solar rfs bid document
TRANSCRIPT
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 1
REQUEST FOR SELECTION
FOR
GRID CONNECTED
SOLAR POWER PROJECTS Bid No.01/2013/CE-IPC-APPCC/Vidyut Soudha/Khairatabad/Hyderabad
ISSUED BY
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED (APTRANSCO)
VIDYUT SOUDHA HYDERABAD 500082
Tele fax: 040 - 23393304,
Email - [email protected] Website: www.aptransco.gov.in
January
2013 `
Important Dates
Last date of submission of bids 07 Feb 2013
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 2
Section 1 INTRODUCTION & BACKGROUND
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 3
Section 1 1.0 Introduction and Background
1.0.1 A solar capacity of 1000 MW is envisaged by floating this RfS under
competitive bidding route to setup Solar Power Projects in the state at
various Locations to have distributed energy generation as per the
policy announced by GoAP vide G.O.Ms No.46, dated 27.11.2012.
1.0.2. The main objective of this RfS is to evacuate the solar power at any of
the EHT substations (“Location(s)”) or at any 33/11 kV substations
connected under each identified EHT substation/Location notified in
the Annexure –A with a capacity limitation for easy and immediate
evacuation of the solar power. As such, the Bidder has the flexibility to
choose the project site at an EHT substation and/or any of the 33/11 kV
substations under the corresponding EHT substation.
1.1. The Andhra Pradesh State Electricity Regulatory Commission (“APERC”)
issued Regulation No.1 of 2012, mandating Renewable Power Purchase
Obligation and its Compliance in accordance with Sections 61, 66 and
86(1)(e) & 181 of the Electricity Act, 2003, by the DISCOMs, Open Access
Consumers, Captive Consumers in the State, to consume a quantum of power
not less than 5% of their consumption from RE sources. The said regulation
also mandated to purchase a minimum of 0.25% solar power out of the 5%
RPPO specified from RE sources.
1.1.1 The distribution licensees (“DISCOM”) were incorporated in the state of
Andhra Pradesh, under the provisions of the Companies Act, 1956, with the
main objective of performing power distribution functions in the state, in
accordance with A.P.Electricity Reform Act 1998, by procuring power from
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 4
different sources and supplying electrical energy to the needy consumers
in the state.
1.2. The APTRANSCO has been designated by GoAP in the Solar Power Policy
issued Vide G.O.Ms.No.46,dated:27.11.2012 for inviting RfS requests from
interested Companies, and/or Bidding Consortium and or any Consortium
Member thereof (Bidders) for selection of successful bidder(s) for setting
up of Solar Power Projects through a competitive bidding process as per
Section-63 of the Electricity Act,2003. The responsibility of the successful
Bidder(s) is to supply power to the DISCOM(s) as per terms & conditions of
Power Purchase Agreement (“PPA”), issued under this RfS, which would be
executed and signed between DISCOM(s) and successful bidder(s), for a
period of 20 years.
1.3 However, under this RfS, Developer shall not be eligible to obtain
Renewable Energy Certificates (“REC”) for the energy generated from
the solar power plant set up by him.
1.4 Total capacity of the project
This RfS is floated for inviting competitive bids for setting up of Solar
Photo Voltaic/Solar Thermal Projects subject to the maximum permissible
capacity at specified Locations as mentioned in Annexure-A.
1.5 Project si te:
The Developer is at his liberty to identify and acquire the suitable land
required for the Project near the EHT substation or associated 33/11 kV
substations. The Developer shall be responsible for getting all statutory
clearances from the concerned departments.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 5
1.5.1 Technology:
The Bidder is at his liberty to choose any available technology, subject to
fulfillment of technical criteria as defined in Section 3C, suitable for
setting up of Solar Power Projects in the specified Locations as mentioned
in Annexure-A.
1.6. Scope of the project:
The main scope of the Project shall mean and include,
a) Designing, constructing, erecting, testing and commissioning of the
solar power plant(s) including all necessary electrical equipment for
metering, transmission and evacuation of electricity to the
nearest 33/11kV or 132/33kV substation and supply of contracted
capacity to DISCOMs.
b) Operation and Maintenance of the aforesaid solar projects including
associated evacuation lines till Interconnection Point for the period
of the PPA.
c) Performance and fulfillment of all other obligations of the Developer
as per this RfS and entering into a Power Purchase Agreement
(“PPA”) and matters incidental thereto or necessary for the
performance of any or all of the obligations of the Developer.
d) Installation of all necessary protection devices to protect the power
plant and connected lines from lightning, sudden surges in voltage
and current and to ensure safety of the grid to which the Project is
connected. The Developer shall also ensure protection of human
lives and equipment likely to be endangered due to the installed
solar power plant.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 6
1.7 Issue of RFS:
The eligibility criteria for the qualification of Bidders for Bid submission are
indicated in this RfS.
1.8 The RfS can be downloaded from http//tender.eprocurement.gov.in. The
same will be available in website of APTRANSCO (www.aptransco.gov.in)
for information.
1.9 Receipt of Bid:
Bids shall be submitted via e-procurement platform and Bidders shall
obtain all necessary keys from Andhra Pradesh Technology Services (APTS)
and can obtain assistance from Vayam Technologies, Panjagutta, Opp.
NIMS, Hyderabad. Phone Number: 040 - 44426250/251 (Timings 9:00 AM to
9:00 PM).
Bidder shall have to pay the transaction fee of Rs.25,000 + Service tax as
applicable, to APTS.
1.10 Steps for E-Procurement: i) Bidder shall obtain digital signature from APTS (Phone Number: 040
23224283/ 0305).
ii) Using the digital signature, bidder shall register himself on the AP
procurement website (URL: https://tender.eprocurement.gov.in).
iii) After successful registration, Bidder shall send a mail confirming the
registration details to Vayam Technologies at:
iv) The user ID created by the Bidder in the previous step will be validated
by Vayam Technologies after which the Bidder can upload the bid
documents using the user ID created on the e-procurement website.
In addition to the bid on e-procurement the following should be sent in
hard copy to the following address:-
Chief Engineer/IPC/APPCC,401/A, Vidyut Soudha, Khairtabad, Hyderabad. Email: [email protected], Telefax: 040-23393304.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 7
Details of processing fee and bid security:
I. Processing fee as per 3.2 (b) in the form of DD or online payment through
RTGS. Insufficient processing fee paid by the bidder through RTGS or DD is
liable for rejection of bids and the scanned copies of DD should be
uploaded.
DD in original containing the Bidders name (on the cover and backside of
the DD, if applicable) - are to be submitted in a sealed cover before the
due date as mentioned to the above address.
II. EMD (Bid security) as per 3.2(c) in the form of BG (as per Format 6.14) shall
be uploaded in the bid. Insufficient bid security and insufficient validity
(120 days) is liable for rejection of the bids.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 8
List of Abbreviations APERC AP Electricity Regulatory Commission APPCC Andhra Pradesh Power Coordination Committee APTRANSCO Transmission Corporation of Andhra Pradesh BG Bank Guarantee BIS Bureau of Indian standards CDM Clean Development Mechanism CEA Central Electricity Authority CERC Central Electricity Regulatory Commission DD Demand Draft DISCOM Power Distribution Company Limited of AP
EMD Earnest Money Deposit GoI Government of India GoAP Government of AP HV High Voltage IEC International Electro-technical Commission
INR Indian Rupees kV Kilo Volt L.C. Letter of Credit LLC Limited Liability Company LLP Limited Liability Partnership LoI Letter of Intent MNRE Ministry of New and Renewable Energy MU Million Units MVAR Mega Volt-Ampere Reactive MW Mega Watt NREDCAP New and Renewable Energy Development
Corporation of AP PPA Power Purchase Agreement PV Photo Voltaic RE Renewable Energy REC Renewable Energy certificate RFID Radio Frequency identification RfS Request for Selection ROC Registrar of Companies
RPPO Renewable Power Purchase Obligation
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 9
SBI State Bank of India SCADA Supervisory Control and Data Acquisition SGC State Grid Code SLDC State Load Dispatch Centre SPD Selected Solar Power Developer STU State Transmission Utility
USD United States Dollars VAR Volt-Ampere Reactive
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 10
Section 2 Definitions
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 11
Section-2 2. Definitions “Affiliate” shall mean a Company that, directly or indirectly,
i) controls, or
ii) is controlled by, or
iii) is under common control with, a Company developing a Project or a Member
in a Consortium developing the Project and control means ownership
by one Company of at least 26% (twenty six per cent) of the voting rights of
the other Company;
“Performance Bank Guarantee (BG)” shall mean a bank guarantee (BG) issued
by banks, listed in the Annexure 2, to guarantee timely and satisfactory
completion of a project by a Developer.
“Benchmark Price” shall be decided by a Committee after opening of the
financial bids. It will be the same for all Locations.
“Bid” shall mean the Non-Financial Bid and the Financial Bid submitted by the
Bidder, in response to this RfS, in accordance with the terms and conditions
hereof.
“Bidder” shall mean Bidding Company or a Bidding Consortium submitting the
Bid. Any reference to the Bidder includes Bidding Company/ Bidding Consortium
/ Consortium, Member of a Bidding Consortium including its successors,
executors and permitted assignees and Lead Member of the Bidding Consortium
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 12
jointly and severally, as the context may require. After the selection of
successful bidder, the successful bidder will be referred as “Developer”.
“Bidding Company” shall refer to such single company that has submitted
the response in accordance with the provisions of the RfS.
“Bidding Consortium” or ”Consortium” shall refer to a group of companies that
has collectively submitted the response in accordance with the provisions of this
RfS.
“Contracted Capacity" shall mean the capacity allocated at each Location to
the Solar Power Developer as described in Clause 3.7.
“Contract Performance Bank Guarantee” shall refer to the bank guarantee to
be produced by Developer/Successful Bidder to the concerned DISCOMs on the
difference of L1 Tariff and Committee decided Benchmark Price to the tune of
amount of rupees equivalent to the energy that would be generated for 3 [three]
years at CUF (capacity utilization factor) of 25% from the plant.
If the difference between the Benchmark Price and the Tariff quoted by the
successful bidder is less than or equal to 5% of the Benchmark Price, then the
CPBG is not required to be submitted.
“Chartered Accountant” shall mean a person (with a minimum experience of 5
years) practicing in India or a firm (in operation for at least 5 years) whereof all
the partners are practicing in India as a Chartered Accountant(s) within the
meaning of the Chartered Accountants Act, 1949.
“Commercial Date of Operation” (COD) shall mean with respect to each
generating unit, the date on which such generating unit is declared by the
Developer to be operational, provided that the Developer shall not declare a
generating unit to be operational until such generating unit has completed its
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 13
standard procedures.
“Company” shall mean a body corporate incorporated in India under the Companies Act, 1956. ”Controlling shareholding” shall mean more than 50 % of the voting rights in the Company/ Consortium. “Capacity Utilization factor” (“CUF”) shall have the same meaning as provided
by APERC from time to time. Till such time, it shall have the same meaning as
provided in CERC (Terms and Conditions for the Tariff determination from
Renewable Energy Sources) Regulations, 2012 and as amended from time to
time.
“Developer” shall have the same meaning as “Successful Bidder” as defined
below in this RfS.
“Financial Closure” or “Project Financing Arrangements” shall mean
arrangements of necessary funds by the Developer either by way of
commitments of funds by the company from its internal resources and / or tie up
of funds through a bank / financial institution by way of sanction of a loan.
“Group Company” of a Company shall mean (i) a Company which, directly or
indirectly, holds 10% (ten per cent) or more of the share capital of the
Company or (ii) a Company in which the Company, directly or directly, holds
10% (ten per cent) or more of the share capital of such Company or (iii) a
Company in which the Company, directly or indirectly, has the power to direct
or cause to be directed the management and policies of such Company
whether through the ownership of securities or agreement or any other
arrangement or otherwise or (iv) a Company which, directly or indirectly, has
the power to direct or cause to be directed the management and policies of the
Company whether through the ownership of securities or agreement or any other
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 14
arrangement or otherwise or (v) a Company which is under common
control with the Company, and control means ownership by one Company of at
least 10% (ten per cent) of the share capital of the other Company or power to
direct or cause to be directed the management and policies of such
Company whether through the ownership of securities or agreement or any
other arrangement or otherwise.
Provided that a financial institution, scheduled bank, foreign institutional
investor, non-banking financial Company, and any mutual fund shall not be
deemed to be Group Company, and its shareholding and the power to direct or
cause to be directed the management and policies of a Company shall not be
considered for the purposes of this definition unless it is Project Company
or a Member of the Consortium developing the Project.
“Interconnection Point/Injection Point/ Metering point” shall mean the point
or points where the Project and the DISCOM’s grid system are interconnected at
APTRANSCO/DISCOM substation. The Developer shall install main and check
meters of static type of 0.2 class accuracy at interconnection point. Besides the
above, the Developer shall install a separate standby meter of same accuracy as
that of main and check meters in C&R panel as per CEA metering regulations, to
account the energy in case of failure of main and check meters.
Metering arrangements shall be done in accordance with APTRANSCO/DISCOMs
procedures in vogue at the specified interconnection point by providing specified
meters approved by DISCOMs where the power would be injected into the GRID.
“L1 bidder” shall mean the shortlisted Bidder who quotes the lowest
Tariff per unit (kWh) of electricity per Location.
“L2 bidder” shall mean the shortlisted Bidder who quotes the second lowest
Tariff per unit (kWh) of electricity per Location.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 15
“L3, L4, L5.....Ln bidder” shall mean the shortlisted Bidder quoting the 3rd, 4th, 5th ......nth lowest Tariff per unit (kWh) of electricity per Location. “L1 Tariff” shall mean the lowest quoted Tariff in Indian Rupees per unit (kWh)
of electricity per Location.
“Location” shall mean the EHT substations as per the list specified in
Annexure – A.
Any Bidder willing to bid at a specific 33/11 kV substation under the respective
EHT substation should refer to the corresponding EHT substation as a Location.
“Lead Member of the Bidding Consortium” or “Lead Member” shall mean the
member of the Consortium nominated by the other members of the Consortium
to be the Lead Member of the Consortium.
“Letter of Intent” or “LoI” shall mean the letter issued by APTRANSCO
to the Selected Bidder for the awarding of the Project.
“Limited Liability Partnership” of “LLP” shall mean a Company governed by Limited Liability Partnership Act-2008. “LLC” shall mean Limited Liability Company; “Maximum Cumulative Capacity” shall mean the maximum capacity the Bidder
will be allowed to bid for across the Locations. This capacity is limited to 200
MW for a Bidder, Affiliates, Parent Company, Group Companies and the Ultimate
Parent Company. “Member in a Bidding Consortium” or “Member” shall mean each Company in
a Bidding Consortium.
