use of a claims triage workshop to choose an analysis method
DESCRIPTION
AACEi Recommended Practice 29R-03, Forensic Schedule Analysis, properly notes that there are a number of factors to consider in choosing a method of analysis in a time-related dispute. The variety, number, and complexity of the reasons to choose the correct method of analysis require more than a casual approach. This presentation demonstrates a process that we call a “Claims Triage” and use for every new dispute resolution assignment, organized and guided with a checklist and procedure.TRANSCRIPT
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE
AN ANALYSIS METHODAN ANALYSIS METHOD
CDR 637
Monday, June 20, 2011
11:15 a.m. – 12:15 p.m.
Chris Carson, PSP, CCM, PMP
Robert Kelly, Jr., PSP, CFCC, PMP
Chris Carson, PSP, CCM, PMP
• Corporate Director of Project Controls, Alpha Corporation– Responsible for standards, processes, and procedures for a team of schedulers, analysts, and project
managers in multiple office locations, as well as analysis, work product, and testimony
– Developed and manages the in-house project controls training program at Alpha
• Certifications: – PSP (Planning & Scheduling Professional – AACEi)
– CCM (Certified Construction Manager - CMAA)
– PMP (Project Management Professional – PMI)
• University: University of Virginia, Mechanical Engineering, 1972
• Professional Field: 38 years of experience in Construction Management Services specializing in Scheduling, Schedule Analysis, Estimating, Claims
22
Scheduling, Schedule Analysis, Estimating, Claims
• Active in AACEi (Association for the Advancement of Cost Estimating International)
– Author of Recommended Practices in Scheduling & Forensic Schedule Analysis RP
• Active in PMI (Project Management Institute) College of Scheduling
– Vice President of Scheduling Excellence
– Managing Director for SEI (Scheduling Excellence Initiative) writing Best Practices and Guidelines for Scheduling and Schedule Impact Analysis
– Serving on team writing Best Practices for Scheduling for GAO
• Active in CMAA (Construction Management Association of America)
– Served on committee revising Time Management Chapter of CMAA’s CM Standards of Practice
• Active in Planning Planet (global planning association)
– Chief Editor for US, writing Planner Users’ Guide, developing accreditation Guild for planners
• Something you don’t know about me: I’m a glider co-pilot, see picture
Robert Kelly, Jr., PSP, CFCC, PMP
• Degree:– BA, English
• University:– The College of William & Mary, 1990
• Years of Experience:– 21 years experience, combined project management and consulting services; partnering
facilitation , neutral dispute resolution
• Professional Field:
3
• Professional Field:– Construction project management, project controls, scheduling; vertical and horizontal
construction, projects $300k - $92m
– Claims evaluation and response; dispute resolution and litigation support
• Certifications: – PSP (Planning & Scheduling Professional – AACEi)
– CFCC (Certified Forensic Claims Consultant)
– PMP (Project Management Professional – PMI)
• Something you do not know about me:– Married to Lisa. Father to Emma Grace (7), Sarah Jane (4) and soon-to-arrive John Curtis (Kelly,
Sr.’s grand-children #2, #4 and #8)
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
• AACEI Recommended Practice 29R-03 “Forensic ScheduleAnalysis” properly notes that there are a number of factors toconsider in choosing a method of analysis in a time-relateddispute
• The presenters have developed a process that they havecalled a “Claims Triage” for use in evaluating every new
4
called a “Claims Triage” for use in evaluating every newdispute resolution assignment, organized and guided by achecklist and procedures.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Why have a Claims Triage to Choose an Analysis Method?
• Variety of methods available – which is best?
• Broad consideration from multiple participants with different experiences
• Apply lessons learned
• Training and mentoring
5
• Choice of methodology is carefully considered and documented for use in the
analysis, well before the analysis begins.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Claims Triage Process
• Process involves a team approach
• Commitment to RP 29R-03 Forensic Schedule Analysis, Section 5 “Choosing a
Method”
• Team assignments based on experience
• Importance of objective viewpoint during document management, review and
6
• Importance of objective viewpoint during document management, review and
analysis
• Lead Consultant is assigned
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Information Needed for the Triage Session
• Lead Consultant is responsible for coordination of triage meeting
• Structure and conduct of the meeting is dependent on information developed
prior to meeting
• See Checklist A “First Meeting Interview with Dispute Resolution Client” for
information necessary
7
information necessary
– Project Facts
– Dispute Facts
– Legal Facts
– Source Documents and Data Validation
• Engagement and Triage Information: chicken or the egg?
