill by the contractor would indicate that he has no further claim in respect of the work executed.
28. VARIATION / DEVIATION
The tender rates shall be fixed and applicable for any increase or decrease in
the tendered quantities. The Employer / Consultant can increase or
decrease any quantities to any extend or even delete particular item as per
the site requirements and the contractor shall not be paid anything extra on
Page 44 SEAL AND SIGN OF BIDDER
this account. Nothing extra will be paid by the Bank on account of omission /
deletion of items or decrease in the quantity of items. The Bank shall not
entertain any claim whatsoever from the contractor on this account.
The price of all additional items / non-tendered items will be worked out on
the basis of rates quoted for similar items in the contract wherever existing. If
similar items are not available, the rates for such items will be derived as per
standard method of rate analysis based on prevalent fair price of labour,
material and other components as required with 15% towards contractor’s
profit and overheads plus applicable Service Tax.
29. SUBSTITUTION
Substitution is generally not allowed, in case of exception it will be permitted after the approval of the Employer / Consultants in writing for any such substitution well in advance. Materials designated in this specification shall be prefer first and in case of non- availability those mentioned in BoQ the substitution by “Equal” or “Other approved” etc. needs approval of the Employer / Consultant in writing.
30. CLEARING SITE ON COMPLETION
On completion of the works the contractor shall clear away and remove from
the site all constructional plant, surplus materials, rubbish and temporary
works of every kind and leave the whole of the site and the works clean and in
a workmanlike condition to the satisfaction of the Employer/Consultants.
31. DEFECTS AFTER COMPLETION
The contractor shall make good at his own cost and to the satisfaction of the
Employer all defects, shrinkage, settlements or other faults, which may appear
within 12 months after completion of the work. In the default, the Employer
may employ and pay other persons to amend and make good such damages,
losses and expenses consequent thereon or incidental thereto shall be made
good and borne by the contractor and such damages, loss and expenses shall
be recoverable from him by the Employer or may be deducted by the employer,
in lieu of such amending and making good by the contractor, deduct from any
money due to the contractor a sum equivalent to the cost of amending such
Page 45 SEAL AND SIGN OF BIDDER
work and in the event of the amount retained being insufficient recover that
balance from the contractor from the amount retained under clause no.11
together with any expenses the Employer may have incurred in connection
therewith.
32. CONCEALED WORK
The contractor shall give due notice to the Employer/Consultants whenever any
work is to be buried in the earth, concrete or in the bodies of walls or otherwise
becoming inaccessible later on, in order that the work may be inspected and
correct dimensions taken before such burial, in default whereof the same
shall, at the opinion of the Employer/ Consultant be either opened up for
measurement at the contractor’s expenses or no payment may be made for such
materials. Should any dispute or differences arise after the execution of any
work as to measurements etc., or other matters which cannot be conveniently
tested or checked, the notes of the Employer / Consultants shall be accepted
as correct and binding on the contractor.
33. IDLE LABOUR
Whatever the reasons may be, no claim for idle labour, additional
establishment cost of hire and labour charges of tools and plants would be
entertained under any circumstances.
34. SUSPENSION OF WORKS
If the contractor except on account of any legal restraint upon the Employer
preventing the continuance of the work or in the opinion of the Employer shall
neglect or fail to proceed with due diligence in the performance of his part of
the contract or if he shall more than once make default, the Employer shall
have the power to give notice in writing to the contractor requiring the work to
be proceeded within a reasonable manner and with reasonable dispatch, such
notice purport to be a notice under this clause.
After such notice shall have been given, the contractor shall not be at liberty to
remove from the site of the works or from any ground contiguous thereto any
plant or materials to subsist from the date of such notice being given until the
Page 46 SEAL AND SIGN OF BIDDER
notice shall have been compiled with. If the contractor fails to start the work
within seven days after such notice has been given to proceed with the
works as therein prescribed, the employer may proceed as provided in clause
34. (Termination of Contract by Employer)
35. TERMINATION OF CONTRACT BY EMPLOYER
If the contractor being a company go into liquidation whether voluntary or
compulsory or being a firm shall be dissolved or being an individual shall be
adjudicated insolvent or shall make an assignment or a composition for the
benefit of the greater part, in number of amount of his creditors or shall enter
into a Deed or arrangement with his creditors, or if the Official Assignee in
insolvency, or the Receiver of the contractor in insolvency, shall repudiate the
contract, or if a receiver of the contractor’s firm appointed by the court shall be
unable within fourteen days after notice to him requiring him to do so, to show
to the reasonable satisfaction of the employer that he is able to carry out and
fulfill the contract, and if so required by the employer to give reasonable
security therefore, or if the contractor shall suffer execution to be issued, or
shall suffer any payment under this contract to be attached by or on behalf of
and of the creditors of the contractor, or shall assign, charge or encumber this
contract or any payments due or which may become due to contractor, there
under, or shall neglect or fail to observe and perform all or any of the acts
matters of things by this contract, to be observed and performed by the
contractor within three clear days after the notice shall have been given to the
contractor in manner hereinafter mentioned requiring the contractor to
observe or perform the same or shall use improper materials of workmanship
in carrying on the works, or shall in the opinion of the employer not exercise
such due diligence and make such progress as would enable the work to be
completed within due time agreed upon, and shall fail to proceed to the
satisfaction of the employer after three clear das notice requiring the contractor
so to do shall have been given to the contractor as hereinafter mentioned or
shall abandon the contract, then and in any of the said cases, the Bank may
notwithstanding previous waiver determine the contract by a notice in
writing to the effect as hereinafter mentioned, but without thereby effecting
the powers of the employer of the obligations and liabilities of the contractor
the whole of which shall continue in force as fully as if the contract, had not
been so determine and as if the works subsequently executed by or on behalf
of the contractor (without thereby creating any trust in favour of the contractor)
further the employer or his agent, or servants, may enter upon and take
Page 47 SEAL AND SIGN OF BIDDER
possession of the work and all plants tools scaffolding sheds machinery, steam,
and other power, utensils and materials lying upon premises or the adjoining
lands or roads and sell the same as his own property or may employ the same
by means of his own servants and workmen in carrying on and completing the
works or by employing any other contractors or other persons or person to
complete the works, and the contractor shall not in any way interrupt or do any
act, matter or thing to prevent or hinder such other contractors or other
persons or person employed from completing and finishing or using the
materials and plants for the works when the works shall be completed, or as
soon thereafter as conveniently may be the employer shall give notice in writing
to the contractor to remove his surplus materials and plants and should the
contractor to remove his surplus materials after receipt by him the employer
may sell the same by Public Auction and shall give credit to the contractor for
the amount so realized. Any expenses or losses incurred by the contractor for
the amount so realized. Any expenses or losses incurred by the employer in
getting the amount payable to the contractor by way of selling his tools and
plants or due on account of work carried out by the contractor prior to
engaging other contractors or against the Security Deposit.
36. ARBITRATION
All disputes or differences of any kind whatsoever which shall at any time arise
between the parties hereto touching or concerning the works or the execution or
maintenance thereof this contract or effect thereof or to the rights or liabilities of
the parties or arising out of or in relation thereto whether during or after
determination foreclosure or breach of the contract (other than those in respect
of which the decision of any person is by the contract expressed to be final and
binding) shall after written notice by either party to the contract to the other of
them and to the Employer hereinafter mentioned be referred for adjudication to a
sole Arbitrator to be appointed as hereinafter provided.
For the purpose of appointing the sole Arbitrator referred to above, the Employer will send within thirty days of receipt of the notice, to the contractor a panel of three names of persons who shall be presently unconnected with the organization for which the work is executed from the following categories of Arbitrators”:-
a. Retired High Court/Supreme Court judge who have experienced in handling Arbitration Cases.
b. Member of Council of Arbitrators
Page 48 SEAL AND SIGN OF BIDDER
c. Fellow of the Institution of Engineers
d. Eminent Retired Chief Engineer from State/Central PWD/Public sector
undertaking of good reputation and integrity
e. Fellow of Indian Institute of Consultants
The contractor shall on receipt of the names as aforesaid, select any one of the
person’s name to be appointed as a sole Arbitrator and communicate his name
to the Employer within thirty days of receipt of the names. The Employer shall
thereupon without any delay appoint the said person as the Sole Arbitrator. If
the contractor fails to communicate such selection as provided above
within the period specified, the Employs should make the selection and
appoint the selected person as the Sole Arbitrator.
If the Employer fails to send to the contractor the panel of three names as
aforesaid within the period specified, the contractor shall send to the Employer a
panel of three names of persons who shall all be unconnected with either party.
The Employer shall on receipt appoint him as the Sole Arbitrator. If the
Employer fails to select the person and appoint him as the Sole Arbitrator
within 30days of receipt of the panel and inform the contractor accordingly, the
contractor shall be entitled to appoint one of the persons from panel as the Sole
Arbitrator and communicate his name to the Employer.
If the Arbitrator so appointed is unable or unwilling to act or resigns his
appointment or vacates his office due to any reason whatsoever another
Sole Arbitrator shall be appointed as aforesaid.
The work under the Contract shall, however, continue during the arbitration
proceedings and no payment due or payable to the contractor shall be withheld
on account of such proceedings.
The Arbitrator shall be deemed to have entered on the reference on the date he
issued notice to both the parties fixing date of the first hearing.
The Arbitrator may from time to time, with the consent of the parties, enlarge the
time for making and publishing the award.
The arbitrator shall give a separate award in respect of each dispute or difference
referred to him. The Arbitrator shall decide each dispute in accordance with the
terms of the contract and give a reasoned award. The venue of arbitration shall
be such place as may be fixed by the Arbitrator in his Sole discretion.
Page 49 SEAL AND SIGN OF BIDDER
The award of the Arbitrator shall be final and binding on the both the
parties.
Subject to aforesaid the provisions to the Arbitration Act. 1992 or any statutory
modification or re-enactment thereof and the rules made there under, and for the
time being in force, shall apply to the arbitration proceeding under this clause.
The Employer and the contractor hereby also agree that arbitration under clause
shall be condition precedent to any right to action under the contract with regard
to the matters hereby expressly agreed to be so referred to arbitration.
Page 50 SEAL AND SIGN OF BIDDER
7. SPECIAL CONDITIONS OF CONTRACT
1. Completeness of contract
Contractor shall be deemed to have carefully examined the specifications,
general conditions and tender drawings, etc. and to have been fully informed
and have satisfied himself as to the nature and character of the work to be
executed, site conditions and other relevant matters and details.
Contractor shall provide all items whether specifically mentioned or not but
which are usual or required to make a complete working plant and to ensure
safe and satisfactory operations. All apparatus, appliances material or labour
which may be necessary to complete the work in accordance with the intent or
purpose of these specifications shall be considered to be in the scope of work of
the contract and shall be furnished without extra charge, as if fully described
and called for these specifications. In case of doubt, the tenderer shall clearly
point out his construction, of the specifications, before award of contract.
Contractor shall study the site conditions and the equipment room layouts and
confirm that the size of various rooms indicated is sufficient for his equipment
to perform to the full capacity.
Unless otherwise agreed in writing, these specifications, drawings and general
conditions etc., form the contract documents and all clauses and conditions
specified by the contractor stand null and void.
2. References
Reference to standards, codes, specifications, and recommendations shall mean
the latest edition of such publications adopted and published at date of
invitations to submit proposals.
3. Inspections and Testing At Contractor's Premises
Employer or his authorized representatives shall have full power to inspect
drawings or any portion of the work or examine the materials and workmanship
of the plant at Contractor's work or at any place from which the material or
equipment is obtained.
Page 51 SEAL AND SIGN OF BIDDER
Acceptance of any material or equipment shall in no way relieve the Contractor
of his responsibility formatting the requirements of the specifications. All the
required tests shall be carried out by the Contractors at no extra cost.
4. Programmes of Work & Progress Reports
Within 15 days of acceptance of the tender the Contractor in consultation with
the consultant & consultant shall submit a detailed schedule showing the
programmed and order in which the contractor proposes to carry out the work
with dates and estimated completion time for various parts of the work in the
form of bar/pert charts based on critical path method.
The application for payments against delivery of major equipment shall not be
earlier than the delivery schedule indicated in the bar chart.
All civil work connected with the A.C. work will be the responsibility of the
contractor and no extra cost shall be paid by the employer.
Such schedules shall be approved by the Consutant/Bank’s engineer or
Authorised Representative of the Bank before starting of the work and shall be
binding on the contractor.
In addition to the above, the Contractor shall furnish weekly reports indicating
his progress with respect to the approved schedule clearly pointing out delays, if
any.
5. Drawing and Literature
Before proceeding with the work the contractor shall submit for approval general
layout and assembly drawings & such additional assembly and sub-assembly
detail drawing as are necessary to demonstrate fully that all parts of the
apparatus to be furnished will confirm to the specifications within 15 days of the
acceptance of the tender the Contractor shall furnish three (3) prints of layout,
assembly and erection drawings for approval. On approval six (6) further prints
of the modified drawings incorporating Consultants & consultant comments
shall be submitted. No modifications shall be made in a drawing after it has
been approved by the Consultant, without his prior consent. All drawings
necessary for assembly, erection, maintenance, repair and operation of the
Page 52 SEAL AND SIGN OF BIDDER
equipment shall be furnished. Different parts shall be suitably numbered for
identifications and ordering of spare-parts.
Approval by the Consultant of the drawings shall not relieve the Contractor of
any part of his obligation to meet all the requirements of the Employer or the
corrections of his drawings. The Contractor shall be responsible for and for all
alteration of the works due to discrepancies or omissions in the drawings of
other particulars supplied by him whether such drawings have been approved
by the Employer or not.
After execution of work, Contractor shall furnish a set of original tracings or
floppy’s of the ‘as built’ drawings.
The Contractor shall furnish and install in the machine room a neatly typed a
set of operating instructions securely framed and glazed as per the directions of
the Engineer.
6. Inspection of Drawings
Before filling in the tender, the Contractor will have to check up all the drawings
and schedule of quantities, and will have to get an immediate clarification from
the Consultant on any point that he feels is vague or uncertain. No claim for
damages or compensation will be entertained on this account.
7. Execution of Work
The whole of the work as described in the Contract (Including the schedule of
quantities, the specifications and all drawings pertaining thereto) and as advised
by the Employer/Consultant from time to time is to be carried out and
completed in all its parts to the entire satisfaction of the Employer/Consultant
and the Engineer, Any details of construction which may not have been
definitely referred to in this contract, but which are usual in sound installation
practice and essential to the work are to be included in this Contract. Rates
quoted in the Schedule shall be inclusive of all freights, taxes, such as Octroi,
Sales Tax, Royalties etc. as well as transportation, so as to execute the contract
as per the rules and regulations, of local bodies, State Government and
Government of India.
Page 53 SEAL AND SIGN OF BIDDER
The rates quoted in the tender should include all charges for:
a) Labour, maintenance, fixing, carrying, cleaning, making good, hauling,
watering etc. b) Plant, double scaffolding, framework, English ladders, ropes, nails, spikes ,
tools, materials and workmanship protecting from weather shuttering, temporary supports, platform and the maintenance of the same.
c) Covering for the walling and other works during inclement weather or strikes
or wherever directed as necessary. d) All temporary canvas, lights, tarpaulin, barricades, water shouts, etc. e) All stairs and steps, thresholds and any other requisite protection of the works
according to rules and regulations. f) All such temporary weather proof sheds at such places and in a manner
approved by the consultant for the storage and protection of materials against the effects of sun and rain.
g) All such temporary fences, guards, approaches and roads as may be necessary
for execution of the Contract works and for safeguarding the public. h) Electrical power for erection, commissioning & testing shall be provide at one
point & all ancillary work shall be in contractor scope. i) The rates quoted by the tenderer in the schedule of probable items will be
deemed to be for the finished work.
8. Contractor to Visit Site
Each tenderer must before submit his tender, visit the site of works so as to
ascertain the physical site conditions and prices, availability and quality of
materials according to specifications before submitting the quotations. Non-
availability of materials or changes in the price will not be entertained and no
extra shall be allowed on that account.
9. Site Meetings
A senior representative of the Contractor shall attend weekly meeting at work
site and in addition meeting as arranged by Employer/Consultant to discuss the
progress of work and sort out problems if any and ensure that the work is
completed in stipulated time.
Page 54 SEAL AND SIGN OF BIDDER
10. Site Supervisor
The Contractor shall appoint at his own cost competent Engineer at site.
Employer/Consultant shall approve his appointment. The Site Engineer shall
not be removed from the site without the written consent of the
Employer/Consultant.
11. Access for Inspection
The Contractor has to provide at all times during the progress of the work and
the maintenance period, proper means of access with ladders, gangways etc.,
and the necessary attendants to move and adapt the same as directed for the
inspection or measurement of the works by the Employer/Consultant or their
representatives.
12. Notices
The Contractor shall give all notices and pay all fees and shall comply with all
acts and regulations for the successful completion of the contract works, as per
the rules and regulations of all relevant authorities.
13. Facilities to Other Contractors
The Contractors shall give full facilities and cooperation to all other contractors
working at site such as civil, plumbing, electrical, machinery erectors, etc., as
directed by the Employer & Consultant and shall arrange his programme of
work so as not hinder the progress of other works. The decision of the
Consultant & Consultant on any point of dispute between the various
Contractors shall be final and binding on all parties concerned.
14. Works at night
If the Contractor is required to work at night in order to complete the work
within the time schedule, the Contractor shall do so with the prior approval of
Employer and provide and maintain at his own cost sufficient lights to enable
Page 55 SEAL AND SIGN OF BIDDER
the work to proceed satisfactorily without danger. Approaches to the site also
shall be sufficiently lighted by the Contractor. No labour force shall be permitted
to stay at site.
15. Work on Holidays
No work shall be done on Sundays or other holidays that may be notified by the
Employer & Consultant without the specific sanction writing of the Employer or
his representatives.
16. Reporting of Accidents to the Employer
The Contractor shall be responsible for the safety of all the persons working at
site including visitors etc., and shall report serious accidents to any of them
wherever occurring on the works to the Consultants and Employers. This shall
be without prejudice to the responsibility to the contractor under the Insurance
Clause of the General Conditions.
17. Dimension
Figure dimensions are in all cases to be accepted in preference to scaled sizes.
Large-scale details take precedence over small-scale drawings. In case of
discrepancy, the Contractor has to ask the Consultants for an explanation
before proceeding with the work.
18. Information to be supplied by the Contractor
The Contractor shall submit to the Employer every week as per the proforma:
i) Detailed industrial statistics regarding the labour employed by him daily.
ii) The list of technically qualified persons employed by him for the execution of
the work.
iii) The total quantity and quality of materials used for the works and supplied
to the site.
Page 56 SEAL AND SIGN OF BIDDER
iv) A weekly progress report.
v) Weather report including temperature and humidity.
vi) Special incident at site.
vii) Whether the work is progressing according to schedule. If not, what are the
hitches and the remedial measure?
19. Treasure Trove
Should any treasure, fossils, mineral or work of art of antiquarian interest be
found during excavation of while carrying out the work, the same will be the
property of the Employer. The Contractor shall give immediate notice of any
such treasure to the Employer.
20. Programmes
The Contractor shall within 3 days of the award of the Contract submit to the
Employer a detailed programme of construction according to the forgiven time
schedule. He shall make all changes deemed necessary by the
Employer/Consultant for the fulfillment of the job by due dates.
21. Work and Services to be provided by the Employer
The Employer will provide electric power and water at one point in the building
for proper execution of the work. The Contractor will however have to pay for the
electric power and water consumed by him at the rates chargeable by the local
authorities.
The contractor shall provide all necessary foundations, wall cuttings, anchor
bolts, nuts, washers, vibration isolators etc., required to be grouted in the
foundations.
The Employer depending on the availability will provide one lockable storage
space. However, the security of the materials and equipment brought to site by
the contractor shall be the responsibility of the contractor till the plant is taken
over by the Employer as stipulated elsewhere in these conditions of contract.
Page 57 SEAL AND SIGN OF BIDDER
Also accommodation required for the contract labour shall be arranged by the
contractor himself.
22. Approved Materials
The Contractor shall get all the equipment and materials approved by the
Employer or its Authorised Representative prior to placing order/ procurement.
23. Time Schedule
The work shall be commenced on 10th day of award of Work and shall be
completed in all respects in 10 weeks as per the time schedule submitted by the
Contractor and approved by the Employer/Consultant.
24. Testing
Witnessing the Testing & Clearance of all major equipment / components at
OEM’s works with simulated operating condition as per the instruction of the
MEP consultant is mandatory before the dispatch of the same.
Routine and type tests for the various items of equipment shall be performed at
the contractors works and test certificates furnished. If required by the
Employer, the contractor shall permit the Employer's authorized representative
to be present during any of the tests. After notification to the Employer that the
installation has been completed, the Contractor shall make, under direction and
in the presence of the Employer such tests and inspections as have been
specified or as the Bank’s Engineer shall considered necessary to determine
whether or not the full intent of the requirements of the plant and specifications
have been fulfilled. In case the work does not meet the full intent of the
specifications and further tests shall be considered necessary, the Contractor
shall bear all the expenses hereof.
All the major equipments may be got inspected & tested before dispatch if
desired by the client at the manufacturers work. The AC Contractor shall
intimate the client minimum 21 days in advance about the date of readiness of
equipment for inspection & testing at a date to be mutually agreed upon by the
client & the AC Contractor. The manufacturer of these equipments must have a
Page 58 SEAL AND SIGN OF BIDDER
facility of testing the equipments at the test bed on full load at their works. All
the test readings mutually taken shall be recorded & evaluated with the
technical data furnished by the AC Contractor.
All equipment shall be tested as per tender specifications where test result
indicate capacity less then specified, the Contractor shall pay to the Employer
pro-rata compensation against each item. No compensation shall however, be
payable if the shortfall is 3% or less. All instruments shall be of the required
accuracies and shall be furnished by the contractor at no extra cost. Generally
ASHRAE CODE shall be followed for testing of equipment.
The contractor shall operate, test and adjust all air conditioning units; fans,
motors etc. provided in connection with this installation and shall make all
necessary adjustments and connections thereof.
Performance tests of the system and individual equipment shall be carried out
during peak summer and monsoon conditions and test reading furnished.
All test equipment, labour, operating personnel, oil and Freon required for these
tests shall be furnished by the Contractor, to enable the plant to be put in
continuous running test for a period of three days after all other tests and
adjustments have been made.
25. Rejection of Defective Plant/works
If the completed plant or any portion thereof certified by the Employer/
Consultant is found to be defective or fails to fulfill the intent of the
specifications, the Contractor shall on receipt from the Employer/Consultant
forthwith make the defective plant good.
The Employer shall have the right to operate all equipments if in operating
condition whether or not such equipment have been accepted as complete and
satisfactory, Repairs and alterations shall be made at such times and as
directed by the Employer.
26. Guarantees and Defects Liability Period
The Contractor shall guarantee that all equipments shall be free from any
defects due to defective materials and / or bad workmanship and that the
equipment shall operate satisfactorily and the performance and efficiencies of
Page 59 SEAL AND SIGN OF BIDDER
the equipment shall not be less than the guaranteed values. The guarantee shall
be valid for a period of 12 (twelve) months after “date of issue of virtual
completion certificate” and any equipment or parts found defective shall be
replaced free of all costs by the Contractor. This period shall be known as the
Defects Liability Period and shall be reckoned from the date the Engineer
certified the plant taking over as laid down in clause “Taking over of Plant”
hereinafter. The services of the Contractor's personnel, if requisitioned during
this period for such work, shall be made available free of all costs to the
Employer.
The guarantee shall cover replacement of refrigerant, oil etc.. If the defects be
not remedied within a reasonable period, the Employer may do so at the
contractor's risk and expenses without prejudice to any other rights.
27. Maintenance and Training for Personnel
The Contractor shall without any extra cost carry out for a period of 12 (Twelve)
months after the installation is taken over by the Employer, all special
maintenance of the plant and attend to any difficulties and defects that may
arise in the operation of the plant. The Contractor shall associate with him
during the erection and this period the Employer's maintenance staff to
familiarize them with the operation and maintenance of the plant. If required by
the consultant the contractor shall also agree to train members of the
Employer's maintenance staff either at his or his sub-contractor's work or at
such place or as may be considered suitable by the Employer & Consultant.
The Contractor during “The Defects Liability Period” shall depute a senior
Engineer at least once a month to check the plant and assist the maintenance
personnel of the Employer. Such visits shall be followed by detailed report
clearly indicating the conditions of the equipment, additional precautions
required to operate the plant in a more efficient way in case he finds the plant
not being used in a proper manner.
28. Tests on Completion
Test on completion shall mean such tests as are prescribed in the specifications
or have been mutually agreed to between the Contractor and the Employer /
Consultants to be made before the plant is taken over by the Employer. In case
tests are not possible due to climatic conditions at the time of completion, the
Page 60 SEAL AND SIGN OF BIDDER
Contractor shall be bound to carry out tests as prescribed hereafter at any time
subsequent to the date of completion but before the end of defects liability
period.
29. Taking over the Plant
The plant when erected at site shall be deemed to have been taken over by the
Employer when the Engineer will have certified in writing that the plant has
fulfilled the contract conditions.
The Contractor shall carry out the performance tests in presence of Employer
/Consultant for peak summer and monsoon conditions before the Employer
takes over the plant. In case due to no fault of the Contractor, it is not possible
to furnish the performance tests before the plant is taken over, the Contractor's
shall carry out the said performance test before the end of Defects Liability
Period. In case the contractor fails to carry out the performance test, Defects
Liability Period shall be extended till satisfactory completion of such tests
subject to performance of the equipment as per Tender Specifications.
30. Compensation for Shortfall in Equipment Capacity
All equipments shall be tested as per tender specifications. When test results
indicate capacity less than specified the contractor shall be asked for
replacement or pay to the Employer pro-rata compensation against each item
which will be proportional to it given in Bill of Quantities.
No compensation shall however be payable if the shortfall is 3% or less.
All instruments required for tests shall be of the required accuracy and shall be
furnished by the contractor at no extra cost. Generally ASHRAE CODE shall be
followed. No compensation shall be payable by the Employer to the Contractor
in case test results are more than the Contracted capacity.
30.1. Attend to any other work connected with the air conditioning and
ventilation work and other services, but not referred to in any of the paras
mentioned above.
30.2. Liaise with local bodies, Government, Quasi-Government and other
concerned authorities as may be necessary in connection with the said work;
Page 61 SEAL AND SIGN OF BIDDER
30.3. Other incidental items as may be necessary for execution of the above
work.
31. Extension of Time
Necessary extension of time for completion of works may be granted to the
Contractor only in exceptional cases, but he shall have no claim for any
compensation whatsoever due to the delay involved in completing the project.
32. Rates
The Contractor shall quote same rates for same items in schedule. In case the
Contractor quotes different rates for the same item in various scheduled the
lowest/smallest be taken as correct and the schedules amended accordingly.
The rates quoted in the tender shall be firm and not subject to any escalation for
any reason whatsoever till the completion of the project.
33. Sales and General Taxes
The Contractor shall include in the amount of their tender sales tax, VAT,
service tax, or any other tax, any octroi or any other charges of fees leviable by
the local authority, as it shall be assumed that the contractor's rates cover all
such taxes and no claims on this account shall be entertained.
34. Excise Duty
The quoted price shall be inclusive of full excise duty except where concessional
excise is applicable. The Contractor shall clearly indicate in his offer the
quantum and rate of excise included for all excisable items.
Statutory variation in excise duty on compressors, chillers and condensers, due
to revision in the rate of excise from the time of submission of offer up to the
agreed delivery time will be to the Employers account. However all other
variations including variation in excise on raw materials, unfinished products
and variation in excise beyond agreed delivery schedule will be to the
Page 62 SEAL AND SIGN OF BIDDER
contractor's account. Variation in accessible value of refrigeration equipment
will also be to the contractors account. Variation if any shall be considered only
against actual proof of excess duty payment.
35. Price Escalation
The accepted price of the successful tenderer shall be firm and free from any
variation till the completion of the project in all respects and handing over of the
plant to the Employer
36. Income Tax
Applicable income tax of value of work shall be deducted from all interim and
final bills and remitted to the Central Government towards provisional income
tax of the Contractor work which cannot be derived from the contract item rates
and are not covered in the contract shall be calculated on the basis of actual
cost plus 15% for supervision, overheads and profit.
37. ESIS and Provident Fund
The Contractor shall bear all the financial liability for Employees State
Insurance Scheme payment and Provident Fund for his workers, staff etc. The
Contractor shall extend all assistance to the Employer to deal with relevant
Local Authorities in these matters at no extra cost.
38. Statutory Regulations
The whole of the work including sanitation is to be complied with, as per the
requirements and bye-laws of the relevant statutory authorities including
Contract Labour (Regulation and Abolition) Act 1970. The contractor will
indemnify the Employer against all statutory rules and regulations of authorities
in the area with regards to construction of the project.
Page 63 SEAL AND SIGN OF BIDDER
39. Bills and Payments
The Contractor shall submit interim bills on the basis of joint measurements
recorded at work site by the Contractor's and Employer’s/Consultant’s
representatives. Payment will normally be made by the Employer in 30 days
from the date of issue of Employer’s/Consultant’s Certificate of payments.
40. Sales Tax on Work Contract
Amendment contractors have to pay Sales Tax only on the value of material and
they shall therefore quote the tender rate after taking net effect of Sales Tax on
work contract. This will not be paid for separately.
41. Machinery and Equipment
The Contractor will arrange to bring to site necessary diesel operated machinery
and equipment like welding sets etc., as required at no extra cost.
42. Insurance
The Contractor, is required to keep the works duly insured in the joint names
of NABARD and the Contractor (NABARD’s name being first) until the
completion of defect liability period of the works. The following insurance
policies are required to be taken by the contractor; From commencement to
completion of the works, the Contractor shall take full responsibility for the
care of the work and for taking precautions to prevent loss or damage to the
works and to minimize the loss or damage to the greatest extent possible and
shall be liable for any damage or loss that may happen to the works or any part
thereof from any cause whatsoever, inherent defects and failures due to poor
workmanship and causes such as fire, lightening, explosion, earthquake,
storm, hurricane, short circuits , floods, inundation, subsidence, landslides,
rock slides, riots (excluding civil war, rebellion, revolution and insurrection) and
shall at his own cost repair and make good the same so that at all times the
work shall be in good order and condition and in conformity in every respect
with the requirements of the Contract. Explanation: For the purpose of this
condition, the expression "from the commencement to completion defect
Page 64 SEAL AND SIGN OF BIDDER
liability period of the works " shall mean the time commencing from the issue of
the work order to the contractor and ending with successful completion of
work.
42.1. Contactor all risk policy : Without limiting the obligations and
responsibilities under this condition, the Contractor shall insure and keep
insured the works from commencement to completion, as aforesaid, for their
full value provided under this Contract, increased by 25% against the risk of
loss or damage from any cause whatsoever including the causes enumerated in
the Clause (a) above. In the event of there being a variation in the nature and
extent of the work, the Contractor shall from time to time increase or decrease
the value of the insurance correspondingly. The entire premium shall be borne
and paid by the Contractor. The said insurance shall also provide for the
removal of debris of the lost or damaged works.