“Month” shall mean only 30 days for all transactions under this RfS.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 16
“Parent” shall mean a Company, which holds at least 26% equity either directly
or indirectly in the Bidding Company or in a Member of a Consortium developing
the Project.
“Performance bank guarantee” shall refer to bank guarantee to be produced by
the successful bidder to the concerned DISCOMS to the total tune of Rs 10 (ten)
Lakhs per MW in three different bank guarantees i.e. Rs 2(two) lakhs per MW,
Rs 3 (three) lakhs per MW and Rs 5 (five) lakhs per MW for a validity period of 22
months from the date of signing of PPA. However the same will be returned after
commissioning of the solar project.
“Power Purchase Agreement (PPA)” shall mean the power purchase agreement
between Developer and DISCOM for selling the solar power.
“Procurer(s)/DISCOM” shall mean the DISCOMs in the state concerned based on
geographic area of location.
“Project(s)” shall mean the solar power plant set up by the Developer. “Project Company” shall mean the company incorporated by the bidder as per the Indian Companies Act, 1956 in accordance with clause 3.5. “Scheduled COD” shall mean 12 months from the date of signing of this
Agreement (PPA).
“Selected Bidder or Successful Bidder” shall mean the Bidder selected by
APTRANSCO pursuant to this RfS to set up the Project and supply electrical
output as per the terms of PPA. This Bidder is also referred to as the
“Developer”.
“Solar Power Project(s)” shall mean either a Solar PV Power Project or a Solar
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 17
Thermal Power Project.
“Solar PV Project” shall mean the Solar Photo Voltaic Power Project that uses
sunlight for direct conversion into electricity through photo voltaic technology.
“Solar Thermal Power Project” shall mean the solar thermal power project
that uses sunlight through Concentrated Solar Power Technology (based on
either line focus or point focus principle) for conversion into heat/steam which
can be used for producing electricity.
“Statutory Auditors” shall mean a reputable firm of Chartered Accountants
acting as the Statutory Auditors of the Company under the provisions of the
Companies Act, 1956.
”Tariff” shall mean the quoted price per kWh of energy delivered from the
proposed solar power plant to the grid by the Bidder in response to the RfS per
Location.
“Technology Partner” shall mean any entity from which the Bidder proposes to
take technology support.
“Ultimate Parent” shall mean a Company, which owns at least twenty six per cent (26%) paid up equity capital in the Bidding Company or Member of a Bidding Consortium either directly or indirectly in the Parent and Affiliates.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 18
Section 3
INFORMATION AND
INSTRUCTIONS TO BIDDERS
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 19
Section 3
3. Information and Instruction to Bidders
3.1 Total capacity offered:
Initially, it is proposed to invite prospective Bidders to setup about 1000
MW capacity Solar Power Projects based on the available solar technology
as per the AP Solar State Policy vide G.O. Ms.No. 46, dated 27.11.2012
under competitive bidding route.
Sl.No. Interfacing/grid substation (interconnection point)
Voltage level Maximum capacity
1 33/11 kV 33 kV 1-5 MW* 2 132/33 kV 33 kV 1-10 MW* 3 132/33 kV 132 kV 10-20 MW*
*The above maximum capacity shall be limited to the capacities specified
in specific Locations as per the Annexure-A. The maximum permissible
capacity at each Location is as mentioned in Annexure A. The Bidder can
choose any 33/11 kV or 132/33 kV substation under each Location, subject
to the maximum permissible capacity mentioned under that Location, for
the purpose of Bid. Any quoted capacity by the Bidder shall not be less
than 1 MW.
For eg:-
Maximum permissible capacity at Chilakapalem (named as Location as per
this RfS document) – 5 MW according to Annexure A.
Thus solar capacity at Chilakapalem EHT substation and all associated
33/11 kV substations cannot exceed 5 MW.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 20
Each Bidder will be allowed to participate in the competitive bid for a
maximum capacity at the identified Locations in Annexure to this RfS as
indicated below:
1. At 33/11 kV Substation: 1 to 5MW capacity of solar projects at
evacuation voltage of 33kV. A maximum of 5 MW are
permitted at 33/11kV substation. However the bidder can
quote based on the availability as per the identified
respective substations only.
2. At 132/33 kV Substation: 1 to 10 MW of solar projects at 33kV
connection voltage level and 10 to 20 MW of solar projects at
132 kV evacuation voltage level. However the bidder can
quote based on the availability as per the identified
respective substations only.
Note: The capacity of the Project in MW is the installed capacity of the
Project/ rated power output (AC) from the solar power plant, which
can be scheduled at any point of injection to the grid during the day
time.
Further, the Bidder has to visit the proposed Location(s) as mentioned in
Annexure A and assess the suitability of distribution /EHT substations
for evacuation of solar power, and ascertain the feasibility for
evacuation before quoting the bid.
3.2 Obtaining RfS Document and Processing Fees
a) RfS is also available in the website Error! Hyperlink reference not valid.
information.
b) Bidders are required to submit their bid for each Location, along with a
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 21
non-refundable processing fee of Rs 2.00 lakhs for each Location in the
form of Demand Draft payable to APPCC A/c. No. 52117479223 at
Hyderabad or the same by online payment through RTGS (RTGS details
as per Annexure – C for RTGS). Bid submitted without or insufficient
processing fee shall be liable for rejection without any intimation.
c) Bid security: EMD in the form of BG as follows:
Rs. 2 lakhs/MW BG in favor of Chief Engineer/IPC/APPCC/APTRANSCO
according to the format specified in 6.14. with a validity period of 90
days from the date of bid submission and claim period of one more
month over and above validity period. EMD will be returned to all
unsuccessful bidders within 15 days of issue of LOI.
Insufficient/Part Bid security submitted by the bidders will be
rejected without any intimation.
3.3 Proposal for Short-listing of Projects
Bidders shall submit response to Request for Selection (RfS) for
establishment of Solar Power Projects as per the terms & conditions
detailed herein.
3.4 Number of response to RfS by a Company
The Company, including its Parent, Affiliate or Ultimate Parent or any
Group Company, or a Bidding consortium will be allowed to submit only
one RfS upto capacity mentioned in Clause 3.1 per each Location as
mentioned in Annexure-A. Alternate bids are prohibited in each
Location.
The total capacity of Projects to be Bid for by a Company including its
Parent, Affiliate or Ultimate Parent-or any Group Company shall be
limited to 200 MW (Maximum Cumulative Capacity) across Locations.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 22
The capacity Bid for across Locations must be indicated in the Format
6.11.
3.5 Qualification Requirements:
Shortlisting of the Bidders will be based on meeting the
qualification requirements specified for net worth, technical criteria
and connectivity with grid as given below:
A. Companies eligible for participation:
i) Companies incorporated in India under the Companies Act 1956.
ii) A foreign company can also participate individually or as a Member of
Consortium at RfS stage. But before signing of PPA, keeping the original
shareholding unchanged, it has to be incorporated as an Indian Company
registered under the Companies Act 1956.
iii) Limited Liability Partnership (LLPs)/ Limited Liability Companies (LLCs)
are not eligible for participation.
B. Financial Criteria
i) Net worth:
The net worth of the Bidder should be equal to or greater than the
value calculated at the rate of Rs 1 Crore per MW (across all Locations
bid for)
Illustration:-
A Bidder bids for following Locations :-
Total Net worth requirement: (10 + 5 + 8 + 2 + 1 ) * 1 Cr = 26 Cr.
Bids Capacity
Offered(MW) Location 1 10 Location 2 5 Location 3 8 Location 4 2 Location 5 1
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 23
Computation of net worth shall be based on unconsolidated audited
annual accounts of the Company. The Company would thus be required
to submit annual audited accounts comprising of audited balance
sheet, profit and loss account, notes and cash flow statement for
the FY 2011-12 and three years preceding it, along with certificate
duly stamped and signed from a Statutory Auditor/Chartered
Accountant to demonstrate eligibility criteria. In case of a foreign
company, the company needs to submit annual account certificate from
a Chartered Accountant or Statutory Auditor for the immediate previous
accounting year.
ii) For companies which are newly incorporated, the net worth criteria
should be met on any date within seven days prior to the date of
submission of RfS document by the Bidder. To demonstrate fulfillment of
the criteria, the Bidder shall submit a certificate from a Chartered
Accountant certifying the net worth on the date within seven days prior
to submission of RfS. Further, the Bidder shall submit the unaudited
financial statements of the Company for the date on which the certificate
of Chartered Accountant has been obtained.
Note:
For the qualification requirements, if data is provided by the Bidder in
foreign currency, equivalent rupees of net worth will be calculated
using bills selling exchange rates(card rates) INR of State Bank of India
prevailing on the date of closing the accounts for the respective
financial year or the date as applicable to newly incorporated
companies as certified by the Bidder’s banker, and on the date for
indicating the net worth as applicable as per the provisions of the RfS.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 24
Net Worth
=Paid-up Share Capital
Add: Free Reserves
Subtract: Revaluation Reserves
Subtract: Intangible Assets
Subtract: Miscellaneous Expenditures to the extent not written off and carry forward losses
Share premium will form an integral part of Net Worth provided it is realized in cash or cash equivalents.
Paid-up Share Capital will include:
a) Paid-up equity share capital and
b) Fully, compulsorily and mandatorily convertible Preference shares and
c) Fully, compulsorily and mandatorily convertible Debentures.
iii) For the purpose of meeting financial requirements, only
unconsolidated audited accounts shall be used. However, audited
consolidated annual accounts of the Bidder may be used for the purpose
of financial requirements provided, the Bidder has at least twenty six
per cent (26%) equity in each Company whose accounts are merged in
the audited consolidated account and provided further that the
financial capability of such Companies (of which accounts are
being merged in the consolidated account) shall not be considered
again for the purpose of evaluation of any bid.
iv) Existing companies
The computation of net worth shall be based on unconsolidated
audited annual accounts of the company. The Bidder would be required
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 25
to submit annual audited accounts for the last four financial years viz
2008-09, 2009-10 and 2010-11, 2011-12. If the period of existence of
the Company is less than four years, then annual audited accounts
should be submitted starting from the year of incorporation. In case of a
foreign company, the same for calendar years - 2009, 2010, 2011,
2012 or the accounting year as adopted by the company and
acceptable as per laws of the respective Country should be
submitted. Net worth of individuals/ Directors, Association of
Persons, Partnerships Firms, section 25 companies of the Companies
Act, 1956 etc., shall not be considered for computation of net worth of
Bidders.
In case of existing Companies/ Consortiums, the net worth criteria shall
be met as on day within seven days prior to the last date of submission
of response to RfS by the Bidding Companies/ Consortium. To
demonstrate fulfillment of the criteria, the Bidder shall submit a
certificate from a Chartered Accountant certifying the availability of
net worth on the date within seven days prior to submission of
response to RfS along with a certified copy of audited Balance Sheet,
Profit and Loss account, Schedules and Cash Flow Statement supported
with Bank statements. All pages of the above financial documents
should be signed and stamped by the concerned Chartered Accountant
as token of their endorsement of the document as well as certification.
Net worth, bank statement and shareholding pattern
indicating controlling shareholding should be submitted as on any date
within 7 days prior to submission of the bid.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 26
Newly Incorporated Companies
For a newly incorporated Company relying solely on its credentials,
where the annual accounts have not been prepared, the net worth
criteria should be met on any day within seven days prior to the last
date of submission of response to RfS by the Bidding
Company/Consortium. To demonstrate fulfillment of the criteria, the
Bidder shall submit a certificate from a Chartered Accountant
certifying the availability of net worth on any day within 7
days prior to submission of response to RfS along with a certified
copy of balance sheet, profit and loss account, schedules and cash
flow statement supported with bank statements.
All pages of the above financial documents should be signed and
stamped by the concerned Chartered Accountant as token of their
endorsement of the document as well as certification.
v) If the response to RfS is submitted by a Consortium the financial
requirement shall be met collectively by all members in the Bidding
Consortium. The financial requirement to be met by each member
of the Consortium shall be computed to the equity commitment
made by each of them in the Project Company. For computation of net
worth of members methodology as provided under Para (i) above shall
be followed. Any Consortium, if selected, shall, for the purpose of
supply of power to DISCOMs of that area, incorporate a Project
Company with equity participation by Members in line with Consortium
agreement ( to be submitted along with RfS) before signing the PPA
with DISCOM i.e. the Project Company incorporated shall have the same
share holding pattern as given at the time of RfS. This shall not change
till the signing of PPA.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 27
For newly incorporated Company the bidder may seek
qualification on the basis of financial capability of Its Parent, Ultimate
Parent and / or its Affiliate (s) for the purpose of meeting the
qualification requirements.
Note:
i) Whether or not financial resources of Parents and/ or
Affiliates(s) are relied upon to achieve the required net worth,
the required net worth has to be infused in the Project
Company before signing of PPA. The bank statement will also
be required to be submitted before 7 days of signing of PPA.
For exhibiting shareholding pattern indicating
the controlling shareholding a certificate from the Chartered
Accountant should be submitted as on any date within 7 days
prior to the date of submission of the bid document.
ii) It is not necessary to have the Technology Partner at RfS stage.
Further it is also not necessary for the Technology Partner to
have an equity stake in the Bidding Company/ Consortium.
iii) Net worth, bank statement and shareholding pattern
indicating controlling shareholding should be submitted as on
any date within 7 days prior to submission of the bid.
C) Technical Criteria
The Bidder shall deploy commercially established solar technologies.
The Bidder is required to undertake to furnish evidence of meeting the
above eligibility criteria. The undertaking shall be as per enclosed
Format – 6.7. Detailed technical parameters for the project are given
in Annexure 1.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 28
D) Connectivity with Grid Substation
(I) The plant should be designed for interconnection with the distribution/
transmission network of DISCOM or APTRANSCO at voltage level of 33 kV
or 132 kV. In this regard the Bidder shall submit Confirmation of
Connectivity in Format 6.8 along with the RfS. Letter from concerned
DISCOMs/ state transmission utility, confirming that the utility will
provide connectivity to the proposed Solar Power Plant should be
submitted within seven days prior to signing of the PPA.
(II) The responsibility of getting connectivity with the distribution/
transmission system will lie with the Developer. Transmission of power
to the point of interconnection at substation of DISCOM/APTRANSCO
where the metering is done shall be the responsibility of the
Developer at its own cost. The installation of equipments for metering
will be the responsibility of the Developer as per Central Electricity
Authority (CEA) norms.