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Information Needed for the Triage Session
• Project Facts
– parties/stakeholders
– project type and description
– project location
8
– project location
– contract value
– bid, start, completion dates
– current project status – cost and schedule
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Information Needed for the Triage Session
• Dispute Facts
– an understanding of the dispute
– size of the dispute
– start of dispute
9
– start of dispute
– duration of the dispute
– prior dispute communications
– current dispute documentation/tracking efforts
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Information Needed for the Triage Session
• Legal Facts
– Litigation calendar
– contract claims process
– prior claim communications
10
– prior claim communications
– current status of claim
– any rebuttal arguments known at this time
– any risks from counterclaims
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Information Needed for the Triage Session
• Source Documents and Data Validation– contract
– plans and specifications
– project baseline schedule
11
– schedule update
– as-built information and accuracy
– contemporaneous validation sources (daily field reports, time cards, etc)
– Detailed bid estimate
– Job Cost Reports
– Requests for Information
– Change Orders
– Internal client analyses or reports
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Information Needed for the Triage Session
• Tasking and Budgeting
– Timeline for performance of the analysis
– Interim deliverables
– Budgetary constraints
12
– Budgetary constraints
– Methodology discussion
– Initial estimate of effort
– Client directive(s)
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Expected Outcome from the Triage Session
• Eliminate potential methodologies
• Focused need on missing information
• Better-performance of final methodology selection
• Quality Control in process of methodology selection
13
• Quality Control in process of methodology selection
• Confidence in methodology selection
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session
• Distribute information prior to Triage
– Documents acquired to date
– Summary of dispute
– Client-interview information
14
– Client-interview information
– Other “First Meeting Interview with the DR Client” information
• The earlier the better
• Well-briefed team = more effective Triage
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session
• Review Project and Case Background
– Client overview
– Project summary
– Disputed issues summary
15
– Disputed issues summary
– Availability & legitimacy of baseline & updates
– Availability & legitimacy of documents
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session
• Open Floor to Q&A from Triage team
– Information validation
– Identification of conflicts
– New questions and perspectives
16
– New questions and perspectives
– Identify missing information
– Guide for follow-up
• Now the Triage Team is ready to discuss the factors to
consider for the choice of methodology
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Contract Requirements
– Review the contract for stipulated method for forensic analysis or a method
for proving entitlement to time related compensation.
17
for proving entitlement to time related compensation.
– Critical Path Methodology?
– Prospective or Retrospective: does specified methodology address either,
both or neither?
– Triage session must establish and discuss contract provisions
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Purpose of the Analysis
– “…quantify delay, determine causation, and assess responsibility for such
delay…”
18
delay…”
– Assess financial consequences for delay
– Disruption impacts?
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Source Data and Reliability
– Certain methodologies cannot be performed without certain data
– Data set must be appropriate for method
19
– Data set must be appropriate for method
– Reliability is as important as existence
– Data set must be consistent, complete, accurate
– Triage may establish need for further investigation of data existence and
reliability
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Size of the Dispute
– Cost of analysis must be commensurate with the risk to the client
– The Lead should attempt to understand what the negative risks and gains
20
– The Lead should attempt to understand what the negative risks and gains
are to the client and case
– Will cost of methodology consume most of or exceed potential gain?
– Is direct negotiation without independent analysis more appropriate?
– The methodology chosen must be limited to one of those that can be done
inexpensively but is still appropriate for the situation.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Complexity of the Dispute
– The Lead should have an understanding of both the Project and the
issues in dispute.
21
– If the project is complex with large schedules and long project
durations, the analysis choice will likely be more limited
– Complexity can include the number and definition of interim, as well
as the need for specific technical background knowledge
– A decision by the Lead to withdraw could ensue
– The is one area where the lessons learned from the triage team can
provide very insightful feedback and raise concerns that might not be
obvious to individual analysts.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Budget for Forensic Schedule Analysis
– The claims triage is an appropriate place to determine if the
budget allowed for analysis is sufficient
22
budget allowed for analysis is sufficient
– It is one of the data points that should be collected from the
client
– The lead can direct the discussion to determine if the budget
seems reasonable
– It is important that the issue of approximate costs for analysis
on the discussion table.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Budget for Forensic Schedule Analysis
– If there is any indication that the budget might be insufficient
for the task, now is the time to establish that concern.
23
for the task, now is the time to establish that concern.