42.2. Workmen Compensation Policy : The Contractor shall at all times
indemnify the Employer against all losses, claims or damages or compensation
under the provisions of the payment of Wages Act 1936, Minimum Wages Act
1948, Employees Liability Act 1938, Workmen's Compensation Act 1923, The
Maternity Benefit Act 1961, Industrial Disputes Act 1947 and Contract Labour
and Regulation and Abolition Act 1970, Employer State Insurance Act 1948 or
any modification thereof or any other law relating thereto and rules made there
under from time to time or as a consequence of any accident or injury to any
workman or other persons in or about the work whether in the Employment of
the Employer, or Contractor or not and also against all costs, charges and
expenses of any suit, action or proceedings whatsoever out of such accident or
injury or combination of any such claims.
42.3. Third party liability policy for a total of Rs. 5 lakhs.
42.4. Before commencing the work, the Contractor shall without limiting his
obligations and responsibilities under this condition, insure against any loss of
life or injury to any personnel in the employment of Contractor / Subcontractor
/ Nominated Sub-Contractor. For this purpose, insurance shall be taken by the
Contractor/Sub-Contractor. Such insurance shall be taken to include both
employees/workmen covered by the Workmen's Compensation Act 1923, as
well those employees/workmen not covered by the said Act. Separate insurance
policies may be taken for employees/workmen covered by Workmen's
Compensation Act 1923, and employees workmen not covered by the said Act.
All the premiums shall be paid by the Contractor.
42.5. The Contractor shall ensure that similar insurance policies are taken out
by his sub-contractors or nominated contractors, if any, and shall be
Page 65 SEAL AND SIGN OF BIDDER
responsible for any claim or loss resulting from their failure to obtain adequate
insurance protection in connection thereof. While taking the insurance policies,
contractor should indicate clearly to the insurance companies that policies
issued shall cover their sub-contractors and nominated subcontractors also.
42.6. No work shall be commenced by the Contractor unless and until he has
obtained the insurance or insurance required to be obtained by him under or
by the foregoing clauses and no work shall be carried out or continued by the
Contractor unless and until each insurance is current and valid at that time.
42.7. In the event of any claim for insurance becoming due on account of any
eventuality covered by the respective insurance policy/policies, the Contractor
shall reinstate the installation, replace the materials or equipments or pay
compensating to the affected personnel/Employees without waiting for
settlement of the claim from insurance company.
43. Terms of payments
The Employer shall pay to the Contractor in the following manner the contract
price unless agreed upon otherwise between the contractor and the Employs:
a) 60% of the Contract Value pro rata against Delivery of the goods delivered to
site and after verifying the same at site and after receipt of detailed test
reports.
b) 30% of Contract Value on pro rata erection of Equipment.
c) 10% of the Contract Value on completion of testing and satisfactory
commissioning of the plant.
Material delivery payment specified in item (a) above for ducting will be not
against delivery of G.I. Sheets but against fabrication of ducts and before
installation.
The contractor shall be eligible for payments only after the contractor has
submitted a detailed schedule showing the programme of work an also subject
to the documentary proof of insurance policy.
Page 66 SEAL AND SIGN OF BIDDER
44. Force Majeure
Neither party shall be held responsible by the other for breach of any condition
of this agreement to any “Act of God”, Act of state, strike, Lockout or any other
reason beyond the control of the parties and any breach of clause arising from
such force majeure conditions as foresaid shall not be regarded as a breach of
the provisions of this agreement.
45. Typographical or Clerical Errors
The Employer's or its authorized representative clarifications regarding partially
omitted particulars or typographical or clerical error shall be final and binding
on the Contractor.
46. Procurement of Materials
The Contractor has to procure sufficient quantities of materials of approved
quality, wall in advance to ensure that the work is completed in the stipulated
time. In case sufficient quantities of good quality materials are not available
locally, the Contractor will arrange to get them from neighboring areas with
longer leads at no extra cost.
47. Site
Limited space as approved by the Employer shall be made available to you at
works site for your storage of materials during the period of Contract in
consultation with the Consultant. You shall arrange any additional space
required at your cost for speedy completion of the project.
48. Prices For Extras etc., Ascertainment of
Should it be found after the completion of the works from measurements taken
(in accordance with the previous paragraph) that any of the quantities or
amounts of the work thus ascertained are less or greater than the amounts
Page 67 SEAL AND SIGN OF BIDDER
specified for the works in the priced schedule of quantities and / or tender or
that any variations, is made, the valuation of such quantities, amounts or
variations, unless previously or otherwise agreed upon, shall be made
accordance with the following rules
a. The net rates or prices in the original tender shall determine the
valuation of the extra work, where extra work is of a similar character
and executed under similar conditions the work priced therein.
b. The net prices in the original tender shall determine the value of the item omitted, provided if omissions vary the conditions under which any
remaining items of work are carried out, the prices for the same shall be valued under thereof
c. Where extra works are not of similar character and / or executed
under similar conditions as aforesaid or where the omissions vary, the conditions under which any remaining items of work are carried out of it the amount of any omission or additions relative to the amount of the
whole of the contract works or to be any part thereof shall be such that in the opinion of the Consultants the net rate or price contained in the
priced schedule of quantities or tender or for any item of work involves loss or expenses beyond that reasonably contemplated by the contractor or is by reason of such omission or addition rendered unreasonable or
inapplicable, the Consultant shall fix in consultation with the Employer such other rate or prices as in the circumstances he shall think reasonable and proper, which shall be final and binding on the
contractor. d. Where extra work cannot be properly measured or valued, the
contractor shall be allowed any work prices at the net rates stated in the tender or the priced schedule of quantities, or if not so stated, then in accordance with the local day work rates and wages for the district,
provided that in either case vouchers specifying the daily time (and if required by the Consultant, the workmen’s name) and materials
employed at or before the end of the week following that in which the work has been executed.
The measurements and valuations in respect of the extra items of contract shall be completed within the “period of final measurement” or within three months of the completion of the contract works as defined under clause no 16 (Certificate of Virtual Completion).
Page 68 SEAL AND SIGN OF BIDDER
49. Extra Items Rates
The work or extra items shall be started only after the approval of extra items
rates by client / Consultant. Rates for additional or extra items of construction
work, which can be derived from the contract item rates and are not
covered in the contract, shall be calculated on the basis of actual cost plus 15
% for profit plus applicable service tax.
50. Consultant’s Delay in Progress
The Consultant may delay the progress of the works in case of rains or
otherwise, without vitiating the contract and grant such extension of time with
the approval of the employer for the completion of the contract as he may think
proper and sufficient in consequences of such delay, and the contractor, shall
not make any claim for compensation or damage in relation thereto.
51. Action Where There is No Specification
In case of any class of work for which is there is no specification mentioned, the same will be carried out in accordance with the Indian Standards Specifications subject to the approval of the Employer / Consultant.
52. Work Performed at Contractor’s Risk
The contractor shall take all precautions necessary and shall be responsible for the safety of the work and shall maintain all lights, goods, signs, temporary passages or other protection necessary for the purpose. All works shall be done by the contractor’s risk and if any loss or damage shall result from fire or from others cause, the contractor shall promptly repaid or replace such loss or damage free from all expenses to the employer.
The contractor shall be responsible for any loss or damage to materials, tools or
other articles used held for use in connection with the work. The work shall be
carried on to completion without interferences with the operations of existing
machinery or equipment, if any.
Page 69 SEAL AND SIGN OF BIDDER
53. Special Conditions of Contract
In the event of any discrepancy with Clauses mentioned anywhere else in the
tender with the Clauses mentioned within ‘Special Condition of Contract’ and /
or ‘Additional Special Conditions of Contract’ the Clauses mentioned within
‘Special Conditions of Contract’ and/or ‘Additional special Conditions of
Contract’ shall supersede those mentioned elsewhere.
54. Contractor's Confirmation
A) Safety Codes:
i. Those engaged in welding works shall be provided with welder's protective eye-
shields and gloves.
ii. No paint containing lead products shall be used except in the form of paste or
ready-made paint.
iii. No floor, roof or other part of the structure shall be so over loaded with
debris or materials as to render it unsafe.
iv. There shall be maintained in a readily accessible place first aid appliances
including adequate supply of sterilized dressings and cotton wool.
vi. The injured person shall be taken to a public hospital without loss of time.
vii. Suitable and strong scaffolds should be provided for workmen for all works
that cannot safely be done from ground.
viii. No portable single ladder shall be over 8 meters in length. The width
between the side rails shall not be less than 30cm (clear) and the distance
between two adjacent rungs shall not be more than 30 cms. When a ladder is
used, an extra man shall be engaged for holding the ladder.
ix. The excavated material shall not be placed within 1.5 meter of the edge of the
trench of half of the depth of trench, whichever is more. All trenches and
excavated shall be provided with necessary fencing and lighting.
x. Every opening in the floor of a building or in working platform be provided
with suitable means to prevent the fall of persons or materials by providing
suitable fencing or railing whose minimum height shall be one meter.
Page 70 SEAL AND SIGN OF BIDDER
xi. Workers employed on mixing and handling material such as asphalt cement
mortar or concrete and lime mortar shall be provided with protective foot wear
and rubber hand- gloves.
xii. Use of hosting machines and tackle including their attachments, anchorage
and supports shall be in perfect working conditions.
xiii. Overcoats shall be supplied by the Contractor to the painters and adequate
facilities shall be provided to enable the working painters to wash during the
cessation of work.
xiv. Suitable facemask should be supplied for use by the workers when the paint
is applied in the form of spray or surface having lead paint dry rubbed and
scrapped.
B) Design Confirmation:
We confirm that the design on which this tender is prepared has been verified by
us and that it meets with the requirements of all Government, Semi-
government, municipal local and other authorities, whose permission would
become necessary for the completion of the project. In our opinion, the design is
economical and safe and we have nothing to suggest either by way of effecting
further economy or providing additional safety.
C) Completion Schedule:
The details of the delivery schedule of major equipment installation time etc.
shall be strictly in accordance with the bar chart to be prepared by the
contractor in consultation with the Employer/Consultant immediately on award
of contract.
As the service work will be carried out simultaneously with the building
construction activity, the tenderer shall quote his rates for this work keeping in
view the details of the building activity and the stage wise completion of the
service work to suit the building activity.
All variation in the contract value due to the variation in excise, taxes etc. on
equipment beyond the agreed delivery schedule shall be borne by the contractor.
However variation in taxes and duties as per special conditions of contract.
Within the stipulated delivery schedule shall be to the Employer's account.
Application for interim payments for the delivery of the equipment on pro-data
basis shall not be earlier than the delivery schedule indicated in the bar chart.
Page 71 SEAL AND SIGN OF BIDDER
D) Confirmation of Tender Prices:
We confirm that quotation is based on the Technical specifications and Tender
Drawings. Tender price indicated in our offer is based on the following stipulated
conditions:-
i. Tender price shall be inclusive of all taxes and levies. However, no statutory
changes in the quantum of taxes or duties for raw materials and unfinished
products will be entertained by the Employer. Also all variation in Excise duty
due to variation in accessible value shall be to the contractor's account.
ii. Tender shall be on lump sum basis for equipment and material delivered,
installed, tested and commissioned in accordance with the specifications and
accompanying drawings.
iii. Bill of quantities given in the tender document gives brief description of the
major equipment only. However, it will be the contractors responsibility to
provide all necessary items like hangers, supports, bends, tees, flanges etc. so
as to give a detailed specifications and drawings, for which no separate charges
shall be payable.
iv. Quantities of piping and sheet metal work given in the Bill of Quantities are
average and are available only for the contractor’s guidance and to provide
uniform basis for tendering. It is the contractor’s responsibility to satisfy himself
that the quantities are sufficient to carry but the work called for the accordance
with the specifications and lump sum price shall be based on drawings and
specifications to provide a complete HVAC system to the complete satisfaction of
the Employer. As bill of quantities does not indicate separately items like
flanges, bends, supports etc. it will be the contractors responsibility to
ascertain the quantities before tendering. No extra claim in this respect will be
entertained once the tender is accepted.
v. For the purpose of ascertaining the difference in quantities for duct
insulation, the average thickness of insulation plus other dimension of the duct
will be considered.
vi. Unit rates for piping, sheet metal work etc. shall remain valid till completion
of work in all respects and shall be free from variation due to increase or
decrease in cost of materials, labour or any other reason whatsoever. Unit rates
shall become applicable only due to variation in quantities due to changes
/modifications in drawings made by the Employer after award of contract. For
the purpose of ascertaining the variation in quantity, no site measurement is
acceptable. Difference in quantities will be arrived at based on tender drawings
Page 72 SEAL AND SIGN OF BIDDER
and quantities arrived from “As built” drawings, for the particular area where
changes have been carried out.
vii. Difference in cost due to variation will be arrived at from the unit rates
quoted by the contractor. All variation will be adjusted in the final bill of
contractor.
viii. Unit rate shall be inclusive of flanges, fittings, tees, bends, vanes, dampers
etc. and no additional payment will be made for these items.
E) Electrical Works:
Cost of cable trays, supports, clamps, etc., shall form a part of the supply and
installation of the cables. Cost of motors and starters etc. shall be included in
the cost of the driven equipment wherever specified. End termination of the
cables shall be included in the cost of cables. Double earthing and specified for
motors, electrical panels, and cables etc. shall form part of the supply and
installation of the respective items. No extra price shall be paid for earthing. All
control accessories valves, solenoid valves, motorized valves, damper motors,
speed controller’s thermostats, etc. including control wiring shall form part of
the respective equipment. No extra payment shall be applicable for these items.
Date: __________________
Name of Company
Seal
(Contractor Signature)
Designation.
Page 73 SEAL AND SIGN OF BIDDER
8. GENERAL DESCRIPTION OF WORKS
1. Outdoor/Inside Design Conditions
1.1 The outdoor design conditions for the location of the NABARD, Maharashtra Regional Office Building at 54, Wellesley Road, Shivaji Nagar,
Pune 411005 is considered as under:
Temp Summer (ºF) Monsoon(ºF) Winter(ºF)
DB 104 83 50
WB 76 79 42
1.2 The inside design conditions to be maintained in First floor, Second floor, Third floor & Fourth Floor has been considered as under:
Temp
RH
75ºF + 2ºF Not exceeding 60%
1.3 The tolerance of +2ºF on the DB will be maintained with suitable automatic
thermostatic control. No close tolerance is considered for RH to be maintained
in the comfort zone of not exceeding 60% to conserve electrical energy
consumption.
2. Dimension / Internal Heat Loads
2.1 The schedule of various internal heat loads sources in First floor, Second floor, Third floor &Fourth Floor areas considered are as per normal occupancy
standards of office buildings, which please note.
Sr.
No.
Floor Particulars
of Location
Area
(Sq. Mt.)
Occu
(nos)
Light load
(w/Sq.
Mt.)
Eqpt
Load
(watt)
Usage
1 First
Floor
Wing A 335 115 15 8500 Office
2 Second
Floor
Wing A 335 60 15 11000 Office
Wing B 335 60 15 11000
Page 74 SEAL AND SIGN OF BIDDER
(Center Wing) 32 4 15 6000 IT
3 Third
Floor
Wing A 335 60 15 11000 Office
Wing B 335 60 15 11000
(Center Wing) 32 2 15 500
4 Fourth
Floor
Wing A 193 30 15 2200 Sports
room
Wing B 235 70 15 1300 Canteen
(Center Wing) 32 2 15 50 Change
room
2.2 Architectural drawings furnished to us in the tender has been considered
for arriving at the areas of walls, floor, ceiling, Partition & Glass etc., for determining the solar & transmission gain.
2.3 The Lighting load is considered for LED type energy efficient Lighting system.
3. Assumptions:
3.1 The exposed roof of forth floor shall be provided with under deck insulation to reduce the heat transfer in the Air conditioned area.
3.2 All exposed glass shall be covered with sun reflective film and /or
Venetian blinds or curtains to achieve a heat transfer factor of 0.56.
4. Plant Capacity
54.1 Based on the design parameters as enlisted in annexure “Basis of Design” the total plant capacity for the First, Second, Third & Fourth floor of the NABARD, Maharashtra Regional Office Building is depicted in the
schematic layouts & tabulated here under:
Page 75 SEAL AND SIGN OF BIDDER
HVAC PLANT CAPACITY SELECTION
Type of
IDU
Ducted
Split
Cassett
e Split
Cassett
e Split
Cassett
e Split
Cassett
e Split
Tot.
IDU
(Nos.)
Tota
l TR
IDU
ODU
(HP)
IDU
Capacity (TR) 2.5 1.5 2.0 2.5 3.5
1st
floor
Nos. 00 16 00 02 02 20
Tot
TR 00 24 00 05 07 36.0 44
2nd floor
Nos. 23 08 02 01 00 34
Tot
TR 57.5 12 04 2.5 00 76.0 96
3rd floor
Nos. 21 02 03 01 00 27
Tot
TR 52.5 03 06 2.5 00 64.0 80
4rd
floor
Nos. 18 05 00 00 00 23
Tot
TR 45 7.5 00 00 00 52.5 66
5. System Design Note
5.1 The centralized AC system for the total Building has been conceived as an air cooled type VRF / VRV multi split - AC system with a combination of
IDU of Type Ducted Split, Cassette split and with ODU Comprising of multiple Inverter Compressors to achieve a close control of Temperature &
Humidity in each areas with a Diversity of Operation on each floor such that there is an saving in the running cost while using the AC system throughout the year.
Page 76 SEAL AND SIGN OF BIDDER
5.2 The work proposed is Independent Ducted Mechanical Exhaust / Ventilation system with Hoods for Kitchen to avoid food smell spreading into other areas of the building.
5.3 Air distribution system: Galvanized sheet steel ducting shall be installed to distribute the cool and dehumidified air in all working areas
which are served by ducted split indoor units. The air distribution flow pattern shall be either top to bottom flow or side to side flow to suit the application and interior design configuration. It shall be thermally as well as
acoustically treated to achieve climate control on inside temperature, humidity, cleanliness and noise levels. Powder coated extruded aluminum
section grilles/diffusers shall be used to supply/Return the air from and to the indoor units.
5.4 Drain: The drain from each unit should be properly laid to avoid any
leakages, nuisance in the air-conditioned areas and shall be terminated in either toilets or pantry areas. Or external drain pipes.
5.5 Central control console system: The VRF type air conditioning system
with outdoor units located on the terrace & various indoor units located on different floors shall be provided with a Central Control Console system
which will be controlled with real time clock precision such that each unit can be programmed for operation throughout the year which will conserve Electrical Energy & Optimize the operating cost.
5.6 Toilet Exhaust System: Toilet Blocks shall be provided with independent Exhaust system for each toilet Block to achieve a fresh toilet facility with 15 ACH for the toilet area on each floor.
Page 77 SEAL AND SIGN OF BIDDER
9. TECHNICAL SPECIFICATION FOR AIR CONDITION WORK
VARIABLE REFRIGERANT FLOW (VRF) AIR CONDITIONING SYSTEM
1. Scope:-
The scope of this article comprises of supply installation, testing and
commissioning of Variable Refrigerant Flow (VRF) split air-conditioning system
of the sizes and capacities set forth in the schedule of equipment.
2. VRF System (AIR COOLED)
2.1 The Variable Refrigerant Flow (VRF) System should be air cooled, split type
modular air conditioning system , consisting of singular condensing units
connected to multiple indoor units, each having the capability of individual set
point control. The system should have the ability to connect each condensing
unit upto 64 indoor units of different types and capacities on one refrigerant
circuit. The system is to be of the cooling & heating type. Each Condensing
unit should incorporate 100% inverter Scroll compressor, to obtain 5% to
100% stepless capacity control for enhanced Power saving. The Indoor units
should be provided with Cordless Remote Control as a standard accessory,
system should be designed such that all the other IDU shall function perfectly
even if some of the IDU is / are either switched off or out of service.
2.2 The outdoor units for all the system shall be air cooled type and mounted on
terrace of the building or on MS structure on the rear face of the building as
shown in the tender drawings. Indoor units in various areas shall be as per
enclosed drawings/ Bill of Quantities and located to suit reflected ceiling
plans.
2.3 All the VRF air conditioners shall be fully factory assembled, wired, internally
piped & tested. The relevant test certificates should be submitted at the time of
delivery of the equipment to site. The outdoor unit shall be pre charged with
first charge of refrigerant. Additional refrigerant charge shall be added as per
refrigerant piping at site. All the units shall be suitable for operation in Indian
conditions with 415 V + 10%, 50 Hz + 3%, 3 Phase supply for outdoor units &
220 V + 10%, 50 Hz + 3%, 1 Phase supply for indoor units.
2.4 The VRF system shall provide stable, trouble free & safe operation, with
flexibility of operating desired indoor units. The outdoor units must be capable
of delivering exact capacity proportional to the number of indoor units
Page 78 SEAL AND SIGN OF BIDDER
switched on & the heat load in the air conditioned area. The proportional
operation shall be achieved by operation of compressor.
2.5 The operation of the VRF system shall be through independent wireless remote
controllers as specified. The entire system shall be integrated with intelligent
building management system of leading vendors like Honeywell/ Johnson
Controls/ Siemens, etc through BAC Net Gateway. The detailing of operation
required through BMS system are detailed under specifications of BMS
system. (Optional)
3. Outdoor Units
3.1 Outdoors units of the VRF system shall be compact air cooled type and
working on refrigerant R-410A.
3.2 All the compressors of the outdoor units must be hermetically sealed high
efficient scroll type. Each system should be provided with the Scroll
compressor with electronic controls, capable of loading and unloading to follow
the variations on cooling and/or heating loads.
3.3 Two or more compressors should be incorporated in condensing units above
8HP with Scroll type. The outdoor unit shall employ system of equal run time
for all the compressors, within each out door unit – Single Module or Multi
Module.
3.4 Modular designs should be incorporated in condensing unit for side-by-side
installation.
3.5 The refrigeration circuit of the condensing unit should be complete with
refrigeration compressors, motors, fans, condenser coils, electronic expansion
valve, solenoid valves, 4 way valve, distribution headers, capillaries, filters,
shut down valves, service ports, receivers and accumulators and all other
components which are essential for safe and satisfactory operation.
3.6 The unit shall be equipped with an oil recovery system to ensure stable
operation for systems with long refrigerant piping. The oil recovery system
should be operated after the first hour of operation and then every consecutive
4 hours of operation. Also high efficiency oil separators should be fitted to the
discharge side of the compressor together with factory fitted oil equalization
system. Back up operation, in case of failure of one of the compressors of
outdoor unit, for single module outdoor units or failure of one of the modules
in case of multiple module outdoor units shall be possible. The VRF outdoor
Page 79 SEAL AND SIGN OF BIDDER
unit shall always be supplying at least 33% of back up operation, of the full
load capacity.
3.7 Complete refrigerant circuit, oil balancing/ equalizing circuit shall be factory
assembled & tested.
3.8 The regulation in Refrigerant flow is to be achieved by Scroll Compressor, &
Electronic Expansion Valve.
3.9 The heat exchanger should be constructed from seamless copper tubes
mechanically bonded to aluminum fins to form a cross fin coil. The aluminum
fins should be coated with an anti-corrosion film for increased durability to
salt corrosion.
3.10 The outdoor units must be suitable for up to 150 Mt (straight length)
refrigerant piping between outdoor unit & the farthest indoor units with 50m
level difference without any oil traps or double risers. The Oil Equalizing line
should be inside the Condensing unit, to avoid ‘inverted’ oil traps at site. Total
piping length shall be of 300 Mt for all the indoor units. Allowable level
difference between outdoor unit & indoor units shall be 50 m in case of
outdoor unit on top & 40 m in case of outdoor unit at bottom and extendable
upon 90m. Allowable level difference between various indoor units connected
to one out door unit shall be up to 15 m.
3.11 The outdoor units shall be suitable to operate within an ambient temperature
range of – 5 Deg C to 45 Deg C, in cooling mode & -20 Deg C to 15 Deg C in
heating mode.
3.12 Air cooled condenser shall have Axial Flow, upward throw fan, directly coupled
to fan motors with minimum IP 55 protection. The outdoor unit condenser fan
shall be able to develop external static pressure up to 6 mm of H2O. The
condensing unit fan motors should have at least two-speed operation to
maintain constant head pressure control in all ambient temperatures and
modes of operation.
3.13 Outdoor units shall be complete with following safety devices:
A) High pressure switch B) Fan driver overload protector C) Fusible Plug
D) Fuses E) Crank case heater
F) Over current protector.
Page 80 SEAL AND SIGN OF BIDDER
3.14 The entire operation of outdoor units shall be through independent remotes of
indoor units. No separate Start/ Stop function shall be required.
3.15 Starter for the Outdoor Unit compressor shall “Direct on Line” type. Inverter
compressor of the unit shall start first & at the minimum load, to reduce the
inrush current during starting.
3.16 The microprocessor panel should incorporate control for precise monitoring of
status of the system. The use of Inverter compressors shall be avoided to
prevent electromagnetic interference & conversion losses.
3.17 The condensing unit should be fitted with printed circuit board (PCB) with
selection switches for the length of pipe work, emergency operation switches
and service mode switches, together with LED indications for operation / fault
indication.
3.18 The Computerized control should be used to maintain a correct form of
temperature. The fan coil units should be incorporated with an on/off switch,
fan speed selector, thermostat setting and liquid crystal display which
indicates temperature setting; operational mode, malfunction codes etc.
3.19 The system should be equipped with a diagnostic function for quick and easy
maintenance and service.
3.20 A multifunctional compact centralized controller shall be provided with the
system.
3.21 The Graphic Controller must act as an advanced air-conditioning management
system to give complete control of VRF air-conditioning Equipment.
3.22 It shall be able to control up to 64 groups of indoor units with the following
functions:-
- Starting/stopping of Air-conditioners as a zone or group or individual unit.
- Temperature setting for each indoor unit or zone. - Switching between temperature control modes, switching of fan speed
and direction of airflow, enabling/disabling of individual remote
controller operation. - Monitoring of operation status such as operation mode & temperature
setting of - Individual indoor units, maintenance information. - Display of air conditioner operation history.
Page 81 SEAL AND SIGN OF BIDDER
3.23 The controller shall have wide screen user-friendly color LCD display and can
be wired by a non-polar 2-wire transmission cable to a distance of 1 km. away
from indoor unit.
3.24 Noise level of outdoor units shall not exceed 63 dB (A) at a distance of 1.5 m
from the unit.
3.25 The condensing units should be fully weatherproof, factory assembled and pre-
wired with all necessary electronic and refrigerant controls. The MO of casing
shall be mild steel panels coated with a baked enamel finish.
3.26 Unit shall be supplied with Installation manual, Operation Manual,
Connection Pipes Clamps
3.27 Units shall be available in capacities as specified in BOQ.
4. Indoor Units
4.1 General Features 4.1.1 Electronic Expansion Valve
Each indoor unit should be fitted with an electronic expansion valve which
controls the refrigerant flow in response to the load variations in the room. The
electronic expansion valve is to be controlled via a computerized control sensing
the return air temperature, refrigerant inlet and outlet temperatures. During
the cooling operation the electronic expansion valve controls the refrigerant
superheat degree at the evaporator.
4.1.2 Indoor Unit Fans
Direct driven of the DIDW multi-blade type, statically and dynamically
balanced to ensure low noise and vibration free operation.
4.1.3 Coils To be direct expansion, constructed from copper tubes expanded into
aluminum fins to form a mechanical bond.
4.1.4 Supply Air Discharge Louvers:
The indoor units should be provided with auto swing of the supply air louvers
for cassette and under ceiling type fan coil units. The louvers should be capable
of providing continuous swing operation or to be fixed in any direction required.
4.1.5 Unit Control Board
Include in the fan coil unit a printed circuit board complete with, address
switches for a variety of operation controls, emergency operation switch and
fault/operation indication LED’s. Thermally protect fan motors.
Page 82 SEAL AND SIGN OF BIDDER
4.1.6 Unit Casing
The fan coil unit casing (ceiling mounted units) to be fully insulated and sealed
to prevent condensation.
4.1.7 Condensate Drain
The Drain connection of each Fan coil unit to the main Header should be of
25mm Dia. The Header Pipe should be of 40mm Dia. The Drain Pipe should be
of Hard PVC, whereas the connection of the Fan-coil unit to the Hard PVC Pipe
should be with flexible braided pipe. The Drain piping should be insulated with
9mm thick tubular Nitrile Rubber Elastomeric insulation.
4.1.8 Unit Control
In case of individual and group control, set the addresses of each fan coil unit
to minimize commissioning time. In case of centralized control, set the
addresses by the remote controller.
4.1.9 Cassette type indoor units
a) These units shall be installed between the bottom of finished slab & top of
false ceiling. The maximum allowable height for the cassette type units shall
be 300 mm.
b) The unit must have in built drain pump, suitable for vertical lift of 750 mm.
c) The unit casing shall be Galvanized Steel Plate.
d) Unit must be insulated with sound absorbing thermal insulation material,
Polyurethane foam. The noise level of unit at the highest operating level shall
not exceed 42 dB(A), at a vertical distance of 1.5 m from the grille of the unit.
e) Unit shall have provision of connecting fresh air without any special chamber
& without increasing the total height of the unit (300 mm maximum).
f) The unit shall be supplied with suitable decorative panel.
g) The unit shall be supplied with Resin Net filter with Mold Resistance. The filter
shall be easy to remove, clean & re install.
h) The unit will be connected in series to a suitable out door unit & it must be
possible to operate the unit independently, through cordless remote specified
in the “Bill of quantities”.
i) The unit shall be supplied with following from the factory-
* Operation Manual,
Page 83 SEAL AND SIGN OF BIDDER
* Installation Manual,
* Paper pattern for installation,
* Drain hose/ Clamp metal/ Washer fixing plate/ Sealing pads/
* Clamps/ Screws/ Washer for hanging bracket/ Insulation for fitting.
j) The unit capacity should be as mentioned in BOQ
4.1.10 Ceiling Mounted duct type units
a) These units shall be ceiling suspended with suitable supports to take care of
operating weight of the unit, without causing any excessive vibration & noise.
The cold air supplied by these units will be supplied to the area to be air
conditioned, through duct system specified in the tender.
b) Each indoor unit must have electronic expansion valve operated by
microprocessor thermostat based temperature control to deliver cooling/
heating as per the heat load of the room.
c) The unit casing shall be Galvanized Steel Plate.
d) Unit must be insulated with sound absorbing thermal insulation material,
Glass Fiber. The noise level of unit at the highest operating level shall not
exceed 49 dB(A), at a vertical distance of 1.5 m below the units with duct
connected to the unit.
e) The unit must be able to develop enough static pressure to overcome the
frictional loss in the ducts as shown in the tender drawing.
f) It is preferable to provide Thermal Fuse for fan motor protection, in case of
motor heating.
g) The unit will be connected in series to a suitable out door unit & it must be
possible to operate the unit independently, through cordless remote specified
in the bill of quantities.
h) The unit shall be supplied with following from the factory
* Operation Manual,
* Installation Manual
* Paper pattern for installation
*Drain hose/Clamp metal/Insulation for fitting/Sealing pads/Clamps/ Screws
i) The unit must be available as per capacity specified in the BOQ
Page 84 SEAL AND SIGN OF BIDDER
4.1.11 Wall Mounted Units
a) Wall mounted units must be compact & stylish design that does not detract
from the décor of the room.
b) Each indoor unit must have electronic expansion valve operated by
microprocessor thermostat based temperature control to deliver cooling/
heating as per the heat load of the room.
c) The unit must have provision of adding drain pump kit if required & specified.