(III) The Interconnection Line from Project switchyard to the designated
substation has to be constructed and maintained by the Developer at his
cost. The entire cost of transmission including cost of construction of
lines, metering equipment, losses, supervision charges etc., from the
Project up to the Interconnection Point shall be borne by the Developer
and shall not be reimbursed by DISCOM(s). Right of way (RoW)
acquisition for laying of the interconnection lines shall lie with the
Developer.
(IV) The accounting of energy delivered by the solar project at the
Interconnection Point will be maintained by the STU/SLDC/ DISCOM.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 29
3.6 Short-listing of Bidders
Only those responses to RfS which are received by due date and time
will be considered for evaluation. The responses will be evaluated based
on the qualification requirements and all those responses meeting the
qualification requirements shall be short listed.
3.7 Selection process of the Bidders:
a) Selection of Bidders will be based on lowest quoted Tariff per
unit of electricity. Bidders must bid for each of the Locations
separately.
b) The Bidders will be required to submit Financial Bid in 6.12
quoting their Tariff up to four (4) decimal points for the entire
tenure of the agreement.
c) After opening of the commercial bids, the Bidders will be listed in
the order of their quoted Tariff as L1, L2, L3……………….Ln, and L1
Tariff will be finalized for each Location. Only L1 Bidder in
each Location will be offered the project in that particular
Location.
d) The Developer shall submit a Contract Performance Bank
Guarantee (CPBG), if applicable, to the concerned DISCOM after
intimation and before the issuance of LOI.
e) In case any Developer does not communicate acceptance of the LoI
within 10 days from the date of issue of the LoI (excluding the
date of issue), then his EMD (Bid security) and CPBG will be
forfeited.
f) In the eventuality of a tie in the bidding process in a particular
Location, all the Bidders quoting the lowest Tariff will be
awarded the Project subject to maximum capacity per Location.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 30
In case the maximum capacity at the Location is exceeded, then
the prorated capacity shall be awarded in the ratio of offered
capacity by the Bidders subject to technical feasibility at the
Interconnection Point of the substation. The decision of
APTRANSCO/DISCOM shall be considered as final in this matter.
g) The capacity thus allocated to the Developer will be referred to
as Contracted Capacity (“Contracted Capacity”).
3.8 Execution of Power Purchase Agreement
The PPA shall be executed between the Selected Bidder(s) and
DISCOM(s) after acceptance of LOI by the Bidder. Power Purchase
Agreement will be valid for tenure of 20 years from the date of
scheduled COD or from actual COD in case of delay, subject to clause
3.20.
3.9 Purchase of Power
DISCOM, at any time during a contract year, will purchase electricity at
the L1 Tariff from the Developer up to the ceiling CUF of 25%, beyond
which electricity will be purchased at a flat rate of Rs 3 / (kWh) unit for
the entire agreement period.
3.10 Submission of Response to RfS by the Bidder The response to RfS shall contain the following:
1. Bid submission shall be through e-procurement platform.
Steps for E-Procurement: i) Bidder shall obtain digital signature from APTS (Phone Number: 040
23224283/ 0305).
ii) Using the digital signature, bidder shall register himself on the AP
procurement website (URL: https://tender.eprocurement.gov.in).
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 31
iii) After successful registration, Bidder shall send a mail confirming
the registration details to Vayam Technologies at:
iv) The user ID created by the Bidder in the previous step will be
validated by Vayam Technologies after which the Bidder can upload
the bid documents using the user ID created on the e-procurement
website.
2. Covering letter as per Format 6.1.
3. In case of a Bidding Consortium, Power of Attorney in favor of the Lead
Member issued by other Members of the Consortium shall be provided in
original as per format 6.2. In the event of any Member of the Bidding
Consortium (other than Lead Member) is a foreign entity; it may submit
Board Resolutions in place of Power of Attorney for the purpose of
fulfilling the requirements under this Clause. Provided that such Board
Resolution shall be supported under this unqualified opinion issued
by the legal counsel of such foreign entity stating that the Board
Resolutions are in compliance with the applicable laws of respective
jurisdiction of the issuing Company and the authorizations granted
therein are true and valid.
4. Bidders are required to submit their RfS document along with a non-
refundable processing fee
I. Processing fee as per 3.2 (b) in the form of DD or online payment
through RTGS. Insufficient processing fee paid by the bidder through
RTGS or DD is liable for rejection of bids and the scanned copies of DD
should be uploaded.
DD in original containing the Bidders name (on the cover and backside of
the DD, if applicable) - are to be submitted in a sealed cover before the
due date as mentioned to the above address.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 32
EMD (Bid security) as per 3.2(c) in the form of BG (as per Format 6.14)
shall be uploaded in the bid. Insufficient bid security and insufficient
validity (120 days) is liable for rejection of the bids.
5. CPBG as per the format 6.13.
6. Performance Bank Guarantee to be submitted at the time of signing of
PPA in form of Bank Guarantee as per Format 6.3.
7. Board Resolutions, as per prescribed formats enclosed as Format 6.4 duly
certified by the Company Secretary or the Director of the relevant
Bidder, as applicable to the Bidder and mentioned hereunder:
a. Board resolution from the Bidding Company or the Lead Member of
the Consortium, as the case may be in favor of the person signing
the response to RfS:
b. Board Resolution from the Bidding Company committing one
hundred per cent (100%) of the equity requirement for the
Project / Board Resolutions from each of the Consortium
Members together in aggregate committing to one hundred per
cent (100%) of equity requirement for the Project (in case of
Bidding Consortium); and
c. Board Resolutions from Parent and / or Affiliate (whose
credentials were used it the response to RfS), of the Bidding
Company / any Member of the Bidding Consortium, undertaking to
invest the entire amount as committed by Bidding Company /
Member of the Bidding Consortium, in event of failure of the same
to make such investment.
8. In case of a Consortium, the Consortium agreement between the Members
in the Consortium as per Format 6.5 along with Board resolution from
each Member of the Consortium for participating in consortium;
9. Format for financial requirement as per Format 6.6 as applicable;
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 33
10. Format for Technical Criteria wherein Bidder shall certify that the
technology to be adopted shall be commercially established technology.
Final details of the same shall be submitted within 210 days of signing of
PPA as per Format 6.7.
11. A letter from the Bidder confirming connectivity of the Project as per
Format 6.8.
12. A disclosure statement as per Format 6.9 regarding participation of
any related companies in this bidding process.
13. Declaration by the Bidding Company / Lead Member of Bidding Consortium
for the Proposed Technology Tie Up as per Format 6.10.
14. Checklist for Bank Guarantee as per Appendix-A;
15. Submission of Summary Data Sheet as per Format-6.11.
16. Technical bid provision made for 161 locations and its associated
injections points. Bidder has to choose locations at his choice and has to
mention the capacity against the injection points.
17. Price bid provision made for 161 locations and its associated injections
points. Bidder has to quote INR/kwh against the same chosen injection
point in technical bid.
18. Memorandum and Articles of Association (highlighting relevant provision
of Power / Energy/Renewable Energy/ Solar Power Plant
development), Certificate of Incorporation (if applicable) of Bidding
Company / all Member companies of Bidding Consortium along with
shareholders rights and obligations as certified by Chartered Accountant.
19. In addition to the price bid, the Bidder has to submit Format 6.12.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 34
3.11 The Bidder should note that:
a. The Bidder may be short listed based on the declarations made by it in
relevant schedules of the RfS.
b. If the Bidder/ Member in a Bidding Consortium conceals or does not
submit any information, any document, bank guarantee, or any
material information or makes a wrong statement or misrepresents
facts or makes a misleading statement in its response to RfS, in any
manner whatsoever, APTRANSCO reserves the right to reject such
response to RfS and/or cancel the Letter of Intent, if issued and in
such event the Bank Guarantee provided up to the stage shall be
encashed.
c. If the event specified at (a) is discovered after the effective date i.e.
date of signing the PPA, consequences specified at (b) above shall
apply.
d. Response submitted by the Bidder shall become the property of
APTRANSCO who shall have no obligation to return the same to the
Bidder.
e. All pages of the response to RfS submitted must be signed and
stamped by authorized by the board as per Format 6.4, on behalf of
the Bidder as a token of unconditional acceptance of all terms and
conditions mentioned in the bid document.
f. The response to RfS shall be submitted as mentioned in clause 3.13.
No change or supplemental information to a response to RfS will
be accepted after the scheduled date and time of submission of
response to RfS. APTRANSCO reserves the right to seek additional
information from Bidders, if found necessary, during the course of
evaluation of the response to RfS.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 35
g. All the information should be submitted in English language only.
h. All fees and charges should be deposited as specified for each under
this RfS document only. No other mode of payment will be accepted.
i. Bidder shall mention the name of the contact person and complete
address of the Bidder in the covering letter.
j. Response to RfS that are incomplete, which do not substantially
meet the requirements prescribed in this RfS, will be liable for
rejection by APTRANSCO.
k. Response to RfS not submitted in the specified formats will be liable
for rejection by APTRANSCO.
l. Bidders not submitting any additional information or clarifications as
sought by APTRANSCO/DISCOM on or before the dates stipulated by
the respective organizations will be liable for rejection by
APTRANSCO.
m. It is the responsibility of the Bidder /Developer to comply with all the
criteria and terms and conditions of the RfS, and for which
APTRANSCO will not be responsible in any case. Non submission and
/or submission of incomplete data / information required under the
provisions of RfS shall not be construed as waiver on the part of
APTRANSCO of the obligation of the Bidder to furnish the said
date/information unless such waiver is given in writing.
n. If necessary, after issue of LoI or at any point of time APTRANSCO
reserves the right to seek additional information or documents as per
the requirement of RfS. Non submission of any relevant information
or relevant document or Bank Guarantee will lead to rejection of
the LoI even after issue of the same. Under any circumstance,
non fulfillment of any criteria and any terms and conditions under the
RfS, APTRANSCO reserves the right to cancel the LoI and such decision
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 36
of APTRANSCO will be final and binding.
o. All the Bidders are advised to visit the website of APTRANSCO before
submitting the Bid.
p. Only High Court of Andhra Pradesh shall have exclusive jurisdiction in
all matters pertaining to this RfS document.
3.12 Due Date
The bid submission and delivery of bids is as indicated at Time Schedules at 3.23.
3.13 Method of Submission
The bidder shall submit the RfS in the e-procurement platform.
3.14 Validity of the Response to RfS
The Bidder shall submit the response to RfS which shall remain valid for
120 days from the date of Bid submission.
3.15 Preparation Cost
The Bidder shall be responsible for all costs associated with the
preparation of the response to RfS and participation in discussions and
attending pre-bid meeting(s), etc. APTRANSCO shall not be responsible
in any way for such costs, regardless of the conduct or outcome of the
bid process.
3.16 Right of APTRANSCO/DISCOM to reject
APTRANSCO/DISCOM reserves the right to reject all or any of the
responses to RfS, including L1 bid at any Location, or cancel the RfS
without assigning any reasons whatsoever and without any liability
incurred.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 37
3.17 Bank Guarantees
The Developer shal l provide the following Bank Guarantees and Demand
Drafts from any of the Banks listed in Annexure 2, to APTRANSCO as
detailed hereunder:
1) Performance Bank Guarantee to be provided to APTRANSCO at the
time of signing of PPA as per Format – 6.3 valid for a period
of 22 months from the date of submission.
Bank Guarantees issued by foreign banks outside India from
bank list given in Annexure – 2 is to be endorsed by the Indian
Branch of the same bank or State Bank of India.
Performance Bank Guarantee would be required to be submitted in
the form of Bank Guarantee (BG) at the time of signing of PPA and
the Performance Bank Guarantee shall be submitted in three
numbers of Bank Guarantee in the amounts of Rs. 2 Lakhs/MW,Rs 3
Lakhs/MW and Rs 5 Lakhs/MW to DISCOMs, at the time of signing
of PPA with DISCOMs.
In case, the Selected Bidder is unable to execute the project within
the stipulated time period as specified in the RfS, the Performance
Bank Guarantees shall be encashed by DISCOMs as specified in Clause
3.20.
The Performance Bank Guarantees have to be executed on
non-judicial stamp paper of appropriate value as per Stamp
Act relevant to place of execution. The Performance Bank
Guarantees have to be in the name of the Bidding Company or in the
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 38
name of Lead Member in case of a Bidding Consortium.
In order to facilitate the Developers to submit the Bank Guarantee
as per the prescribed Format 6.3 and in line with the requirements,
checklist at Appendix A has been attached. Developers are
advised to take note of the above checklist while submitting
the Bank Guarantees.
2) Contract Performance Bank Guarantee (CPBG) to APTRANSCO, if
applicable, before issuance of LoI as per Format – 6.13 valid for
a period of 3 years from the date of submission. DISCOM reserves
the right to encash the CPBG in case of non-fulfillment.
3.18 a) Monitoring and Supervision Fee: The Developers are not required
to pay such fee in setting up of solar power plants under this RfS to
APTRANSCO/DISCOMs. However, the Developer has to pay all
relevant charges according to procedures of APTRANSCO/DISCOM for
evacuation.
b) Operation and Maintenance of the solar plant and its connected lines
during PPA period (20 years) is the responsibility of the Developer.
3.19 Financial closure or Project Financing Arrangements:
The Developer shall report tie-up of Financing Arrangements for the
project within 180 days from the date of signing of PPA. In case the
Developer does not achieve the financial closure within the stipulated
time period, DISCOM reserves the right to encash the BG and to
terminate the PPA without any intimation.
3.20 Penalties:
3.20.1 Under normal circumstances the Project has to be commissioned within
12 months from the date of signing of this Agreement. In case the
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 39
Developer fails to achieve this milestone, DISCOM shall encash the
Performance Bank Guarantee in the following manner.
a) Delay up to one month from scheduled COD: 2 lakhs/MW of capacity
not commissioned.
b) Delay of more than one month up to two months from scheduled
COD: 3 lakhs/MW of capacity not commissioned.
c) Delay of more than two months up to four months from scheduled
COD: 5 lakhs/MW of capacity not commissioned.
d) Delay of more than 4 months:
• In case of part commissioning, the Agreement shall be
amended to reflect the capacity that has been commissioned
• Else, the Agreement stands terminated for unfulfilled
obligation. CPBG will be returned on COD. If commissioning
doesn’t happen within 15 months of signing this Agreement,
the CPBG will be encashed.
3.21 Submissions to be made by Developer
During the installation and commissioning process, the Developer will be
required to submit the following documents (Hard and Softcopy on
the letter head of the Developer and stamped by the Developer) to
APTRANSCO/DISCOM in a timely manner, at least one month before
the commissioning.