– If the Team determines the Project is appropriate and there is a
legitimate and appropriate methodology, the Lead should open
the discussion about rough costs to perform the analysis, so he
or she is armed with an approximate range of costs for later
discussions with the client.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Time Allowed for Analysis– The allowable time determined by the client will factor very much into the selection
of an appropriate methodology.
24
of an appropriate methodology.
– The time frame should incorporate:
• document review
• data validation
• time for research
• meetings with the construction team for interviews
• verification of facts in dispute
• development of the analysis and associated edits
• Alternate Dispute Resolution (ADR) calendar
• Trial calendar (ID experts, expert report production, response, deposition, etc.)
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Expertise of the Analyst and Resources Available– During triage, Lead should address all expertise needs to develop the analysis and to
testify in the case
25
testify in the case
– The triage Lead should develop an understanding of the technical support available
from the full company resources, and make some initial determinations about team
composition.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Forum for Resolution and Audience– The triage lead will have discussed the forum for adjudication with the client prior to the
conduct of the triage work shop. It would have been inclusive in the answers to the “First
Meeting Interview with Dispute Resolution Client”.
26
Meeting Interview with Dispute Resolution Client”.
– We believe it’s appropriate to treat every analysis matter as ”going to trial” and prepare
accordingly. This establishes a presumption of a higher level of scrutiny accorded to our
selection and implementation of methodology.
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Legal or Procedural Requirements
– The Lead should be fully briefed by client counsel regarding venue of the
trier of fact.
27
trier of fact.
– Sound methodologies generally survive varying venues.
– Certain venues require atypical consideration
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Past History/Methods and What Method Opposition is Using
– Triage discusses any history with parties and methodologies
• Methodology
28
• Methodology
• Technical competence
• Results
– Examine friend and foe history
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Choosing an Analysis Methodology
• Discuss Elimination of Methodologies
– Immediate elimination due to Factors
– Transition from easy elimination to in-depth discussion to elimination
29
– Transition from easy elimination to in-depth discussion to elimination
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
The Triage Session:
Choosing an Analysis Methodology
• Recommend Methodology
– Methodologies surviving elimination round
– General methodology type
30
– General methodology type
– Specific implementation
– Challenges to implementation
– Steps to address challenges
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE AN ANALYSIS METHOD
Conclusion
• Document triage effort
• Empirical support for decision-making
• Application of lessons learned
• Targeted need for information
31
• Targeted need for information
• Prepare for next meeting with client
• Efforts and resources: assignment
• Guided performance
• Effort confidence
• Training and mentoring
Practice Triage Session
Now, let’s perform a sample Triage
32
Practice Triage Session
The Triage Session
• Review Project and Case Background
– General Contractor client – Design-Bid-Build delivery
– Construction of new high school
– Disputed issues summary
33
– Disputed issues summary
• Foundation problems
• Slow shop drawing submittals
• Pre-engineered building problems
• Contractor production problems
• IT re-design issues
• Utility changes
Practice Triage Session
The Triage Session
• Review Project and Case Background
– Availability & legitimacy of baseline & updates
• Baseline approved
• Monthly updates produced, no response about approvals
34
• Monthly updates produced, no response about approvals
– Availability & legitimacy of documents
• Daily field reports reasonably detailed
• Meeting minutes haphazard
• Correspondence file light
• RFI, Change Estimate and Change Order logs available
• Monthly invoices available
• Several TIAs submitted contemporaneously
Practice Triage Session
• Schedule Log
Chron
OrderFile Name Start Date Data Date Early Finish
Activity
Count
Critical
Activities Cum Delay
Update Window Size
(cd)
Project Duration
(cd)
Remain. Time
(cd)Notes
6-Jul-09 15-Apr-09 15-Apr-09 26-Jul-10 578 29 0 N/A 467 467 baseline DC 2003
6-Jul-09 15-Apr-09 15-Apr-09 26-Jul-10580 83 0 N/A
467 467 revised baseline DC Hodges 03
16-Jul-08 15-Apr-09 16-Jul-09 10-Aug-10578 61
1092
482 390 Revised baseline (Zero Progress)
9-Mar-0915-Apr-09 15-Apr-09 26-Jul-10 571
50 0 N/A467 467 Baseline Revisions DC 03
115-Apr-09 15-Apr-09 15-Apr-09 26-Jul-10 571
50 0 N/A467 467 Baseline Final
DESIGN15-Apr-09 1-May-09 N/A
8 8
#VALUE! 16#VALUE!