The drain pump must be suitable to lift drain up to 1000 mm from the bottom
of the unit.
d) Unit must be insulated with sound absorbing thermal insulation material,
Polystyrene/Polyethylene foam. The noise level of unit at the highest operating
level shall not exceed 46 dB(A), at a vertical distance of 1.5 m from the grille of
the unit.
e) The unit shall be supplied with Resin Net filter with Mold Resistance. The filter
shall be easy to remove, clean & re install.
f) The unit grille must be washable with soap solution.
g) It shall be possible to set minimum 4 steps of discharge angle by remote
controller.
h) It shall be possible to fit drain pipe from either side of the unit (Left or right)
i) The unit will be connected in series to a suitable out door unit & it must be
possible to operate the unit independently, through cordless remote specified
in the bill of quantities.
j) The unit shall be supplied with following from the factory
* Operation Manual
* Installation Manual
* Installation panel
* Paper pattern for installation
* Insulation tape/ Clamps/ Screws
k) The unit must be available in capacity specified in BOQ
Page 85 SEAL AND SIGN OF BIDDER
4.1.12 Ceiling mounted Built – In type
a) These units shall be ceiling suspended with suitable supports to take care of
operating weight of the unit, without causing any excessive vibration & noise.
The cold air supplied by these units will be supplied to the area to be air
conditioned directly through duct collar & grille or, through duct system
specified in the tender.
b) Each indoor unit must have electronic expansion valve operated by
microprocessor thermostat based temperature control to deliver cooling/
heating as per the heat load of the room.
c) The unit casing shall be Galvanized Steel Plate.
d) Unit must be insulated with sound absorbing thermal insulation material,
Glass Fiber. The noise level of unit at the highest operating level shall not
exceed 48 dB(A), at a vertical distance of 1.5 m below the units with duct
connected to the unit.
e) The unit must have provision to set external static pressure in three stages
from max 10 mm to min 2 mm, depending on the air supply system.
f) The unit must include as standard equipment, maintenance free long-life filter,
resin net with mold resistant.
g) The unit must include as standard equipment, a drain pump kit suitable to lift
drain water up to 250 mm from the drain pipe opening.
h) Unit must have Thermal Fuse for fan motor protection, in case of motor
heating.
j) The unit will be connected in series to a suitable out door unit & it must be
possible to operate the unit independently, through corded/ cordless remote
specified in the bill of quantities.
k) The unit shall be supplied with following from the factory
* Operation Manual
* Installation Manual
* Paper pattern for installation
* Drain hose/ Clamp metal/ Insulation for fitting/ Sealing pads/ Clamps/
Screws
l) The unit must be available in capacity specified in BOQ
Page 86 SEAL AND SIGN OF BIDDER
4.2 Specification for Controls System for VRF air conditioning system
A) Wired Remote Controller a) Wired remote controller shall be supplied as specified in the “Bill of
Quantities” b) The controller must have large crystal display screen, which displays
complete operating status.
c) The digital display must allow setting of temperature with 1 Deg C interval. d) Remote shall be able to individually program by timer the respective times
for operation start and stop within a maximum of 72 hours
e) Remote must be equipped with thermostat sensor in the remote controller that will make possible more comfortable room temperature control
f) The remote shall be able to monitor room temperature & preset temperature by microcomputer & can select cool/ heat operation mode automatically.
g) The remote must constantly monitor malfunctions in the system & must be equipped with a “self-diagnosis function” that let know by a message
immediately when a malfunction occurs. h) It shall be possible to wire the remote up to 500 RMT.
B) Wireless Remote Controller. a) Wireless remote controller shall be supplied as specified in the “Bill of
Quantities”
b) The same operation modes & settings as with wired remote controllers must be possible.
c) Compact light receiving unit to be mounted into wall or ceiling shall be included.
C) Central Remote Controller. a) Central Remote controller shall be supplied as specified in the “Bill of
Quantities”
b) Following functions shall be possible a. Control Max 64 Groups (128 indoor units)
b. Zone control c. Malfunction code display d. All the functions available with wired remote controller
e. It should be possible to wire the remote to 1000m All the Outdoor / Indoor units shall be mounted / suspended on isolators to
minimize the transmission of vibration from the equipment to the surrounding.
Cushy foot mounting shall be used to mount the outdoor units, where indoor units
shall be mounted / suspended on spring type vibration isolators.
Page 87 SEAL AND SIGN OF BIDDER
10. Sheet Metal Work
1. Scope
1.1 The Scope of work covers supply and installation of:
i) Sheet metal ducting
ii) Volume, Smoke and Fire dampers
iii) Outside intakes & exhausts louvers
iv) Grilles and diffusers
1.2 Grilles & diffusers shall be standard products for which catalogues shall be
submitted.
1.3 Smoke and Fire dampers shall be tested products.
2. Material
2.1 The material for various applications of air ducting shall be as follows:
Sr.
No.
Application Material
1 Ducting for Air-conditioning Cold rolled sheets continuous galvanized
with a zinc coating of 375 g/Sqm both sides
inclusive to IS 277-1977
2 Duct for ventilation & Exhaust - Do -
3 Kitchen Exhaust C.R.C.A. Sheet
4 Supports & duct flanges Mild steel structural steel sections
5 Gasket Foamed rubber 3.2 mm
6 Bonding Mastic sealant
2.2 All galvanized plain sheets shall be reasonably flat and free from twist. The zinc
shall be clean, even and free from galvanized spots. Sheets shall not crack or
peel during bending or fabrication. All sheets shall be procured from approved
manufacturers.
Page 88 SEAL AND SIGN OF BIDDER
3. Fabrication
3.1 All ducts for air-conditioning and ventilation shall be rectangular in cross-section and fabrication in accordance with the following table:
Maximum Size Minimum Transverse Joints
(mm)
Reinforcement
thickness (mm)
Upto 400 0.63 25mm ket/s slip Cross Break
401to 600 0.63 25 x 25 x 3.2mm Companion flanges
25 x 25 x 3.2mm Girth angles @ 1200
601 to 800 0.80 25 x 25 x 3.2mm Companion flanges
25 x 25 x 3.2mm Girth angles @ 1200
801 to 1000 0.80 40 x 40 x 4mm Companion flanges
25 x 25 x 3.2mm Girth angles @ 900
1000 to 1500 1.00 40 x 40 x 4mm Companion flanges
40 x 40 x 4mm Girth angles @ 760
1501 to 2250 1.00 50 x 50 x 6mm Companion flanges
40 x 40 x 4mm Girth angles @ 760
2251 & above 1.25 50 x 50 x 6mm
Companion flanges
50 x 50 x 4mm Girth
angles @ 760
3.2 In odd positions, the ducts shall be fabricated to suit the conditions, with the
specific approval of the Engineer - in -charge.
3.3 Girth angles and companion flanges shall be mitered and welded at corners and
riveted to duct sheets at 75 mm centers. Flanged joints shall be made with 9.5
mm GI bolts spaced at 100 mm centers and provided with 3.2 mm foamed
rubber gasket. All joints and seams shall be rendered air tight with approved
sealant. Duct panels are not to be cross broken, if insulated. Longitudinal
seams shall be inside groove or Pittsburgh type.
3.4 Standard elbows with an R/D ratio of not less than 1.25 shall be used as far as
possible. Where space restrictions do not permit use of standard radius elbow
with lesser R/D ratio square elbow with equally space double thickness vanes
may be used.
3.5 All duct fabrication and installation shall conform to the extent modified herein,
to the SMACNA standard for Low Pressure Duct Construction. Length of taper
ducts shall be at least four times the maximum size difference between the
ends.
3.6 All duct lining for acoustic insulation shall be carried out as specified under sec
“Noise & Vibration” before the duct is installed in position.
Page 89 SEAL AND SIGN OF BIDDER
4. Accessories
4.1 Air turning devices shall be provided at least for first four outlet collars after
every elbow and at all non-split branch take offs. Turning blades shall be
fabricated out of 0.8 mm (22 SWG) thick G.S sheets and equally spaced on side
runner to be riveted/bolted to duct sheets.
4.2 Splitter dampers shall be installed in branches wherever split takes place.
Louvers dampers shall be provided in all branches. Any feeding more than
outlets shall be regarded as a branch and louver dampers provided whether
shown or not.
4.3 Splitter dampers shall consist of double thickness air foil blades hinged at the
downstream edge. The operation rod shall terminate outside of the duct and
insulation, and an air tight hub and locking set screw shall be provided.
Damper blade thickness shall be the same as the duct in which it is installed
but not less than 1.5 mm (16G). Entire splitter damper shall be enclosed in a
sheet steel ducting with flanges at both ends aligning with main run of ducting.
The enclosure shall be made of sheets one size larger than the corresponding
duct.
4.4 Louvers dampers shall be multi-blade type with opposed blades or parallel
blades of airfoil construction. Blades shall be 250 mm max. width and 1200 mm
maximum length mounted in a 50 mm channel frame. Blades shall be
connected with suitable linkage for gang operation by an operating rod
extending beyond the frame and insulation if any and terminating in a locking
quadrant with damper position indicator. Damper larger shall be enclosed in a
sheet steel box with thickness one size larger than the corresponding duct with
flanges at both ends. The dampers shall rotate in bronze bushes.
4.5 Fire dampers shall be rated for 2 hours five resistance according to BSS 476-
I/1953. Damper shall be single blade (butterfly) with central pivot extending into
the actuator housing. The damper together with actuator housing shall be
certified be an appropriate testing authority for its fire resistance. The damper
and the actuator housing shall fit into the fire rated wall.
4.6 The damper shall be actuated by a fusible element set for 70 deg C (158 deg F)
fusing temperature or a motor actuator. Actuators shall be operable from 230
VAC 50 Hz source of supply. A manual adjusting handle shall also be provided
in the actuator housing which shall be located wherever shown. An access door
in the duct shall be provided as shown on drawings.
4.7 400 x 400 mm access panel stud bolted with rubber gasket shall be provided
adjacent to splitter, fire, louvers dampers or any other duct enclosed device.
Page 90 SEAL AND SIGN OF BIDDER
4.8 Duct supports shall be as follows.
Duct Perimeter (mm) Support Location
Upto 1800 40 x 40 x 3 mm
MS angle with 9 mm tie rod
At Transverse Joints
Over 1800 to 2500 40 x 40 x 6 mm
MS angle with 12.5 mm tie
rod
At Transverse Joints
Over 2500 50 x 50 x 6 mm
MS angle with 15 mm tie rod
At Transverse Joints
4.9 Additional supports wherever considered necessary by the Engineer-in-charge
shall be provided. Support shall be taken from steel members grouted in the RCC
work and fixing of steel members shall involve minimum damage. The entire
supporting system shall be met with the approval of the Engineer-in-charge.
4.10 All duct supports, flanges, hangers shall be hot-dip galvanized before
installation.
4.11 Where ducts are connected to the wall, such connections shall be made
through galvanized steel frame fixed to the wall through suitable shear fasteners.
Ducts connecting to air moving apparatus shall be through 15 OZ mildew
resistant double canvas as directed by the Engineer. On all circular spigots the
flexible material is to be screwed or clip band with adjustable screw or toggle
fitting. For rectangular ducts the material is to be flanged and bolted with
backing flat or bolted to mating flange with backing flat.
The flexible connection shall not be less than 75mm and not more than 200 mm.
5. Air Intakes & Exhaust
5.1 i) Galvanized sheet steel louvers 100 mm wide 1.25 mm thick fixed to enclosure
box at 45 deg to vertical & 100 mm centers.
ii) 15 mm x 1.0 mm galvanized steel bird screen in set with 0.8 mm galvanized
sheet steel framing all-round bolted to the flange with 12 mm M8 brass bolts &
nuts at 150 mm center to center.
Page 91 SEAL AND SIGN OF BIDDER
iii) 1.25 mm galvanized sheet metal enclosure box 250 mm long with 4-hold
fasts and flanged at both ends (one end with the bird screen)
5.2 The entire assembly shall be fitted into the wall clear opening and the edges
sealed with a mastic sealant. All frames and clamps used shall be hot galvanized
or extruded aluminum.
6. Air Diffusing Equipment
6.1 Supply air grilles shall be double deflection type with horizontal face bars and
vertical rear bars placed in a rigid marginal frame. Bars shall be shaped and
paced at 18 mm centers with swaged pivot pins positively holding the deflection
setting under all conditions of velocity and pressure. All grilles shall be
provided with integral opposed blade, grille-face key operated dampers.
6.2 Return grilles shall have fixed face bars shaped and set at 18mm (34) centers.
Bars shall be set at 40 deg deflections for vision-proof installation. The grilles
shall be complete with rigid marginal frames and shall be matching with the
supply grilles.
6.3 Ceiling diffusers shall be round/square/rectangular face flush type horizontal
air diffusion pattern. Diffusers shall have ample margins to minimize ceiling
smudge. All diffuser shall be provided with face operated volume control
dampers. Half diffusers shall be similar to full diffusers.
6.4 Linear diffusers/ grilles shall be die formed, flush mounted type with single or double directional air flow. The diffuser /grille shall be in a mild steel frame
with minimum 20 mm margin. All linear air diffusing equipment shall be fitted with a distribution sheet metal plenum as shown on drawings.
6.5 Grille types are indicated in the drawings and equivalent types of any other
standard manufacturer are acceptable. Mild steel grilles and diffusers shall be
fabricated out of 1.0 mm mild steel and painted with two coats of red oxide. All
duct collars terminating on to a grille or diffuser shall be given two coats of
black paint for a length of 300 mm. Grilles & diffusers shall be selected for an
aero-dynamic noise power not in excess of NC 30.
6.6 Aluminum grilles and diffusers wherever specified shall be of extruded
aluminum with margins & GSS butterfly dampers. Grilles shall have horizontal
face bars only.
Page 92 SEAL AND SIGN OF BIDDER
7. Testing & Balancing
7.1 Capped air-flow connections shall be provided as necessary for testing and
balancing of air distribution.
7.2 The entire air distribution shall be adjusted and balanced for delivery of designs
air quantities or as required for achieving design space conditions. After all
adjustments are made, the air readings shall be recorded on the drawings vis-a-
vis the space conditions. All dampers after adjustment shall be set and locked in
position. All air and static pressure measurements shall be done through probe
type meters. Vane type meter reading are not considered reliable.
8. Mode of measurement
8.1 All sheet metal ducting complete with duct supports, turning vanes, canvas
connections, erected in position shall be measured externally and paid per unit
area. All dampers shall be excluded in the duct area.
8.2 All manual control/ splitter damper sections with operating linkages locking
quadrant, steel enclosure, frame, erection, supporting etc. shall be measured on
the basis of damper cross sectional area and paid per unit area. Intake and
exhaust louvers with bird screen, sheet steel louvers and frame, erection etc.
shall be measured on the basis or cross sectional area and paid per unit are.
8.3 Side wall grilles shall be measured on the basis of the core area excluding the
margins and shall include dampers. Minimum payable unit is 0.1 sqm (1.0 sqft)
8.4 In line diffusers and grilles shall be measured per unit length. The backup
plenum shall be measured as additional sheet metal ducting or part of the grille as defined in the schedule of work.
8.5 All fire dampers with operating linkage actuator, locking quadrant plate steel
enclosure, frame, fusible links, actuator, access door etc. shall be measured on
the basis of cross sectional area of damper and pais per unit area or per piece as
defined in the schedule of work.
8.6 All duct liners for acoustic insulation shall be measured and paid as specified under ' Noise & Vibration'.
Page 93 SEAL AND SIGN OF BIDDER
11. Insulation Work
1. Duct Insulation: Insulation materials will be resin bonded fiber glass or expanded polystyrene of TF (Treated for fire) quality, of two specifications, with sand cement plaster (10mm). The thermal conductivity of resin bonded fiber glass shall not exceed 0.034 kcal-m/hr Deg C or 0.27 BTU in/hr sq.ft Deg F at 32 Deg C (90 Deg F) mean temperature, and density shall not be less than 24kg/cu.m. 2. For resign bonded fiber glass thermal conductivity shall not exceed 0.022 kcal-m/hr sq.m Deg C or 0.018 BTU-in/hr-sq.ft Deg F at 32 Deg C mean temperature, and density shall not less than 36 kg/cu.m (3lb/cu.ft).
2. Acoustic Lining: The acoustic lining for ducts so identified and marked in
the drawing and included in the schedule of quantities shall be provided with acoustic lining of thermal insulation.
Installation:
i. The duct surface shall first be cleaned from inside.
ii. The insulation boards shall be wrapped in glass cloth of 7 mm thickness with end stitched.
iii. Then the Boards shall be fixed inside the duct.
iv. The insulation shall then be covered with 0.5mm perforated aluminum sheets. v. The sheet and the insulation shall be secured to the duct by means of bolts,
nuts washers. The ends should be completely sealed off, so that, no
insulation material is exposed. 3. Duct Thermal Insulation, External:
i. Wherever supply air ducting exposed to atmosphere shall be insulated with
50mm thick thermocole. First external duct shall be cleaned with a w i r e brush to remove dirt and dust. Apply a thick coat of bituminous primer. When the primer is still tacky, apply the insulation material.
ii. Seal the joints using bitumen. Warp the insulation with 24 gauge GI chicken wire mesh around the insulation and two layers of smooth setting
cement plaster each of 6mm thickness applied over length of wire mesh. Duct shall be painted with water proof paint of approved make.
4. Under Deck Insulation:
i. Exposed roof over the conditioned areas shall be insulated with 50mm thick Resin bonded fiber glass. For under deck insulation in the conditioned
areas, the insulation of fire resistant Quality shall be used. ii. Under deck insulation shall be done by fixing the slabs of Resin bonded fiber
glass by wire and mesh method as well as sticking & pasting along with bolting it in the ceiling as per site instructions. raw plugs shall be fixed in the grid of 500mm x 500mm, tie wires and fix Resin bonded fiber glass rigidly
using 24G Plate washers through the GI Wires.
Page 94 SEAL AND SIGN OF BIDDER
12. Refrigerant Piping
1. The specifications that follow cover the requirements of piping.
2. Only copper piping/tubing of refrigeration quality shall be used. Soft copper
tubing can be employed for sizes up to and including 22mm (7/8") OD and
9.5mm (3/8") OD shall have a minimum nominal thickness of 0.76mm (0.030") and
0.81mm (0.032") respectively.
3. All piping / tubing shall be new fresh, clean and dry.
4. Fittings like bends, tees, sockets, etc. shall be of copper or forged brass. Flare
type fittings may be used for copper tubing while hard drawn tubes upto and
including 15mm size may be bent to from 90 Deg bends with throat radius
being not less than 3 times the tube diameter. For bigger sizes, bends should be
used as noted already.
5. Valves for pipe sizes up to 15mm OD shall be all brass, hand wheel operated,
Diaphragm pack less type, globe or angle valves, for sizes over 15mm OD Valves
shall be of bronze, globe or angle type, packed back sealed.
6. Liquid line strainers shall be made of brass shall incorporate bronze screen and
permanent management. Strainers shall be provided with shut valves on either side.
7. Thermostatic expansion valve shall be complete with remote bulb and external
equalizer and external super head adjustment. Solenoid valves shall have manual
opening system to serve as by - pass in case of failure of solenoid valve. Liquid-
moisture indicator shall be provided in the liquid line.
8. Flare type joints may be used for copper tubing while for a hard drawn pipe
only brazed joints shall be used. For Small lines also such as equalizer lines,
expansion valves connections, gauge connections, connecting pressure switches
etc., flared fittings and joints shall be used.
9. Piping shall be insulated sufficient number of bends and turns t o ensure
sufficient fleetly and minimize vibration. Supports, Clamps, Saddles, hangers etc.,
of adequate strength should be provided as required to support the piping
adequately and minimize vibration.
10. Necessary isolating material like rubber, felt, spring, etc, Should also be
provided as an additional measure to limit transmission of noise and vibration.
11. Refrigerant piping shall be carried out giving due consideration to the need to
ensure oil return and avoid liquid slope-over into the compressor, Accordingly, the
piping shall include necessary loops, traps, slopes, etc,. to achieve these objectives.
Page 95 SEAL AND SIGN OF BIDDER
12. While installing the piping, adequate clearance between pipes should be
provided for insulation is called for.
13. On completing the erection, the system shall be pressure tested with dry
nitrogen or carbon de-oxide. The test pressure shall be as under for R-22.
14. High Pressure side - kg /sqcm(psi) : 25 (365)
15. Low Pressure side - kg /sqcm(psi) : 110 (150)
16. The system shall hold the pressure for a minimum period of 24 hours without
revealing leaks.
17. After the leak test has been completed successfully, the pressure due to
Nitrogen or Carbon- de-oxide in the system.
18. The System shall then be dehydrated by drawing a vacuum. The vacuum
achieved shall be achieved shall be atleast as deep as 500 microns and shall be
maintained for a period of atleast 24 Hours after the vacuum pump has been shut
off.
19. Insulation for Refrigerant Piping:
All suction lines (insulated both indoors & outdoors) and liquid lines laid outdoors
shall be applied over a coat of bituminous primer applied on the pipe surface. Before
putting on the insulation sleves.
20. Condensate Drain Piping:
i. PVC Pipes (Medium) shall be used for condensate drain piping. ii. Piping shall be supported suitably on walls/floor and all charges involved
there to shall be applied in the prices quoted by the tenderers.
iii. While installing piping, the contractor shall keep in mind the requirement that i t should not foul with the structural or consultantural features of the building. Further, all piping must be installed in a neat and workman
- like - manner. 21. Propeller Fans
Propeller type, Ring/Diaphragm mounted fans shall be equipped with a TEFC phase motor with the impeller mounted directly on the shaft. The blades shall be dia formed steel. The fan shall be fitted with gravity type louvers. The speed of fan shall
not exceed 900 RPM. The fan speed can go upto 1400RPM only in case of fans having diameter of 305 mm.
22. Installation
i. The Contractor shall supply all foundation bolts, base frame wherever required, vibration eliminators etc. and shall ensure that all the above
Page 96 SEAL AND SIGN OF BIDDER
accessories are placed securely in proper position while the foundation is cast.
ii. Vibration eliminators shall be provided with an efficiency of not less than 80%
wherever necessary. iii. Fan inlet and outlet connections shall be with flexible canvas connections
wherever necessary.
23. Testing:
All the fans shall be tested for performance and the following test results shall be
furnished:
a. Air flow rate in CFM.
b. Static pressure at the fan supply end.
24. Painting
On completion of the erection and testing, the outside of the fans shall be painted
with two coats of Synthetic Enamel paint of approved colour over and under coat of primer.
Page 97 SEAL AND SIGN OF BIDDER
13. Electrical works (HVAC) 1. Scope
1.1 This specification along with specific job requirement (if any) defines the
requirements for design, engineering, procurement, installation, testing and
commissioning of the electrical facilities for the package unit as covered in the
enclosed data sheet.
1.2 It is not intended to cover all aspects of system design but to indicate the basic
requirements only. Vendor shall ensure that the design and installation is
carried out as per good engineering practices and shall meet the requirements
of safety, reliability, ease of maintenance and operation, aesthetics, scope of
further expansion and maximum interchangeability of the equipment. Vendor
shall acquaint himself with EIL standards, specification and field testing
procedures as deemed necessary for proper execution of the work.
1.3 Compliance with this specification and/or approval of any of the vendor
documents shall not relieve the vendor of his responsibility towards his
contractual obligation with regard to the completeness and satisfactory
operation of the plant.
2. Codes and Standards
2.1 All electrical equipment and complete installation shall meet the requirement
of this specification and data sheet in addition to the relevant Indian
Standards/Code of practices. Complete system must also conform to the
following:
a) Indian Electricity Act and Rules.
b) Fire Insurance Regulations.
c) Indian Petroleum rules and any other regulations laid down by Chief Controller
of Explosives.
d) Regulations laid down by Factory Inspectorate.
e) Regulations laid down by local statutory authorities and Electrical Inspector.
2.2 Approvals of statutory authorities for materials, plant design/drawings and
complete installation shall be the responsibility of the vendor.
Page 98 SEAL AND SIGN OF BIDDER
3. Area Classifications and Equipment Selection
3.1 In case of storage, handling or processing of flammable material within the
battery limits of the package unit, area classification shall be carried out in
line with IS:5572 and Indian Petroleum Rules. The vendor shall furnish “Area
Classification Drawing” indicating the zone of hazardous area and the gas
group. A list of flammable material along with their properties like flash point,
ignition temperature, explosive limits etc. shall also be furnished by the
vendor.
3.2 Selection of the type of equipment for use in hazardous areas shall be done in
accordance with IS:5571.
3.3 Electrical equipment for hazardous areas shall have the approval of recognized
testing/certifying authority. Vendor shall furnish the necessary certificates
indicating such approvals.
4. Equipment Specifications
4.0.1 Specifications of each system and equipment shall be furnished by the vendor
for approval by the Employer. However, certain minimum requirements for the
major equipment are highlighted in this section.
4.0.2 All equipment shall be new and supplied by approved reputed manufacturers.
Equipment requiring specialized maintenance or operation shall be avoided as
far as possible and prototype equipment shall not be accepted. All equipment
shall be complete with all necessary weather and anticorrosion protection
including tropicalization to prevent damage due to climate saline atmosphere,
dust and corrosive vapors.
4.0.3 The Employer or his authorized representative may visit the works during
manufacture of various electrical equipment/materials to assess the progress
of work as well as to ascertain that only quality raw materials are used for the
same. He shall be given full assistance to carry out the inspection. Employer’s
representative shall be given minimum two weeks advance notice for
witnessing the final testing.
The minimum testing/inspection requirements for all components/equipment
shall conform to the requirements stipulated in applicable codes and
standards. Test certificates including test records and performance curves etc.
shall be furnished by the vendor.
Page 99 SEAL AND SIGN OF BIDDER
4.0.4 All equipments/material shall be protected for inland/ marine transport,
carriage at site and outdoor storage during transit and at site. Vendor shall be
responsible for any damage to the equipment during transit. All packages shall
be clearly, legible and duly marked with uniform block letters giving the
relevant equipments/material details. Such package shall contain a packing
list in a waterproof envelope.
4.1 Medium Voltage Motors
All medium voltage induction motors shall meet the requirements of enclosed
data sheet and following specific requirements in addition to the general
requirements as per latest edition of IS : 325.
4.1.1 Motors shall be squirrel cage type in standard frame sizes rated for continuous duty and designed for direction line starting across full line voltage. Motors
shall be capable of withstanding occasional bus transfer/reaccelerating at a voltage not exceeding 150% of the rated voltage. All motors shall be suitable for starting under specified load conditions with 75% of the rated voltage at the
terminals. 4.1.2 Motors shall be designed to allow three consecutive starts from cold condition,
two consecutive starts from hot condition and four uniformly distributed starts
in on hour. Minimum locked rotor thermal with stand time at rated voltage
shall be 10 seconds under cold conditions and 8 seconds under hot
conditions. Motor starting time shall be less than its hot thermal withstands
time.
4.1.3 Starting current shall generally be limited to six times the rated current for all
motors. Starting torque, minimum torque and pump out torque shall be
compatible with the speed torque curve of the driven equipment with due
regard to pulsating loads with minimum acceptable values as 110%, 90% and
175% respectively of the rated torque. For heavy duty motors, high starting
torque (Min. 150%) motors shall be provided with starting time preferably less
than ten seconds.
4.1.4 Motors shall be provided with class “B” or class “F” insulation and the
permissible temperature rise above the specified ambient temperature shall be
limited to the values applicable for class “B” insulation. The windings shall be
tropicalised and adequately braced. The ends of the windings shall be brought
out in a terminal box with six terminals with suitable links to connect them in
Delta. However, motors rated up to 2.2 KW may be connected in star with
three terminals.
Page 100 SEAL AND SIGN OF BIDDER
4.1.5 The terminal box shall be capable of withstanding the full internal short-circuit conditions with the specified system fault level. The fault duration shall be taken as 0.25 secs. for motors rated 55 KW and above for motors rated below
55 KW the fault energy to be considered shall depend upon the backup fuse rating. The terminal box shall be located on the right hand side viewed from
the driving (coupling) end. It shall be routable in steps of 90 deg to allow cable entry from any direction. The terminal box shall be of sturdy construction and large enough to facilitate easy connection of cables. Additional trifurcating
boxes shall be provided for all motors rated above 75 KW. Following sizes of aluminum conductor, PVC insulated armored cables shall be applicable for
design of terminal box and related accessories.
RECOMMENDED SFU RATINGS & CABLE SIZES
*Each starter feeder will be provided with
1 No. ‘ON’ lamp
1 No. ‘TRIP’ lamp 1 No. Start Push Button
1 No. Stop Push Button, Stay put type. INCOMER - 1 No. Ammeter + ASS 1 No. Volt meter + VSS,
All switchgear shall be of Siemens Make or equivalent.
Motor Rating Type of Starter SFU Cable Size.
170 KW AYFY Star/Delta 400/355 2# 3C - 185 mm2
110 KW AYFY Star/Delta 250/200 2# 3C - 95 mm2
75 KW AYFY Star/Delta 250/160 2# 3C - 75 mm2
30 KW AYFY Star/Delta 63/63 2# 3C - 16 mm2
22 KW AYFY Star/Delta 63/50 2# 3C - 10 mm2
15 KW AYFY Star/Delta 32/32 2# 3C - 6 mm2
7 KW AYFY DOL 32/25 1# 3C - 4 mm2
5.5 KW AYFY DOL 32/25 1# 3C - 4 mm2
2.8 KW AYFY DOL 32/10 1# 3C - 4 mm2
1.5 KW AYFY DOL 32/10 1# 3C - 4 mm2
Page 101 SEAL AND SIGN OF BIDDER
General Notes :
1) Vendor to submit single line diagram of all panels
2) G.A. drawings and detailed Bill of Material to be submitted.
3) Unit Rate of Cable Laying in trays to be submitted, from the cable listed.
4.1.6 Motors shall be suitable for either direction of rotation except 2 pole motors in
frame sizes 280 and above, which may have unidirectional fans. Bearings shall
be chosen to provide a minimum operating life of 40,000 hours and shall
preferably be capable of grease injection from outside without removal of
covers with motors in running condition. Pre-lubricated bearings wherever
used must provide 4 to 5 years of trouble free service without any replacement
or re-lubrication. Motors vibrations shall be within the limits of IS: 4728
unless otherwise required for the driven equipment.
4.1.7 Motors shall be totally enclosed fan cooled type. Minimum degree of protection
for motor enclosure, terminal box and bearing housing shall be IP-55 as per
IS-4691. In addition motors for use in hazardous areas shall have type of
protection Ex. (d), Ex (e) or Ex (n) as required and shall meet the requirements
of applicable Indian Standards. Vertical motors shall be provided with fully
covering rain canopies. In addition to the two earth terminals on the motor
body, an earth terminal shall be provided inside the terminal box.
4.1.8 All motors rated above 30 kW shall be provided with 240 V anti-condensation
heater. These heaters shall conform to the provisions of applicable standards
for motors installed in hazardous area. The heater leads shall be brought out
to a separate terminal box in IP-55 enclosure suitable for two core 4 Sq.mm.
aluminum conductor armored cable.
4.1.9 Generally four pole motors shall be preferred. The min. value for product of
efficiency and power factor shall be as per IS: 8789. For motor ratings not
covered in IS: 8789, product of efficiency and power factor shall be as agreed
between the Employer and vendor.
4.1.10 Internal and external parts of the casing and metal parts likely to come in
contact with the surrounding air shall be protected with anti-acid paint. All
external surfaces shall be given a coat of epoxy-based paint.
Page 102 SEAL AND SIGN OF BIDDER
4.2 Medium Voltage Switchboard
Medium voltage switchboard shall meet the requirements of enclosed data
sheet and following specific requirements in addition to the general
requirements as per latest editions of applicable Indian Standards.