(a) Sl. No. of all modules. (b) I-V Curve including wattage of each module.
(c) PV/STP model Testing Reports of Solar equipments Generator, (as per Annexure-I)
(d) Warranty as per Annexure -I (e) Identification and Traceability (as per Annexure-I) (f) Certificate of quality of module (as per Annexure-I)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 40
(g) All technical details of Inverter, SCADA System, Wires, Cables, including all peripherals
(h) Protection devices (lightning arrester, earthing, etc.) and their technical specifications.
(i) Protection devices for the safety of Grid at the time of connectivity, and their Technical Specifications.
(j) Copy of the bills of module, balance of system, and all other equipment like generators etc.
(k) Commissioning Report from DISCOMs, APTRANSCO.
(l) Any other information as per RfS. 3.22 Incentive in case of expedited commissioning:
The Solar Power Developer will be paid an incentive by DISCOM for early
commissioning. The incentive will be paid as follows:
i. Commissioning between 30 and 59 days before Scheduled COD: Rs 1
lakh/MW of capacity commissioned.
ii. Commissioning between 60 and 89 days before Scheduled COD: Rs 2
lakh/MW of capacity commissioned.
iii. Commissioning before 90 days of the Scheduled COD: Rs 3 lakh/MW of
capacity commissioned.
3.23 Time Schedules
Event Date
1 Submission of response to RfS with relevant documents.
Till 07/02/2013 at 3 pm
2 Opening of technical bid 08/02/2013 at 3 pm
3 Opening of financial bid After evaluation of technical bid.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 41
4 Evaluation and Short-listing of Bidders,
15 days after opening of financial bids
5 Issue of letter of intent Within 7 days from shortlisting of Bidders
6 Communication of acceptance of LoI by successful bidder
Within 10 days from the date of issue of LoI excluding the date of issue.
7 Signing of PPA Within 30 days from the date of issue of letter of intent.
8 Financial closure / Financing Arrangement for the project
Submission of financial closure documents 210 days from the date of signing of PPA.
9 Commissioning of the Project The plant has to be commissioned within
12 months from the date of signing of the PPA.
NOTE (1) All the above are to be adhered to strictly as per the
requirements under the RfS.
(2) For the purpose of determination of dates, the date of issue
of the letter will be excluded. However, the decision of
APTRANSCO/DISCOMs will be final in this regard and the
Bidder has to duly comply with it.
3.24. In the event of any conflict of interpretation in terms and conditions
between RfS document and the clarifications issued under this RfS or
in case of any ambiguity, the provisions of these RfS guidelines
would prevail.
3.25. Check list for submission of documents after issue of LOI.
i. Bank statement, shareholding pattern, Profit & Loss Account, and
net worth (Certified by CA).
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 42
ii. Net worth infusion for newly incorporated company (Certified by
CA).
iii. Controlling shareholding details for the company (Certified by CA).
iv. Any other document as per RfS.
3.26 Check list for submission of documents before signing of PPA.
(i) Bank Statement, shareholding pattern, profit & loss Account, and
net worth certified by CA).
(ii) Net worth infusion for newly incorporated company (certified by
CA).
(iii) Controlling shareholding details for the company (certified by CA).
(iv) Certificate from Transmission Utility
(v) Bank Guarantee as per Format 6.3.
(vi) Any other document as per RfS.
3.27 Check list for submission of document after signing of PPA.
i. Financial closure or financing arrangements
ii. Technology undertaking as per format 6.7.
iii. Submission of details about the following (Hard and Softcopy on the
letter head of the Developer and stamped by the Developer):
(a) Sl. No. of all modules/Turbines/Generators/Heat collecting devices etc.
(b) I-V Curve including wattage of each module. (c) Testing Report of plant equipment (as per Annexure-I)
(d) Warranty as per Annexure -I.
(e) Identification and Traceability (as per Annexure-I)
(f) Certificate of quality of all equipment (as per Annexure -I)
(g) All technical details of Inverter, SCADA System, Wires,
Cables, including all peripherals of generators, turbines
etc.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 43
(h) Protection devices (lightening arrester, earthling, etc.) and
their technical specifications.
(i) Protection devices for the safety of Grid at the time of
connectivity, and their Technical Specifications.
(j) Copy of the bills of solar equipment, balance of system, and all
other items.
(k) Commissioning Report from DISCOMs/ APTRANSCO.
(l) Any other information as per RfS.
Note: All the above are to be submitted as per the provisions in this RfS.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 44
Section 4 Evaluation Criteria
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 45
Section 4
4.0 Evaluation Criteria
4.1 The evaluation process comprises of the following two steps:
Step I- Responsiveness check Step II – Technical bid evaluation Step III-Price bid evaluation.
4.2 Step I- Responsiveness check
The response to RfS submitted by the Bidder shall be scrutinized to establish “Responsiveness”. Each Bidder’s response to RfS shall be checked for compliance with the submission of requirements set forth in this RfS. Any of the following conditions shall cause the bid to be “Non-responsive”:
a. Response to RfS submitted by a Bidding Consortium not including the Consortium Agreement
b. Response to RfS having conflict of interest. c. Non submission of processing fee or EMD in acceptable format along
with RfS document. d. Non submission of documents as per the Annexure 3. e. Non-submission of all relevant documents related
to Net Worth, Shareholding, Lead Member etc. as required in this RfS document.
f. Non submission of Memorandum and Articles of Association (highlighting relevant provision of Power / Energy / Renewable Energy/ Solar Power Plant development), Certificate of Incorporation (if applicable) of Bidding Company / all Member companies of Bidding Consortium along with shareholders rights and obligations as certified by Chartered Accountant.
g. Submission of Tariff bid in Format 6.12 h. Non-submission of RfS document duly signed and stamped on every
page. i. Submission of financial documents without the signature of the
Chartered Accountant on all pages of the same. j. If the bid and other documents are submitted in language other
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 46
than English. Note: Non responsive bids will not be considered for step II bid
evaluation.
4.3 Step II-Technical Bid (6.11A) evaluation
The bid evaluation will be carried out as per section 6.1 to 6.11-
formats and technical bid and Format for RTGS. Bidder can upload
either DD or ‘Format for RTGS’ for processing fee.
4.4. Step III -Financial bid
The financial bid will be evaluated as per Price Bid 6.12, only for those
who qualify in the technical bid.
Evaluation of price bid is based on lowest quoted price for any of the
injection point with respect to its location as indicated in the Price Bid
i.e. the Bidder’s quoted price at 33kV SS or 132kV SS, both will be
referred to the respective location as indicated in the Price Bid.
APTRANSCO/DISCOM reserves the right to reject all or any of the
responses to RfS, including L1 bid at any Location, or cancel the RfS
without assigning any reasons whatsoever and without any liability
incurred to DISCOMs/APTRANSCO.
Bidder can quote their price up to four (4) decimal points only for the
entire tenure of the agreement.
Note: The bidder has to choose same injection points both in Technical
bid and Price bid. Failing which, the bid is liable for rejection.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 47
Section 5 OTHER PROVISIONS
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 48
Section 5
5.0 Other Provisions
5.1 Role of the State Level Agencies
APTRANSCO/DISCOM has no obligation to recommend any department to
grant permissions /sanctions by the Solar Power Projects.
5.2 Role of Carbon Financing
Project Developers are encouraged to identify the potential role of
carbon finance in their investment analysis including:
i. The expected revenues for emission reductions; and
ii. The cost of power with and without carbon revenues and
iii. Sharing the carbon credits as per PPA.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 49
Section 6
FORMATS FOR BID SUBMISSION
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 50
Format 6.1 -Format of Covering Letter
(The covering letter should be on the Letter Head of the Bidding Company/ Lead Member of the Bidding Consortium)
Date: From: (insert name and address of Bidding
Company/ Lead Member of the Bidding Consortium)
Tel. #: Fax#: E-mail address#
To
The Chief Engineer/IPC, APPCC, Vidyut Soudha, Hyderabad
Sub: Response to RfS dated for development of _____MW Solar Project
Dear Sir,
We, the undersigned ……. [insert name of the ‘Bidder’] having read, examined and understood in detail the RfS including Qualification Requirements in particular and PPA for supply of power for 20 years to DISCOMs, hereby submit our response to RfS for setting up __ MW solar power plant in Andhra Pradesh.
We confirm that neither we nor any of our Parent Company/ Affiliate/ Group Company has submitted response to RfS other than this response to RfS, directly or indirectly, in response to the aforesaid RfS.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 51
1. We give our unconditional acceptance to the RfS, dated …………….and PPA attached thereto, issued by the APTRANSCO. In token of our unconditional acceptance to the RfS & PPA, the same have been initialed and stamped by us on all pages and enclosed with the response to RfS. We shall ensure that the PPA is executed as per the provisions of the RfS and provisions of PPA shall be binding on us. Further, we confirm that the Project shall be commissioned within 12 months of the date of signing of PPA.
2. Earnest Money Deposit (Bid security) : -
We have enclosed bank guarantee …………. [Insert bank guarantee reference] towards EMD of Rs.___________ (Insert Amount), dated ………. [Insert date of BG] from ………… [Insert name of bank providing bank guarantee]
3. We have submitted our response to RfS strictly as per Section – 6 (Formats)
of this RfS, without any deviations, conditions and without mentioning any assumptions or notes in the said Formats.
4. Acceptance
We hereby unconditionally and irrevocably agree and accept that the decision made by the APTRANSCO in respect of any matter regarding or arising out of the RfS shall be binding on us. We hereby expressly waive any and all claims in respect of this process.
5. Familiarity with Relevant Indian Laws & Regulations
We confirm that we have studied the provisions of the relevant Indian laws and regulations as required to enable us to submit this response to RfS and execute the PPA, in the event of our selection as Successful Bidder.
6. We are enclosing herewith our response to the RfS with formats duly signed
as desired by you in the RfS for your consideration.
7. It is confirmed that our response to the RfS is consistent with all the requirements of submission as stated in the RfS and subsequent communications from the APTRANSCO.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 52
8. The information submitted in our response to the RfS is correct to
the best of our knowledge and understanding. We would be solely responsible for any errors or omissions in our response to the RfS.
9. Contact Person
Details of the contact person are furnished as under:
Name: …………………………………….
Designation: ……………………………………….. Company : ……………….
Address : …………………………………….
Phone Nos. : ………………………………………. Fax Nos. :………………………….
E-mail address: …………………………………………..
Dated the day of , 20…
Thanking you,
Yours faithfully,
(Name, Designation and Signature of Person Authorized by the board as per Clause 3.10 (5) (a))
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 53
Format 6.2 –Format for Power of Attorney to be provided by each of the other Members of the Consortium in favor of the Lead Member
POWER OF ATTORNEY
(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)
KNOW ALL MEN BY THESE PRESENTS THAT …………….……………. [Name of the Consortium Member company] having its registered office at…………..….…..,………..…and …….…………………….…. [Name of the Consortium Member company] having its registered office at ………………………………….. , (Insert names and registered offices of all Members of the Consortium) the Members of Consortium have formed a Bidding Consortium named …………. (Insert name of the Consortium if finalized) (Hereinafter called the ‘Consortium’) vide Consortium Agreement dated………..……………….. (copy enclosed) and having agreed to appoint ……………………………..…[Name & Address of the Lead Member Company] as the Lead Member of the said Consortium do hereby constitute, nominate and appoint M/s…………….…………..a company incorporated under the laws of ……….………and having its Registered /Head Office at ……………………..……….as our duly constituted lawful Attorney (hereinafter called as Lead Member) to exercise all or any of the powers for and on behalf of the Consortium in regard to submission of the response to RfS and if required. We also authorize the said Lead Member to undertake the following acts:
i) To submit on behalf of Consortium Members response to RfS and if
required, to Sign PPA.
ii) To do any other acts or submit any information and documents related to the above response to RfS.
It is expressly understood that in the event of the Consortium being selected as Successful Bidder, this Power of Attorney shall remain valid, binding and irrevocable until the Bidding Consortium achieves execution of PPA.
We as the Member of the Consortium agree and undertake to ratify and confirm all whatsoever the said Attorney/Lead Member has done on behalf of the Consortium Members pursuant to this Power of Attorney and the same shall bind us and deemed to have been done by us.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 54
IN WITNESS WHEREOF …………………………………………..…….[Name of Member consortium Company], as the Member of the Consortium have executed these presents on this……….. day of ........under the Common Seal of our company.
For and on behalf of Consortium Member
M/s………………………….
------------------------
(Signature of person authorized by the board)
(Name Designation Place: Date:)
Accepted
---------------------------------
(Signature, Name, Designation and Address
of the person authorized by the board of the Lead Member)
Attested
---------------------
(Signature of the executant)
------------------------------
(Signature & stamp of Notary of the place of execution)
Place:-----------
Date:-------
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 55
Format 6.3 – Format for Performance Bank Guarantee
(Note: - Total Performance Bank Guarantee is to be submitted in three separate Bank Guarantees, viz, Rs. 2 lakhs/MW, Rs.3 lakhs/MW, Rs. 5 lakhs/MW).
(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)
In consideration of the ----------- [Insert name of the Bidder] (hereinafter referred to as selected Solar Power Developer') submitting the response to RfS, inter-alia, for selection of the project of the capacity of ______ MW, at …………[Insert name of the place], for supply of power there from on long term basis, in response to the RfS dated ………….issued by APTRANSCO/DISCOM and considering such response to the RfS of ………[insert the name of the selected Solar Power Developer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Solar Power Project of the Developer and issuing Letter of Intent No ------- to (Insert Name of selected Solar Power Developer) as per terms of RfS and the same having been accepted by the selected SPD resulting in a Power Purchase Agreement (PPA) to be entered into, for purchase of Power [from selected Solar Power Developer or a Project Company, M/s --------- ---- {a Special Purpose Vehicle (SPV) formed for this purpose}, if applicable ]. As per the terms of the RfS, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to APTRANSCO/ DISCOM at [Insert Name of the Place from the address of the APTRANSCO/DISCOM ] forthwith on demand in writing from APTRANSCO/ DISCOM or any Officer authorized by it in this behalf, any amount up to and not exceeding Rupees------ [Total Value] only, on behalf of M/s [Insert name of the selected Solar Power Developer / Project Company]
This guarantee shall be valid and binding on this Bank up to and including __________________________ and shall not be terminable by notice or any change in the constitution of the Bank or the term of contract or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective agreement.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 56
Our liability under this Guarantee is restricted to Rs. (Rs. only). Our Guarantee shall remain in force until _[Insert date] APTRANSCO/ DISCOM shall be entitled to invoke this Guarantee till [Insert date].