Design Issues Schedule
2
19-Oct-0915-Apr-09
19-Oct-09 29-Sep-10571
112 65 171532 345 Update October 19, 2009
3
4-Dec-0915-Apr-09
4-Dec-09
25-Oct-10571
133
91 46558 325 Update December 04, 2009
35
3 25-Oct-10 133
3
4-Dec-09 15-Apr-09 4-Dec-09 9-Dec-10 571 221 136 0 603 370 Update December 04, 2009, with Glenwood
4
21-Jan-1015-Apr-09
21-Jan-10 15-Dec-10571
212 142 48609 328 January Update 2010
5 3-Mar-1015-Apr-09
3-Mar-10 27-Dec-10571
213
154 41621 299
February Update 2010
6 19-May-1015-Apr-09
19-May-10 27-Dec-10571
127
154 77621 222
May update 2010
7 2-Jul-1015-Apr-09
2-Jul-10 6-Dec-10571
134
133 44600 157
June Update 2010
8 28-Jul-1015-Apr-09
28-Jul-10 17-Dec-10571
185
144 26611 142
July Update 2010
IT15-Apr-09 28-Jul-10
14-Jan-11 577 185
172 0639 170
IT Claim with July Update
9 1-Oct-1015-Apr-09
1-Oct-10 10-Feb-11571
113
199 65534 266
September Update 2010
TANK15-Apr-09 3-Oct-10
10-Mar-11 576 114
227 2694 158
Day Tank Claim with Sept Update
10 3-Nov-1015-Apr-09
3-Nov-10 24-Feb-11571
82
213 31680 113
October Update 2010
11 10-Dec-1015-Apr-09
10-Dec-10 2-Mar-11571
62
219 37686 82
November Update 2010
12 15-Feb-1115-Apr-09
15-Feb-11 21-Feb-11571
18
210 67677 6
January Update 2011
13 18-Mar-1115-Apr-09
18-Mar-11 8-Apr-11571
6
256 31723 21
February Update 2011
14 26-Apr-1115-Apr-09
26-Apr-11 17-May-11571
6
295 39762 21
March/April Update 2011
Practice Triage Session
• Schedule Log
Chron
OrderFile Name Start Date Data Date Early Finish
Activity
Count
Critical
Activities Cum Delay
Update Window Size
(cd)
Project Duration
(cd)
Remain. Time
(cd)Notes
6-Jul-09 15-Apr-09 15-Apr-09 26-Jul-10 578 29 0 N/A 467 467 baseline DC 2003
6-Jul-09 15-Apr-09 15-Apr-09 26-Jul-10580 83 0 N/A
467 467 revised baseline DC Hodges 03
16-Jul-08 15-Apr-09 16-Jul-09 10-Aug-10578 61
1092
482 390 Revised baseline (Zero Progress)
9-Mar-0915-Apr-09 15-Apr-09 26-Jul-10 571
50 0 N/A467 467 Baseline Revisions DC 03
115-Apr-09 15-Apr-09 15-Apr-09 26-Jul-10 571
50 0 N/A467 467 Baseline Final
DESIGN15-Apr-09 1-May-09 N/A
8 8
#VALUE! 16#VALUE!