4.2.1 The switchboard shall be free standing, metal enclosed compartmentalized,
modular type, dust and vermin proof suitable for indoor installation,
switchgear enclosure shall provide a degree of protection not less than IP-31 as
per IS:2147. The switchgear shall be assembled out of vertical panels of
uniform height not exceeding 2450mm. The maximum height of the operating
handle/switches shall not exceed 1800mm and the minimum height not below
300mm. All feeders shall be provided with door safety interlock.
Rubber mat shall be provided on all sides of electrical panel in view of the
safety of the operator & in accordance with required standards.
The switchgear shall be designed to ensure max. safety during operation,
inspection, connection of cables, relocation of outgoing circuits and
maintenance with the energized bus bar system and without taking any
special precautions. The switchgear shall permit max. Interchangeability and
shall be extensible on either side.
The switchboard shall be sheet steel clad with the frame fabricated out of 14
SWG cold rolled sheet steel and doors/covers out of 16 SWG cold rolled sheet
steel; having integral base frame for each vertical panel. All hardware shall be
corrosion resistant. All joints and connections of the panel members shall be
made of galvanized. Zinc passivated or cadmium plated high quality steel
bolts, nuts and washers, secured against loosening. The switchgear shall be
suitable for bottom/top cable entry. However, the incomers for PMCC fed by
transformers rated 1250 KVA and above shall have provision for bus duct
connection at the top. Each MCC panel shall have separate cable alley of
150mm minimum width.
4.2.2 Individual circuit breakers, motor starters, switch fuse units, horizontal bus
bars, auxiliary/control bus bars, cable termination compartment shall be
housed in separate enclosed compartments separated from each other by
metallic barriers.
Circuit breakers panel shall be in single front execution only. Not more than
two breaker cubicles shall be housed in one vertical panel except for the
incomer and bus coupler, which shall each be housed in independent vertical
panels. Motor starter and switch fuse units shall be in multitier arrangement
Page 103 SEAL AND SIGN OF BIDDER
in single or double front fully draw out or fixed execution as specified in the
data sheet. All auxiliary devices for control, indication, measurement and
protection such as push buttons, control and selector switches, indicating
lamps, metering instruments, protective relays except bimetallic relays shall be
mounted on the front side of the respective compartment. Components
requiring frequent inspection during operation shall be easily accessible.
Each vertical panel shall be provided with an anti-condensation heater rated
for 240V AC supply with a switch fuse and a thermostat.
4.2.3 Main bus bars shall be of high conductivity aluminum having uniform current
rating throughout their length. Horizontal and vertical bus bars shall be sized
depending upon the max-expected current and to limit the max. Operating
temperature at specified design ambient temperature to 85 deg.C for normal
operating condition and to 200 deg.C for short circuit condition considering
installation in poorly ventilated area. Double front panels shall have two
independent sets of vertical bus bars.
Adequately sized auxiliary copper/aluminum bus bars running horizontally in
a separate enclosure shall be provided for space heaters, control supply and
metering requirements. Necessary tee-off connections shall be used for
distributing auxiliary supply to each vertical panel.
All bus bars shall be colour coded and designed to withstand specified short
circuit currents for one second.
4.2.4 Aluminum earth bus with 300 mm2 min. size or equivalent copper bus shall be
provided throughout the length of the switchboard with provision for
interconnection to earthing grid. All non-current carrying metallic parts of the
mounted equipment shall be earthed. Doors and movable parts shall be
earthed using flexible copper connections.
4.2.5 Inside the switchboards, the wiring for power, control, signaling, protection
and instrument circuits shall be done with the PVC insulated copper
conductors having 660/1100V grade insulation. For modules rated above 100
Amp. Preferably copper strip connection shall be used. Minimum size of
control wire shall be 1.5mm2 copper for circuits having fuse rating 10 Amp. or
less. For higher fuse rating control circuits, min. 2.5 mm2 copper conductor
shall be used.
“Elmex” type terminals shall be acceptable for wires up to 10 mm2 size and for
conductors larger than 10 mm2 bolt type terminals with crimping lugs shall be
provided. Each wire shall be terminated at a separate terminal. A min. of 10%
spare terminal shall be provided for all CT terminals.
Page 104 SEAL AND SIGN OF BIDDER
All motor starting shall be DOL type unless otherwise specified.
4.2.6 All circuit breakers shall be air-break, fully draw out type. Circuit breaker
panel shall have three distinct positions viz. “Service”, “Test”, “Full Out”
position complete with necessary safety inter locks, scraping earth connection,
shutters, safety barriers and suitable guides for easy movement of the trolley.
Access to the cables shall be from the rear side after opening the door of the
separate cabling compartment. Circuit breakers shall be trip free type having
antipumping feature and electrically operated mechanism suitable for control
supply as specified in the data sheet. Circuit breaker trip coils shall be rated
for satisfactory operation with 50% to 110% of the rated voltage and the
closing coil shall be rated for 85% to 110% of the rated voltage.
4.2.7 For fully draw out MCC, trolley movement shall be on guided rollers or by
means of a crank and screw arrangement. Plug in operation shall be
independent of manual force. The trolley shall be lockable in fully plugged in
and fully draw out positions. A device shall be provided to ensure fully plugged
in condition. There shall be positive indication for the various position of the
trolley. Trolleys/modules of same size shall be completely interchangeable.
240V AC control supply for motor starters shall be derived from a common
415/240V transformer having 1000 VA rating for each bus section.
4.2.8 All switches shall be load break, heavy duty, air break type with the operating
handle mounted on the compartment door, complete with necessary interlock
and defeat mechanism.
All fuses shall be non-deteriorating HRC cartridge, pressure-fitting link type.
The contractors shall be air break type having AC-3 duty rating.
Thermal overload relays shall be three elements, positive acting ambient
temperature compensated type with adjustable setting range and built in
protection feature against single phasing. Bimetal relays shall be manually
reset type with the reset push button provided on the cubicle door.
4.2.9 All relays shall be back connected, draw out type suitable for flush mounting
and fitting with dust tight covers along with hand reset type built in flag
indicators.
Current transformers for metering shall have an accuracy class 1.0 and
instrument safety factor less than 5. Protective current transformers shall have
an accuracy class 5P and an accuracy limit factor greater than 10.
Page 105 SEAL AND SIGN OF BIDDER
All indicating instruments shall be moving iron, flush mounting type and of 96
x 96mm square pattern. However 72mm x 72 mm instruments may be
acceptable for outgoing feeders in the MCC.
All control/selector switches shall be rotary back connected type having a cam
operated contract mechanism with pistol grip handle for circuit breaker control
and knob type handle for other applications.
Indicating lamps shall be suitable for 6.0V AC, complete with built in 240/6V
transformers. Lamps shall be provided with translucent covers to diffuse light.
The following indicating colours shall be used.
Close/on : Red
Open/off : Green
Auto/fault trip : Amber
Test Position : Blue
Spring charged/trip healthy/Control supply on: White
Push Button Colours shall be as follows:
Stop/Open/Emergency : Red
Start/Close : Green
Reset/Test : Yellow/Black/White
‘Stop’ push buttons for motor control feeders shall have stay put feature.
4.2.10 All motors starter feeders shall have STOP and RESET push buttons and
RUN, NON-RUN and TRIP indication lamps.
All breakers feeder shall have Test/Service selector switch breaker control
switch, trip healthy push button; ON TRIP, CONTROL SUPPLY FAILURE and
TRIP healthy indication leaps, Metering shall include a KWH meter and
ammeter with selector switch. Incomers to PMCC/MCC shall also have a
415/110V PT with primary fuse, secondary MCB along with a voltmeter and a
selector switch.
Page 106 SEAL AND SIGN OF BIDDER
Audio/visual annunciation shall also be provided for medium voltage
switchboards having auto-transfer provision between the two incomers and/or
bus coupler.
All feeders shall be provided with 1 NO + 1 NC as spare auxiliary contacts
wired to the terminal strip for Employer’s use.
4.2.11 All metal parts shall be thoroughly cleaned, degreased and made free from
rust. After application of the primer, the switchboard shall be spray painted
with two coats of final paint. Colour shade of the final paint shall be as per
manufacturer standard unless otherwise specified in the data sheet.
4.2.12 A centrally located engraved name plate shall be provided for the switchboard.
Each module shall have engraved nameplate-bearing data as per approved
drawings. Nameplate or polyester adhesive stickers shall be provided for each
equipment mounted on the switchboard.
4.2.13 At least 10% spare of each rating of outgoing feeders subject to a minimum of
one feeder of each rating shall be provided in the switchboard.
4.3 Local Push Button Station
Each motor shall be provided with a pedestal mounted control station in the
field near the motor. The local control station shall have die-cast
aluminum/sheet steel enclosure of IP-55 protection and shall be flame proof
type with cast iron/Aluminum alloy enclosure for installation in hazardous
area. The control station shall include START/STOP push buttons, cable
glands, ammeter etc. as required. STOP push button shall have stay put
feature. All push button shall be shrouded type, rear connected with 2 NO + 2
NC momentary contact and shall be complete with necessary inscription
plates. Outdoor control stations shall have necessary canoples.
5. Cabling System
5.1 Power cables for use in 415V system shall be of 1100V grade, aluminum
conductor, PVC insulated, PVC sheathed armored with overall PVC sheet as
per IS: 1554 (Part-I). Power cables for 3.3kv/6.6kv/11kv system shall be
aluminum conductor. XPLE insulated, screened, PVC bedded, galvanized steel
flat armored and PVC sheathed as per IS:7098. Both inner and outer sheath
shall be extruded PVC for all power and control cables.
Page 107 SEAL AND SIGN OF BIDDER
Control cables shall be 1100V grade, 2.5mm2 copper conductor, PVC
insulated, PVC sheathed, single wire armored with an overall PVC sheath as
per IS:1554 (Part-I). Adequate derating factors shall be used for sizing the
cables. Sizes of cables feeding motors shall be as per clause 4.2.5.
5.2 Cables shall preferably be laid in overhead cable trays along the pipe rack
wherein available. Overhead cable funs shall be supported by GI saddle with
bars spaced 300 mm apart. Painted MS ladder type trays or cable trays
fabricated out of hot dip galvanized sheet shall be used as per data sheet.
Cable trays shall be supported at a distance not exceeding 2000 mm. Tray
widths shall be preferably 300/500/750mm and shall be arranged in
single/multi-tiers as required. All supporting steel shall be painted before
laying of cables.
Underground cables in paved areas shall be in lined trenches with concrete
covers having proper slope and drainage holes for water. Underground cables
in unpaved areas shall be in lined trenches or directly buried as specified in
data sheet. In hazardous areas trenches shall be completely filled up with
sand. Direct cable runs shall be laid at a depth of not less than 750 mm for
MV cables and 900 mm for HV cables and shall be covered with 150 mm of
sand on top of the largest diameter cable followed by a protective covering of
75mm thick second class red bricks. The remainder of the trench shall then be
back filled, rammed and leveled. Where underground cables cross roadways,
pipe sleepers at grade etc., they shall be protected by being drawn through
sleeves/ducts to provide a permanent crossing. Conduits, where used, and all
conduit fittings shall be galvanized. Where cables rise up through floors to
connections, these shall be protected by GI conduits up to a min. of 300mm
above grade and open ends shall be sealed.
All exposed cables shall be suitably covered in a boxing to maintain the
aesthetics of the area as well as for protecting the cable from any abuse.
5.3 All power and control cables shall be of continuous lengths without
intermediate joints. All cables shall be identified close to their termination
point by cable number (as per cable schedule) punched on 2mm thick
aluminum strape securely fastened to the cable. In case of control cables all
cores shall be identified at both ends by their terminal numbers using PVC
ferrules as per interconnection diagrams.
5.4 All PVC cables upto 1.1kv grade shall be terminated at the equipment by
means of double compression type cable glands preferably of comet make and
Page 108 SEAL AND SIGN OF BIDDER
crimping type lugs of dowels make. All cable entries shall be through bottom
only unless otherwise approved.
5.5 All cables routes shall be marked and order of lay shall be designed to avoid
crisscrossing. High voltage, medium voltage, control and signal cables shall be
separated from each other by adequate spacing or running through
independent pipes, trenches or cable trays as applicable. Adequate space shall
be provided for running HT cable, communication cables and fire alarm cables
even where these are not included in vendor’s scope.
6. Earthing System
6.1 Earthing system design and installation shall generally be as per IS:3043. All
metallic non-current carrying parts of electrical apparatus, current and
potential transformer secondaries, structural steel, vessels, towers, stacks,
storage tanks, loading racks etc. shall be earthed at least by two distinct
separate earth conductors from the earth plate connected to the main earthing
loop.
6.2 The main grid conductor shall be hot dip galvanized MS flat or PVC insulated
aluminum/copper conductor having min. size of 40 x 5mm for GI strip or
equivalent copper/aluminum section. Thickness of hot dip galvanizing shall
not be less than 75 microns. The main earth loop shall be laid at a depth of
500mm below grade. Wherever lined trenches are available, the main earth
conductor shall be laid in trenches firmly created to the walls of concrete lined
trenches. In the process areas having overhead cable trays, the main earthing
conductor shall run along cable trays, wherever possible, suitable cleated and
electrically bonded to the cable tray at regular intervals. Joints and tapings in
the main loop shall be made in such a way that reliable and good elect.
Connections are permanently ensured. All joints below grade shall be welded
and suitably protected by giving two coats of bitumen and covered with
Hessian tape. Tee connectors shall be used for tapping earth leads from the
main earth loop wherever installed above ground.
6.3 Adequate number of 65mm dia. 3 M long GI pipe earth electrodes shall be
provided with main loop to limit the earth resistance of the package unit earth
grid to less than 5 ohms during dry weather conditions. All earth electrodes
shall preferably be driven to a sufficient depth to reach permanently moist soil.
Package unit earth grid shall have provisions for interconnection to Employer’s
main plant earth grid.
Page 109 SEAL AND SIGN OF BIDDER
6.4 Multiple earth connections shall be taken from suitably located earth plates
connected to earth loop. All hardware used for earthing installation shall be
hot dip galvanized or zinc passivated. Spring washers shall be used for all
earthing connections of equipment. Following sizes of earth conductors shall
be used for motors:
Upto 3.7 kw : 8 SWG GI wire
5.5 to 30 kw : 3/8" GI fine wire rope of 35mm
2. All insulated cond.
37 to 75 kw : 5/8" GI fine wire rope of 70mm
2. All insulated cond.
Above 75 kw : Same size as main earth loop.
Earthing connections to equipment shall be made by means of specially
provided bolts and lugs.
6.5 Lighting protection shall generally be as per IS:2309 Lighting protection shall
be provided for the equipment, structures and buildings higher than 20
meters. Self-conducting structures need not be provided with aerial rod and
down conductors but shall be connected to the earthing grid at two points of
the base.
6.6 All utility, process pipe lines shall be bounded and earthed on entering/leaving
any hazardous area.
7. System Testing and Commissioning
Vendor shall submit the field-testing procedures for Employer’s approval. Field
tests as per the approved procedures shall be performed on the electrical
system/equipment before its being put into service. The vendor shall arrange
all test equipment. Test reports shall be approved by the site-in-charge before
acceptance of the complete plant and equipment.
Page 110 SEAL AND SIGN OF BIDDER
8. Spares
Vendor shall supply all spares and consumables required for proper operation
and maintenance for minimum two years of the complete system and
associated equipment in addition to those required during field testing and
commissioning, these spares shall include but not be limited to the following:
8.1 M.V. Motor
- Driving end and non-driving end bearings
- Terminal block
- Terminal cover with screws etc.
- Fans for critical motors.
8.2 Medium Voltage Switchboard
- Spares for the breaker
- Switches and fuses of all ratings
- Set of main contacts and coils of all contractors
- Bimetal relays of critical ratings.
- Indicating lamps.
9. Guarantee
The vendor shall warrant that the equipment and installation shall satisfy the
requirements of the intended use and is free from intent defects. Vendor shall
assume responsibility for obtaining manufacturer’s performance guarantee for
all equipment purchased by him. Vendor shall then assume this warranty in
his guarantee to the Employer. Vendor shall repair or replace any equipment,
which proves to be defective within 12 months after its being put in operation,
but not later than 18 months from date of shipment.
Page 111 SEAL AND SIGN OF BIDDER
14. Technical Specifications (Electrical Works)
A] WIRING SYSTEM
1. SCOPE
The scope of work under this section generally covers internal wiring for lights,
fans, exhaust fans, call bells, fan coil units, geysers, power sockets etc., The
contractor shall provide all materials, labour, equipment, scaffoldings, etc., as
required for the completion of wiring installation called for. The wiring shall
generally be done using PVC insulated copper conductor wires in PVC/M.S./G.I
conduit as called for including providing switches, sockets, plug tops, fan
regulators, outlet boxes etc.,
2. STANDARDS APPLICABLE
The applicable standards for above work shall be as listed below: IS: 732 Code of practice for electrical wiring installation
(System voltage not exceeding 650 V). IS : 1646 Code of practice for fire safety of buildings (General
Electrical installation).
IS : 2667 Fittings for rigid steel conduits for electrical wiring.
IS : 3480 Flexible steel conduits for Electrical wiring.
IS : 3837 Accessories for rigid steel conduit for electrical wiring.
IS : 694 PVC insulated cables. IS : 2509 Rigid - non-metallic conduits for electrical wiring.
IS : 6946 Flexible (Pliable) non-metallic conduits for electrical installation.
IS : 1293 3 Pin plugs and sockets.
IS : 8130 Specifications for conduits for electrical installation. IS : 3854 Switches for domestic purpose.
Page 112 SEAL AND SIGN OF BIDDER
IS : 3415 Fittings for rigid non-metallic conduits. IS : 4648 Guide for electrical layout in residential building.
IS : 9537 Conduits for electrical installation.
IS : 302 General and safety requirements for
household and similar electrical appliances.
IS : 3043 Code of practice for earthing.
IS : 5216 Guide for safety procedures and practices in electrical work. Indian Electricity Act and Rules.
Regulations for the electrical equipment in buildings issued by the Bombay
Regional Council of Insurance association of India, CEIG Karnataka, EB.
All standards and codes mean the latest.
3. POINT WIRING FOR LIGHTS, FANS, EXHAUST FANS & 5A
CONVENIENCE SOCKETS
A point wiring shall consist of the branch wiring from the distribution board
together with a switch/fan regulator as required, including providing
conduit and accessories, the ceiling rose or pendant holder or a swan
holder, or ceiling fan hook box or socket etc., with suitable termination.Point
wiring shall include, in addition, the earth continuity conductor/wire from the
distribution board to the earth pin/stud of the outlet/switch box and to the
outlet points.
The point wiring shall be carried out in the under mentioned manner:
Supply, installation, fixing of conduits and GI pull wire with necessary
accessories, junction/pull/inspection/switch boxes and outlet boxes/Fan
hook box etc. Switches, switch plates and switch boxes are not required
for the lights which are controlled directly from the MCB DB's.
Supplying and drawing of wires of required size including earth continuity
PVC insulated wire.
Page 113 SEAL AND SIGN OF BIDDER
Supply, installation and connection of flush type switches, sockets,
cover plates, switch plates, and fixing fan regulator, lamp holder, ceiling
rose etc..
The point shall be complete with the branch wiring from the
distribution board to the outlet point, through switch board, conduit
with accessories, junction, pull, inspection boxes, control switch,
socket, outlets boxes, ceiling roses, lamp holder, connector, extension
cord wire, flexible conduits etc..
4. POINT RATE
For purposes of measurements and payments the rate for point wiring for
lights/fans etc., is divided into two parts.
a) Circuit Main
b) Point Wiring.
a. Circuit Main for Light/Fan Point: The circuit main for lights/fan/6A
sockets (where 6A sockets connected to light circuit) shall include the
wiring from the MCB distribution boards upto the first switch/light
point/fan point. This is measured in linear meter. The scope of work
under this section shall include,
Supply and wiring in concealed/surface conduit from DB’s to first
switch/light/fan point.
Providing and installing PVC insulated copper conductor earth wire.
Providing and installing GI fish wire (pull wire) in the conduit.
Termination of wires in DB's and switches using proper tinned copper
lugs of crimping type.
Providing and installing necessary pull/junction boxes where
necessary.
Page 114 SEAL AND SIGN OF BIDDER
b. Point Wiring: The rate for point shall include supply, installation, and
connection, testing and commissioning of point wiring in conduit. The
points shall be measured in No/sets for the set/group of lights controlled
as mentioned in SOQ.
The exact scope of work included in the point wiring for the purposes of
measurement is enumerated as stated below.
Wiring starting from the first switch/light/fan point, where the circuit
main is terminated to the various lights/fans/sockets (where 6A sockets
connected to light circuit loop), and then looping between the
switches/lights/fans/6A sockets etc.,
Providing and installing all necessary switches, switch plates, sockets,
pull/junction/fan hook boxes etc. as called for.
Providing and installing insulated earth continuity wire in each conduit
along with the wiring system.
Providing and installing G.I. fish wire (pull wire) in the conduits.
Providing and installing ceiling roses, lamp holders where necessary.
Providing and installing PVC insulated, PVC sheathed flexible three core
1.5 sq.mm extension cords including flexible conduits from light/fan
outlet points mounted at ceiling point to the light/fan outlet.
Wiring for 6A Sockets, 16A Power Sockets for Equipment Wiring :
Except where 6A sockets connected to the lighting loop which are
measured in Number of points, the measurement for wiring of 6A/16A
sockets and wiring for power outlets is done as follows :
Length of circuit wire including conduit, accessories and earth wire for
power wiring is measured together in linear meter.
The socket outlet with outlet box is measured in Numbers.
Page 115 SEAL AND SIGN OF BIDDER
5. SYSTEM OF WIRING
Unless otherwise mentioned on drawings, the system of internal wiring
shall be as follows : The system of wiring shall consist of single core, PVC
insulated, 650/1100 Volt grade, stranded copper conductor
wires/cables laid through concealed or exposed PVC/GI/MS conduits
as mentioned elsewhere or as directed by Employer/client.
GENERAL: Prior to laying and fixing of conduits and light outlet boxes,
contractor shall carefully examine the layout drawings and prepare
detailed shop drawings, indicating the exact location of light outlets,
with distances marked, conduit routing, with sizes, number of wires run
in each conduit, control switch location etc., The contractor shall obtain
the approval of all shop drawings by the Employer/client prior to the
installation of conduits. Any discrepancy noticed in the design drawings
shall be brought to the notice of the Employer/client. Any suggestions or
modification suggested by the contractor shall have approval of Client
before execution.
Type of Installation
Unless otherwise specified all conduits for surface wiring shall be
heavy gauge rigid GI/MS conduits and all concealed installation
including conduits running above false ceiling shall be heavy gauge rigid
PVC.
All conduits buried in grade or in damp wet areas shall be heavy gauge
G.I. conduits.
Concealed Wiring shall be done using PVC conduits in the following
areas,
i. Staircase area lighting.
ii. Wiring inside offices.
iii. Wiring in the false ceiling area.
iv. All other areas where surface conduit is not specifically mentioned.
Page 116 SEAL AND SIGN OF BIDDER
Surface Wiring shall be done using Heavy Gauge G.I/Black Enamelled
M.S. Conduit.
i. Wiring installation in the electrical sub-station room, D.G. Room.
ii. Pump room, sewage treatment plant room.
iii. Ventilation fan room, AHU room and electrical room.
Conduit Installation in False Ceiling Area: The PVC conduits shall run
exposed using above false ceiling.
6. MATERIALS : CONDUITS
Type of Conduit: All conduits for fire alarm system irrespective of surface or
concealed shall be of G.I/M.S. Generally concealed electrical wiring
installation shall be in PVC conduits and surface wiring in G.I/M.S. conduits.
7. PVC CONDUITS: Non-metallic conduits and accessories shall conform to IS
9537 (part 3) - 1983, IS 2509 & IS 3419 and each conduit shall bear the ISI
Mark. PVC conduits shall be of the black, round, heavy gauge polyvinyl
chloride (PVC). The conduit shall be plain end type as specified in IS 2509-
1973/IS 2537-1983. The conduit internal surface shall be smooth. Only
approved quality factory made bends/accessories shall be used. Minimum size
of conduits shall be 20mm diameter. PVC conduits shall be rigid unplasticised,
heavy gauge having minimum wall thickness of 2.0mm up to 25mm diameter
conduit and 2.5mm wall thickness for all sizes above 25mm diameter.
8. CONDUIT ACCESSORIES
i. PVC CONDUIT BENDS & COLLARS: The PVC conduit bends & collars
shall be of heavy duty and preferably of the same make as of conduit.
This shall conform to IS 9537/1983 Part III with ISI Mark where
necessary bends or diversion may be achieved by means of using bends
and or circular inspection boxes with adequate and suitable inlet and
outlet termination. In case of recessed installation system. The bends
Page 117 SEAL AND SIGN OF BIDDER
shall be properly secured & flush with the finished wall surface. Elbows
shall not be used. No bends shall have radius less than 2 1/2 times the
outside diameter of the conduit.
ii. PVC/INSPECTION/JUNCTION/PULL BOXES : The Inspection/pull
box/junction box, where used, with relevant PVC conduit installation
shall be of heavy gauge PVC and conform to IS specification and shall
match with the conduit sizes. The box shall be round/square
rectangular with conduit stub projection for termination of conduit. The
box shall be of minimum 50mm deep and the size of box shall be
suitable to pull/make necessary joints of wires inside the boxes. Extra
deep boxes are preferred. The boxes shall have flush type cover. The
colour of plate shall match the colour of paint of the surface where
installed. The boxes shall have concealed screwed socket for fixing the
ceiling rose.
9. SWITCH OUTLET & SOCKET OUTLET BOXES
Concealed Type Outlet Boxes: The concealed outlet boxes for switches,
sockets, power outlets, telephone outlet, fan regulator etc., shall be of standard
factory made and to match the exact requirement of combination of outlets.
The boxes shall be fabricated out of heavy gauge CRCA cold rolled carbon alloy
sheet steel with zinc plating (G.I). The size of boxes shall match the type of
outlet/switch plate to be mounted on the box. Adequate No. and size of
knockout holes shall be provided to terminate the conduits in the box. These
boxes shall be of standard factory made product and of same make as of
switch plates and sockets. Separate screwed earth terminal shall be provided
in the box for earthing.
The outlet box shall be of minimum depth of 50mm. Boxes shall be suitable for
grid mounting type of accessories. Long screw shall be provided to take care of
the extra plaster thickness to mount the switch plates. Provision shall be
Page 118 SEAL AND SIGN OF BIDDER
made in the box and switch plate to have the minor adjustment of alignment of
switch plate to plumb level.
Surface Type Boxes: The boxes for mounting switches, sockets and other
wiring devices shall be either moulded plastic or heavy gauge CRCA sheet steel
painted to match the colour of wall. The box shall be suitable to terminate the
G.I/M.S. surface conduit into the box. The size and shape of box shall match
the exact type and combination of switch plates, receptacles and wiring
devices. Deep boxes shall be used to facilitate easy termination of conduit and
wires/cables. Separate screwed earth terminal shall be provided in the box
for earthing.
Light Outlet Boxes: For concealed PVC conduit installation the light outlet
box shall be of PVC round/square with knock-out holes. Conduit projection
shall be suitable to terminate the conduit to the box. The box shall be made of
heavy gauge PVC and the sample to have the approval of Construction
Manager before use. The boxes shall have concealed screwed socket to fix the
ceiling rose. The boxes shall be minimum 50mm deep.
For surface conduit installation the light outlet box shall be of G.I/black
enamelled M.S. boxes. The boxes shall have threaded stub projection having
internal threading to terminate the conduits of different sizes. The boxes shall
have concealed screwed socket for fixing the ceiling rose. The boxes shall be
minimum 50mm deep.
Ceiling Fan Hook Boxes: The ceiling fan hook box shall be fabricated of 2mm
thick G.I/M.S. with adequately sized G.I/M.S. rod/hook to fix the ceiling fan.
The hook shall be concealed within the fan hook box. The side extensions of
rod shall be sufficiently long to provide adequate anchorage in the concrete.
The size of the box shall be such that it should be totally covered by the plastic
canopy of the ceiling fan. The box shall have anticorrosive primer coating.
Switches: Switches shall conform to IS: 3854, and IS: 4615. Switches shall be
single pole, single or two way as shown on the drawings. They shall be of the
Page 119 SEAL AND SIGN OF BIDDER
molded type rated for 250V, 5/15A. They shall be provided with insulated
dollies and covers.
The switches shall be rocker operated with a quiet operating mechanism with
bounce-free, snap acting mechanism in an arc resistant chamber. The
switches shall have pure silver and silver cadmium contacts. The switches
shall be of approved make as indicated in the `List of Approved Makes’.
Switches installed outdoors shall be industrial, metal clad type, and shall be
provided in weather-proof enclosure, complete with weather proof gasketed
covers.
Cover Plates For Switches & Outlets: Switches/sockets/wiring devices plates
shall be of the same make as of switches/sockets/wiring devices. These shall
be of best quality. Moulded plastic grid mounting type device plates/frames
shall be used and these shall match with the type of switches/sockets and
boxes.
Cover Plates For Inspection/Junction/Pull Boxes: The cover plate for PVC
boxes shall be with minimum 3mm thick perspex/formica sheet cover and for
the G.I/M.S. boxes, shall be of G.I/black enamelled M.S. Plates. The shape of
the plate shall match with that of the box.
Receptacles: The sockets shall conform to IS 1293. Each socket shall be
provided with control switch of appropriate rating. The sockets shall be
moulded type rated for 250 volts and of 6 A or 16 A capacity as mentioned on
the drawings. The 16 Amps sockets shall be multi pin (6 pin) automatic
shutter type suitable for plugging 6 A/16 A plugs. The shutter shall open when
the earth pin of the plug is inserted in the socket. Where called for, the 16 a
socket shall have indicating lamp. The socket outlets and switches shall be of
grid mounting type. Where called for sockets shall be provided with three pin
plug top suitable to the socket and of the same make as of socket. The plug
shall conform to IS 6538. The socket outlets installed outside the
Page 120 SEAL AND SIGN OF BIDDER
building/open to sky or in damp/wet areas shall of weather-proof, water-tight
type.
Industrial Type Sockets: The socket outlets single phase or three phase
installed in electrical room, D.G room etc., shall be three pin or 5 pin
industrial type with MCB (1 phase or 3 phase) control. The socket and MCBs
shall be mounted in a sheet steel enclosure and shall be standard factory
made product.
Conductors: All PVC insulated copper conductor wires shall conform in all
respects to standards as listed under sub-head 'Regulations and Standards'
and shall be of 650/1100V Grade.
10. PVC INSULATED WIRES (FOR LIGHT & SMALL POWER WIRING)
The PVC cables shall conform to IS: 696/1977 and IS: 1554 as per direction of
consultant. For all internal wiring PVC insulated cables of 650/1100V grade,
single core shall be used. The wires shall have the approval of Tariff Advisory
Committee.
The conductors shall be plain, circular stranded annealed copper conductors
complying with BS: 6360.
The minimum number and diameter of wires for circular stranded conductor
shall meet the requirements set out in the relevant British Standards.
The insulation shall be PVC compound complying with the requirements of BS:
6746. It shall be applied by an extrusion process and shall form a compact
homogeneous body. The PVC compound shall comply with the requirements of
IS 5831-84.
The cores of all cables shall be identified by colors in accordance with the
following sequence.