The Guarantor Bank hereby agrees and acknowledges that the APTRANSCO/ DISCOM shall have a right to invoke this PERFORMANCE BANK GUARANTEE in part or in full, as it may deem fit.
The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written demand by APTRANSCO/ DISCOM, made in any format, raised at the above mentioned address of the Guarantor Bank, in order to make the said payment to APTRANSCO/ DISCOM
The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and notwithstanding any objection by -------------[Insert name of the selected Solar Power Developer / Project Company as applicable] and/or any other person. The Guarantor Bank shall not require APTRANSCO/ DISCOM to justify the invocation of this PERFORMANCE BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against APTRANSCO/ DISCOM in respect of any payment made hereunder
This PERFORMANCE BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at Andhra Pradesh shall have exclusive jurisdiction.
The Guarantor Bank represents that this PERFORMANCE BANK GUARANTEE has been established in such form and with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.
This PERFORMANCE BANK GUARANTEE shall not be affected in any manner by reason of merger, amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.
This PERFORMANCE BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly APTRANSCO/ DISCOM shall not be obliged before enforcing this PERFORMANCE BANK GUARANTEE to take any action in any court or arbitral proceedings against the selected Solar Power Developer / Project Company, to make any claim against or any demand on the selected Solar Power Developer / Project Company or to give any notice to the selected Solar Power Developer / Project Company or to enforce any
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 57
security held by APTRANSCO/ DISCOM or to exercise, levy or enforce any distress, diligence or other process against the selected Solar Power Developer / Project Company .
The Guarantor Bank acknowledges that this PERFORMANCE BANK GUARANTEE is not personal to APTRANSCO/ DISCOM and may be assigned, in whole or in part, (whether absolutely or by way of security) by APTRANSCO/ DISCOM to any entity to whom APTRANSCO/ DISCOM is entitled to assign its rights and obligations under the PPA.
Notwithstanding anything contained hereinabove, our liability under this Guarantee is restricted to Rs. _________(Rupees ___________ only) and it shall remain in force until with an additional claim period of thirty (30) days thereafter. We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if APTRANSCO/ DISCOM serves upon us a written claim or demand.
Signature
Name
Power of Attorney No. For [Insert Name of the Bank]
Banker's Stamp and Full Address.
Dated this day of , 20 Witness: 1. ……………………………………. Signature Name and Address 2. …………………………………..
Signature Name and Address
Notes: The Stamp Paper should be in the name of the Executing Bank. The Performance Bank Guarantee shall be executed by any of the Bank from the List of Banks enclosed in Annexure 2.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 58
Format 6.4 - Format for Board Resolutions
(Format for the Board resolution to be passed)
The Board, after discussion, at the duly convened Meeting on ………… (Insert date), with the consent of all the Directors present and in compliance of the provisions of the Companies Act, 1956, passed the following Resolution: 1. RESOLVED THAT Mr/Ms………………., be and is hereby authorized to do on our behalf, all such acts, deeds and things necessary in connection with or incidental to our response to RfS for setting up ________ MW solar power plant in AP , including signing and submission of all documents and providing information / response to RfS to APTRANSCO, representing us in all matters before APTRANSCO, and generally dealing with APTRANSCO in all matters in connection with our bid for the said Project. (To be provided by the Bidding Company or the Lead Member of the Consortium) 2. FURTHER RESOLVED THAT pursuant to the provisions of the Companies Act, 1956 and compliance thereof and as permitted under the Memorandum and Articles of Association of the company, approval of the Board be and is hereby accorded to invest total equity in the Project. (To be provided by the Bidding Company) [Note: In the event the Bidder is a Bidding Consortium, in place of the above resolution at Sl. No. 2, the following resolutions are to be provided] FURTHER RESOLVED THAT pursuant to the provisions of the Companies Act, 1956 and compliance thereof and as permitted under the Memorandum and Articles of Association of the company, approval of the Board be and is hereby accorded to invest (- ----%) equity [Insert the % equity commitment as specified in Consortium Agreement] in the Project. (To be provided by the each Member of the Bidding Consortium including Lead Member such that total equity commitment is 100%) FURTHER RESOLVED THAT approval of the Board be and is hereby accorded to participate in consortium with ------------ [Insert the name of other Members in the Consortium] and Mr/Ms………………., be and is hereby authorized to execute the Consortium Agreement. (To be provided by the
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 59
each Member of the Bidding Consortium including Lead Member) And FURTHER RESOLVED THAT approval of the Board be and is hereby accorded to contribute such additional amount over and above the percentage limit (specified for the Lead Member and other Member in the Consortium Agreement) to the extent becoming necessary towards the total equity share in the Project Company, obligatory on the part of the Consortium pursuant to the terms and conditions contained in the Consortium Agreement dated …………… executed by the Consortium as per the provisions of the RfS. [To be passed by the Lead Member and other Members of the Bidding Consortium] 3. FURTHER RESOLVED THAT approval of the Board be and is hereby accorded to M/s. ………. (Insert name of Bidding Company/ Consortium Member(s)) to use our financial capability for meeting the Qualification Requirements for setting up a __ MW solar power plant in AP and confirm that all the equity investment obligations of M/s……. (Insert Name of Bidding Company/ Consortium Member(s)), shall be deemed to be our equity investment obligations and in the event of any default the same shall be met by us. [To be passed by the entity(s) whose financial credentials have been used i.e. Parent and / or its affiliate.]
Certified true copy ---------------------
(Signature, Name and stamp of Company Secretary / Director)
Notes:
1) This certified true copy should be submitted on the letterhead of the Company, signed by the Company Secretary / Director.
2) The contents of the format may be suitably re-worded indicating the identity of the entity passing the resolution.
3) This format may be modified only to the limited extent required to comply with the local regulations and laws applicable to a foreign entity submitting this resolution. For example, reference to Companies Act 1956 may be suitably modified to refer to the laws applicable to the entity submitting the resolution. However, in such case, the foreign entity shall submit an unqualified opinion issued by the legal counsel of such foreign entity, stating that the Board resolutions are in compliance with the applicable laws of the respective jurisdictions of the issuing company and the authorizations granted therein are true and valid.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 60
Format 6.5 – Consortium Agreement (To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution)
THIS Consortium Agreement (“Agreement”) executed on this day of Two thousand between M/s [insert name of Lead Member]a Company incorporated under the laws of and having its Registered Office at (hereinafter called the “Member-1”, which expression shall include its successors, executors and permitted assigns) and M/s Company incorporated under the laws of and having its Registered Office at (hereinafter called the “Member-2”, which expression shall include its successors, executors and permitted assigns), M/s a Company incorporated under the laws of and having its Registered Office at (hereinafter called the “Member-n”, which expression shall include its successors, executors and permitted assigns), [The Bidding Consortium should list the details of all the Consortium Members] for the purpose of submitting response to RfS, and execution of Power Purchase Agreement (in case of award), against RfS dated ……………
WHEREAS, each Member individually shall be referred to as the “Member” and all of the Members shall be collectively referred to as the “Members” in this Agreement.
WHEREAS the DISCOMs desires to purchase power under Renewable Power Purchase obligation, Regulation 2012;
WHEREAS, the APTRANSCO had invited response to RfS vide its Request for Selection (RfS) dated
WHEREAS the RfS stipulates that in case response to RfS is being submitted by a Bidding Consortium, the Members of the Consortium will have to submit a legally enforceable Consortium Agreement in a format specified by APTRANSCO wherein the Consortium Members have to commit equity investment of a specific percentage for the Project.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 61
NOW THEREFORE, THIS AGREEMENT WITNESS AS UNDER:
In consideration of the above premises and agreements all the Members in this Bidding Consortium do hereby mutually agree as follows:
1. We, the Members of the Consortium and Members to the
Agreement do hereby unequivocally agree that Member-1 (M/s ), shall act as the Lead Member as defined in the RfS for self and agent for and on behalf of Member-2, -----, Member-n.
2. The Lead Member is hereby authorized by the Members of the
Consortium and Members to the Agreement to bind the Consortium and receive instructions for and on their behalf.
3. Notwithstanding anything contrary contained in this Agreement, the Lead Member shall always be liable for the equity (as well as total financing if committed to be met from internal financing) investment obligations of all the Consortium Members i.e. for both its own liability as well as the liability of other Members.
4. The Lead Member shall be liable and responsible for ensuring the
individual and collective commitment of each of the Members of the Consortium in discharging all of their respective equity as well as other financing if committed to be met internally obligations. Each Member further undertakes to be individually liable for the performance of its part of the obligations without in any way limiting the scope of collective liability envisaged in this Agreement.
5. Subject to the terms of this Agreement, the share of each Member of
the Consortium in the issued equity share capital of the project Company is/shall be in the following proportion:
Name Percentage Member 1 --- Member 2 ---
Member n --- Total 100%
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 62
6. The Lead Member, on behalf of the Consortium, shall inter alia undertake full responsibility for liaising with Lenders or through internal accruals and mobilizing debt resources for the Project, and ensuring that the Seller achieves Financial Closure in terms of the PPA.
7. In case of any breach of any equity investment as well as other
financing requirements commitment by any of the Consortium Members, the Lead Member shall be liable for the consequences thereof.
8. Except as specified in the Agreement, it is agreed that
sharing of responsibilities as aforesaid and equity investment obligations thereto shall not in any way be a limitation of responsibility of the Lead Member under these presents.
9. It is further specifically agreed that the financial liability for equity
contribution of the Lead Member shall not be limited in any way so as to restrict or limit its liabilities. The Lead Member shall be liable irrespective of its scope of work or financial commitments.
10. This Agreement shall be construed and interpreted in accordance with
the Laws of India and courts in India alone shall have the exclusive jurisdiction in all matters relating thereto and arising thereunder.
11. It is hereby further agreed that in case of being selected as the
Successful Bidder, the Members do hereby agree that they shall furnish the Performance Guarantee in favor of APTRANSCO in terms of the RfS.
12. It is further expressly agreed that the Agreement shall be irrevocable
and shall form an integral part of the Power Purchase Agreement (PPA) and shall remain valid until the expiry or early termination of the PPA in terms thereof, unless expressly agreed to the contrary by APTRANSCO/DISCOMs.
13. The Lead Member is authorized and shall be fully responsible for
the accuracy and veracity of the representations and information
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 63
submitted by the Members respectively from time to time in the response to RfS.
14. It is hereby expressly understood between the Members that no Member
at any given point of time, may assign or delegate its rights, duties or obligations under the PPA except with prior written consent of APTRANSCO.
15. This Agreement
(a) has been duly executed and delivered on behalf of each
Member hereto and constitutes the legal, valid, binding and enforceable obligation of each such Member;
(b) sets forth the entire understanding of the Members hereto with
respect to the subject matter hereof; and
(c) may not be amended or modified except in writing signed by each of the Members and with prior written consent of APTRANSCO.
16. All the terms used in capitals in this Agreement but not defined herein
shall have the meaning as per the RfS & PPA.
IN WITNESS WHEREOF, the Members have, through their authorized representatives, executed these present on the Day, Month and Year first mentioned above.
For M/s----------------------------- [Member 1] -----------------------------------------
(Signature, Name & Designation of the person authorized vide Board Resolution Dated [? ] )
Witnesses: 1) Signature ----------------------- Name: Address:
2) Signature --------------------- Name: Address:
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 64
For M/s----------------------------- [Member 2]
-----------------------------------------
(signature, Name & Designation of the person authorized vide Board Resolution Dated [?])
Witnesses: 1) Signature ----------------------- Name: Address:
2) Signature ---------------------- Name: Address: For M/s-----------------------------[Member n]
-----------------------------------------
(signature, Name & Designation of the person authorized vide Board Resolution Dated [?])
Witnesses:
1) Signature ----------------------- (2) Signature ----------------------
Name:
Address: Name:
Address:
Signature and stamp of Notary of the place of execution
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 65
[on the letter head of Bidder]
Format 6.6- FORMAT FOR FINANCIAL REQUIREMENT – NET WORTH (to be filled separately for individual projects)
To,
` The Chief Engineer/IPC
APPCC, VIdyut Soudha, Hyderabad
Dear Sir,
Sub: Response to RfS for setting up________MW Solar Power plants in AP.
We certify that the Bidding Company / Member in a Bidding Consortium [Name of Bidding Company or Bidding Consortium] has a minimum Net Worth of Rs. crore (Rupees ) on
(i) For Existing Companies
Description Select any one
(whichever is applicable)
Audited annual accounts of any of the last four (4) financial years 2008-09, 2009-10, 2010-11 and 2011-12 [Strike out the financial years not applicable] Or
Applicable / Not Applicable
Net Worth as on day dd/mm/yyyy (within seven days prior to the last date of submission of response to RfS by the bidding companies)
Applicable / Not Applicable
(ii) For new Companies
Net Worth as on day dd/mm/yyyy (not more than seven days prior to the last date of submission of response to RfS by the bidding companies)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 66
Exhibit (i): Applicable in case of Bidding Company
For the above calculations, we have considered the Net Worth by Bidding Company and/ or its Parent / Affiliates as per following details:
Name of Company / Parent/ Affiliate/ Group Company
Name of Company / Parent/ Affiliate whose Net Worth is to be considered
Relationship with Bidding Company*
Either Financial Year to be considered for Net Worth or Net Worth of the respective Company not later than 7 days prior to submission of RfS
Net Worth (in Rs. Crore) of the Member Company
Company 1
---
---
Total
The column for “Relationship with Bidding Company” is to be filled only in case the financial capability of Parent/Affiliate has been used for meeting Qualification Requirements. Further, documentary evidence to establish the relationship, duly certified by the company secretary/chartered accountant is required to be attached with the format.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 67
Exhibit (ii): Applicable in case of Bidding Consortium
(To be filled by each Member in a Bidding Consortium separately)
Name of Member: [Insert name of the Member]
Net worth Requirement to be met by Member in Proportion to the Equity Commitment: Rs. -------------Crore (Equity Commitment (%) * Rs. [ ] Crore)
For the above calculations, we have considered Net Worth by Member in Bidding Consortium and/ or Parent/ Affiliate as per following details:
Name of Consortium Member Company
Name of Company / Parent/ Affiliate/ Consortium Member whose Net Worth is to be considered
Relationship with Bidding Company* (if any)
Either Financial Year to be considered for Net Worth or Net Worth of the respective Company not later than 7 days prior to submission
Net Worth (in Rs. Crore) of the Consortium Member Company
Equity Commitment (in %age) in Bidding Consortiu m
Committed Net Worth (in Rs. Crore)
Company 1
---
---
Total
* The column for “Relationship with Bidding Company” is to be filled only in case the financial capability of Parent/Affiliate has been used for meeting Qualification Requirements. Further, documentary evidence to establish the relationship, duly certified by the company secretary/chartered accountant is required to be attached with the format.