Design Issues Schedule
2
19-Oct-0915-Apr-09
19-Oct-09 29-Sep-10571
112 65 171532 345 Update October 19, 2009
3
4-Dec-0915-Apr-09
4-Dec-09
25-Oct-10571
133
91 46558 325 Update December 04, 2009
Note – Activity Count does not change within updates
36
3 25-Oct-10 133
3
4-Dec-09 15-Apr-09 4-Dec-09 9-Dec-10 571 221 136 0 603 370 Update December 04, 2009, with Glenwood
4
21-Jan-1015-Apr-09
21-Jan-10 15-Dec-10571
212 142 48609 328 January Update 2010
5 3-Mar-1015-Apr-09
3-Mar-10 27-Dec-10571
213
154 41621 299
February Update 2010
6 19-May-1015-Apr-09
19-May-10 27-Dec-10571
127
154 77621 222
May update 2010
7 2-Jul-1015-Apr-09
2-Jul-10 6-Dec-10571
134
133 44600 157
June Update 2010
8 28-Jul-1015-Apr-09
28-Jul-10 17-Dec-10571
185
144 26611 142
July Update 2010
IT15-Apr-09 28-Jul-10
14-Jan-11 577 185
172 0639 170
IT Claim with July Update
9 1-Oct-1015-Apr-09
1-Oct-10 10-Feb-11571
113
199 65534 266
September Update 2010
TANK15-Apr-09 3-Oct-10
10-Mar-11 576 114
227 2694 158
Day Tank Claim with Sept Update
10 3-Nov-1015-Apr-09
3-Nov-10 24-Feb-11571
82
213 31680 113
October Update 2010
11 10-Dec-1015-Apr-09
10-Dec-10 2-Mar-11571
62
219 37686 82
November Update 2010
12 15-Feb-1115-Apr-09
15-Feb-11 21-Feb-11571
18
210 67677 6
January Update 2011
13 18-Mar-1115-Apr-09
18-Mar-11 8-Apr-11571
6
256 31723 21
February Update 2011
14 26-Apr-1115-Apr-09
26-Apr-11 17-May-11571
6
295 39762 21
March/April Update 2011
Note – Activity Count does not change within updates
Practice Triage Session
• Chart Cumulative Delays directly from Schedule Log
37
Practice Triage Session
• Chart Cumulative Delays – Overlay known delay event timeframes
38
Practice Triage Session
• Chart Cumulative Delays – Label known delay timeframes
39
Practice Triage Session
• Chart Cumulative Delays
Period of possible concurrent submittal problems
40
Practice Triage Session
• Chart Cumulative Delays – Note any general issues/concerns
41
Shows two schedules with same data date & different EF dates
Could be acceleration or mistake, but worthy of investigation during triage?
Practice Triage Session
• Chart Cumulative Delays – Identify specific delay/acceleration concerns
No overall delay due to IT design
42
Practice Triage Session
• Chart Cumulative Delays – Identify specific delay/acceleration concerns
Period of possible concurrent production problems
43
Practice Triage Session
• Chart Cumulative Delays
No overall delay due to IT design
Period of possible
concurrent submittal
Period of possible concurrent production problems
44
Shows two schedules with same data date & different EF dates
concurrent submittal
problems
Practice Triage Session
• Chart Cumulative Delays
– Only provides very simplified overview for discussion
– Can show if analysis will be dealing with simple delay
– Helps expose more complicated analysis needs
• Acceleration/mitigation
• Concurrency
• Disruption?
45
Practice Triage Session
The Triage Session
• Open Floor to Q&A from Triage team
– Hold questions here for when we go through the specific
factors
46
• Now the Triage Team is ready to discuss the factors to
consider for the choice of methodology
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Contract Requirements
– Contract documents specify contemporaneous prospective TIAs
– Contract is silent on forensic analysis methodologies
47
– Contract is silent on forensic analysis methodologies
– Contract stipulates project duration
– Contract stipulates project schedule must run from NTP to CCD
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Purpose of the Analysis
– Quantify delays
– Determine causation
48
– Determine causation
– Assess responsibility for delays
– Review concurrency – potential overlapping responsibilities for delay
– Used for negotiations
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Source Data and Reliability
– Schedules appear OK
• Baseline approved
49
• Baseline approved
• Updates not approved or disapproved, but used for
contemporaneous project management
– Little information about project progress meetings
– Little correspondence from Contractor
– More correspondence from Owner but still light
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Size of the Dispute
– Claim entitlement believed by contractor
• $220,000
50
• $220,000
– Liquidated Damages risk - $600/day – 300j days delay
• $180,000
– Swing of risk costs
• $400,000
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Complexity of the Dispute
– High school project – straightforward construction
– Complexity of issues
• Foundations problem – simple
51
• Foundations problem – simple
• Pre-engineered building –may require some engineering
evaluation
• Submittals issue – simple
• Production issue – requires resource data
• IT redesign may require technical assistance
• Utilities changes - straightforward
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Budget for Forensic Schedule Analysis
– Contractor first reaction - doesn’t want to spend over $50,000
– Using $180/hour for Analyst
52
– Using $180/hour for Analyst
• Supports 7 weeks at that maximum cost
• Reduce max by 3 weeks for meetings, contingency
• Budget permits ~4 weeks of analysis
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Time Allowed for Analysis