Single phase - Red
Three phase - Red, Yellow, Blue
Neutral - Black
Page 121 SEAL AND SIGN OF BIDDER
Earth - Green or Green/Yellow.
A means of identifying the manufacturer shall be provided throughout the
length of cable.
Unless otherwise specified in the drawings, the sizes of the cables/wires used
for internal wiring shall be as follows:
In case of circuit wiring for lights, exhaust fans, ceiling fans, bells, convenience
socket outlet points:-
2.5 Sq.mm - For Lights/fans/5A socket wiring from DB's upto the outlet
points including control wiring where the circuit length from the DB's to
1st outlet is less than 40 m.
In case of power socket outlet circuit.
6.0 Sq.mm - From DB’s 20/32 A Industrial type sockets.
4.0 Sq.mm - From DBs to 16 A sockets.
The earth continuity conductor size as indicated in the drawing/SOQ shall be
drawn through conduit along with other circuit cables/wires. The size of the
earth continuity conductor shall be as follows:-
UNLESS OTHERWISE SPECIFIED MINIMUM SIZE OF EARTH CONTINUITY
CONDUCTOR WIRES NOT FORMING PART OF THE SAME CABLE AS THE
ASSOCIATED CIRCUIT CONDUCTOR
Nominal cross sectional area of
largest associated copper circuit
conductor in sq.mm
Nominal cross sectional area of earth
continuity conductor in sq.mm (PVC
insulated green colour wire)
1.5 2.5
2.5 2.5
4.0 2.5
6.0 4.0
10.0 6.0
16.0 6.0
Page 122 SEAL AND SIGN OF BIDDER
25.0 10.0
35.0 10.0
50.0 10.0
Separate circuits shall run for each water heater, pantry/kitchen equipment,
window air conditioner, and similar outlets at locations as shown on drawings.
11. INSTALLATION OF CONDUIT
Concealed Conduit System : Unless otherwise Specified, all wiring shall be
in heavy gauge rigid PVC conduit embedded in wall, or ceiling and
concealed in the false ceiling. The size of the conduit shall be selected in
conformity with I.S. code and as specified in the table given below. Factory
made conduit bends and accessories shall be used. PVC Conduit shall be
jointed using Solvent Cement as recommended by the conduit supplier. The
conduit in ceiling slab shall be straight as far as possible. Before the conduits
are laid in the ceiling, the position of the outlet points, controls, junction
boxes shall be set out clearly as per the dimensions and to minimize off-sets
and bends. Before the reinforcement rods are kept in position electrical
contractor shall mark in paint the position of outlet points and conduit drop
on the shuttering. When the outlet boxes are kept in position and before
pouring the concrete, all outlet boxes shall be filled with paper to avoid
entry of concrete into the box. Conduits in ceiling shall be bonded to the
reinforcement rods with G.I. bonding wire at intervals not more than 1000mm,
to secure them in position. PVC deep light outlet / pull boxes shall be provided
as required. The conduit in ceiling slab shall be laid above the first layer of
reinforcement rods to avoid cracks in the ceiling surface. In general the
conduit shall not be laid directly on the shuttering surface to avoid cracks in
the ceiling surface.
Page 123 SEAL AND SIGN OF BIDDER
Conduits concealed in the wall shall be secured rigidly by means of steel hooks
/ staples at min. 750 mm intervals. Before conduit is concealed in the walls,
all chases, grooves shall be neatly made to proper required dimensions using
electrically operated groove cutting tools to accommodate number of conduits.
The outlet boxes for control switches, inspection and draw boxes shall be fixed
as and when conduits are being fixed. The recessing of conduits in walls shall
be so arranged as to allow at least 12mm plaster cover on the same. All
grooves, chases etc. shall be refilled with 1:4 cement mortar and finished up to
wall surface before plastering of walls is taken up by the general civil
contractor. Horizontal chases in walls are not allowed. Where unavoidable,
prior permission of Employer/client shall be obtained before making any
chasing. Where conduits pass through expansion joints in the building,
adequate expansion fitting or other approved devices shall be used to take
care of the relative movement. Whenever the conduits terminate into control
boxes, distribution boards etc. conduits shall be rigidly connected to the
boxes/boards with check nuts on either side of the entry. After conduits,
junction boxes, outlet boxes etc. are fixed in position, their outlets shall be
properly plugged with PVC stoppers or any other suitable materials, so that
water, mortar, vermin or any other foreign materials do not enter into the
conduit system. All conduit ends terminating into an outlet shall be
provided with bushes of PVC or rubber after the conduit ends are properly
filed to remove burrs and sharp edges.
Necessary G.I. pull wires shall be inserted into the conduit for drawing wires
before concreting. Insulated earth wires shall be run in each conduit
originating from the panel board upto the Light, Socket and Switch boxes. If
the Electrical Contractor forgets to install any conduit/boxes etc., before the
plastering/painting work is done by other agencies, he may be permitted to
install the same with prior permission of Employers/ client and he shall be
liable to make good the wall, floor, ceiling etc. at his own cost.
Page 124 SEAL AND SIGN OF BIDDER
Conduits shall be so arranged as to facilitate easy drawing of wires through
them. Entire conduit layout shall be done in such a way as to avoid additional
junction boxes other than light points. The wiring shall be done in a looping
manner. All the looping shall be done in either switch boxes or outlet boxes.
Joints in junction or pull boxes are strictly not allowed. Where conduits cross
building expansion joints, adequate expansion fittings or other approved
devices shall be used to take care of any relative movement.
All conduits shall be installed so as to avoid touching of steam and hot water
pipes.
Conduits shall be installed in such a way that the junction and pull boxes
shall always be accessible for repairs and maintenance work. The location of
junction/pull boxes shall be marked on the shop drawings and approved by
the Employer/client.
A minimum separation of 200mm shall be maintained between electrical
conduits and hot water lines in the building.
No run of conduit shall exceed ten meters between adjacent draw-in points
nor shall it contain more than two right angle bends, or other deviation from
the straight line.
Caution shall be exercised in using the PVC conduits in locations where
ambient temperature is 50 degree celsius or above. Use of PVC conduits in
places where ambient temperature is more than 60 degree C is prohibited. The
entire conduit system including boxes shall be thoroughly cleaned after
completion of installations and before drawing of wires. Conduit system shall
be erect and straight as far as possible. Traps where water may accumulate
from condensation are to be avoided and if unavoidable, suitable provision for
draining the water shall be made.
All jointing methods shall be subject to the approval of the Employer/client.
Separate conduits shall be provided for the following system.
- Lighting wiring
- 16 Amp power outlets.
- 6 Amp outlets and lighting system.
Page 125 SEAL AND SIGN OF BIDDER
- 24 Volt supply system.
- Telephone/intercom system,
- Fire Alarm system,
- Computer data cabling system.
- Equipment wiring.
Conduit Joints: Conduits shall be joined by means of plain couplers. Where
there are long runs of straight conduits, pull/inspection boxes shall be
provided at intervals, as approved by the Employer/client/construction
manager. The conduits shall be thoroughly cleaned before making the joints.
In case of plain coupler joints, proper jointing material like a vinyl solvent
cement (gray in color) or any material as recommended by the manufacturer
shall be used.
Bends in Conduit: Wherever necessary, long bends or diversions may be
achieved by bending the conduits or by employing normal bends. No bends
shall have radius less than 2.5 times outside diameter of the conduit. Heat
may be used to soften the PVC conduit for bending, but while applying heat to
the conduit, the conduit shall be filled with sand to avoid any damage to the
conduit. Kinks in the conduit bends shall not be acceptable.
Bunching of Cables : Cables of AC supply of different phases shall be
bunched in separate conduits. The number of insulated wires/cables that
may be drawn into the conduits shall be as per the following table. In this
table, the space factor does not exceed 40%. However, in any case conduits
having less than 20mm diameter shall not be used.
MAXIMUM PERMISSIBLE NUMBER OF 650 VOLT GRADE SINGLE CORE
WIRES THAT MAY BE DRAWN IN TO RIGID PVC CONDUITS.
CABLE SIZE
IN Sqmm
SIZE OF CONDUITS (mm) (MAX NO. OF WIRES)
20 25 32 40 50
1.5 4 8 14 - -
Page 126 SEAL AND SIGN OF BIDDER
2.5 4 6 10 - -
4.0 3 4 8 12 -
6.0 2 4 6 8 -
10.0 1 3 5 10 -
16.0 0 2 4 5 12
Wires carrying current shall be so bunched in the conduit that the
outgoing and return wires are drawn into the same conduit. Wires
originating from two different phases shall not be run in the same conduit.
Wiring: All final branch circuits for lighting and appliances, shall be single
conductor cables run inside conduits. Branch circuit conductor sizes shall be
as shown in the load analysis of drawing and conforming to the requirements
of the I.E. Regulations and I.S. Code.
Home runs indicated on the drawings for the final branch circuits shall
be kept in a separate conduit upto the panel board via switches wherever
called for. No other wiring shall be bunched in the conduit unless the other
circuit main of same phase runs in the same conduit.
For each lot of wire supply, Contractor shall supply a certificate issued by the
Manufacturer stating its origin, date of manufacture, constitution and
standards to which it complies and the test certificates.
Looping system of wiring shall be used. Wires shall not be jointed inside the
conduit or pull boxes. Where joints are unavoidable, they shall be made
through approved mechanical connectors with prior permission of
Employer/client.
Control switches shall be connected in the phase conductors only and
shall be 'ON' when knob is down. Switches shall be fixed in galvanized steel
boxes. Chromium plated screws shall be used.
Power wiring shall be distinctly separate from lighting wiring.
Each circuit phase wire from the distribution boards should be followed with a
separate neutral wire of the same size as the circuit wire.
Bunching of Wires: Wires carrying current shall be bunched so that the
outgoing and the return wires are drawn in the same conduit. Wires
originating from two different phases shall not run in the same conduit.
Drawing Conductors: The drawing and jointing of PVC insulated copper
conductor wires and cables shall be executed with due regard to the following
precautions. While drawing wires through conduits, care shall be taken to
Page 127 SEAL AND SIGN OF BIDDER
avoid scratches and kinks which cause breakage of conductors. There shall be
no sharp bends.
Insulation shall be shaved off like sharpening of a pencil and it shall not be
removed by cutting it square.
PVC insulated copper conductor wire ends shall be soldered (atleast 20 mm
length).
Strands of wires shall not be cut for connecting terminals. The terminals shall
have sufficient cross sectional area to take all strands and shall be
soldered. Connecting brass screws shall have flat ends. All looped joints shall
be soldered and connected through block/connectors. The pressure applied
to tighten terminal screws shall be just adequate, neither too much nor too
less. Conductors of all sizes shall always be terminated using cable sockets.
At all bolted terminals, brass flat washers of large area and approved steel
spring washers shall be used. Brass nuts and bolts shall be used for all
connections.
Only certified wiremen and cable jointers shall be employed to do jointing
work. All wires and cables shall bear the manufacturer's label and shall
be brought to site in original packing. For all internal wiring, PVC insulated
wires of 650/1100 volts grade shall be used. The sub-circuit wiring for point
shall be carried out in loop system and no joints shall be allowed in the length
of the conductors. If the use of joint connections are unavoidable due to any
specific reason, prior permission, in writing, shall be obtained from the
Employer/client. No wire shall be drawn into any conduit, until all work of
any nature, that may cause injury to wire, is completed. Care shall be taken in
pulling the wires so that no damage occurs to the insulation of wire. Before the
wires are drawn into the conduits, the conduits shall be thoroughly cleaned
of moisture, dust, dirt or any other obstruction by forcing compressed air
through the conduits. The minimum size of PVC insulated conductor wires
for all sub-circuit wiring for light points shall be 2.5 sq.mm.
Joints: All joints shall be made at main switches, distribution boards, socket
outlets, lighting outlets and switch boxes only. No joints shall be made in
conduits and in junction boxes. Conductors shall be continuous from outlet to
outlet.
Mains and Sub-Mains: Mains and sub-mains cables or wires where called for
shall be of the rated capacity and approved make. Every main and sub-main
wire shall be drawn through an independent adequate size conduit. An
independent earth wire of the proper rating shall be provided for every single
phase submain. For every 3-phase submain, 2 nos. earth wires of proper
Page 128 SEAL AND SIGN OF BIDDER
rating shall be provided alongwith the submain. The earth wires shall be
drawn inside the conduits along with the circuit main. Where mains and sub-
mains cables are connected to switchgear, sufficient extra lengths of cables
shall be provided to facilitate easy connections and maintenance.
Load Balancing: Load balancing of circuits in three phase installation shall be
planned before the commencement of wiring and shall be strictly adhered to.
Colour Code of Conductors: Colour code shall be maintained for the entire
wiring installation: red, yellow, blue for three phases, black for neutral,
green/yellow green for earthing. The control wire from light control switches to
the light/fan points shall be the same colour as that of the phase/circuit wires
feeding that particular loop.
Earthing: All earthing system shall be in accordance with IS 3043 - 1985 Code
of practice for Earthing. The type and size of earthing wire shall be as specified
under the heading of cables. Each conduit originating from the DB to various
outlets shall have one earth wire (PVC insulated green colour wire).
Testing of Installation: Before a completed installation is put into service,
the following tests shall be complied with Following:
Insulation Resistance
The insulation resistance shall be measured by applying 500 Volt megger with
all fuses in place, circuit breaker and all switches closed.
The insulation resistance in megohms of an installation measured shall not be
less than 50 megohms divided by the number of points in the circuit.
The insulation resistance shall be measured between
Earth to Phase
Earth to Neutral
Phase to Neutral
Earth Continuity Path: The earth continuity conductors shall be tested for
electrical continuity and the electrical resistance of the same along with the
earthing lead but excluding any added resistance or earth leakage circuit-
breaker, measured from the connection, with the earth electrode to any point
in the earth continuity conductor in the completed installation and shall not
exceed one ohm.
Polarity of Single Pole Switches: A test shall be made to verify that every
non-linked, single pole switch is connected to one of the phases of the supply
system.
Page 129 SEAL AND SIGN OF BIDDER
Completion Certificate: All the above tests shall be carried out in presence of
Construction Manager and the results shall be recorded in prescribed forms.
Any default during the testing shall be immediately rectified and that section of
the installation shall be retested. The completed test result forms shall be
submitted to the Employer/client.
On completion of an electric installation a certificate shall be furnished by the
contractor, countersigned by the certified supervisor under whose direct
supervision the installation was carried out. This certificate shall be in a
prescribed form as required by the local electric supply authority.
B] M.V.DISTRIBUTION BOARDS
1. SCOPE :
This section covers the design, manufacture, assembly, testing at
manufacturer's works, inspection, packing for transportation, delivery at
site, installation, connection, testing and commissioning of 415V switch
boards with guarantee of performance for a period of twelve (12) months from
the date of commissioning. The contractor shall provide all materials, labour,
equipment, scaffolding etc., as required for the completion of the job.
2. STANDARDS APPLICABLE
The following standards and rules shall be applicable:
The Distribution Boards shall comply with the latest edition of relevant
Indian Standards and Indian Electricity rules and regulations. The
following Indian Standards shall be complied with:
IS 4237-83 : General requirements for switch gear and control gear for
voltages not exceeding 1000V.
IS 5578-85 : Guide for marking of insulated conductors.
IS 11353-85 : Guide for uniform system of marking and identification of
conductors and apparatus terminals.
IS 2147-62 : Degree of protection provided by enclosures for low voltage
switch gear and control gear.
Page 130 SEAL AND SIGN OF BIDDER
IS 2675-83 : Enclosed distribution fuse boards and cutouts for voltages not
exceeding 1000V.
IS 2551-82 : anger notice plates.
IS 2516 : Circuit breakers Part 1. Requirements (Part I/Sec 1): and tests:
Section 1. Voltages not exceeding 1000V ac or 1200V dc.
IS 4064-78 : Air break switches, air break disconnectors, air break
switch disconnectors and fuse combination units for voltages not
exceeding 1000V ac or 1200V dc.
IS 1818-72 : Alternating current isolators (disconnectors) and earthing
switches.
IS 8623-77 : Factory built assemblies of switchgear and control gear for
voltages upto and including 1000V AC & 1200V DC.
IS 8828-78 : Miniature air break circuit breakers for voltages not exceeding
1000V.
IS 9926-81 : Fuse wires used in rewireable type electric fuses upto 650 Volts.
IS 8544-79 : Motor starters for voltages not exceeding 1000 Volt A.C.
or 1200 Volt D.C.
IS 2959-85 : Contactors for voltages not exceeding 1000 Volt A.C or 1200
Volts D.C
IS 9224-79 : Low Voltage fuses.
IS 12640-89 : Residual current operated circuit breakers.
IS 1248-83 : Direct acting indicating analogue (all parts) electrical measuring
instruments and their accessories.
IS 2705-81 : Current transformers. (all parts)
IS 4201-83 : Application guide for voltage transformers.
IS 8197-76 : Terminal markings for electrical measuring instruments and
their accessories.
Indian Electricity Act and Rules.
Page 131 SEAL AND SIGN OF BIDDER
3. 415V SWITCH BOARDS
The 415 volt switchboard shall be metal-clad, dead front totally enclosed, indoor
type, forming a self-supporting continuous board. The front portion of the
board shall have individual compartments arranged in tier formation to
accommodate draw-out type air-circuit-breakers. The back portion of the board
shall contain three-phase and neutral air-insulated busbars, cable
terminations, instrument transformers, etc. The busbars and all other
outgoing live terminals shall be protected to prevent accidental contact while
carrying out maintenance work.
4. DISTRIBUTION ARRANGEMENT
For single transformer load-centres, the panel shall accommodate one
transformer secondary circuit-breakerand specified number of outgoing circuit-
breakers all connected to the common busbar.
For two transformer load-center, the 415 volt bus shall be sectionalised and
each transformer shall be connected to the corresponding bus-section over
its secondary circuit-breakers. Bus-tie circuit breaker shall be provided
between adjacent bus sections and the outgoing switchgear distribution on each
bus-section shall be as specified.
5. 415 VOLT MAIN BUSBARS
Copper / Aluminium bus-bars shall be used. Busbars shall be made from
rectangular sections of high wrought aluminium alloy and the current density
shall not exceed 0.8 A / sq.mm and where copper sections are used the current
density shall not exceed 1.4 A / sq.mm.
The continuous current rating and the short circuit values which the main
bus bars are able to withstand shall be as per the requirements of the system
and as mentioned in SLD.
Page 132 SEAL AND SIGN OF BIDDER
The neutral bus bars shall be designed to carry 50 percent continuous current
rating of the main bus bars.
6. 415 VOLT CIRCUIT-BREAKERS
The circuit-breakers shall be triple-pole, air-break draw-out type. All current
carrying contacts of the breakers shall be silver plated. Arc-chute fitted on each
pole shall be easily removable for inspection of the main contacts. Inter-phase
barriers of proper design shall also be incorporated. All MCCB should be
ICS=100%ICU.
The plug connections of main and auxiliary circuit shall be fitted with self-
aligning contacts. The fixed position of the plug connections shall be easily
accessible for maintenance. Automatically operated shutters shall be provided
to screen the fixed portion of the plug when the breaker is fully withdrawn from
the cubicle.
The continuous current ratings of the various Circuit-Breaker units at specified
ambient temperature shall be as specified. The RMS Symmetrical breaking
capacity of the different air circuit-breakers shall be as follows, unless otherwise
specified:-
CURRENT RATING OF THE ACBs BREAKING CAPACITY RMS
SYMMETRICAL AT PF OF 0.2 TO 0.3
A A
200 15000
400 21000
630 36000
1000 36000
1600 36000
2500 36000
3200 50000
Page 133 SEAL AND SIGN OF BIDDER
7. OPERATING MECHANISM
The Circuit-breakers shall be either manually or electrically operated as
specified. For emergency closing and testing, the electrically operated breaker
shall be capable of manual closing. For manually operated breakers, manual,
independent-type closing mechanism shall be provided. If manual dependent
mechanism is provided then the breakers shall compulsorily have electrical
closing and tripping devices. All types of operating mechanisms shall be trip-
free throughout the breaker travel and designed to reduce mechanical shock to
a minimum during operation. All electrically operated breakers shall be provided
with mechanical/electrical anti-pumping device.
Each breakers shall be equipped with visible 'ON' and 'OFF' position
indicator on the front door of the compartment, mechanically connected to
the circuit- breaker mechanism. Separate ON and OFF indicating lamps also
shall be provided.
For electrically operated circuit-breakers, satisfactory operation shall be
guaranteed for closing the circuit-breakers with the operating voltage of the
drive, in the range of 85 to 110 percent of the rated voltage. The electrical
closing shall be either by solenoid or motor operated spring charged mechanism
suitable for 240 V AC.
The circuit-breaker shunt trip coil provided shall operate satisfactorily with
the operating voltage within the range of 70 t0 120 per cent of the rated
voltage. The shunt trip coil shall be suitable for 240 V AC. No separate control
source will be available as such capacitor trip Circuit shall be provided where
shunt tripping is proposed with protective relay so that ability to trip is not
impaired by momentary drop in voltage at the time of a fault.
Each circuit-breaker shall be provided with four (4) normally open and four
(4) normally closed spare auxiliary contacts in addition to the ones
already used for various control purposes. All auxiliary contacts shall be
wired internally up to the terminal block.
Page 134 SEAL AND SIGN OF BIDDER
All MCCB Accessories should be user friendly and site fixable and MCCB should
have defeat knob for door interlock.
8. INTERLOCKS
The switchgear shall be provided with all necessary interlocks designed to
prevent incorrect operation and to ensure safety of operating personnel and
also the equipment.
The moving portion of the circuit-breakers shall be so interlocked that with the
breaker closed it shall not be possible to isolate it from the connected position
or to plug it in from the isolated position.
Interlocking shall be provided to prevent operation of the circuit-breaker
unless it is fully plugged in or fully isolated and is locked correctly in
either position.
The circuit-breaker compartment doors shall be so interlocked as to prevent
access to a breaker which is in an energized and plugged in position. Special
means shall however be provided for undoing this interlock in an emergency.
Inadvertent withdrawal of a circuit-breaker movable unit too far beyond its
supports shall be prevented by a suitable mechanical stop.
The unit shall be provided with "test" position in which the circuit-breaker
main contacts are in the fully disconnected position with only the
secondary circuits remaining connected. All secondary connections including
control, signaling and metering circuits between the fixed and removable
sections shall be by means of flexible able and plug and socket arrangement.
9. PROTECTIVE DEVICES
The circuit-breakers shall be provided on each pole with any combination of
the following protective devices with ratings as called for in the specification:
Page 135 SEAL AND SIGN OF BIDDER
Direct acting over current tripping device with long time element having
inverse time current characteristic for protection against overloads and
instantaneous element for short-circuit tripping with alarm contact.
Direct acting over current tripping device with long time element having
inverse time current characteristic for protection against overloads and
short time element with definite time delay for short-circuit protection
with alarm contact.
Shunt tripping device with alarm contact.
Non-directional IDMT earth fault relay.
The under voltage tripping device when specified shall be designed for
the following operating conditions:
a) The circuit-breakers shall trip for voltage value set between 70 and 35
per cent of rated system voltage.
b) The under voltage relay shall not prevent manual closing of the circuit-
breaker above 85 percent of rated system voltage.
The CTs provided for protective devices shall have adequate VA capacity
and accuracy class of 10P10.
Release should be Microprocessor Based with Overload, Short Ckt &
Earth Fault.
Release should have facility of Zone Selectivity.
10. INSTRUMENTS AND METERS
Instruments, meters and relays shall be of flush-mounted design, housed
in dust-proof casing located in an accessible position on the breaker panel.
All incoming circuit-breaker units shall be provided with a voltmeter and
changeover switch on the live side for indicating the three-phase voltages and
ammeter with a changeover switch complete with C.Ts for measuring the
currents in all three phases. Ammeters with C.Ts and selector switches shall
also be provided for all outgoing feeders. For motor feeders the ammeter shall
Page 136 SEAL AND SIGN OF BIDDER
be provided with a normal scale up to full-load value and a suppressed scale
beyond full-load for indication of motor starting current. C.Ts provided for
ammeter shall have accuracy Class of 1.0 KWH meters, 15-minute maximum
demand indicators shall be provided, where specified.
11. CABLE TERMINALS
The cable terminal arrangement for incoming 415 volt circuit-breaker from
400 KVA transformer secondary and for all outgoing feeders shall be suitable
for single-core and multi-core aluminium conductor PVC insulated cables
of number, type and sizes as specified. The termination arrangement of
multiple cables shall permit connection and disconnection of each individual
cable without disturbing the other cables. For termination of cables
suitable lugs of proper size shall be provided. Where armoured cables are
to be terminated suitable armour clamps shall be provided.
12. LOW VOLTAGE BUS-DUCTS
Bus-ducts with 3 phase and neutral busbars shall be able to withstand
the short-circuit currents as specified in item 1.04 above. It shall be
designed for a rated voltage of 1,000 volts.
The bus-duct , if specified, shall be of metal-enclosed, dust and vermin
proof type divided into factory made sections suitable for easy assembly at
site. It shall be complete with mounting arrangement and all necessary
accessories required to make the installation complete.
The bus-duct, if specified shall have suitable side covers where required for
easy access to all the busbars. Space shall be provided within the bus-duct
for taking secondary wiring as required, The bus-bar supports and their
terminal connections shall be designed to permit expansion and contraction
of the bar with a variation in the site ambient temperatures. Throat
Page 137 SEAL AND SIGN OF BIDDER
connection with links shall be provided at the transformer terminal for easy
removal of transformer, when necessary.
13. ALARM AND INDICATION
Each load-center substation shall be provided with static audible and visible
alarm indication with alarm accept and cancellation device. The system shall
have arrangement for repeat alarm facilities as well as testing the alarm
circuits. The scheme shall be designed to give the following indications:
When any circuit-breaker trips on fault only
Temperature rise of winding
Earth fault indication
Provision shall be made for transmitting signals if required to remotely
located signaling system to indicate tripping of incoming circuit-breaker on
fault and operation of earth fault relay provided in the transformer neutral
circuit. Provision shall also be made to transmit the alarm and tripping signals
to 11 kV switchboard from which the transformer is fed or to a remote
signaling panel.
14. REMOTE CONTROL SCHEME FOR BREAKERS
For electrically operated circuit-breakers in addition to ON-OFF control switch
provided on the front side of the panel, provision shall be made where
required for remote closing and tripping of circuit-breakers from an external
control desk with arrangement to prevent closing of the breaker by the
control switch mounted on the front of the circuit-breaker cubicle.
15. OTHER CONSTRUCTIONAL FEATURES
All operating handles, control switches, push-buttons, indicating lamps,
instruments, meters etc shall be mounted on the front of the cubicles.
Page 138 SEAL AND SIGN OF BIDDER
The auxiliary relays for temperature alarm and tripping shall be mounted on
the incoming breaker panels. Terminal boards shall be provided at the
transformer sections for all control circuit taken out from the transformers.
All wiring from these terminal boards to the switchgear sections shall be
provided with the equipment.
All wiring within the cubicles shall be with PVC insulated cables and
shall be effectively protected from possible damage by electrical flashover.
As far as possible each essential control circuit shall be contained in the
respective cubicle. All wiring shall be such that it is easily identifiable and
accessible for maintenance.
For equipment earthing a suitable copper earthing bus shall be provided for
the complete length of the switch board and bonded to all the units
including the transformer and high tension cubicles. Proper terminals
shall be provided for external earth connections to be fully in conformity
with IER.
A suitable universal type truck shall be provided with each load-center
substation for withdrawing the breakers from the board. The trucks shall
have platforms of adequate mechanical strength for bearing the weight of
the circuit-breaker units and shall be provided with necessary guide rails
and stops. The height of the platform shall be adjustable to suit the levels at
which the different circuit-breakers are mounted on the switchboard.
Identification labels shall be provided for each circuit-breaker and control
devices to be located in readily visible positions.
All steelwork of each load-center substation shall undergo rust removal
procedure before application of primer and shall be given epoxy paint
finish of Aircraft Grey colour as per ISS Shade 693 or any other colour of
approved shade.
Page 139 SEAL AND SIGN OF BIDDER
The busbars of each unit substation shall be painted as per following norms:
A Phase - Red
B Phase - Yellow
C Phase - Blue
Insulated neutral - White
Earthed neutral - Black
ABC are the three phases of AC circuit with anti-clockwise vector rotation.
16. FINAL DISTRIBUTIONS: MCB, RCCB, RCBO
Miniature Circuit shall comply with latest relevant IS / IEC standard codes
i.e. IS-8828-1996 & IEC – 60898. Manufacture shall submit the relevant IEC
and IS certificates to client for reference and records. ISI Marked.
MCBs shall be quick make and quick break type, suitable for 230 / 415V AC
50 Hz application with magnetic thermal release for over current and short
circuit protection.
The breaking capacity (Icn) shall not be less than 10 kA, which is to be
suitably marked on the product. MCB shall not have load line biasing and line
and load can be terminated on either side of MCBs.
MCBs shall be classified as B, C or D type (ref IS standard) as per their
tripping characteristic curves defined by the manufacturer. The MCB shall
have minimum power loss (Watts) per pole defined as per the IS / IEC
and the manufacturer shall furnish these values.
All MCBs used on UPS circuit shall be D-Curve only. MCBs for general
lighting shall be C Curve and for heating loads like heater / geysers / socket
outlet shall be B curve.
17. CONSTRUCTION
The housing shall be made from heat resistant thermoplastic material and
shall have high impact strength. All 2P, 3P and 4P miniature circuit
Page 140 SEAL AND SIGN OF BIDDER
breakers shall have a common trip bar independent to the external operating
handle to ensure opening of all the poles simultaneously on faults.
The MCB shall be current limiting type (Energy Limitation Class – 3) and
it shall be clearly marked on the product. This shall reduce the electro-
dynamic stresses on conductors and insulation during short circuit faults,
thereby ensuring maximum safety to electrical network.
The terminals shall be protected against direct contact conforming to
IP2X Degree of protection to provide total safety to operating personnel.
MCBs terminals shall have provision for DUAL TERMINATION for mounting
bus bar as well as cables on the same side of MCBs. This shall eliminate the
chances of loose wiring. All the MCBs shall be suitable for connection through
a standard insulated copper bus bar.
MCBs shall have Positive Contact Indication and shall be suitable for
Isolation Duty as specified in IS. The internal contacts ON-OFF status of MCB
shall be displayed on front through a mechanical flag for showing true position
of contacts.
MCBs shall be suitable to accommodate accessories like Aux Contact, trip
Alarm contact, and under-voltage & Shunt Trip unit as required in the circuit.
The MCBs shall have pad locking facility to lock it in ON or OFF position.
18. RESIDUAL CURRENT CIRCUIT BREAKERs
RCCB shall comply with latest to IS 12640 / IEC 61008 standards.
RCCB shall be current operated type and shall be independent of the
line voltage; current sensitivity shall be of 30 mA / 100mA / 300 mA at
240/415 volts AC as specified in BOQ.
Mechanical Operation
The moving contacts of the phases shall be mounted on a common
bridge, actuated by a rugged toggle mechanism. Hence, the closing
/opening of all the three phases and neutral shall occur simultaneously.
Page 141 SEAL AND SIGN OF BIDDER
This also shall ensure simultaneous opening of all the contacts under
tripping conditions.
Testing Provision
A test trip push button shall be provided on front face to check the
integrity of the earth leakage detection system and the tripping
mechanism healthiness.