(Signature & Name of the person Authorised (Signature and Stamp of By
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 68
the board) Statutory Auditor or Chartered Accountant)
Date:
Note: i. Along with the above format, in a separate sheet, provide details
of computation of Net Worth duly certified by Statutory Auditor. ii. Certified copies of Balance sheet, Profit & Loss Account, Schedules
and Cash Flow Statements and Bank statement by bank are to be enclosed in support thereof for confirmation of balance in cash & bank.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 69
[On the letter head of Bidder]
Format 6.7 - FORMAT FOR TECHNICAL CRITERIA
To,
The Chief Engineer/IPC APPCC, VIdyut Soudha, Hyderabad Dear Sir,
Sub: Response to RfS setting up _________ MW Solar Power Plant in AP.
We hereby undertake to certify in line with clause 3.21 that the following details shall be furnished within 210 days of signing of PPA: -
1.0 That the technology proposed to be used is commercially established solar
technology 2.0 Details of the project with Location and the successful operational period
of the project utilizing this technology. Authorised Signatory Stamp
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 70
(On the letterhead of the Bidding Company / Consortium)
Format 6.8 Format for Confirmation of Connectivity (To be filled separately for individual Locations)
To,
The Executive Director/Planning, RAC& Reforms, APTRANSCO/Vidyut Soudha, Hyderabad.
Dear Sir,
Sub: Response to RfS for setting up one unit of solar Power Plant of_______MW in______ __________Distribution Company Limited of AP.
1. We hereby agree to lay the evacuation with necessary infrastructure from our
proposed solar power plant to nearest 33 kV or 132 kV transmission sub-station as may be available at our own cost for all the items as mentioned in the RfS document like transmission lines, grid interface equipment, metering, bay etc.
2. We hereby undertake to obtain the letter from transmission utility
/distribution utility confirming connectivity before and after the same is carried out.
3. We hereby undertake to sign necessary Power Purchase Agreement with APTRANSCO/DISCOMs as specified in the RfS.
4. We hereby undertake to pay the connectivity charges as decided by APTRANSCO/DISCOMs.
Authorized Signatory Stamp
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 71
Format 6.9 - Format for Disclosure
[On the letter head of Bidding Company/Each Member in a Bidding Consortium]
Disclosure We hereby declare that our Parent, Affiliate or Ultimate Parent-or any Group Company with which we have direct or indirect relationship are not separately participating in this Bid.
We further declare that the above statement is true & correct. We are aware that if at any stage it is found to be incorrect, our response to RfS bid will be rejected and if LoI has been issued or PPA has been signed, the same will be cancelled and the bank guarantees will be encashed.
(Signature & Name of the person Authorised By the board)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 72
Format 6.10 Declaration by the Solar power Developer for the proposed technology
1 Name of Bidding Company / Lead Member of Bidding Consortium
2 Project proposed Solar
3 Capacity proposed (in MW)
4 Technology proposed to be adopted for the project to supply contracted annual output (units per MW in the first year)
(solar PV or Solar thermal) Conventional / Advance
5 Give brief description about the proposed Solar Technology
Signature of the Bidder
Stamp
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 73
Bidders D
etails
Format 6.11 Summary Data Sheet
Summary Data Sheet (Format 6.11)
Asterisk Marked(*) Fields are Mandatory
Section
Details to be Furnished by the Bidder
Refer RfS DoName of Bidder* Bidders
status*
Address (Line-1) Address (Line-2)
City State
Country Zip/Pin
Bidder's website if any
Bid
List of parent/Ultimate Parent/ Group Companies, if any.
Project 1
Company Name
Capacity inMW
Location
Details of bids across other Locations ,if any, being developed by Parent /Ultimate Parent/ Affiliates/ Group Companies (ADD ROWS IF NECESSARY)
Project 2
Company Name
Capacity inMW
Location
Name of the Controlling Shareholding
Whether listed with any stockexchange.*
Name of Exchange (s) wherelisted
EMD
Details of the EMD
Details
(I) Amount(inRs.Lakhs)*
(II) Banker
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 74
(III)DD/Pay Order No
(IV)DD/Pay OrderDate
Details of the Processing Fee
(I) Amount(in Rs.Lakhs)*
(II) Banker
Processing fee details
(III)DD/Pay Order No (IV)DD/Pay Order
Date
Name & Contact Details of the person authorized by the Company/ Consortium to sign the RfS
Name of the Person Authoriza
tion De
tails
Mobile No
Office Tel No(with STD)
Fax(with STD Code)
Same as biddersaddress
Add Line 1 Add line 2
Correspondence address
City State Country Zip/Pin
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 75
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 76
Format 6.11A Technical Bid
TECHNICAL BID List of Identified Substations for Solar Power RfS
Location
No. of Transform
ers X capacity
Total Tr. Capacity
(MVA)
Maximum Solar
Capacity (MW)
Bidders offered
capacity in MW at
Injection points
SRIKAKULAM
Location -1 132 KV SS Chilakapalem 1X31.5 + 1X50
81.50 5 --
Injection Points
a) 132KV SS
Chilakapalem
b) 33 KV SS Tadivalasa
c) 33 KV SS Indoor d) 33 KV SS A.S.N.COLONY
e) 33 KV SS AMADALAVALASA
f) 33 KV SS THOGARAM g) 33 KV SS KINTALI
h) 33 KV SS PONDURU
i) 33 KV SS BUDUMURU
j) 33 KV SS LAVERU
k) 33 KV SS KS PALEM
l) 33 KV SS DHARMAVARAM m) 33 KV SS ETCHERLA
n) 33 KV SS GUJARATHIPETA
o) 33 KV SS CHALLAPETA p) 33 KV SS TULUGU
q) 33 KV SS ARASAVALLI
r) 33 KV SS SRIKAKULAM
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 77
s) 33 KV SS BHYRI
t) 33 KV SS RAGOLU
u) 33 KV SS Alikam
Location -2 132 KV SS Palakonda 1X31.5 + 1X16
47.50 5 --
Injection Points a) 132KV
SS Palakonda
b) 33 KV SS BHAMINI
c) 33 KV SS GURANDI d) 33 KV SS HIRAMANDALAM
e) 33 KV SS L.N.PETA S.S
f) 33 KV SS KOTTURU g) 33 KV SS NIVAGAM
h) 33 KV SS SARUBUJJILI
i) 33 KV SS UNGARADAMETTA
j) 33 KV SS SANTHAKAVITY
k) 33 KV SS KOLLIVALASA
l) 33 KV SS NAVAGAM m) 33 KV SS PALAKONDA
n) 33 KV SS SEETHAMPETA
o) 33 KV SS DONUBAI p) 33 KV SS VANGARA
q) 33 KV SS VEERAGATTAM
r) 33 KV SS Parvateesampeta
Location -3 132 KV SS Pydibheevaram 2X31.5 63.00 5 -- Injection Points a) 132KV
SS Pydibheevaram
b) 33 KV SS P.B.Varan
c) 33 KV SS Patharlapalli
d) 33 KV SS Ranasthalam
e) 33 KV SS Yerravaram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 78
VIZIANAGARAM
Location -4 132 KV SS Vizianagaram 1X31.5 + 1X50
81.50 5 --
Injection Points
a) 132KV SS
Vizianagaram
b) 33 KV SS Dharmapuri
c) 33 KV SS Denkada
d) 33 KV SS Nathavalasa
e) 33 KV SS Vontithadi
f) 33 KV SS B. koneru g) 33 KV SS Indoor
h) 33 KV SS Phoolbagh
i) 33 KV SS Dasannapeta j) 33 KV SS Ayyannapeta
k) 33 KV SS Collectrate
l) 33 KV SS Gajularega
m) 33 KV SS Gotlam
n) 33 KV SS Bondapalli
o) 33 KV SS Gajapathinagaram
p) 33 KV SS Mentada
q) 33 KV SS Rajapulova
r) 33 KV SS Akkivaram s) 33 KV SS Savaravalli
t) 33 KV SS Bhogapuram
u) 33 KV SS Mukkam
Location -5 132 KV SS Kothavalasa 1X16 + 1X31.5 47.50 5 --
Injection Points a) 132KV
SS Kothavalasa
b) 33 KV SS L. Kota
c) 33 KV SS Malliveedu
d) 33 KV SS Kothavalasa
e) 33 KV SS Kantakapalli
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 79
f) 33 KV SS Vepada
g) 33 KV SS Ramalingapuram
VISAKHAPATNAM
Location -6 132 KV SS Koruprolu 1X16 + 1X31.5
47.50 5 --
Injection Points a) 132KV
SS Koruprolu
b) 33 KV SS Bhalighattam
c) 33 KV SS Darlapudi d) 33 KV SS Kotavarutla
e) 33 KV SS Pamulawaka
f) 33 KV SS Narsipatnam g) 33 KV SS Rolugunta
h) 33 KV SS Golugonda
i) 33 KV SS Chintapalli
j) 33 KV SS GK Veedhi (Unmanned)
k) 33 KV SS Duppiliwada (Unmanned)
l) 33 KV SS Etigyrampeta m) 33 KV SS S.Rayavaram
n) 33 KV SS P Dharmavaram (Penugollu)
o) 33 KV SS Yelamanchili p) 33 KV SS Koruprolu
q) 33 KV SS Upmaka
r) 33 KV SS Vempadu s) 33 KV SS Lamsanghai
t) 33 KV SS K.D.peta
Location -7 132 KV SS Kasimkota 2X31.5 63.00 5 Injection Points a) 132KV
SS Kasimkota
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 80
b) 33 KV SS Venkannapalem
c) 33 KV SS Chodavaram
d) 33 KV SS Cheedikada
e) 33 KV SS Koppaka SS f) 33 KV SS Anakapalle
g) 33 KV SS Rajam
h) 33 KV SS Gadirai (Vommali) i) 33 KV SS Madugula
j) 33 KV SS Waddadi
k) 33 KV SS Ravikamatham
l) 33 KV SS Kothakota SS
m) 33 KV SS Makavarapalem
n) 33 KV SS Anarak Aluminium o) 33 KV SS Velagapudi Steels
p) 33 KV SS Bayyavaram
q) 33 KV SS Narasingabilli r) 33 KV SS Toshali Cements
s) 33 KV SS Munagapaka (RECS)
Location -8 132 KV SS Payakaraopeta 1X16 + 1X31.5
47.50 5
Injection Points
a) 132KV SS
Payakaraopeta
b) 33 KV SS Srirampuram
c) 33 KV SS Nathavaram
d) 33 KV SS Satyavaram
EAST GODAVARI
Location -9 132 KV SS Peddapuram 2x31.5+1x15 78.00 5
Injection Points a) 132KV
SS Peddaparum
b) 33 KV SS PITHAPURAM, ,
c) 33 KV SS KUMARAPURAM
d) 33 KV SS CHEBROLU
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 81
e) 33 KV SS B.PRATHIPADU
f) 33 KV SS DIVILI
g) 33 KV SS PEDDAPURAM IDA
h) 33 KV SS R.B.PATNAM i) 33 KV SS SAMALKOT
j) 33 KV SS PEDDAPURAM
k) 33 KV SS MADHAVAPATNAM l) 33 KV SS VETLAPALEM
m) 33 KV SS BORRAMPALEM
n) 33 KV SS JAGGAMPETA
o) 33 KV SS GANDEPALLI
p) 33 KV SS RANGAMPETA
Location -10
132 KV SS Ramachandrapuram 2x31.5 63.00 5
Injection Points
a) 132KV SS
Ramachandrapuram
b) 33 KV SS KUTUKULURU
c) 33 KV SS BICCAVOLU
d) 33 KV SS BB PURAM
e) 33 KV SS RANGAPURAM
f) 33 KV SS RAYAVARAM g) 33 KV SS CHELLURU
h) 33 KV SS K.GANGAVARAM
i) 33 KV SS SEELAMVARI SAVARAM
j) 33 KV SS ALAMURU
k) 33 KV SS ANGARA
l) 33 KV SS SIVALA m) 33 KV SS DRAKSHARAM
n) 33 KV SS INJARAM
o) 33 KV SS TALLAREVU
p) 33 KV SS R.C.PURAM
q) 33 KV SS ARYAVATAM
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 82
r) 33 KV SS KARAPA
Location -11 132 KV SS Rajanagaram 1X16 +
1X31.5 47.50 5 --
Injection Points a) 132KV
SS Rajanagaram
b) 33 KV SS G.DONTHAMURU
c) 33 KV SS PRC PURAM