– Contractor wants analysis done in 4 weeks – 20 days – ready to
meet with Owner
53
meet with Owner• 2 days - document review
• 1 day - data validation
• 8 days - time for research
• 1 day - meetings with the construction team for interviews
• 2 day - verification of facts in dispute
• 6 days - development of the analysis and associated edits
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Expertise of the Analyst and Resources Available
– Expert and team has experience in observational and modeled analyses
– No experience in subtractive modeling (sorry, Andrew)
54
– No experience in subtractive modeling (sorry, Andrew)
– Workload is moderate, lead analyst and staff available
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Forum for Resolution and Audience
– Analysis designed for negotiation with Owner and Owner’s CM
– Informal meeting, no rules
55
– Informal meeting, no rules
– Owner’s CM is knowledgeable about forensic analysis (OK, we know, just
take this on trust)
– Owner is generally fair if case can be proven, but bar for convincing Owner
is fairly high
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Legal or Procedural Requirements
– Moderate potential for need to go to litigation
– Contract calls for litigation, not arbitration
56
– Contract calls for litigation, not arbitration
– Mediation may be first step in path to litigation
Practice Triage Session
The Triage Session:
Factors to Consider in Choosing an Analysis Methodology
• Past History/Methods and What Method Opposition is Using
– Methodology
• CM uses forensic consultant who prefers additive modeling
57
• CM uses forensic consultant who prefers additive modeling
– Technical competence
• CM’s consultant and CM historically have fairly low level of
competence in forensic analysis
• Owner has minimum level of technical competence
– Results
• CM’s consultant has weak litigation success history
Practice Triage Session
The Triage Session:
Choosing an Analysis Methodology
• Discuss Elimination of Methodologies
– Lack of experience
• Eliminate MIP 3.8/3.9 Subtractive modeling (collapsed as-built)
• Questions
58
– How does negotiation venue affect choice?
• Can perform simpler analysis? How simple?
• Analysis must still be capable of expansion into litigation ready?
– Eliminate MIP 3.6 – Modeled additive single base (IAP)
» Ignores changing nature of critical path
» Cannot show concurrency
» Will likely show very different results than other methods
» Highly unlikely to prevail in court
Practice Triage Session
The Triage Session:
Choosing an Analysis Methodology
• Discuss Elimination of Methodologies
– How does opposition consultant’s preference for additive modeling affect?
• More likely to choose additive modeling? - working in same
method
• Less likely to choose additive modeling? – prefer not to get into
59
• Less likely to choose additive modeling? – prefer not to get into
methodology comparison arguments
Practice Triage Session
The Triage Session:
Choosing an Analysis Methodology
• Discuss Elimination of Methodologies
– What about opposition’s weak history?
• Use of MIP 3.6 Modeled additive multi-base (Retro TIA)
– Eliminate modeled additive multiple base (MIP 3.7)
» Document availability and validation need similar to MIP 3.3/3.4 (CPA)
60
» Document availability and validation need similar to MIP 3.3/3.4 (CPA)
» Cannot show concurrency or pacing
» Modeled approach more subjective than observational
» Increases challenges over observational approaches
» Takes more time and cost more than observational
Practice Triage Session
Choosing an Analysis Methodology
• Recommend Methodology
– Methodologies surviving first elimination round
• MIP 3.1/3.2 – Observational static gross/periodic (APAB)?
• MIP 3.3/3.4 – Observational dynamic as-is/split (CPA)?
• MIP 3.5 – Observational dynamic recreated (Modified CPA)?
– General methodology type discussion
61
– General methodology type discussion
• Unlikely to need to recreate updates since they were used
– Eliminate MIP 3.5
• Presence of usable/contemporaneous updates
– Eliminate MIP 3.1/3.2
• Activity count did not change in updates
– Eliminate MIP 3.4 – likely no logic changes – can still choose later
Practice Triage Session
The Triage Session:
Choosing an Analysis Methodology
• Recommend Methodology
– Observational
• Specific implementation
– Choose MIP 3.3 – Observational dynamic as-is (CPA)
62
– Choose MIP 3.3 – Observational dynamic as-is (CPA)
• Challenges to implementation– “To yield accurate results, critical aspects of the contemporaneous schedule updates used in
the analysis must be validated as accurate both in reported progress to date and in the
network’s representation of contemporaneous means and methods”
– “ The method is strengthened if it can be shown that the project participants considered or
used the contemporaneous schedules in constructing the project”
– “Cannot be implemented if contemporaneous schedule updates do not exist “
• Will need to validate the updates during implementation for both the as-built
and current as-planned condition
USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE USE OF A CLAIMS TRIAGE WORKSHOP TO CHOOSE
AN ANALYSIS METHODAN ANALYSIS METHOD
CDR 637
Questions?
Chris Carson, PSP, CCM, PMP
Robert Kelly, Jr., PSP, CFCC, PMP