Positive Contact Indication
Positive Contact Indication / True position of contacts inside RCCB shall
be displayed on front face through a mechanical flag showing RED color
for RCCBs contact ON and GREEN color for RCCB contacts OFF.
Fault Tripping Diagnosis
Mechanical flag indication shall be provided on front face of RCCB to
distinguish a Fault tripping from a manual switch OFF operation. Incase
RCCB has tripped on fault; a yellow color flag shall be displayed on front
to distinguish tripping from a manual switch OFF operation.
This shall facilitate maintenance person to identify the fault and take
corrective action at earliest.
Protection against Nuisance Tripping
All RCCBs used on UPS circuits shall be HIGH IMMUNITY type i.e.
they shall have an inbuilt filter to protect nuisance tripping due to high
level of harmonics due to presence of nonlinear loads like UPS, laptops,
computers, printers, photocopiers, HVAC drives etc.
TEST
All equipment shall be tested in accordance with the relevant clauses of
applicable standards. All internal wiring shall be checked for correct
operation before dispatch.
Page 142 SEAL AND SIGN OF BIDDER
C] M.V. CABLES AND CABLE TRAYS
1. SCOPE OF WORK :
This section covers the supply, installation storing, laying, fixing, jointing /
termination, testing and commissioning of Medium Voltage PVC insulated or
XLPE insulated PVC Sheathed armored aluminium/copper conductor cables
laid in built up trenches, directly buried underground, on cable trays, in
pipes, clamped directly to wall or structures etc. as called for in the
drawing. The contractor shall provide all materials, labour, equipments,
scaffoldings etc., as required for the completion of M.V. Cables, Cable Trays
etc., as called for.
2. STANDARDS APPLICABLE
The following standards and rules shall be applicable.
IS 1554-88 : PVC insulated (heavy duty) electric cables Part I for
working voltages upto and including 1100V.
IS 8130-84 : Conductors for insulated electric cables and flexible
cords.
IS 3961-67 : Recommended current ratings for cables: (Part 2): PVC
insulated a PVC sheathed heavy duty cables.
IS 5831-84 : PVC insulation and sheath of electric cables.
IS 7098-89 : Cross linked polyethylene insulated PVC sheathed
cables.
The individual cores shall have continuous numbering of
the core all along its length and also be provided with
identification ferrules at both ends. Individual control
cables shall have 20% spare cores.
FRLS cables shall be used for fire protection system
controls to prevent flame propagation, smoke reduction
and to avoid toxic gas emission in the event of a fire.
Page 143 SEAL AND SIGN OF BIDDER
FRLS compound shall be tested rigorously for oxygen
index as per ASTM D2863, acid gas generation to IEC
754-1, smoke density to ASTM D 2843 and flammability
to SS 424 1475 class F3, IEEE 383 and IEC 332-1.
Manufacturer’s name, ISI Mark, cable size and type shall
be clearly embossed at regular intervals on all cables.
3. TYPE AND QUALITY
Medium voltage cables shall be circular, multicore annealed copper or
aluminium conductor, PVC insulated, PVC sheathed and steel wire armoured
or steel tape armoured construction or unarmoured. The conductors of cable
shall be stranded. Sector shaped stranded conductors shall be used for cables
of 50 sq.mm size and above. The cables shall conform to IS: 1554 part-I in all
respects.
M.V power cables shall have 3, 3.5 or 4 cores, as required and shall have
conductors made from electrical purity aluminium conductors conforming to
IS: 8130 - 84.
Conductors shall be insulated with high quality PVC base compound.
Insulation and outer sheathing compounds shall conform to IS 5831 – 84.
A common covering shall be applied over the laid-up cores by an extruded
sheath of un-vulcanised rubber compound.
Armouring of galvanised round steel wires or galvanised flat steel strips shall
be provided over the inner sheath.
Outer sheath of PVC shall be extruded over the armouring. Cables shall be
manufactured and tested in accordance with IS 1554.
Unless otherwise specified, all control cables shall be multicore, 1100V grade
PVC insulated, armoured and overall PVC sheathed with stranded copper
conductors of 2.5 sq.mm, conforming to IS 1554. Cores shall be identified
by colour scheme of PVC insulation.
Page 144 SEAL AND SIGN OF BIDDER
4. RATING :
The cables shall be rated for a voltage of 650/1100 Volts.
Core Identifications: Cores shall be provided with the following colour scheme
of PVC insulation:
1. Single Core : Green yellow for earthing.
2. Two Cores : Red and Black, Blue & Black, Yellow & Black.
3. Three Cores : Red, Yellow & Blue
4. Four Core : Red, Yellow, Blue & Black
5. INSPECTION
All cables shall be tested inspected at manufacturer’s works. However upon
receipt at site cables shall be checked for physical damages during transit.
6. JOINTS IN CABLES
The contractor shall take care to see that all the cables received at site are
apportioned to various locations in such a manner as to ensure maximum
utilisation and avoidance of straight cable jointing. This apportioning shall
be got approved by the Construction Manager. Before the cables are cut to
lengths.
Where straight joints in cable are unavoidable, the use and location of such
straight joints shall be got approved by Construction Manager.
7. JOINTING BOXES FOR CABLES
Cable joint boxes shall be of appropriate size, suitable for PVC insulated
armoured cables of particular voltage rating.
8. JOINTING CABLES
All cable joints shall be made in suitable, approved cable joint boxes,
jointing of cables in the joint boxes and the filling in of compound
Page 145 SEAL AND SIGN OF BIDDER
shall be done in accordance with manufacturer's instructions and in an
approved manner. All straight joints shall be done in epoxy mould boxes
with epoxy resin only of makes/types as indicated in the list of approved
makes. All terminal leads of conductors shall be heavy soldered upto at
least 50mm length.
All cables shall be joined colour to colour and tested for continuity and
insulation resistance before jointing commences. The seals of cables shall
not be removed until preparations for jointing are completed. Joints shall be
finished on the same day as commenced and sufficient protection from the
weather shall be arranged. The conductors shall be efficiently
insulated with high voltage insulating tape and by using preaders of
approved size and pattern. The joints shall be completely filled with epoxy
compound and taped so as to ensure that the box is properly filled.
Epoxy compound shall be filled as follows:
Equal quantities of resin and hardener shall be mixed thoroughly by hand
until the mixture is free from white patches and has uniform colour. No
water, oil or any other liquid shall be added to the mixture to make it soft as
is will affect the properties of the compound. The mixture shall be used
within 30-40 minutes of mixing. The on which epoxy compound is to be
used, shall be free from dust, rust, oil, grease and shall be dry. The joint
neither be disturbed nor moved till the epoxy compound is completely
hardened. A smooth surface can be made by rubbing a damp cloth smoothly
on the compound before it sets. The joints shall be painted after they have
completely hardened.
Alternatively, ready mix of epoxy cable jointing compound may also be used.
In all cases manufacturer’s recommendations shall be strictly adhered to.
Page 146 SEAL AND SIGN OF BIDDER
9. CABLE MARKERS
All underground cables and cable joints shall be marked on the surface by
markers generally manufactured and tested to the requirements of relevant
Bureau of Indian Standards. Approved CI cable markers shall be provided
at every 30m along the route of the cables and at both ends of road
crossing, indicating cable joints and cables as applicable. Special CI
markers shall be provided at all buried cable joints indicating "Electrical
Cable Joints". CI plates duly engraved with the size of the cable and the
place it serves shall be tied to the cable at regular intervals of 5m for easy
identification of cables.
10. TERMINATION OF CABLES
Cable termination shall be done in terminal box or cable end box or
distribution boards, or apparatus/equipments. Terminations are to be made
with Mechanical and glands be tinned/nickel plated, anti-corrosive, three
piece improved pattern which is to grip inner and outer PVC sheaths as well
as the armour of the cable. The cable ends or the core conductor are to be
connected by solderless lugs or sockets using crimping tool of approved
make for all cables.
All terminations of cable conductors and base conductors shall be
mechanically and electrically sound and shall comply with the requirements
of IEE regulations.
The connectors or connecting sockets are to have such dimensions so as to
limit temperature rise.
When required the water tightness of the terminal boxes may be obtained by
filling with a compound preferably plastic flame-retarding and non-dripping
type within the normal range of temperatures.
When the cable is cut during the course of installation the open ends are to
be sealed immediately by means of self-adhesive non-hygroscopic tape over
Page 147 SEAL AND SIGN OF BIDDER
a wax water seal to make an air and watertight joint.
11. INSTALLATION OF CABLES
Cable shall be laid in a manner as indicated on the drawings. Generally
cables are laid in the following manner.
i. In the underground masonry trench.
ii. On the cable tray/or on cable ladders.
iii. Buried underground.
iv. Through pipe sleeves.
Various installation methods are discussed in the following paragraphs.
Cables shall be laid by skilled and experienced workmen using adequate
rollers to minimize stretching of the cable. The cable drums shall be placed
on jacks before unwinding the cable. The cable drums shall be rotated in
the direction as indicated by the manufacturer. Care shall be exercised in
laying cables to avoid forming kinks. The drums shall be unrolled and
cables run over wooden rollers, placed at intervals not exceeding two (2)
meters.
12. GENERAL
All cables shall be adequately protected against any risk of mechanical
damage to which they may be liable in normal conditions of service.
When cables pass through holes in metal work, precautions shall be
taken to prevent abrasion of the cables on any sharp edges.
In every vertical cable ladder, channel, duct, trunking or cable trench
containing cables and exceeding three meters in length, internal barriers
shall be provided so as to prevent the air at the top of the unit from
attaining an excessively high temperature. In every vertical cable shaft,
cable trench or any passage of cable through wall, ceiling, floor barriers
Page 148 SEAL AND SIGN OF BIDDER
against spread of fire and smoke shall be provided for compliance with
IEE regulations.
Where cable passes through walls, ceiling, floor, it shall run through sleeves
of PVC pipes or hume pipes of adequate diameter. After pulling the cable
through sleeves, both the ends of the sleeves shall be sealed water tight
with fire-resistant material to prevent spread of fire and seepage of water.
Generally along each cable route either in trench or in cable trays/ladders
or in pipe separate Two Nos. of earth strips/wires shall run exposed.
Where an installation comprises medium voltage cables as well as extra low
voltage circuits, precaution shall be taken in accordance with IEE
regulations and shall be physically separated by minimum of 300mm
distance.
Metal sheaths and armour of all cables, metal conduits, ducts, trunking,
and bare earth continuity conductors associated with such cables, which
might otherwise come into fortuitous contact with other fixed metal work
shall be effectively bonded there to earth so as to prevent appreciable
potential difference at such possible points of contact.
If it is necessary to install cables in a situation where flammable
and/or explosive dust, flammable volatile liquid/vapor/gas is likely to be
present or where explosive materials are handled or stored, the cabling
shall be as per IEE regulations.
13. UNDERGROUND INSTALLATIONS
The cables shall be laid in an excavated trench. The depth of the trench shall
be minimum 750mm. below the final ground level but shall be decided on the
number of cables to be laid in the trench so that the vertical distance between
two adjacent layers of cables shall not be less than 350mm. The width of the
trench shall be decided on the number of cables to be laid in the trench so that
Page 149 SEAL AND SIGN OF BIDDER
the distance between two adjacent cables shall not be less than one able
diameter.
Before laying cables the bottom of the trench shall be well compacted and the
cables shall be laid on a 100mm fine sand bedding. The second layer of
150mm of fine sand then be spread over the cable and shall be further
covered by 150mm of compacted soil. For the second layer of the cable same
procedure shall be repeated.
The cables shall be protected by placing precast concrete tiles or burnt
bricks over the cables on top layer of sand and for the full length of
underground cables. Where more than one cable is running in the same
trench, the concrete tiles/bricks shall cover all the cables and shall project
a minimum of 80mm on either side of the cables.
In any case the top layer of the cables shall be minimum 600mm below the
finished level of the ground.
The top of the cable trench shall be well compacted till the finished level of
the ground and shall be approved by the Construction Manager. If required
a laboratory compaction test shall be carried out in presence of the
Construction Manager.
H.V., M.V., cables shall not be laid in the same trench/cable tray and/or
alongside of water main.
Cables under road crossings and any surfaces subjected to heavy traffic shall
be protected by running them through hume pipes of suitable size.
The relative position of the cables laid in the same trench shall be preserved
and the cables shall not cross each other as far as possible. At all changes in
direction in horizontal and vertical planes, the cable shall be bent smooth
with a radius of bend not less than 15 times the diameter of the cable.
Minimum 3meters long loop shall be provided at both sides of every straight
joint and 5 meters at each end of the cable. Distinguishing marks shall be
made at the cable ends for identification.
Page 150 SEAL AND SIGN OF BIDDER
Insulation tapes of appropriate voltage and in red, yellow, and blue colors shall
be wrapped just below the sockets for phase identification.
All the excavation and back fill including timbering, shoring, and pumping
required for the installation of the cables shall be carried out as indicated on
the drawing and as per requirements laid down elsewhere or as per
Construction Manager’s direction. Trenches shall be dug true to line and
grades. Back fill for trenches shall be filled in layers not exceeding 150mm. At
each layer compaction test shall be carried out in presence of Construction
Manager. Each layer shall be properly rammed and consolidated before laying
the next layer. The contractor shall restore all surfaces, roadways, side
walls, curbs, walls, landscaping or other works cut for excavation to
their original condition, the satisfaction of the Construction Manager.
Suitable approved type cable markers shall be installed along the cable route
& where change of direction takes place.
14. CABLES INSTALLED INSIDE THE BUILDING
The cables inside the building shall be installed in one of the following
manner, as indicated in the drawing and approved by the Construction
Manager.
15. INSTALLED IN BUILT-UP TRENCH
The cables laid on the bottom of the structural trenches shall not lie
freely upon the trench bottom. They shall be raised to prevent the possibility
of their coming into contact with deleterious materials.
The cables laid in the trench shall be laid on angle iron brackets/cable
tray/cable ladder/cable troughs/cable racks as indicated on the drawings,
and as approved by the Construction Manager. Where cables are clamped to
the wall a minimum clearance of 100mm shall be maintained between wall
and cable and minimum 150mm vertical clearance shall be maintained
Page 151 SEAL AND SIGN OF BIDDER
between two cables. Where cables are laid on brackets the brackets shall
not be fixed more than 500mm apart to avoid sag in the cables, where the
cables are laid on cable tray/ladder/troughs/racks, minimum 300mm
distance shall be observed between adjacent tier of tray/ladder/
troughs/racks, and cable shall be fixed minimum 25mm away from the
wall, and minimum of one cable diameter distance shall be observed between
two adjacent cables. Cables shall be properly fixed with the
tray/ladder/troughs/racks with cable tie or saddles or straps.
16. CABLES ON CABLE TRAYS/LADDERS UNDER THE CEILING OR ON
WALL
Where cables are installed under/above suspended ceiling or below ceiling
or on wall, they shall be laid on a perforated G.I. cable tray/ladder type cable
tray and shall be run in such positions that they are not liable to be
damaged by contact with the floor or the ceiling or other fixtures.
The cable tray/ladder shall be properly fixed with tie rod to the ceiling. The
concrete inserts for fixing the tie of shall be put in place while casting the slab.
If insert plates are not placed in position, Anchor fasteners shall be fastened to
support cable trays. The cable tray route shall be coordinated with other
services to avoid crisscross of all the services.
While laying the cables on the tray minimum one cable diameter distance shall
be observed between two adjacent cables. 25% space shall be kept spare for
any future installation.
The trays shall be made of 16 SWG/12 SWG G.I. perforated sheet having
minimum 50mm depth. The width of perforation shall be maximum 10mm
spaced at maximum 20mm distance. The width of the cable tray shall be
selected so as to accommodate required number of cables to be laid on it, with
minimum separation of minimum one cable diameter between two adjacent
Page 152 SEAL AND SIGN OF BIDDER
cables. The cables shall be tied with the cable tray with nylon strip.
17. CABLES INSTALLED IN THE MECHANICAL ROOM
The cable reaching the motors in the mechanical room or plant room or
machines room or service area shall be laid on cable tray except where
indicated in masonry underground trenches.
The cable reaching the motors shall be protected by rigid galvanized conduits
up to a height of 300mm above the floor.
Above that height, the cable shall be protected by means of oil tight flexible
metallic G.I. conduits to the terminal box of the motor. The connection
between the rigid conduit and the flexible conduit shall be done by a rewett
coupling of an approved type.
The flexible conduit shall be properly fixed with the terminal box of the motor
by means of double hexagonal check nut.
18. CABLE TRAY/LADDER TRAY
GI Cable tray shall be manufactured to comply with the specifications of
National Electrical Code (NEC) and National Electrical Manufacturer's
Association (NEMA).
Cable trays shall be of steel as per IS 226 and galvanised and the
thickness of galvanisation shall be not less than 110 microns. All bolts nuts
and washers shall also be galvanised and shall conform to IS 1363- 60 for
quality, threading and dimensions before galvanising. Hot dip galvanising
shall conform to IS 2633 Galvanising of each member shall be carried out in
one complete immersion. The galvanising shall be uniform, clear, smooth,
continuous and free from acid spots. Quality of zinc used for galvanising shall
be of 98.8% purity.
Page 153 SEAL AND SIGN OF BIDDER
Cable trays shall generally be of the following type:
Perforated cable trays shall be generally of channel type and the perforations
in the trays shall be either 8 x 15mm or 10 x 20mm oval holes. Control cables,
extra low voltage cables and instrument cables shall be laid on perforated
cable trays.
Ladder type cable trays shall be made out of 50x50x 6mm slotted M.S. angles
for the rungs and channels for the side rails. Pitch of the rungs shall be not
more than 250mm center to center. Rungs shall be welded to the side rails.
Cable trays shall be of standard sizes:
Length 2500mm
Width 300/450/600/800/1000mm as required.
Flange of perforated tray 75/100mm
Height of side rail (ladder type) 75mm
Thickness of sheet steel - 2.0mm to 3.0mm as per width of tray.
The flange and width of the cable trays shall be decided based on the diameter
and the number of cables running through each section of the cable tray.
19. Accessories for Cable Trays
Following accessories of cable trays, as required, shall be supplied with the
cable trays.
Coupler plates
90 deg bends - Horizontal and Vertical.
Tees - Horizontal and Verticals.
i. for power cables of medium
Voltage and high voltage
Ladder type with slotted angles.
ii. for control cables and Low
voltage cables
Perforated sheet extra steel slotted
angle type.
Page 154 SEAL AND SIGN OF BIDDER
Reducers
4-way cross
Tray covers
Fasteners.
Accessories also shall be hot dip galvanised, thickness of galvanising being
not less than 110 microns.
20. TESTING
Prior to laying cables, and prior to energizing the cables, following tests
shall be carried out :-
Insulation Resistance test between phases and phase to neutral and phase to
earth.
Continuity test of all the phases, neutral and earth continuity conductor.
Sheathing continuity tests.
Earth resistance test of all the phases and neutrals
All tests shall be carried out in accordance with relevant Indian Standard
Code of practice and Indian Electricity Rules. The Contractor shall provide
necessary instruments, equipments and labour for conducting the above
test and shall bear all expenses in connection with such tests. All tests shall
be carried out in the presence of the Construction Manager and results
shall be recorded in the prescribed forms.
21. STORING
All the cables shall be supplied in drums. On receipt of cables at site, the
cables shall be inspected and stored in drums with flanges of the cable
drum in vertical position. The end of the cable shall be sealed for water
tightness.
Page 155 SEAL AND SIGN OF BIDDER
D. TECHNICAL SPECIFICATION FOR L.T PANEL BOARDS
PART A: GENERAL
The work described herein shall in all respects be carried out in accordance
with the current Engineering Practices, and / or in compliance with this
Specification Document, in the most economical manner, and to the
satisfaction of Client.
All the instructions and obligations as prescribed in this document shall be
strictly adhered to, and shall be observed as a matter of procedure.
1. SCOPE
This specification covers the Technical Requirements for Equipment, Materials
and Installation Methods, associated with Design, Manufacture, Testing at
works, Supply and subsequent Erection and Testing associated with the
electrical work at site.
The contractor shall be responsible for the supply of materials as defined in
the Bill of Quantity and Unit Rates, as well as assistance during Testing and
Commissioning at site for all the Equipment described in Bill of quantity.
The work of the Contractor shall include, but not necessarily be limited to the
following activities; so as to ensure that the entire installation is not only in
accordance with the designs and drawings, but also complies with the
statutory requirements; including reliability and safety aspects.
The activities of the Contractor to name a few, shall cover the following:
Detail engineering of panel boards as specified.
Manufacturing of panel boards.
Testing of equipments at manufacturer’s works.
Loading of all the equipments at manufacturer’s work.
Supply of materials at site as per the Bill given including all taxes / packing /
forwarding / insurance etc.
Unloading all the equipments at site and shifting to basement floor of electrical
room of the substation.
Providing assistance during testing and commissioning at site.
Page 156 SEAL AND SIGN OF BIDDER
Handing over, after demonstrating the satisfactory performance and/or
operation of the Equipment, including such interfaces / interactions which the
equipment will have, with respect to others.
A Set of ‘As-built’ drawings (hard copy as well as soft copy), Instruction and
O&M Manual.
2. STANDARDS
The equipment and accessories covered by this specification shall be designed,
manufactured and tested in compliance with the latest relevant standards
published by the Indian Standards Institute wherever available in order that
specific aspects under Indian conditions are taken care of.
The equipment shall also conform to the latest Indian Electricity rules as
regards safety, earthing and other essential provisions specified therein for
installation and operation of electrical plants and shall conform to the
requirements and approval of:
i) Fire Insurance Association.
ii) Indian Electricity Rules and Relevant Indian Standard Codes.
iii) Electrical Inspectors.
iv) SEB
v) Client Engineers
The design, identification, manufacturing and testing of equipment shall
comply with the latest edition of the relevant standards and codes of practice,
some of which are given below:
IS : 4237 General requirements for switchgear and control gear for
voltages not exceeding 1000 V.
IS : 375 Switchgear busbars, main connection and auxiliary wiring,
marking and arrangement.
Page 157 SEAL AND SIGN OF BIDDER
IS : 2147 Degree of protection provided by enclosures for low voltage
switchgear and control gear.
IS : 8197 Terminal marking for electrical measuring instrument and their
accessories.
IS : 2551 Danger notice plates
IS : 2516 Specifications for A.C. circuit breaker
IS : 9921 Specifications for A.C. isolator and earthing switch
IS : 10118 Code of Practice for installation and maintenance of switchgear.
IS : 8623 Specification for factory built assemblies of switchgear and
control gear for voltage upto and including 1000 V A.C. and
1200 V D.C.
IS : 8828 Miniature circuit breakers.
IS : 2516 Air circuit breaker
IS : 4064 Fuse switch and switch fuse unit.
IS : 9224 HRC fuse links
IS : 2705 Current transformer
IS : 3155 Voltage transformer
IS : 3231 Electrical relay for protection
IS : 1248 Indicating instrument
IS : 722 Integrating instrument
IS : 6875 Control switches and push buttons
IS : 2959 Auxiliary contactor
IS : 1822 A.C. motor starters of voltage not exceeding 1000 V
Page 158 SEAL AND SIGN OF BIDDER
Indian Electricity Act and Rules (as amended up to date) and approval of FIA
of India.
The Panels also require approval of the client at various stage of their
manufacture such as design, selection, construction, testing, shipping etc.
3. DRAWINGS, TEST CERTIFICATES, ETC.
All drawings, test certificates, instructions etc. shall be in English language
and all dimensions and weights shall be in metric units.
With Tender:
The tenderer shall submit general arrangement drawings with cross-sections
as required, showing overall dimensions of the equipment together with the
approximate weights of each unit.
Manufacturers’ Drawings:
The contractor shall submit for approval all layout, general arrangement and
sectional drawings as required, before commencing manufacture of equipment.
These drawings shall be submitted in triplicate of which one (1) set shall be
returned to the Contractor with the Purchaser’s or his Client’s approval and/or
comments within five working days.
After obtaining approval of the above drawings, the contractor shall supply five
(5) sets of all the certified drawings including the following:
a) Single Line Diagram
b) Dimensioned drawings showing front, rear and sectional views and
indicating positions of all accessories and fittings.
c) General arrangement drawings showing methods of assembly and dis-
assembly of each equipment.
Page 159 SEAL AND SIGN OF BIDDER
d) Details of operating mechanisms, mounting arrangement etc of the
equipment specified.
e) Schematic circuit diagram / wiring diagram / terminal block details.
f) Control logic scheme
g) Complete drawings of separately mounted equipment, if any.
h) Bill of materials with manufacturer catalogue / product number, rating,
type etc.
All the above drawings shall be supplied in accordance with a Bill to be
approved by the Purchaser / Client.
Drawings, Instructions and Test Certificates with Equipment.
The contractor shall supply five (5) copies each of the following with the
delivery of the equipment:
a) Sets of instructions for proper erection and assembly of all equipment.
b) Sets of instructions for operation and maintenance of the equipment and
controls.
c) Sets of list of spare parts with manufacturer’s catalogue wherever
available.
‘AS-BUILT’ Drawings: During the progress of work the contractor should
prepare As-Built drawings showing deviation/alteration from construction
drawings and on completion of the work, the contractor shall supply five (5)
sets of prints of all such electrical drawings properly laminated as well as one
CD.
Page 160 SEAL AND SIGN OF BIDDER
4. INFORMATION TO BE FURNISHED BY THE TENDERER:
The tenderer shall furnish all such essential technical information as are
required for proper assessment of the equipment offered including filled up
data sheets as asked for in the tender. The successful tenderer will have to
furnish complete technical data of the equipment covered under the equipment
specification.
- Panel manufacturer shall be an authorized OEM or approved manufacturer
of the approved and finally selected switchgear & control gear
manufacturer.
- Manufacturer should have in house sufficient manufacturing facility of
electrical panel boards as well as adequate qualified and experience
personnel as required.
- Manufacturer must have executed nos. of similar type and magnitude of
works.
Manufacturer has to submit all relevant details / documents / papers for all
above requirements. If any bidder fails to comply with the above requirement
or not furnishing the details will be liable to reject.
PART-B: TECHNICAL
1. GENERAL
This specification covers the manufacture, testing, supply, providing
assistance during testing and commissioning at site of all the equipments
supplied as indicated in the scope, specification, bill of quantity, drawings and
standards.
2. DESIGN BASIS
2.1 All equipment shall be designed for operating in tropical humid climate at
the required capacity in an ambient air temperature of 45C maximum and
Page 161 SEAL AND SIGN OF BIDDER
40C average over 24 hours. The derating of all equipment shall be done for an
ambient temperature of 40C maximum. Relative humidity of 95% shall also
be taken into consideration for design of equipment.
2.2 All equipment shall be complete with approved safety devices wherever a
potential hazard to personnel exists and with provision for safe access of
personnel to and around equipment for operational and maintenance
functions. The design shall include all reasonable precautions and provisions
for the safety of operating and maintenance personnel.
2.3 The control circuit voltage adopted shall be 230V AC for contactors,
auxiliary relays, instruments, indicating lamps etc.
2.4 If any equipment / component is required to operate at a voltage other
than those specified above, the necessary transformers and / or converter
equipment shall be included in the scope of supply of the contractor.
2.5. Special care shall be taken to make the enclosed equipment proof against
entry of rats, lizards and other creeping reptiles that may create short circuit
inside the live equipment.
3. SPECIFICATION FOR 415V PANEL BOARD
i. GENERAL
Medium voltage panel board shall be metal enclosed welded construction free
standing compartmentalised dust and vermin proof modular type suitable for
indoor installation. The panel board shall be single front comprising of fixed
compartments but air circuit breakers shall be fully drawout type. The panel
shall be extensible at both ends. The degree of protection shall be IP 51 as per
IS: 2147 preferably with neoprene gasket.
The electrical panel shall be placed on suitable ISMB having minimum height
on 100MM. The frame shall be fabricated from 14 SWG CRCA sheet steel. The
doors / covers and Partitions shall be of 16 SWG and gland plate shall be
Page 162 SEAL AND SIGN OF BIDDER
minimum 10 SWG only. CRCA sheets used for fabrication shall be cleaned, de-
rusted, de-phosphated, de-greased by seven tank process before fabrication.
Joints of any kind in sheet metal shall be seam welded and all welding slag
ground off and welding pits wiped smooth with plumber metal.
All openings, covers and doors shall be provided with neoprene gaskets around
the perimeters.
A base channel of 100mm height shall be provided at the bottom throughout
the length of the panel board.
The panel shall be accessible both from front and rear side by hinged doors.
No operating switches shall be provided above 1800mm or below 300mm from
the bottom of the panel board. Total Height of panel board shall not exceed
2100mm.
Nameplate for panel board, feeders, bus sections etc. shall be provided.
Nameplate or polyester adhesive stickers shall be provided for lamps, push
buttons, switches, relays etc. mounted on the switchboard. Special danger
warning plates shall be provided on removable covers or doors of cable alley
and bus bar chamber. Engraved nameplate shall be of anodised aluminium.
The panel shall be painted with powder coating. The paint shade of internal as
well as external surface shall be shade 631 of IS: 5.
All the Paints & Adhesives used for the equipments and during execution work
at site should have Low VOC content as recommended by LEEDs.
The panel shall be provided with door operated cubicle illumination lamp and
thermostat controlled space heater with switch.
A common hooter shall be provided for indication of trip faults operated by
230V AC. Push buttons shall be provided for acceptance and reset purpose.
Hooters shall conform to IS: 2268.
Suitable lifting hooks for each shipment section shall be provided for handling.
Page 163 SEAL AND SIGN OF BIDDER
Each circuit breaker unit shall be housed in separate compartments and shall
be enclosed on all sides. Sheet steel hinged lockable door shall be duly
interlocked with the breaker in `ON’ and `OFF’ position.
All instruments and indicating lamp shall be mounted on the compartment
door. Sheet steel barriers shall be provided between the tiers in a vertical
section.
Separate adequate compartment shall be provided for accommodating
protection relays, instruments, indicating lamps, control contactors / relays
and control fuses etc. These components shall be accessible for testing and
maintenance without any danger of accidental contact with live parts of the
switchgear / control-gear, busbar and connections.
ii. BUS BAR
The bus bar shall be made of Electrolatic grade Aluminum /Copper as
specified in Single Line Diagram. The main horizontal bus bars shall be
housed in the top chamber of each cubicle running throughout length of the
board unless otherwise specified. Each cubicle section shall be provided with
vertical bus bars serving feeder modules and of adequate rating of each
section.
For Aluminum busbar, Main bus bars shall be three phases and neutral
(100% of Phase). The size of the bus bars shall be so selected that the current
density in each phase shall not exceed 0.8 amp per sq. mm. It shall be ensured
that temperature rise of bus bar shall not exceed 85C in normal condition and
200C under short circuit.
The insulators shall be SMC/DMC. The structural supports shall be able to
withstand mechanical stresses developed during short circuit condition of 50
kA current. Calculations of temperature rise and stress under short circuit
shall be furnished. In the calculation, upgrading by black painting or PVC
Page 164 SEAL AND SIGN OF BIDDER
sleeves should not be taken into account. The calculations shall be furnished
by the contractor for approval of Engineer-in-Charge.
The clearance of bus bars between phases and between phase and earth shall
be maintained as per IS. The bus bars shall be sleeved by heat shrinkable PVC
sleeve excluding joints. Colour of PVC sleeves for phase bus bars shall be red,
yellow and blue and that of neutral shall be black.
All busbar connections shall be done by drilling holes in busbars and
connecting by chromium plated or tinned plated brass bolts and nuts.