d) 33 KV SS DIWANCHERUVU
e) 33 KV SS KALAVACHARLA f) 33 KV SS RAJANAG ARAM
WEST GODAVARI Location -12 132 KV SS Kamavorapukota 1x31.5+1x2
0 51.50 5 --
Injection Points
a) 132KV SS
Kamavorapukota
b) 33 KV SS UPPALAPADU
c) 33 KV SS ANKALAMPADU
d) 33 KV SS EDAVALLI e) 33 KV SS PERAMPETA
f) 33 KV SS RAJAVARAM
g) 33 KV SS KALLACHERUVU h) 33 KV SS RANGAPURAM
i) 33 KV SS R.POTHEPALLI
j) 33 KV SS Adamilli k) 33 KV SS G.G.KUNTA
l) 33 KV SS TADIKALAPUDI
Location -13
132 KV SS Jangareddygudem 2x31.5 63.00 5
Injection Points a) 132KV
SS Jangareddygudem
b) 33 KV SS BUTTAIGUDEM
c) 33 KV SS RAMARAOPETA d) 33 KV SS DHRABAGUDEM
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 83
e) 33 KV SS JILUGUMILLI
f) 33 KV SS MYSANNAGUDEM
g) 33 KV SS TADUVAI
h) 33 KV SS J.R.GUDEM i) 33 KV SS LAKKAVARAM
j) 33 KV SS BAYYANAGUDEM
k) 33 KV SS KOYYALAGUDEM l) 33 KV SS PAREDDYGUDEM
Location -14 132 KV SS Jangareddygudem 2x31.5+1x5
0 113.00 5 --
Injection Points
a) 132KV SS
Pedatadepalli
b) 33 KV SS JAGANNAPETA
c) 33 KV SS KUNCHANAPALLI
d) 33 KV SS MODUGUNTA
e) 33 KV SS A.GOKAVARAM
f) 33 KV SS BADAMPUDI
g) 33 KV SS BHUVANAPALLI h) 33 KV SS CHEBROL
i) 33 KV SS VARADARAJAPURAM
j) 33 KV SS NEELADRIPURAM k) 33 KV SS VEERAMPALEM
l) 33 KV SS P.T.PALLI
m) 33 KV SS GOLLAGUDEM
n) 33 KV SS YERRAMALLA
o) 33 KV SS ARUGOLANU
p) 33 KV SS H.B.COLONY q) 33 KV SS PENTAPADU
r) 33 KV SS TPG
KRISHNA Location -15
132 KV SS Nuzivedu 3x50 150.00 10 --
Injection a) 132KV Nuzivedu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 84
Points SS
b) 33 KV SS Advainakkalam
c) 33 KV SS Agripalli
d) 33 KV SS katrenipadu e) 33 KV SS Meerjapuram
f) 33 KV SS Morasapudi
g) 33 KV SS Gopavaram h) 33 KV SS Gudipadu
i) 33 KV SS Musunuru
j) 33 KV SS Venkatapuram
k) 33 KV SS Ganapavaram
l) 33 KV SS Nuzivedu
m) 33 KV SS Chetlapalle n) 33 KV SS Kotapadu
o) 33 KV SS Polavaram
p) 33 KV SS Thummalagudem q) 33 KV SS Ramanakkapeta
r) 33 KV SS Janardhanapuram
s) 33 KV SS Vattigudipadu
t) 33 KV SS Chatrai
u) 33 KV SS Narasapuram
v) 33 KV SS Vissanapeta w) 33 KV SS Kondaparava
x) 33 KV SS Annavaram
GUNTUR Location -16 132 KV SS Macherla 1X31.5 +
1X50 81.50 5 --
Injection Points a) 132KV
SS Macherla
b) 33 KV SS Veldurhy.1
c) 33 KV SS Kadlakunta d) 33 KV SS Gangalakunta
e) 33 KV SS Sirigiripadu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 85
f) 33 KV SS Macherla.II
g) 33 KV SS Koppunuru
h) 33 KV SS NSDsam
i) 33 KV SS Tallapalle j) 33 KV SS Gurajala
k) 33 KV SS Retachintala
l) 33 KV SS Palvai m) 33 KV SS Mutukuru
n) 33 KV SS Durgi
o) 33 KV SS Mandadi
p) 33 KV SS Bodiveddu
q) 33 KV SS Rayavaran
Location -17
132 KV SS Piduguralla 2X31.5 63.00 10 --
Injection Points
a) 132KV SS
Piduguralla
b) 33 KV SS Nakarikallu
c) 33 KV SS rompicherla
d) 33 KV SS Vipparlareddypalem
e) 33 KV SS Cherjerala
f) 33 KV SS PGPadu
g) 33 KV SS Brhamanapalle
h) 33 KV SS Macahvaram
i) 33 KV SS Srinagar j) 33 KV SS Nadikudi
k) 33 KV SS Madinapadu
l) 33 KV SS Gadevaripalle m) 33 KV SS Janapadu
n) 33 KV SS Piduguralla
o) 33 KV SS Kondamodu
p) 33 KV SS Bellamkonda
q) 33 KV SS Rajupalem
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 86
r) 33 KV SS Papalpalem
s) 33 KV SS Sattenpalli
t) 33 KV SS Dulipalla
Location -18
132 KV SS Chilakaluripeta 1X50 + 1X31.5
81.50 5 --
Injection Points a) 132KV
SS Chilakaluripeta
b) 33 KV SS Pollireddypalem
c) 33 KV SS Maddirala d) 33 KV SS Santhamaguluru
e) 33 KV SS Purushothapatnam
f) 33 KV SS Kotappakonda g) 33 KV SS Nandivardhana
h) 33 KV SS Nadendla
i) 33 KV SS Chilaluripeta
j) 33 KV SS R.Pasumarru
k) 33 KV SS Boppudi
l) 33 KV SS Ganapavaram Location -19 132 KV SS Marripalem 1X31.5 +
1X16 47.50 5 --
Injection Points a) 132KV
SS Marripalem
b) 33 KV SS Edlapadu c) 33 KV SS Boyapaolem
d) 33 KV SS Sakku
e) 33 KV SS Viswateja f) 33 KV SS Vasundara
g) 33 KV SS Supriya
h) 33 KV SS Ananathalakshmi i) 33 KV SS Ranganayaka
PRAKASHAM Location -20 132 KV SS Cumbum 1X31.5 +
2X16 63.50 5 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 87
Injection Points a) 132KV
SS Cumbum
b) 33 KV SS Racherla
c) 33 KV SS Yerrabalem
d) 33 KV SS Akaveedu e) 33 KV SS Mohiddinpuram
f) 33 KV SS Yachavaram
g) 33 KV SS Aradhaveedu h) 33 KV SS Akkapalle
i) 33 KV SS Pitakayagulla
j) 33 KV SS Kandulapuram k) 33 KV SS BVPeta
l) 33 KV SS Tarlupadu
m) 33 KV SS Ravipadu n) 33 KV SS Ummareddypalle
o) 33 KV SS TRPalle
p) 33 KV SS Komatikunta
q) 33 KV SS Puchakayalapalle
r) 33 KV SS Thippayapalem
Location -21
132 KV SS Kanigiri 2X31.5 63.00 5 --
Injection Points
a) 132KV SS
Kanigiri
b) 33 KV SS KKMitta
c) 33 KV SS Nandanamarella d) 33 KV SS Chinnarikatla
e) 33 KV SS Gotlagattu
f) 33 KV SS TRPalle g) 33 KV SS SRPuram
h) 33 KV SS Veligandla
i) 33 KV SS Rallapadu
j) 33 KV SS Tallur
k) 33 KV SS P.Alavalapadu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 88
l) 33 KV SS P.Eralapadu
m) 33 KV SS PCPalle
n) 33 KV SS Guravajipeta
o) 33 KV SS BPAddaroad Location -22 132 KV SS Kandukuru 1X31.5 +
1X15 46.50 5 --
Injection Points a) 132KV
SS Kandukuru
b) 33 KV SS Kandukuru Town c) 33 KV SS East Kandukuru
d) 33 KV SS Pamur Road
e) 33 KV SS Kandukuru Rural f) 33 KV SS Ponnalur
g) 33 KV SS Agraharam
h) 33 KV SS Lingasamudram
i) 33 KV SS VV Palem
j) 33 KV SS Chinnapavani
k) 33 KV SS Pokuru l) 33 KV SS Naladalapur
m) 33 KV SS Gudlur
n) 33 KV SS Machavaram o) 33 KV SS S.Konda
p) 33 KV SS Karedu
q) 33 KV SS Ulavapadu
r) 33 KV SS Tettu
s) 33 KV SS Pakala
t) 33 KV SS Narasingolu u) 33 KV SS Kondepi
v) 33 KV SS Uppalapadu
w) 33 KV SS M.Nidamanur x) 33 KV SS Jarugumalli
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 89
Location -23 132 KV SS Peddadornala 2X16 32.00 5 --
Injection Points
a) 132KV SS
Peddadornala
b) 33 KV SS Dornala
c) 33 KV SS Sanikavaram
d) 33 KV SS B.Cherlopalli
e) 33 KV SS P.Bommanapuram
f) 33 KV SS Y.Cherlopalli
Location -24
132 KV SS Martur 2X31.5 63.00 5 --
Injection Points
a) 132KV SS
Martur
b) 33 KV SS Ballikurava
c) 33 KV SS Kommalapadu d) 33 KV SS V.Kopperapadu
e) 33 KV SS Konanaki
f) 33 KV SS Dhramavaram NELLORE
Location -25 132 KV SS Kavali 2X31.5 63.00 5 --
Injection Points a) 132KV
SS Kavali
b) 33 KV SS Jaladanki c) 33 KV SS Brahmanakraka
d) 33 KV SS Ananathapuram
e) 33 KV SS Ayyapreddypalem f) 33 KV SS Basireddypalem
g) 33 KV SS Kaligiri
h) 33 KV SS Bogolu
i) 33 KV SS VRNagar
j) 33 KV SS Maddurupadu
k) 33 KV SS Pullaredynagar l) 33 KV SS Annagaripalem
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 90
m) 33 KV SS Chowdawaram
n) 33 KV SS Kommi
o) 33 KV SS Kondapuram
Location -26
132 KV SS Chendodu 2X31.5 63.00 5 --
Injection Points a) 132KV
SS Chendodu
b) 33 KV SS N.P.Kothapalem
c) 33 KV SS Kota d) 33 KV SS Siddawaram
e) 33 KV SS Gunapadu
f) 33 KV SS Eswarawaka g) 33 KV SS Mallam
h) 33 KV SS Kothagunta
i) 33 KV SS Vakadu
j) 33 KV SS BRPalem
k) 33 KV SS Konduru
l) 33 KV SS Ankulapaturu m) 33 KV SS Chinthavaram
Location -27 132 KV SS Naidupet 2X31.5 63.00 5 --
Injection Points
a) 132KV SS
Naidupet
b) 33 KV SS Chillakuru
c) 33 KV SS Sirasmabedu
d) 33 KV SS KGKandriga e) 33 KV SS Menskur
f) 33 KV SS Naidupeta
g) 33 KV SS Thummuru h) 33 KV SS Annamedu
i) 33 KV SS Yakasini
j) 33 KV SS Puduru
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 91
CHITTOOR Location -28
132 KV SS Palamaneur 1X31.5 + 1X50
81.50 5 --
Injection Points
a) 132KV SS
Palamaneur
b) 33 KV SS Bairedipalle
c) 33 KV SS Kolamasanpalle
d) 33 KV SS Kasturinagar
e) 33 KV SS Tekumanda
f) 33 KV SS Ragimanupenta g) 33 KV SS Mogili
h) 33 KV SS Kadirimadugu
i) 33 KV SS Pathikonda j) 33 KV SS Peddapurm
k) 33 KV SS Melmai
Location -29
132 KV SS Madanapally 1X50 + 1X31.5
81.50 10 --
Injection Points
a) 132KV SS
Madanapally
b) 33 KV SS Nimmanapalle
c) 33 KV SS Reddivaripalle d) 33 KV SS Vengamavariapalle
e) 33 KV SS CTM
f) 33 KV SS Kantevaripalle g) 33 KV SS Kotavuru
h) 33 KV SS Ammcheruvu mitta
i) 33 KV SS Nayanabavi j) 33 KV SS Pothapolu
k) 33 KV SS Valasapalle
l) 33 KV SS Vemaplle m) 33 KV SS Bommanacheruvu
n) 33 KV SS Kurabalakota
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 92
Location -30 132 KV SS Pakala 1X31.5 +
1X16 47.50 5 --
Injection Points
a) 132KV SS
Pakala
b) 33 KV SS Achamaagaraharam
c) 33 KV SS M.N.Palle
d) 33 KV SS Damaracheruvu
e) 33 KV SS Kalluru
f) 33 KV SS Pulicherla
g) 33 KV SS Ashoknagar h) 33 KV SS Mangalamapeta
i) 33 KV SS Vallivedu
j) 33 KV SS Puthalapattu k) 33 KV SS Petamitta
l) 33 KV SS M.Bandapalle
Location -31
132 KV SS Shanthipuram 1X50 + 1X31.5
81.50 5 --
Injection Points
a) 132KV SS
Shanthipuram
b) 33 KV SS Rallbuduguru
c) 33 KV SS Chinnabaldar d) 33 KV SS Ramakuppam
e) 33 KV SS Aanikeri
f) 33 KV SS Suddalakuppam g) 33 KV SS Sivaramanapuram
h) 33 KV SS Arimanupenta
i) 33 KV SS V.Kota j) 33 KV SS Cheldiganipalle
Location -32 132 KV SS Nagiri 1X31.5 +
1X16 47.50 10 --
Injection Points
a) 132KV SS
Nagiri
b) 33 KV SS Nethamkandriga
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 93
c) 33 KV SS M.Kothuru
d) 33 KV SS Pannuru
e) 33 KV SS Vijayapuram
f) 33 KV SS Kalikapuram g) 33 KV SS Kosalanagaram
h) 33 KV SS Netteri
i) 33 KV SS Mittakandriga j) 33 KV SS Irruguvoi
Location -33 132 KV SS Kothapallimitta 1X50 +
1X31.5 81.50 10 --
Injection Points
a) 132KV SS
Kothapallimitta
b) 33 KV SS Katiripalle
c) 33 KV SS Chinnatayyuru
d) 33 KV SS Katikapalle
e) 33 KV SS SRPuram
f) 33 KV SS Nelavoi
g) 33 KV SS Kondakindpalle h) 33 KV SS Vedurkuppam
i) 33 KV SS Mambedu
j) 33 KV SS NVPalle k) 33 KV SS Allamadugu
l) 33 KV SS Penumuru
m) 33 KV SS Mattampalle
n) 33 KV SS Polavaram
o) 33 KV SS Bandarlapalle
p) 33 KV SS GDNellore q) 33 KV SS Avulakonda
r) 33 KV SS SSKonda
s) 33 KV SS VRKuppam t) 33 KV SS SBRpuram
u) 33 KV SS Vepamjeri
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 94
Location -34
132 KV SS Burakayalakota 2X31.5 63.00 10 --
Injection Points
a) 132KV SS
Burakayalakota
b) 33 KV SS Rangasamudrum
c) 33 KV SS Nanbavi
d) 33 KV SS kandukuru
e) 33 KV SS Gopidinne
f) 33 KV SS Chowdasamudurm g) 33 KV SS Burakayalakota
h) 33 KV SS Mulakalacherubu
i) 33 KV SS B.Kohakota j) 33 KV SS PTM
k) 33 KV SS Varikasuvupalle
l) 33 KV SS Mallela
Location -35 132 KV SS Kuppam 2X31.5 63.00 10 --