Additional cross-section of busbar shall be provided in all Panels to cover up
the holes drilled in the busbar. Spring and flat washers shall be used for
tightening the bolts.
All connections between busbars and circuit breakers / switches and cable
terminals shall be through copper strips of proper size to carry full rated
current. These strips shall be insulated with insulating tapes.
Panel to panel entry of bus bar shall be effectively sealed by electrical and
thermal insulation barriers so that products of flashover do not travel
from one part of the panel to another part creating multiple faults.
iii. WIRING
All control and auxiliary wiring shall be done by using 650/1100V grade PVC
insulated stranded 1.5 sq. mm. copper conductor FRLS wires excluding CT
circuits. CT circuits shall be made using minimum 2.5 sq. mm. copper wire.
CT circuits shall be shorted using links if not in use.
All wires shall be bunched and clamped to the body to good engineering
practice and in a presentable manner. Wires shall run through flexible PVC
conduit / trunking, wherever run through intersection of panel sections. All
wires shall be properly marked by PVC ferrule at both ends as per wiring
diagram and properly terminated in the terminal blocks.
Page 165 SEAL AND SIGN OF BIDDER
Both power and control wiring shall be brought out in cable alley for easy of
external connections and maintenance.
iv. TERMINAL BLOCK
Terminal blocks for control and auxiliary wiring shall be clip on type suitable
to accommodate 6 sq. mm. Cable and for higher rating shall be stud type
only. Terminals for power and control shall preferable be separated from each
other by suitable barriers. Each terminal block shall have identification
number marked in accordance with wiring diagram / terminal details. At least
20% spare terminals shall be left in each terminal block for client’s use.
Terminals for power and control shall preferable be separated from each other
by suitable barriers.
v. AIR CIRCUIT BREAKERS (ACB)
CONSTRUCTION:
The ACBs shall have following features:
- 230V A.C closing and shunt trip coil
- Electrically Draw-out type with "service", "test", "isolated" and
"maintenance" position (for Electro-mechanical interlocking).
- Safety shutter of Fiber glass / polycarbonate sheet of 2mm thickness
shall be provided
- Mechanically trip free plus anti-pumping feature is to be provided.
- Electrical trip free plus anti pumping shall be provided with relay ONLY
and not by contactors.
- Electrical/Mechanical operation counter shall be provided.
- Door interlock with defeat features to be provided.
- Interlocking shall be provided to prevent operation of ACB unless it is
locked in isolation / test / service position.
Page 166 SEAL AND SIGN OF BIDDER
- Circuit breaker shall be provided with mechanical ON-OFF indicator and
number of operation indicator clearly visible from outside.
- The operating mechanism shall be motor wound spring charged. The
spring charging motor shall be universal type suitable for 230V AC. The
closing spring shall be automatically charged after closing of breaker for
next cycle of operation as well as the tripping spring will be fully
charged. A mechanical indication for ‘Spring charged / discharged’ shall
be provided which shall be visible from outside.
- The operating sequence of circuit breaker shall be O – 0.3 sec – CO – 3
min – CO.
- Manual emergency trip push button and manual spring charging
mechanism shall be provided.
- Circuit breakers shall be provided with 4 NO+ 4 NC auxiliary contacts
exclusively for client’s use.
- The circuit breaker rating shall be as per SLD and it shall comply with
the technical parameters specified elsewhere.
- The electrical contacts of the circuit breaker shall be of high conducting
non-deteriorating silver alloy contacts.
- Air Circuit Breakers shall fully confirm to IEC60947-2 / IS 13947-2
standard
- The circuit breakers shall be for continuous rating without line-load
restriction at 55 deg.C and Short Circuit Breaking Capacity (Ics) shall be
as specified on the single line diagram and shall be equal to the Short
Circuit Withstand (Icw/1sec) values. (Ics) value upto 2500A rating shall
be 50kA where as for 3200A & above rating it shall be 80kA. Circuit
breaker shall be designed to ‘close’ and ‘trip’ without opening the circuit
breaker compartment door. The operating handle and the mechanical
Page 167 SEAL AND SIGN OF BIDDER
trip push button shall be at the front of the breakers panel and integral
with the breaker.
- Racking handle should be integral part of ACB and should have
padlocking facility to prevent un-authorised racking in / out.
vi. CRADLE
The cradle shall be so designed and constructed as to permit smooth
withdrawal and inspection of the breaker into it. The movements shall be free
from jerks, easy to operate and shall be steel balls/rollers and not on flat
surfaces.
There shall be 4 distinct and separate position with positive lock at each
position of the circuit breaker on the cradle i.e Service Position, Test Position,
Isolated Position, Maintenance.
There shall be provision for locking the breaker in any or all of the first three
positions.
As an option, it should be possible to rotate the orientation of rear connections
from standard horizontal connections to vertical connection for better heat
dissipation.
vii. PROTECTIONS
The Thermal Magnetic based release unit shall be provided on circuit
breaker.
viii. MOULDED CASE CIRCUIT BREAKER :
The moulded case circuit breaker (MCCB) shall be air break type and having
quick make – quick break with trip free operating mechanism.
Housing of the MCCB shall be of heat resistant and flame retardant insulating
material.
Operating (Rotary) handle of the MCCB shall be in front and clearly
indicate ON/OFF/TRIP positions.
Page 168 SEAL AND SIGN OF BIDDER
The electrical contacts of the circuit breaker shall be of high conducting non-
deteriorating silver alloy contacts.
The MCCB shall be provided with thermal / magnetic type bi-metal
overload release with overload setting (on front fascia) from 80% to 100%
and electromagnetic short circuit protection device with adjustable time
delay. All the releases shall operate on common trip busbar so that in case of
operation of any one of the releases in any of the three phases, it will cut off all
the three phases and thereby single phasing of the system is avoided.
The MCCB wherever called for in the appended drawings shall provide an
earth fault protection with C.Ts of the same manufacturer and factory
calibrated.
The MCCB shall provide 4 N0 + 4 NC auxiliary contacts (Auxiliary contactor)
with connections for additional controls at future date.
The electrical parameters of the MCCB shall be as per the description given in
the appended drawings.
The MCCB shall be provided with 230 V A.C motor for closing and
tripping / switching off for the feeders if indicated in single line diagram.
ix. SWITCH FUSE DISCONNECTOR UNIT :
The SDF should have been tested for Type II coordination along with fuse and
contactor /Overload relay combination. There should be a published chart of
type-II selection by the manufacturer.
The terminal of SDF should be suitable for termination of Aluminium busbars
and lugs.
The terminal size for SDFs rated upto 63A should be 15mm, upto 125A it
should be 20mm, upto 315A it should be 30mm and for 400A SDF terminal
size should be 40mm. For ratings more than 400A terminal size should be
55mm.
Page 169 SEAL AND SIGN OF BIDDER
The SDF should have Positive OFF indicator. This indicator should be directly
coupled to the position of the moving contacts.
The SDF should come in IP20 execution i.e Fuse cover, Terminal Cover and
Neutral Cover should come with SDF as standard.
There should be a provision of interlocking the fuse cover on the SDF such
that user should not be able to remove fuse cover when SDF is in ON position.
This interlocking facility should be supplied with SDF as standard.
The SDFs should be supplied with 5 nos phase barriers upto current rating
160A and 4 Phase barriers upto current rating 800A as standard. This is to
ensure that phase barriers not only prevent phase to phase short circuit but
also prevent access to live parts from two sides of the
x. SDF
The SDF should have self-cleaning moving roller contacts to ensure high
switching life.
The SDF should be suitable for mounting at 900 in the vertical plane.
There should be provision in the SDF for installing fuse monitoring system.
This should be a standard feature of the product.
xi. FUSE
Fuses shall be of high rupturing capacity (HRC) fuse links and shall be in
accordance with IS : 2000-1962 and having high rupturing capacity at 415 V.
HRC fuses shall be of the make as specified in Make of Material and are of the
rating as indicated in Single Line Diagram ( S.L.D).
xii. CONTACTORS:
The contactors shall meet with the requirements of IS : 13947 and BS : 775.
Page 170 SEAL AND SIGN OF BIDDER
The contactors shall have minimum making and breaking capacity in
accordance with utilization category AC3 and shall be suitable for minimum
Class II intermittent duty.
If the contactor forms part of a distribution board then a separate enclosure is
not required, but the installation of the contactor shall be such that it is not
possible to make an accidental contact with live parts.
xiii. METERS
Digital multi-function meter, digital ammeter/voltmeter, KWh meter, Load
manager etc. as indicated in S.L.D shall be square in shape of 96 x 96 mm.
Multi-function and load manager shall indicate minimum electrical parameters
viz. Amp. Volts, KW, KVA, KVAR, P.F, Hz. etc. and having communication port
for PC compatibility
xiv. CURRENT TRANSFORMER
Current transformer shall be in accordance with IS: 2705 - 1992 as amended
upto date. C.T’s shall be cast resin, primary wound only.
Where ammeters are called for C.T.s shall be provided for current measuring.
Each phase shall be provided with separate current transformer of accuracy
Class I and suitable VA burden for operation of associated metering and
controls. C.T for protection shall be of Class 5P10. C.T ratio and burdens shall
be as indicated in S.L.D
xv. PUSH BUTTONS
The push button unit shall comprise of the spring return type contact element,
a fixing holder, and a shrouded actuator. The push button shall be momentary
contact type. The contacts shall be of silver alloy and rated at 10 Amps.
continuous current rating. The actuator shall of standard type and colour as
per its usage for ON, OFF and TRIP. Push buttons shall be provided with 2 NO
+ 2 NC contacts
Page 171 SEAL AND SIGN OF BIDDER
xvi. INDICATING LAMPS
Indicating lamps assembly shall be 22.5 mm diameter, screw type with built in
resistor having non fading colour lens. LED type lamps are required. Colour
shade for the indicating lamps shall be as below :
ON indicating lamp : Red
OFF indicating lamp : Green
TRIP indicating lamp : Amber
PHASE indicating lamp : Red, Yellow, Blue
TRIP circuit healthy lamp : Milky
xvii. SELECTOR SWITCH
Selector switches shall be 3 way and OFF (4 position). The contacts shall be air
break wiping contacts of 16A/440V AC rating. Knob type handles shall be
provided. The selector switches shall be flush mounted on panel board.
xviii. EARTHING
One 32 x 6 mm GI earth bus shall run throughout the length of the panel
board. Two earthing terminal bolts on outside faces of panel board sides at the
bottom shall be provided for external connection. All non-current carrying
metallic parts shall be connected to the earth bus.
xix. DRAWINGS AND DOCUMENTS
Following drawings shall be furnished by the contractor for approval of
Engineer-in-Charge.
i. Data sheet as per format enclosed in the tender document
ii. General Arrangement drawing showing plan with gland plate details,
elevation and side view sections
iii. Sectional elevation showing bus bar arrangements
Page 172 SEAL AND SIGN OF BIDDER
iv. Incoming bus duct joint flange and bus bar details
v. Single Line Diagram of LT panel board
vi. Control Scheme Diagram
vii. Wiring Diagram
viii. Terminal Block details
ix. Bus bar sizing calculation
xx. TESTING AND INSPECTION
The panel board and ACB shall be of type tested design. Type test certificates
of similar panel board and ACB shall be furnished. In the absence of type
tested design, the contractor has to type test the panel at his own cost and
type test certificates shall be furnished. All routine tests as per IS shall be
conducted on the completely assembled panel board. Routine tests shall be
witnessed by client’s representative. Witnessing inspection may be waived at
client’s discretion. However, witnessing the routine tests will not absolve the
contractor of his responsibilities and contractual obligations. Routine test
certificates of panel board, ACB, MCCB, SFU, CT, relays, meters shall be
furnished by the contractor.
4. SPECIFICATION FOR L.T. CAPACITOR BANK
The system shall be an Automatic Power Correction system, ready for
connection automatic compensation of reactive power in three phase supply
systems for NORMAL LOAD CHANGES. The Stages in the systems should
be switched ON and OFF using Electro Mechanical Contractors, to
respond to the dynamically Varying loads.
The response time of the systems shall be between 1 seconds.
Page 173 SEAL AND SIGN OF BIDDER
The System Power Output, Total Steps for Regulation, Individual Step power
available and physical steps KVAR ratings shall be as per the drawings
provided with this document.
The main components used in the systems include - The Controller, The
Electronic Contactors, The Capacitors, Fuse Links. The same has to be
provided with the manufacturers test certificate.
THE CONTROLLER SPECIFICATIONS
The controller should be able to provide following things.
RMS Voltage & Current Measure
Response Time - 10milli seconds to 20 millin seconds
4 Qudrant Operation
Dual Power Factor Set Points ( One Set point for DG and One Set point
for Electricity Board)
12 output (transistor outputs) contacts for capacitor switching through
electronic contactors.
Operating Frequency - 50 Hz or 60 Hz +/- 1% (Self Configurable)
No Voltage release protection, Inbuilt.
Automatic Setup Function
Dual Display.
MODBUS-RTU/ ASCII communication protocols.
Protection against Capacitor Overload & Panel Overheating.
Inbuilt Event logging facility, when harmonic limits exceeded.
Protection against Capacitor Overload & Panel Overheating.
Inbuilt Event logging facility, when harmonic limits exceeded
Page 174 SEAL AND SIGN OF BIDDER
Adjustable Tripping Sensitivity & Integral Switching Time.
Adjustable Reconnection Time Delay.
Should be capable of measuring the average weekly power factor,
Capacitor Overload, Electrical Panel Temperature, Voltage & Current
Harmonic Content.
Power Factor Adjustment to be possible from 0.80 Inductive To -0.8
Capacitive.
The Outputs provided by the Controller shall be Opto Isolated Bi-
Directional (Opto-MOSFET).
Material shall be Self Extingusihing Thermoplastic & Mounting shall be
Flush Mount (144mm * 144mm).
Approved Makes: Belek, Power Matrix, Epcos.
CAPACITORS SPECIFICATIONS
Capacitors shall be rated at 440 volts for continuous operation. Capacitors
shall be be completely DRY Type, and shall be provided in variants from 5
KVAR to 150 KVAR single bank. The capacitors should be rated to with stand
upto 20% Over Voltage continuously. The Over Voltage Capacity of the
capacitors should be 1.2 * Vn for 24 hours. The Over Current Capacity of the
capacitors shall be 1.5*in for 24 hours. Capacitors case shall be made of
Duroplastic Polyurethane. Capacitor Dielectric shall be MPP. Capacitor
Impregnant shall be Epoxy Resin based and Dry Type.
Capacitor shall have following three levels of inbuilt safety features.
Self-Healing
Over Pressure Disconnector
One electric fuse per phase
Page 175 SEAL AND SIGN OF BIDDER
Capacitor shall be class 2 insulated. The losses should be < 0.3 W/KVAR
inclusive of the discharge resistors. Tolerance on the capacitance shall not be
more than ± 5%.
5. SPECIFICATION FOR AUTO TRANSFER SWITCH (ASCO MAKE)
PART 1: GENERAL
i. Scope
Furnish and install automatic transfer switches (ATS) with number of poles,
amperage, voltage, and withstand current ratings as shown on the plans.
Each automatic transfer shall consist of an inherently double throw power
transfer switch unit and a microprocessor controller, interconnected to provide
complete automatic operation. All transfer switches and control panels shall be
the product of the same manufacturer.
ii. Acceptable Manufacturers
Automatic transfer switches shall be ASCO Series 7000 in the Main Panels &
Series 300 for the Metering Panels. Any alternate shall be submitted to the
consulting engineer in writing at least 10 days prior to bid. Each alternate bid
must list any deviations from this specification.
iii. Codes and Standards
The automatic transfer switches and accessories shall conform to the
requirements of:
A. UL 1008 - Standard for Automatic Transfer Switches
B. NFPA 70 - National Electrical Code
C. NFPA 110 - Emergency and Standby Power Systems
D. IEEE Standard 446 - IEEE Recommended Practice for Emergency and
Standby Power Systems for Commercial and Industrial Applications
Page 176 SEAL AND SIGN OF BIDDER
NEMA Standard ICS10-1993 (formerly ICS2-447) - AC Automatic Transfer
Switches
NEC Articles 700, 701, 702
International Standards Organization ISO 9001: 2000
PART 2: PRODUCTS
i. Mechanically Held Transfer Switch
A. The transfer switch unit shall be electrically operated and mechanically
held. The electrical operator shall be a single-solenoid mechanism,
momentarily energized. Main operators which include overcurrent
disconnect devices will not be accepted. The switch shall be mechanically
interlocked to ensure only one of two possible positions, normal or
emergency.
B. The switch shall be positively locked and unaffected by momentary outages
so that contact pressure is maintained at a constant value and temperature
rise at the contacts is minimized for maximum reliability and operating life.
C. All main contacts shall be silver composition. Switches rated 600 amperes
and above shall have segmented, blow-on construction for high withstand
current capability and be protected by separate arcing contacts.
D. Inspection of all contacts shall be possible from the front of the switch
without disassembly of operating linkages and without disconnection of
power conductors. A manual operating handle shall be provided for
maintenance purposes. The handle shall permit the operator to manually
stop the contacts at any point throughout their entire travel to inspect and
service the contacts when required.
E. Designs utilizing components of molded-case circuit breakers, contactors,
or parts thereof which are not intended for continuous duty, repetitive
switching or transfer between two active power sources are not acceptable.
Page 177 SEAL AND SIGN OF BIDDER
F. Where neutral conductors must be switched, the ATS shall be provided with
fully-rated neutral transfer contacts.
G. Where neutral conductors are to be solidly connected, a neutral terminal
plate with fully-rated AL-CU pressure connectors shall be provided.
ii. Microprocessor Controller with Membrane Interface Panel
A. The controller shall direct the operation of the transfer switch. The
controller's sensing and logic shall be controlled by a built-in
microprocessor for maximum reliability, minimum maintenance, and
inherent serial communications capability. The controller shall be
connected to the transfer switch by an interconnecting wiring harness. The
harness shall include a keyed disconnect plug to enable the controller to be
disconnected from the transfer switch for routine maintenance.
B. The controller shall be enclosed with a protective cover and be mounted
separate from the transfer switch unit for safety and ease of maintenance.
Sensing and control logic shall be provided on printed circuit boards.
Interfacing relays shall be industrial grade plug-in type with dust covers.
C. The controller shall meet or exceed the requirements for Electromagnetic
Compatibility (EMC) as follows:
1. ANSI C37.90A/IEEE 472 Voltage Surge Test
2. NEMA ICS – 109.21 Impulse Withstand Test
3. IEC801-2 Electrostatic discharge (ESD) immunity
4. ENV50140 and IEC 801 – 3 Radiated electromagnetic field immunity
5. IEC 801 – 4 Electrical fast transient (EFT) immunity
6. ENV50142 Surge transient immunity
7. ENV50141: Conducted radio-frequency field immunity
Page 178 SEAL AND SIGN OF BIDDER
8. EN55011: Group 1, Class A conducted and radiated emissions
9. EN61000 –4 – 11 Voltage dips and interruptions immunity
iii. Enclosure
A. The ATS shall be furnished in a NEMA type 1 enclosure unless otherwise
shown on the plans.
B. Provide strip heater with thermostat for Type 3R enclosure requirements.
C. Controller shall be flush-mounted display with LED indicators for switch
position and source acceptability. It shall also include test and time delay
bypass switches.
PART 3: OPERATION
i. Voltage and Frequency Sensing
A. The voltage of each phase of the normal source shall be monitored, with
pickup adjustable to 95% of nominal and dropout adjustable from 70% to
90% of pickup setting.
B. Single-phase voltage and frequency sensing of the emergency source shall
be provided.
ii. Time Delays
A. An adjustable time delay shall be provided to override momentary normal
source outages and delay all transfer and engine starting signals.
B. An adjustable time delay shall be provided on transfer to emergency,
adjustable from 0 to 5 minutes for controlled timing of transfer of loads to
emergency.
C. A generator stabilization time delay shall be provided after transfer to
emergency.
Page 179 SEAL AND SIGN OF BIDDER
D. An adjustable time delay shall be provided on retransfer to normal,
adjustable to 30 minutes. Time delay shall be automatically bypassed if
emergency source fails and normal source is acceptable.
E. A 5-minute cool down time delay shall be provided on shutdown of engine
generator.
F. All adjustable time delays shall be field adjustable without the use of
special tools.
iii. Additional Features
A. A set of contacts rated 5 amps, 32 VDC shall be provided for a low-voltage
engine start signal. The start signal shall prevent dry cranking of the
engine by requiring the generator set to reach proper output, and run for
the duration of the cool down setting, regardless of whether the normal
source restores before the load is transferred.
B. A push-button type test switch shall be provided to simulate a normal
source failure.
C. A push-button type switch to bypass the time delay on transfer to
emergency, the engine exerciser period on the retransfer to normal time
delay whichever delay is active at the time the push-button is activated.
D. Terminals shall be provided for a remote contact which opens to signal the
ATS to transfer to emergency and for remote contacts which open to inhibit
transfer to emergency and/or retransfer to normal.
E. Auxiliary contacts, rated 10 amps, 250 VAC shall be provided consisting of
one contact, closed when the ATS is connected to the normal source and
one contact, closed, when the ATS is connected to the emergency source.
F. Indicating lights shall be provided, one to indicate when the ATS is
connected to the normal source (green) and one to indicate when the ATS is
connected to the emergency source (red). Also provide indicating lights for
both normal and emergency source availability.
Page 180 SEAL AND SIGN OF BIDDER
G. Terminals shall be provided to indicate actual availability of the normal and
emergency sources, as determined by the voltage sensing pickup and
dropout settings for each source.
H. Engine Exerciser - An engine generator exercising timer shall be provided,
including a selector switch to select exercise with or without load transfer.
I. Inphase Monitor - An Inphase monitor shall be inherently built into the
controls. The monitor shall control transfer so that motor load inrush
currents do not exceed normal starting currents, and shall not require
external control of power sources. The inphase monitor shall be specifically
designed for and be the product of the ATS manufacturer.
J. Selective Load Disconnect - A double throw contact shall be provided to
operate after a time delay, adjustable to 20 seconds prior to transfer and
reset 0 to 20 seconds after transfer. This contact can be used to selectively
disconnect specific load(s) when the transfer switch is transferred. Output
contacts shall be rated 6 amps at 28 VDC or 120 VAC.
Optional Accessories (Specify if Required)
K. Communications Interface - Serial Module (5110) to allow local or remote
communications with ASCO PowerQuest ® or SiteWeb ™ communication
products. The module shall be used to connect the Series 300, and ASCO
ATS Annunicators to the serial network via an RS-485 interface. The
module shall have two port connectors used for ATS & Standalone Power
Manager connectivity. (Accessory 72A).
L. Communications Interface – Connectivity Module (5150) to allow several
different serial devices that communicate at different baud rates and with
different protocols to a common Ethernet media. The module shall be used
to connect Series 300 and ASCO ATS Annunciators to the standard
Ethernet TCP/IP network with standard 10 base-T (RJ-45) connector. The
module shall be designed to communicate with up to 8 clients such as Web
Page 181 SEAL AND SIGN OF BIDDER
applications (web pages) or PowerQuest ® communication products
simultaneously over an Ethernet connection. (Accessory 72E).
M. Programmable Engine Exerciser - A seven or fourteen day programmable
engine exerciser with digital readout display. Shall include one form C
contact for availability of normal and emergency sources. Include “with or
without” load control switch for exerciser period. The exerciser shall be
backed up by a permanent battery. (Accessory 11BG).
N. Enclosure Heater - A 125 watt enclosure heater with transformer and
thermostat (adjustable from 30 to 140 F) (Accessory 44 G).
O. Power Monitoring and Control
A PowerQuest ® PC based Automatic Transfer Switch (ATS) remote monitoring
and control system designed to communicate with other ATSs located in
remote locations shall be provided. System shall utilize serial
communications capability inherent with the ATS microprocessor based
control panel offering. Refer to separate Suggested Specification.
A SiteWeb™ remote monitoring and control system that is accessible from
any network connected pc. It shall be an internet browser based system
that can be configured to remotely monitor and control from a pc connected
to the internet. Refer to separate Suggested Specification.
PART 4: ADDITIONAL REQUIREMENTS
i. Withstand and Closing Ratings
The ATS shall be rated to close on and withstand the available rms
symmetrical short circuit current at the ATS terminals with the type of
overcurrent protection shown on the plans. WCR ATS ratings as be as
follows when used with specific circuit breakers:
Page 182 SEAL AND SIGN OF BIDDER
ATS Size Withstand & Closing
Rating MCCB
W/CLF
30 22,000A 100,000
70 - 200 22,000A 200,000
230 22,000A 100,000
260 – 400 42,000A 200,000
600 – 1200 65,000A 200,000
1600 – 2000 85,000A 200,000
2600 – 3000 100,000A 200,000
ii. Tests and Certification
A. The complete ATS shall be factory tested to ensure proper operation of the
individual components and correct overall sequence of operation and to
ensure that the operating transfer time, voltage, frequency and time delay
settings are in compliance with the specification requirements.
B. Upon request, the manufacturer shall provide a notarized letter certifying
compliance with all of the requirements of this specification including
compliance with the above codes and standards, and withstand and closing
ratings. The certification shall identify, by serial number(s), the equipment
involved. No exceptions to the specifications, other than those stipulated at
the time of the submittal, shall be included in the certification.
C. The ATS manufacturer shall be certified to ISO 9001: 2000 International
Quality Standard and the manufacturer shall have third party certification
verifying quality assurance in design/development, production, installation
and servicing in accordance with ISO 9001: 2000.
Page 183 SEAL AND SIGN OF BIDDER
iii. Service Representation
A. The ATS manufacturer shall maintain a national service organization of
company-employed personnel located throughout the contiguous United
States. The service center's personnel must be factory trained and must be
on call 24 hours a day, 365 days a year.
B. The manufacturer shall maintain records of each switch, by serial number,
for a minimum of 20 years.
C. For ease of maintenance, the transfer switch nameplate shall include
drawing numbers and serviceable part numbers.
Page 184 SEAL AND SIGN OF BIDDER
15. TECHNICAL DATA SHEETS
I] 415 PANEL BOARD
A. PANEL
1 Type Indoor single front free standing
2 Rated Voltage 415 V
3 No. of Phases Three phases and neutral
4 Frequency 50 Hz
5 Fault Level 25 MVA
6 Minimum Short Circuit Current 35 kA
7 Thickness of sheet steel
a) Main frame
b) Doors / Covers / Partitions c) Gland Plate
14 SWG
16 SWG
10 SWG
8 Cable entry From Top
9 Paint shade
a) Exterior
b) Interior c) Type
Shade 631 as per IS: 5
Shade 631 as per IS: 5
Seven tank process with powder
coating
10 Bus bar
a) Material b) Current Density c) Capacity
Copper
1.4 Amp / mm2 As per S.L.D ( Same
size of phase & neutral busbars )
11 Control wiring By 1.5 sq. mm. PVC insulated
stranded copper wire except CT
circuits. By 2.5 sq. mm. PVC insulated
stranded copper wire for CT circuits.
12 Gaskets Neoprene
Page 185 SEAL AND SIGN OF BIDDER
B. CIRCUIT BREAKER
1 Type Air Circuit Breaker
2 Rated Voltage 415 V
3 No. of Phases 3 (Three )
4 Frequency 50 Hz
5 Rated Current As per SLD
6 Fault Level 25 MVA
7 Breaking Capacity More than 45 kA
8 Making Capacity More than 80 kA
9 Main / Arcing Contacts Silver plated
10 Operating Mechanism Motor wound spring charged
11 Auxiliary / Control Voltage 230V AC
12 Method of Tripping Trip free
13 Operating Sequence O – 0.3 sec – CO – 3 min – CO
14 No. of auxiliary contacts 4 NO + 4 NC
C. MCCB
1 Type 3 or 4 Pole
2 Rating As per SLD
3 Tripping Shunt release
4 Rated Voltage 415 V
5 Rated Frequency 50 Hz
6 Breaking Capacity More than 45 Ka
Page 186 SEAL AND SIGN OF BIDDER
G. SELECTOR SWITCH
D. CURRENT TRANSFORMER (CT)
1 Type Cast resin
2 CT Ratio As per SLD
3 Accuracy Cl. 1.0 for Metering
5P10 for Protection
4 VA Burden 15 VA for each core
5 Insulation class E
E. DIGITAL METER
1 CT / PT Ratio As per SLD
2 Accuracy Class 1.0
3 Type Digital
4 Size 96 mm x 96 mm
5 Range As per SLD
6 Mounting Flush
7 Reference Standard IS: 1248
1 No. of positions 4 (3 – way and OFF)
2 Type of handle Knob
3 Voltage 440V AC
4 Current 16 A
5 Mounting Flush
Page 187 SEAL AND SIGN OF BIDDER
H. PUSH BUTTON
1 Rating 10A, 250V AC
2 Diameter 22.5 mm
3 Type of Actuator Shrouded
4 Contact elements 2 NO + 2 NC
5 Colour As per SLD
6 Type Spring Return
I. INDICATING LAMP
1 Type LED
2 Diameter 22.5 mm
3 Description As per SLD
4 Colour As per SLD
5 Resistor Required
Page 188 SEAL AND SIGN OF BIDDER
II] L.T CAPACITOR BANK & APFCR PANEL
1. GENERAL
1.1 Applicable Indian Standards IS 13340- 13585
1.2 Quantity As per BOQ
2. RATING
2.1 Basic Unit Rating As per drawing
2.2 Bank Rating As per drawing
2.3 Mode of connection As required
2.4 Voltage Rating 415 volts 10 %
2.5 Phase 3 Phase
2.6 Frequency 50 Hz,+3 % / - 6 %
2.7 Duty Indoor suitable for panel
mounting
3. DESIGN
3.1 Dielectric used MPP Type
3.2 Guaranteed Looses
Watts/KVAR
Less than 0.3
3.3 Sealing Hermetically sealed
3.4 Ambient Temp. 500 C
3.5 Type of cooling Natural air cooled
4. CAPACITOR CONTROL PANEL
4.1 Material of casing MS-CRCA
4.2 Thickness of casing 14 SWG
4.3 Painting Powder Coating
4.4 Type of Bushing
5. BUS BAR
5.1 Bus bar size & Rating TP, Copper
6. TESTING
6.1 Routine Testing Required
6.2 Loss Angle Test Required
Page 189 SEAL AND SIGN OF BIDDER
III] LIGHTNING PROTECTION SYSTEM.
i. SCOPE
The scope of work under this section covers the supply, installation,
connection, testing and commissioning of lightning protection system. The
contractor shall provide all materials, labour, equipments, scaffoldings etc., as
required for the complete lightning protection system.
ii. STANDARDS APPLICABLE
The lightning protection system shall comply with British Code of Practice 326:
1965 and I.S.2309:89- code of practice for the protection of buildings and
allied structures against lightning, Indian Electricity Act and Rules.
iii. GENERAL The lightning protection system consists of:
Air termination network. Roof conductors. Down conductors.
Testing joint Earth termination network.
iv. SYSTEM The lightning protection system shall be installed as indicated on the
drawings or in case such is not available the contractor shall prepare one as per British CP 326 or IS 2309:89 and get same approved by the Bank’s engineer/Consultant.
As air terminals shall be installed on the highest roof of the building, the air terminals shall be joined to horizontal roof conductor by means of
rivets/clamps. Roof conductor shall be laid horizontally on the roof as indicated on the drawing.
Down conductor shall be installed on the vertical surface of the building.
The down conductor shall be joined with roof conductors in the method as prescribed by the code. A test joint shall be provided in the down conductor 100mm above the ground level at a place which is easily
accessible for testing.
Page 190 SEAL AND SIGN OF BIDDER
The down conductor shall be joined with earth termination network
or to the earthing station as indicated on the drawing.
The earthing station and the earthing conductor shall be as per section under heading "EARTHING".
v. COMPONENT PART AIR TERMINALS AND ROOF CONDUCTORS
An air termination shall consist of vertical conductor or a system of
horizontal conductors and shall be installed along the outer perimeter of
the roof. No part of the roof shall be more than 9 m from the nearest
horizontal protective conductor.
All metallic projections, chimneys, ducts, vent pipe, railings, gutters etc.,
on or above the main surface of the roof of the structure shall be bonded
to and form part of the air termination network. The method and nature
of the fixing shall be simple, solid and permanent.
The minimum dimension of the air termination network shall be as
follows:
a) Aluminium - 40 x 6mm
b) Aluminium, aluminium alloy copper and bronze rods -10mm dia. The Air terminal shall be installed vertical on the highest point of the
roof and shall be clamped firmly with the structure. The roof conductor
shall be laid horizontally below the finishing of the roof surface.
DOWN CONDUCTOR
The number of down conductors shall be as follows: -
A structure having a base area not exceeding 100 sq.m shall have only
one down conductor.
For a structure having a base area exceeding 100 sq.m, the number of
down conductors shall equal to smaller of the following:
One, plus one for every 300 sq.m or part thereof in excess of the first
100 sq.m or one for every 30 m of perimeter.
The down conductor shall be distributed round the outside wall of the
structure.
Any external metal running vertically through the structure shall be
bonded to the down conductor at the top and bottom.
Page 191 SEAL AND SIGN OF BIDDER
A down conductor shall follow the most direct path possible between
the air terminals and the earth termination.
The size of the down conductor shall be similar to roof conductor/air
termination network.
Each down conductor shall be provided with a testing joint in such a
position that it is convenient for testing.
JOINTS AND BONDS The lightning protection system shall have as few joints as possible.
Joints and bonds shall be mechanically and electrically effective eg.
clamped, screwed, bolted, riveted or welded. With overlapping joint, the
length of overlapping shall not be less than 25mm for all types of
conductor.
Contact surfaces shall be first cleaned, then inhibited from oxidation
with a suitable non-corrosive compound. Joints of dissimilar metals
shall be protected from moisture by an inert, tenacious material.
vi. EARTH RESISTANCE
The resistance from any part of the lightning protection system to earth shall
not exceed 1 Ohm before any bonding has been effected to metal in or on a
structure or to services below ground. If the value obtained exceeds the
specified 1 Ohm it shall be reduced by adding to the number of earth
electrode.
Page 192 SEAL AND SIGN OF BIDDER
IV] LIGHT FITTINGS AND ACCESSORIES
i. SCOPE
Scope of work under this section shall include inspection at suppliers /
manufacturer's premises, appropriate, receiving at site, safe storage,
transportation from point of storage to point of erection and erection of light
fittings, fixtures and accessories including all necessary supports, brackets,
down rods and painting as required. The contractor shall supply all materials
and accessories (other than those supplied by the Employer), labour, tools,
transportation, scaffolding etc., required for the completion of above work in all
respects.
ii. STANDARDS APPLICABLE
The lighting and their associated accessories such as lamps, reflectors,
housings, ballasts etc., shall comply with the latest applicable standards, more
specifically the following:
Electric light fittings General and safety requirements: IS - 1913.
Industrial lighting fittings with metal reflectors: IS - 1777
Decorative lighting outposts: IS - 5077 Flood Lights: IS - 1947 Luminaries for street lighting: IS - 2149
Bayonet lamp holders: IS - 1258 Bi-pin lamp holders for tubular fluorescent lamps: IS - 3323
Ballasts for use in fluorescent light fittings: IS - 1534 Starters for fluorescent lamp: IS - 2215 Ballast for HP MV lamps: IS - 6616
Capacitors for use in fluorescent, HPMV & LP sodium Vapour lamps circuits: IS - 2215
Tubular Fluorescent lamps: IS - 2418 (Part I)
High pressure mercury vapour lamps: IS - 2183 Tungsten filament general electric lamps: IS - 418
High pressure sodium vapour lamps: IS - 9974 (Part -I)
Page 193 SEAL AND SIGN OF BIDDER
iii. Light Fittings - General Requirements
Fittings shall be designed for continuous trouble free operation under
atmospheric conditions, reduction in lamp life or without deterioration of
materials and internal wiring. Outdoor fittings shall be weather - proof
and rain proof.
Fittings shall be so designed as to facilitate easy maintenance including
cleaning, replacement of lamps/starters etc.
All fittings shall be supplied complete with lamps. All mercury vapour
and sodium vapour lamp fittings shall be complete with accessories like
ballasts, power factor improvement capacitors, starters, etc. outdoor type
fittings shall be provided with weather proof boxes.
Fluorescent lamp fittings shall be complete with all accessories like
ballasts, power factor improvement capacitors, starters capacitors for
correction of stroboscopic effect.
Each fitting shall have a terminal block suitable for loop-out connection
by 1100 V PVC insulated copper conductor wires upto 4 sq.mm. The
internal wiring should be completed by the manufacturer by means of
standard copper wire and terminated on the terminal block.
All hardware used in the fitting shall be suitably plated or anodised and
passivated for use in industrial plants.
Earthing each light fitting shall be provided with an earthing terminal.
All metal or metal enclosed parts of the housing shall be bonded and
connected to the earth terminal so as to ensure satisfactory earthing
continuity throughout the fixture.
Painting/Finish All surfaces of the fittings shall be thoroughly cleaned
and degreased and the fittings shall be free from scale, rust, sharp-
edges, and burrs.
The housing shall be stove-enamelled or anodised as required. The
surface shall be scratch resistant and shall show no sign of cracking or
flaking when bent through 90 deg. over 12 mm dia mandrel.
Page 194 SEAL AND SIGN OF BIDDER
iv. LED Recessed Light Fittings – Technical Specifications Requirement
LED Recessed 2x2 ft. light fitting
1. Maximum power consumption – < 35 watt +/- 5 watt tolerance
2. Colour temperature 6000K +/-5% Tolerance
3. Power factor > = 0.9
4. Colour rendering index >= 70
5. Rated voltage 200 –240 volts/ 100 -242 volts if imported
6. Driver Integral (Part of the whole fitting in single casing)
7. Rated lumen Output >= 1000 Lm + / - 10 % tolerance
8. Ingress Protection IP 20 9. Housing Aluminum die cast housing duly powder coated
10. Diffuser PMMA (Poly methyl methacrylate) diffuser or equivalent. 11. Bezel colour White
12. Mounting specially designed Frame suitable for facilitating installation in Gypsum ceiling for recess mounted. LED Recessed Down Lighter Round 6’’ dia OR Square 6’’x6’’
1. Maximum power consumption – < 15 watt +/- 2 watt tolerance
2. Colour temperature 6000K +/-5% Tolerance
3. Power factor => 0.9
4. Colour rendering index => 70
5. Rated voltage 200 –240 volts/ 100 -242 volts if imported
6. Driver Integral (Part of the whole fitting in single casing)
7. Rated lumen Output => 1000 Lm + / - 10 % tolerance
8. Ingress Protection IP 20
9. Housing Aluminum die cast housing duly powder coated 10. Diffuser PMMA (Poly methyl methacrylate) diffuser or equivalent. 11. Bezel colour White
12. Mounting specially designed Frame suitable for facilitating installation in Gypsum ceiling for recess mounted.
Page 195 SEAL AND SIGN OF BIDDER
Warranty including LED driver - Minimum 6 years on complete fixture from date of final completion of work. ISO 9001:2008 or any subsequent revisions.
14 Photometric and electrical test report As per IS –16106 –2012/ IES
LM –79 –08 issued from laboratory having valid accreditation certificate of NABL.
v. DECORATIVE TYPE FITTINGS
Decorative fluorescent fittings shall be provided with mounting/housing
channel cum reflectors of CRCA sheet steel. Stove enamelled diffusers or
louvers shall be translucent white polystyrene.
vi. ACCESSORIES FOR LIGHT FITTINGS REFLECTORS :
The reflectors shall be made of CRCA sheet steel / aluminum / silvered glass /
Chromium plated sheet copper as required. The thickness of reflectors shall be
as per relevant standards. Reflectors made of steel shall have stove enameled /
vitreous enameled / epoxy coating finish. Aluminium used for reflectors shall
be anodised/epoxy stove enamelled/mirror polished. The finish for the
reflector shall be as specified. The reflectors shall be free from scratches
blisters and shall have a smooth and glossy surface having no premium
light reflecting coefficient. Reflectors shall be readily removable from the
housing for cleaning and maintenance without use of tools.
vii. LAMP/STARTERS HOLDERS :
Lamp holders shall have low contact resistance, shall be resistant to wear.
They shall hold lamps in position under normal conditions of shock and
vibration prevalent in an industrial atmosphere. Lamp holders for fluorescent
lamps shall be of spring loaded BI-pin rotar type. Live parts of the lamp holder
shall not be exposed during insertion or removal of the lamp or after the lamp
has been taken out.
Page 196 SEAL AND SIGN OF BIDDER
Lamp holders for incandescent and mercury vapour lamps shall be bayonet
type upto 100 W and Edison screw type for higher wattage. Starter holders for
fluorescent lamps shall be so designed that they are mechanically robust and
shall be capable of withstanding shocks during transit, installation and use.
viii. BALLASTS
The ballasts shall be designed for long life and low power loss. They shall be
mounted using self-locking, anti -vibration fixtures and shall be easy to
remove without demounting the fittings. The enclosures shall be dust tight
and non-combustible. Ballasts shall be inductive, heavy duty type, filled with
thermosetting, insulating, moisture repellent polyester compound filled
under pressure or vacuum. Ballasts shall be provided with taps to set the
voltage. The ballast wiring shall be of copper and they shall be free from dust.
Separate ballast shall be provided in case of multi-lamp fittings, except in case
of 2 x 20 W fittings. Starters shall have bi-metal electrodes of high
mechanical strength. Starters shall be replaceable without disturbing the
reflector of lamps and without use of any tool. Starters shall have brass
contacts and radio interference suppression capacitor.
ix. CAPACITORS
The Capacitors shall have a constant value of capacitance and shall be
connected across the supply of individual lamp circuits. The capacitor shall
have a value of capacitance so as to correct the power factor of its
corresponding lamp circuit to 0.95 lag or better. Capacitor shall be
hermetically sealed preferably in a metal enclosure to prevent seepage of
impregnant and ingress of moisture.
x. LAMPS
Incandescent lamps shall be clear type unless otherwise specified. Fluorescent
lamps shall be "day-light colour" type unless otherwise specified and shall be
provided with features to avoid blackckening of lamp ends. Mercury vapour
lamps shall be of high pressure, colour corrected type. Lamps shall be capable
of withstanding vibrations prevalent in an industrial atmosphere, the filament
/ electrodes shall not break under such circumstances.
Page 197 SEAL AND SIGN OF BIDDER
PL Lamps shall be energy effective compact single ended light sources in 9 to
11W ratings consisting of two narrow glass tubes welded together. The lamp
shall be complete with integral glow switch starter and capacitor and two
pin electrical connection the lamp shall be colour rendered to give warm
colour impression. The compact lamp shall have a long life and shall be energy
efficient.
xi. INSTALLATION :
The light fixtures and fittings shall be assembled and installed in position
complete and ready for service, in accordance with details, drawings,
manufacturer’s instructions and to the satisfaction of the Construction
Manager. Pendent fixtures specified with overall stem lengths are subject to
change and shall be checked with conditions on the job and installed as
directed. All suspended fixtures shall be mounted rigid and fixed in
position in accordance with drawings, instructions and the approval of
the Construction Manager. Fixtures shall be suspended true to alignment,
plumb, level and capable of resisting all lateral and vertical forces and shall be
fixed as required.
All suspended light fixtures, fans etc, shall be provided with concealed
suspension arrangement in the concrete slab/roof members. It is the duty of
the Contractor to make these provisions at the appropriate stage of
construction. Exhaust fans shall be fixed at location shown on drawings. They
shall be wired to a plug socket outlet at a convenient location near the fan. All
switch and outlet boxes, for fans and light fittings shall be bonded to earth.
The recessed type fixtures shall not be supported into the false ceiling frame
work. This shall have independent support from the socket of ceiling using
G.I.conduit down rods/chromium plated steel chain with provision for
adjusting the level of fitting. Wires shall be connected to all fixtures through
connector blocks. Wires brought out from junction boxes shall be encased in
flexible pipes for connecting to fixtures concealed in suspended ceiling. The
flexible pipes shall be check-nuted to the junction box with a brass bush
and double checknut at the fixture and flexible pipes, wherever used shall
be of make and quality approved by the Construction Manager/Client.
Page 198 SEAL AND SIGN OF BIDDER
V] EARTHING SYSTEM
i. SCOPE
This section covers the requirements for providing "Earthing" connection
to metal parts of equipment etc., The contractor shall supply all materials, labour, tools, plant etc., and everything necessary for the complete Earthing installation".
ii. STANDARDS APPLICABLE
The following standards shall be applicable:
IS 3043 -Code of practice for earthing. IEEE - 80:86.
IEEE - 142:92.
iii. GENERAL
All the non-current carrying metal parts of electrical installation shall be
earthed as per IS: 3043. All equipment, metal conduits, rising main cable
armour, switch gear, distribution boards, meters, all other metal parts
forming part of the work shall be bonded together and connected by two
separate and distinct conductors to earth electrodes. Earthing shall be in
conformity with the provisions of Rules 32, 61, 62, 67 and 68 of IER 1956.
iv. G.I. PIPE EARTH STATION
Electrodes shall be made of G.I. Pipe of internal diameter of 100mm dia. The
pipe electrode shall be as far as practicable embedded below permanent
moisture level. The length of the pipe electrode shall not be less than 2.5 m.
except where rock is encountered, pipes shall be driven to a depth of at least
2.5mtr where rock is encountered at a depth of less than 2.5mtr. The
electrode may be buried inclined to the vertical and the inclinations not more
than 30 dig C from the vertical. The pipe electrode shall be made of one piece.
Page 199 SEAL AND SIGN OF BIDDER
Earth leads to the electrode shall be laid in a heavy duty GI pipe and
connected to the pipe electrode with brass bolts, nuts and washers. GI pipe
shall be terminated in a wire meshed funnel. The funnel shall be enclosed in
a masonry chamber of 450mm x 450mm dimensions. The chamber shall be
provided with C.I. frame and CI inspection cover. The earth station shall also
be provided with a suitable permanent identifications label tag. The earth
electrode shall conform to IS: 3043 latest edition. The soil around the
earthing electrode shall be treated to reduce the resistivity of the soil by filling
the complete depth of electrode with alternative layers of charcoal and salt.
v. PLATE EARTH STATION
Plate electrodes shall be made of copper (CU) plate of 3mm thick and 600 x
600mm size. The plate shall be buried vertically in ground at a depth of
not less than 2.5 meters to the top of the plate, the plate being encased
in charcoal to a thickness of 300mm all round. It is preferable to bury the
electrode to a depth where subsoil water is present. Earth leads to the
electrode shall be laid in a heavy duty GI pipe and connected to the plate
electrode with brass bolts, nuts and washers. A GI pipe of not less than
19mm dia shall be clamped with bolts vertically to the plate and terminated
in a wire meshed funnel. The funnel shall be enclosed in a masonry chamber
of 450mm x 450mm dimensions. The chamber shall be provided with GI
frame and CI inspection cover. The earth station shall also be provided with
a suitable permanent identifications label tag. The earth electrode shall
conform to IS: 3043.
vi. EARTHING CONDUCTORS
All earthing conductors shall be of high conductivity copper and shall be
protected against mechanical damage and corrosion. The connection of earth
electrodes shall be strong secure and sound and shall be easily accessible.
The earth conductors shall be rigidly fixed to the walls, cable trenches, cable
tunnel, conduits and cables by using suitable clamps.
Main earth bus shall be taken from the main medium voltage panel to the
earth electrodes. The number of electrodes required shall be arrived at taking
into consideration the anticipated fault on the medium voltage network.
Page 200 SEAL AND SIGN OF BIDDER
Earthing conductors for equipment shall be run from the exposed metal
surface of the equipment and connected to a suitable point on the sub main
or main earthing bus. All switch boards, distribution boards and isolators
disconnect switches shall be connected to the earth, bus. Earthing
conductors shall be terminated at the equipment using suitable lugs, bolts,
washers and nuts.
All conduits cable armouring etc., shall be connected to the earth all along
their run by earthing conductors of suitable cross sectional area. The
electrical resistance of earthing conductors shall be low enough to permit the
passage of fault current necessary to operate a fuse/protective device or a
circuit breaker and shall not exceed 2 ohms.
vii. PRECAUTIONS
Earthing system shall be mechanically robust and the joints shall be capable
of retaining low resistance even after subjection to fault currents.
Joints shall be tinned, soldered and/or double riveted. All the joints shall be
mechanically and electrically continuous and effective. Joints shall be
protected against corrosion.
viii. TESTING
On the completion of the entire installation, the following tests shall be
conducted:
i) Earth resistance of electrodes
ii) Impedance of earth continuity conductors as per is 3043.
iii) Effectiveness of earthing as per is 3043.
All meters, instruments and labour required for the tests shall be provided
by the contractor. The test results shall be submitted in the prescribed
tabulated form in triplicate to the clients for approval.
Page 201 SEAL AND SIGN OF BIDDER
16. METHOD OF MEASUREMENTS FOR WORKS
(ELECTRICAL ITEMS)
1. POINT WIRING Mode of measurement is as follows:
For purposes of measurement the point wiring for lights/fans/6A
sockets (where 6A sockets are connected to lighting circuit loop) is
divided into two parts.
a) Point Wiring
b) Circuit Main a) POINT WIRING
The wiring for light/fan/6A socket (where 6A sockets are connected to lighting circuit loop) point starting from first
light/switch/fan and looping between switches/ fans/sockets etc., shall be measured either in `Number' or `Set'.
One light/fan point controlled by one switch is measured in Number
(No.) Set of Two or more light points controlled by one switch is measured in
`Sets'.
Where set of light points wired and controlled directly from MCB DB shall be measured in `Sets'. The rate for this item shall not include the
cost of switch & switch box. 6A socket wiring where connected to the lighting circuit loop is
measured in Number (No.)
b) CIRCUIT MAIN
i. The length of circuit main including conduit starting from MCB DB to first switch/light/fan shall be measured separately in `Linear Metres'
(Rm). (Futher wiring is measured in point wiring).
ii. Circuit main for wiring 6A sockets, 16A sockets and power outlets shall
be measured as under - Length of circuit wire including conduit starting from MCB DB to
outlets and looping between outlets shall be measured in linear meters (Rm).
The commercial type socket outlet with outlet box and cover plate shall
be measured in numbers (No.) The Industrial type socket outlet including MCB, plug top, outlet box
and cover plate shall be measured in numbers (No.)
The plug tops where called for shall be measured in numbers (No.)
Page 202 SEAL AND SIGN OF BIDDER
2. CABLES.
Mode of measurement is as follows:
All power cables including fixing accessories as described in specifications and SOQ are measured in linear meter (Rm).
Power cable terminations are measured in Number (No)
Control cables including terminations are measured in linear metres (Rm)
Cable trays and conduit/pipes are measured in linear meters (Rm).
3. LIGHTENTING PROTECTION SYSTEM.
The earth conductor (G.I. or Aluminum strip) including all accessories is measured in linear meter (Rm).
The air termination including support is measured in Number (No) Earthing stations with all associated works as described in SOQ are
measured in number (No).
4. LIGHT FITTINGS.
Installation of light fittings with all associated works including fixing
accessories is measured in numbers (No).
Supply and installation of down rods and C.P. Chain with associated
works as per SOQ and specifications are measured in linear meter
(Rm).
5. EARTHING
Mode of measurement is as follows:
Earth strips (GI/Cu), earth conductor are measured in linear meter
(Rm).
Earthing station with all associated works (G.I pipe or copper plate) is
measured in number (No)
Page 203 SEAL AND SIGN OF BIDDER
17. APPENDIX
ABSTRACT TO GENERAL CONDITIONS OF CONTRACT
1 Earnest money Deposit(EMD)/ Initial Security Deposit(ISD)
An initial part amount of Rs 8,20,000/-(Rupees eight lakh twenty thousand only) towards Earnest Money Deposit (EMD) by way of a Bank Guarantee from Nationalised Bank/ Scheduled Bank to be submitted along with the “Technical Bid”. The ISD (which will be 2% of the accepted tender value minus EMD) will be submitted by the contractor after awarding of the work.
2 Date of commencement Date of commencement shall be either one-week from the date of issue of work order to the contractor or day on which the contractor will take possession of site whichever is earlier
3 Period of Completion 10 weeks from the date of commencement
4 Defects Liability Period 12 months from the date of virtual completion
completion. 5 Agreed Liquidated Damages 0.25% of the value of the accepted tender
for every week of delay or part thereof,
subject to maximum of 5% of the value of
the accepted tender. 6 Period of Final Measurement 30 days
7 Value of work for the issue of Interim Certificate
Certificate
Minimum Rs 75.00 Lakhs per month
8 Retention money from each interim bill
5% of all the RA bills
Ra
9 Total retention money including Earnest Money and initial security deposit
As per Clause 11, of General Conditions
10 Consultants certificate of payment 15 days after submission of interim bills
by the Contractor.
11 Period of honoring payment certificate
15 working days from date of Consultant’s
certificate of payment for interim bills and
its acceptance to employer.
12 Delayed Payments No interest will be paid on this account
Page 204 SEAL AND SIGN OF BIDDER
18. DECLARATION
I/We have inspected the site of works and have made me / we fully
acquainted with the local conditions in and around the sites of works.
I/We hereby declare that I/We have gone through the conditions laid down
in the Notice Inviting Tender, Conditions of Contract, Technical
Specifications and understood the same and on the basis of the same I/We
quoted our rates in the Schedule of Quantities attached with the tender
documents.
I/We shall also uniformly maintain such progress as may be directed by the
Employer / Consultant to ensure completion of same within the target date
as mentioned in the tender document.
Witness: _____________________
Signature of Tenderer
Address : _____________________________
_____________________________
______________________________
Date : __________________
Note: All Technical clarification if any should form a part of technical bid.
Technical clarification after opening of the Tender will not be entertained at
any cost.
Page 205 SEAL AND SIGN OF BIDDER
19. APPROVED MAKES OF EQUIPMENT & MATERIALS
List of approved makes of different equipment/materials to be used in this project
S.NO. DETAILS OF EQUIPMENT
AND MATERIALS
MANUFACTURER’s NAME
EQUIPMENT
1 VRF type multi split units LG (KOREA) / Daikin (JAPAN) / Blue
Star / Hitachi
2 Centrifugal Fans Green Heck / Nutech
3 Exhaust Fan Section & fan
Filter Unit
Nutech / Zeco
4 Inline Fans Kruger / Caryaire
5 Propeller fans GEC/ Alstom
6 V-Belts Fenner India / Dunlop
7 Motors Siemens / ABB
8 Variable Frequency Drive Siemens / Danfoss
S.NO DETAILS OF EQUIPMENT
AND MATERIALS
MANUFACTURER’S NAME
1. AIR DISTRIBUTION
GS Sheet
SAIL/Tata Steel/Jindal
2. Pre Filters airtech / thermadyne
3. Fine Filters/Carbon filters airtech / Thermadyne / Klenzaids
4. Metallic air Filters Thermadyne / Airpack
5. Anti-vibration canvass sleeve Caryaire/Mapro/Tanus/Servex
6. Extruded Aluminum grilles &
diffusers
Komalko / Trox / System Air
7. Air transfer grilles Komalko / Trox / System Air
Page 206 SEAL AND SIGN OF BIDDER
8. Fire Dampers
a) Bare Dampers
b) Actuators
Komalko / Trox / System Air
Belimo / Siemens
9. Kitchen Hoods Airmaster / Citizen
10. Sound Attenuators Komalko / Trox / System Air
11. Intake Louvers Komalko / Trox / System Air
12. Duct Dampers Komalko / Trox / System Air
13. Air Curtains Beacon / Thermadyne
14. Rubber Insertion for mating
flanges of duct.
Escotape / Arrowflex
15. Dash Fastners/ Suspension
accessories for
ducts/pipes/cables
Ficher / HILTI
16. AUTO TRANSFER SWITCH
(MAINS to DG)
ASCO 300 / RUSSEL ELECTRIC
(USA)
17. ELECTRICAL PANEL BUILDER SMASH CONTROLS / S.S.
CONTROLS
18. FIRE ALARM / PUBLIC
ADDRESS SYATEM
FIKE / NOTIFIRE
19. LED LIGHTING WITH SENSOR
& DALI CONTROLLER
PHILIPS / OSRAM/GM
20. WIRE & CABLE FINOLEX / POLYCAB
21. GI CONDUIT JAVERI / EQUI
22. FALSE CEILING GYPROC / EQUI
23. TRANSFORMER & CSS SIEMENS / ABB / TELAWNE
24. EARTH PIT (MAINTAINANCE
FREE)
ELINK / ASHLOCK
25. DISTRIBUTION BOARD & MCB LEGRAND / SCHNEIDER
26. SWITCH GEAR (MCCB & ACB) SIEMENS / SCHNEIDER/L&T
Page 207 SEAL AND SIGN OF BIDDER
27. CABLE TYAY CABELOFIL / PROFAB
28. SWITCH / SOCKET NOWASYS / ARTIOR / ZENCELLO
29. RACEWAY & JUNCTION BOX JINDAL / MK
30. BUS DUCT SIEMENS / SCHNIDER
31 Surge Protection devices ASCO / EQUI
NOTE:
Make of any other equipment not mentioned above shall be got approved from the
Employer before execution.
Any other equivalent make in place of the above makes can be provided if the same
meets the standards and is acceptable to the Employer/Consultant
Page 208 SEAL AND SIGN OF BIDDER
BLANK PAGE
Page 209 SEAL AND SIGN OF BIDDER
20. Format of Bank Guarantee for EMD
The Chief General Manager
NABARD, Maharashtra Regional Office
54 Wellesley road, Shivaji Nagar
Pune, 411005
Dear Sir
WHEREAS the National Bank for Agriculture and Rural Development, a body
corporate established under the NABARD Act, 1981 (hereinafter referred to as
NABARD, which expression shall, include its successors and assigns) has invited
tenders S / I / T/ C OF AIR CONDITIONING SYSTEM & ALL REQUIRED CIVIL
& ALLIED WORKS, FOR NABARD, MAHARASHTRA REGIONAL OFFICE,
SHIVAJI NAGAR, PUNE
WHEREAS ………………………………………hereinafter called the “Tenderer” has
represented to us that they intend to participate in the tender for the said Project.
AND WHEREAS it is one of the condition of the said tender that the Tenderer shall
deposit with NABARD at the time of submitting the tender a sum of Rs. 8,20,000/-
(Rupees eight lakh twenty thousand only) as and by way of Earnest Money Deposit
(EMD), which shall not bear any interest and which shall be liable for forfeiture in
the event of the Tenderer, after acceptance of his tender by NABARD, failing to
observe any of the terms and conditions of the tender or the Tenderer not
completing the said project to the satisfaction of NABARD.
AND WHEREAS at the request of the Tenderer, NABARD has agreed not to insist
for payment of the said EMD in cash and accept Bank Guarantee from a Scheduled
/Nationalized Bank in lieu thereof and has agreed to accept the same from us, the
Bank, as hereinafter contained.
In the premises aforesaid and in consideration of NABARD having agreed to exempt
the tenderer from depositing the said EMD in cash,
Page 210 SEAL AND SIGN OF BIDDER
WE,_________________________Bank having our Head Office at
___________________and one of our Branches at ___________________Do hereby
unconditionally and irrevocably guarantee unto NABARD that the Tenderer will
execute the Agreement soon upon acceptance of the tender by NABARD and will
diligently, efficiently and satisfactorily perform all their obligations under the
various terms and conditions of the said tender (read with any amendments made
thereto by mutual consent of NABARD and the Tenderer) to the satisfaction of
NABARD within the time stipulated therein, failing which WE
the__________________________Bank shall, on demand and without demur, pay to
NABARD the sum of Rs. 8,20,000/- (Rupees eight lakh twenty thousand only) at
its office at Pune.
We _____________________________________________Bank further covenant that
(a) Our Liability under this guarantee shall not exceed Rs. 8,20,000 (Rupees eight
lakh twenty thousand only)
(b) We shall pay the aforesaid sum on demand made in writing by NABARD
without reference to the Tenderers and notwithstanding any dispute or difference
that may exist or arise between NABARD and the tenderer;
(c) That this guarantee shall be a continuing guarantee and shall not be revoked
by us without prior consent in writing of NABARD.
(d) that the decision of NABARD on the breach of any of the terms and conditions
of the said contract / tender by the Tenderers or their failure to perform their
obligations or discharge their duties under the said tender / contract shall be final
and binding on us and shall not be disputed by us inside or outside the court,
tribunal, arbitration or other authority;
(e) that the notice of demand in writing issued by NABARD shall be conclusive
proof as regards the amount due and payable to NABARD under this guarantee
and it shall not be disputed by us either inside or outside the court, tribunal or
arbitration or other authority;
(f) that any neglect or forbearance on the part of NABARD in enforcing any of the
terms and conditions of the said tender / contract or any indulgence shown by
NABARD to the Tenderer or any variation in the said tender / contract terms made
by mutual agreement between NABARD and the Tenderer or any other act or deed
on the part of NABARD which but for this clause may have the effect of discharging
us under the law relating to guarantee / sureties shall not discharge us from our
obligations herein and we shall be discharged only by compliance by the Tenderers
Page 211 SEAL AND SIGN OF BIDDER
with all their obligations / duties under the said tender / contract or by payment of
the sum.
(g) that this guarantee shall not be affected by any infirmity or absence or
irregularity in the exercise of the powers by or on behalf of the tenderers to submit
the said tender and enter into the said contract or any change in the constitution
or dissolution of the Tenderers or change in its name;
(h) that it shall not be necessary for NABARD to exhaust its remedies against the
Tenderers before invoking this guarantee and the guarantee therein contained shall
be enforceable against us notwithstanding any other security which the NABARD
may have obtained or may hereafter be obtained from the Tenderers at the time
when this guarantee is invoked is outstanding and unrealized;
(i) that we hereby agree that this guarantee shall be valid and be in force for a
period of Six months or 90 days from the date of opening of the price bid,
whichever is later (the expiry date) and we hereby agree to renew this guarantee for
such further period or periods at the request of NABARD and such renewal shall be
entirely at the cost and expense of the Tenderer.
(j) Any claim arising under this guarantee shall be preferred by NABARD within
a period of six months from the aforesaid expiry date or, in the event of any
renewal, within a period of six months from the date of expiry of such renewed
period extended by such renewal, and unless the claim is so preferred against us,
we shall stand discharged of all our liabilities hereunder irrespective of the fact
whether the Guarantee in original is returned back to us or not.
IN WITNESS WHEREOF the Bank, through its authorized officer, has set its hand
and stamp on this day of ………………………………………
Date:
For and on behalf of
_______________Bank
(Authorized Official)
Page 212
BLANK PAGE
Page 213
DRAWINGS
Page 214
BLANK PAGE