Injection Points a) 132KV
SS Kuppam
b) 33 KV SS Mallanuru c) 33 KV SS Laskhmipuram
d) 33 KV SS Adivibuduguru
e) 33 KV SS Gudipalle f) 33 KV SS Vasanadu
KADAPA Location -36 132 KV SS Badwel 2X16 32 5 --
Injection Points a) 132KV
SS Badvel
b) 33 KV SS Peddapolukunta
c) 33 KV SS Gangapenta
d) 33 KV SS Payalakunta
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 95
e) 33 KV SS B.Kodur
f) 33 KV SS Konduru
g) 33 KV SS Sidaout
h) 33 KV SS Venkatasettipalle i) 33 KV SS D.Agraharam
j) 33 KV SS Badvel-II
Location -37 132 KV SS Rayachoti 2X31.5 63 5 --
Injection Points
a) 132KV SS
Rayachoti
b) 33 KV SS T.Sundupalli
c) 33 KV SS Rayavaram d) 33 KV SS Gundlapalli
e) 33 KV SS Pujarivandlapalli
f) 33 KV SS Rayachoty
g) 33 KV SS Masapeta
h) 33 KV SS L.R.Pallif
i) 33 KV SS Ramapuram j) 33 KV SS Veeraballi
k) 33 KV SS Matil
l) 33 KV SS Vangimalla m) 33 KV SS Gadikota
n) 33 KV SS Galiveedu
o) 33 KV SS Madhavaram
p) 33 KV SS Nooliveedu
Location -38 132 KV SS Vontimitta 2x16 32 5 --
Injection Points a) 132KV
SS Vontimitta
b) 33 KV SS Peddapalle
c) 33 KV SS Mantapamapalle
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 96
Location -39 132 KV SS Jammalamadugu 2X16 32 5 --
Injection Points
a) 132KV SS
Jammalamadugu
b) 33 KV SS Gundlakunta
c) 33 KV SS Diguvakalavatala
d) 33 KV SS Namalladinne
e) 33 KV SS Torivemula
f) 33 KV SS Thalamanchipatnam
g) 33 KV SS Mylavaram h) 33 KV SS Dodlum
i) 33 KV SS Ambavaram
j) 33 KV SS Danavulapadu
Location -40 132 KV SS Sambepalli 2X16 32 5 --
Injection Points a) 132KV
SS Sambepalle
b) 33 KV SS C.Mandam
c) 33 KV SS Pedamatikona
d) 33 KV SS Devapatla
e) 33 KV SS Mallur ANANTHAPUR
Location -41
132 KV SS Kadri 1X50 + 1X31.5
81.5 5 --
Injection Points a) 132KV
SS Kadri
b) 33 KV SS Kondakamarla c) 33 KV SS Amadugur
d) 33 KV SS Mohamadbad
e) 33 KV SS Nallacheruv u f) 33 KV SS Tanakallu
g) 33 KV SS Chikatimanipalli
h) 33 KV SS Kokanti Cross i) 33 KV SS Peddapalli
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 97
j) 33 KV SS N.P.Kunta
k) 33 KV SS Gajulavaripalli
l) 33 KV SS Gandlapenta
m) 33 KV SS Kadiri n) 33 KV SS Kuttagulla
o) 33 KV SS N.S.G.Palli
p) 33 KV SS Malakavemula q) 33 KV SS Mallepalli
r) 33 KV SS Mudigubba
s) 33 KV SS Kodavandlapalli
t) 33 KV SS O.D.Cheruvu
u) 33 KV SS Pulagampalli
v) 33 KV SS Talapula w) 33 KV SS Batrepalli
x) 33 KV SS Ganjivaripalli
Location -42 132 KV SS Tadipatri 2 X50 100 5 --
Injection Points a) 132KV
SS Tadipatri
b) 33 KV SS Tadipatri Nandyala Road
c) 33 KV SS Rayalacheruvu
d) 33 KV SS Konauppalapadu
e) 33 KV SS Sajjaladinne
f) 33 KV SS Chukkalur g) 33 KV SS P.Yekkaluru
h) 33 KV SS P.Pappuru
i) 33 KV SS Dharmapuram j) 33 KV SS Kammavaripalli
k) 33 KV SS Nitturu
l) 33 KV SS Bugga
m) 33 KV SS AVT.Palli
n) 33 KV SS A.Kondapuram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 98
o) 33 KV SS Maddipalli
p) 33 KV SS Yellutla
KURNOOL Location -43 132 KV SS Allagadda 2X31.5 63 5 --
Injection Points a) 132KV
SS Allagadda
b) 33 KV SS Uyyalawada,
c) 33 KV SS Perusomula,
d) 33 KV SS Nossam e) 33 KV SS Chagalamarri,
f) 33 KV SS K. Kandukuru,
g) 33 KV SS P.Bodanam h) 33 KV SS Chinthalacheruvu
i) 33 KV SS Alamuru (Allagada)
j) 33 KV SS Ahobilam,
k) 33 KV SS C T R Palli
l) 33 KV SS Muthylapadu,
m) 33 KV SS R.K.Puram, n) 33 KV SS Rudravaram
o) 33 KV SS Yerraguntla
p) 33 KV SS Dornipadu,
q) 33 KV SS Kalugotla (Koilakuntla)
Location -44 132 KV SS Adoni 2X31.5 63 5 --
Injection Points a) 132KV
SS Adoni
b) 33 KV SS S.K.D.Colony,
c) 33 KV SS Arts College
d) 33 KV SS Baichigiri e) 33 KV SS Kamavaram,
f) 33 KV SS Kowthalam
g) 33 KV SS Halvi,
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 99
h) 33 KV SS Nadichagi
i) 33 KV SS Gulyam
j) 33 KV SS yellarthy
k) 33 KV SS Holagunda
l) 33 KV SS Chippagiri (Alternate)
m) 33 KV SS Molagavalli
n) 33 KV SS Basaladoddi, o) 33 KV SS Vandagal,
p) 33 KV SS Kosigi
q) 33 KV SS Kolamanpeta r) 33 KV SS Market yard
s) 33 KV SS santhakodur,
t) 33 KV SS Kallubavi u) 33 KV SS Alur,
v) 33 KV SS Kammarachedu
w) 33 KV SS Nagaradona,
x) 33 KV SS Halaharvi
y) 33 KV SS Ganekal
z) 33 KV SS Pedda thumbalam Location -45
132 KV SS Pathikonda 2X31.5 63 10 --
Injection Points a) 132KV
SS Pathikonda
b) 33 KV SS Devanakonda c) 33 KV SS E.D.Banda,
d) 33 KV SS Yerrabadu,
e) 33 KV SS Kothiralla f) 33 KV SS Gundlakonda
g) 33 KV SS Aspari,
h) 33 KV SS Dibbanakal,
i) 33 KV SS Devanabanda
j) 33 KV SS Maddikera,
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 100
k) 33 KV SS Tuggali,
l) 33 KV SS Jonnagiri
m) 33 KV SS Pathikonda,
n) 33 KV SS R.S.Pendekal Location -46 132 KV SS Gudur 2X16 32 5 --
Injection Points a) 132KV
SS Gudur
b) 33 KV SS Kothakota c) 33 KV SS Gudur
d) 33 KV SS C.Belagal
e) 33 KV SS Polakal f) 33 KV SS Gundrevula
g) 33 KV SS Kodumur,
h) 33 KV SS Pulakurthy
Location -47 132 KV SS Banaganapalli 2X16 32 5 --
Injection Points a) 132KV
SS Banaganapalli,
b) 33 KV SS Yanakandla, c) 33 KV SS Palukuru.
d) 33 KV SS Owk,
e) 33 KV SS Akumalla, f) 33 KV SS I.K.Peta,
g) 33 KV SS Uppalapadu,
h) 33 KV SS Ramapuram. (Alternate)
i) 33 KV SS Gundla Singavaram
j) 33 KV SS Kolilakuntla,
k) 33 KV SS Gulladurthy, l) 33 KV SS Sanjamala
m) 33 KV SS Pathapadu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 101
Location -48 132 KV SS Gandikota 1X50 50 5 --
Injection Points
a) 132KV SS
Gandikota (LIS)
MAHABUBNAGAR Location -49 132 KV SS Nagarkurnool 1X31.5+1X
50 81.5 10 --
Injection Points
a) 132KV SS
Nagarkurnool
b) 33 KV SS Ithole
c) 33 KV SS Tadoor
d) 33 KV SS Yangampally
e) 33 KV SS Kummera
f) 33 KV SS Bijnapally
g) 33 KV SS Peddamudunoor h) 33 KV SS Manganoor
i) 33 KV SS Mumaipally
j) 33 KV SS Waddeman k) 33 KV SS Manthati
l) 33 KV SS Kollapur X Roads
m) 33 KV SS Telkapally n) 33 KV SS Rakonda
o) 33 KV SS Peddur
p) 33 KV SS Tallapally q) 33 KV SS Peddapur
r) 33 KV SS Kondareddypally
Location -
50 132 KV SS Wanaparthy 2X50 100 5 --
Injection Points a) 132KV
SS Wanaparthy
b) 33 KV SS Kothakota
c) 33 KV SS Kurumurthy d) 33 KV SS Madanapur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 102
e) 33 KV SS Kothapally
f) 33 KV SS Ramanpad
g) 33 KV SS Peddamandadi
h) 33 KV SS Addakal i) 33 KV SS Ponnakal
j) 33 KV SS Veltoor
k) 33 KV SS Solipur l) 33 KV SS Buddaram
m) 33 KV SS Balijapally
n) 33 KV SS Kandur
o) 33 KV SS Mamidimada
p) 33 KV SS Gopalpet
q) 33 KV SS Revally r) 33 KV SS P.K.Pally
s) 33 KV SS Thudkurthy
t) 33 KV SS Chennaram u) 33 KV SS Peddakarpamula
v) 33 KV SS Ayyavaripally
w) 33 KV SS Remaddula
x) 33 KV SS Rajapur
y) 33 KV SS Kodair
z) 33 KV SS Tirumalapur a1) 33 KV SS Kethepally
a2) 33 KV SS Pangal
a3) 33 KV SS Pebbair a4) 33 KV SS Williamkonda
a5) 33 KV SS Srinivasapuram
a6) 33 KV SS Nasanally
a7) 33 KV SS Sri Rangapur
Location -
51 132 KV SS Thimmapur 1X50+2X31.5 113 10 --
Injection a) 132KV Thimmapur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 103
Points SS
b) 33 KV SS Kothur
c) 33 KV SS Sangem
d) 33 KV SS Inmulnarva e) 33 KV SS Kothapet
Location -
52 132 KV SS Gadwal 2X50 100 10 --
Injection Points
a) 132KV SS
Gadwal
b) 33 KV SS Veerapur
c) 33 KV SS Beechupally
d) 33 KV SS Kodandapur e) 33 KV SS Gadwal
f) 33 KV SS Gadwal Town
g) 33 KV SS Alwalpad
h) 33 KV SS Dharoor
i) 33 KV SS Nandinne
j) 33 KV SS Dyagadoddi k) 33 KV SS Maldakal
l) 33 KV SS Ieeza
m) 33 KV SS Mallamdoddi n) 33 KV SS P.T.Pad
o) 33 KV SS Budidapad
p) 33 KV SS Bijjaram
q) 33 KV SS Amarchinta
r) 33 KV SS Atmakur
s) 33 KV SS Peddakadmoor Location -
53 132 KV SS Makthal 1X50+1X31.5 81.5 5 --
Injection Points a) 132KV
SS Makthal
b) 33 KV SS Jaklair
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 104
c) 33 KV SS Bijwar
d) 33 KV SS Narva
e) 33 KV SS Narayanpet
f) 33 KV SS Utkoor g) 33 KV SS Pasupula
h) 33 KV SS Mushtipally
i) 33 KV SS Gudeballore j) 33 KV SS Kolpur
k) 33 KV SS Maganoor
l) 33 KV SS Krishna
Location -
54 132 KV SS Kodangal 2X31.5 63 5 --
Injection Points a) 132KV
SS Kodangal
b) 33 KV SS Dudyal
c) 33 KV SS Kosigi
d) 33 KV SS Kodangal
e) 33 KV SS Ravulapally f) 33 KV SS Doultabad
g) 33 KV SS Suraipally
h) 33 KV SS Sarjakhanpet i) 33 KV SS Hamsanpally
Location -
55 132 KV SS Balanagar 1X50+2X31.5 113 10 --
Injection Points
a) 132KV SS
Balanagar
b) 33 KV SS Chinchode
c) 33 KV SS Peddarevally
d) 33 KV SS Thommidirekula e) 33 KV SS Balanagar
f) 33 KV SS Rajapur
g) 33 KV SS Polepally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 105
h) 33 KV SS Kollur
i) 33 KV SS Udityal
j) 33 KV SS Yedira
k) 33 KV SS Raikal l) 33 KV SS Gantlavelly
m) 33 KV SS Dooskal
n) 33 KV SS Gundlapotlapally Location -
56 132 KV SS Achampet 2X31.5 63 5 --
Injection Points a) 132KV
SS Achampet
b) 33 KV SS Lingal c) 33 KV SS Kondanagula
d) 33 KV SS Inole
e) 33 KV SS Amrabad
f) 33 KV SS Vankeshwaram
g) 33 KV SS Hajipur
h) 33 KV SS Uppununthala i) 33 KV SS Veltoor
j) 33 KV SS Mannewaripally
Location -
57 132 KV SS Amangal 2X31.5 63 10 --
Injection Points a) 132KV
SS Amangal
b) 33 KV SS Madgul
c) 33 KV SS Nagilla d) 33 KV SS Arkepally
e) 33 KV SS Polepally
f) 33 KV SS Irvin g) 33 KV SS Akutotapally
h) 33 KV SS Amangal
i) 33 KV SS Kadthal
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 106
j) 33 KV SS Mudwin
k) 33 KV SS Karkalpad
l) 33 KV SS Talakondapally
m) 33 KV SS Chukapur n) 33 KV SS Raviched
Location -
58 132 KV SS Kalwakurthy 2X31.5+1X50 113 10 --
Injection Points
a) 132KV SS
Kalwakurthy
b) 33 KV SS Sirsangandla
c) 33 KV SS Tandra
d) 33 KV SS Jajala e) 33 KV SS Polkampally
f) 33 KV SS Gundoor
g) 33 KV SS Ellikal
h) 33 KV SS Totapally
i) 33 KV SS Dindichintapally
j) 33 KV SS Veldanda k) 33 KV SS Peddapur
l) 33 KV SS Bollampally
m) 33 KV SS Rachur n) 33 KV SS Madaram
o) 33 KV SS Marchala
p) 33 KV SS Jaknalpally
q) 33 KV SS Urkonda
r) 33 KV SS Gattuippalapally
s) 33 KV SS Juppally t) 33 KV SS Vangoor
u) 33 KV SS Sarvareddypally
v) 33 KV SS Kalwakurthy Location -
59 132 KV SS Midjil 2X16 32 5 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 107
Injection Points a) 132KV
SS Midjil
b) 33 KV SS Velgomula
c) 33 KV SS Kothapally
d) 33 KV SS Kodgal e) 33 KV SS Konded
f) 33 KV SS Avancha
g) 33 KV SS Donur h) 33 KV SS Vemula
i) 33 KV SS Veljal
j) 33 KV SS Keshampet k) 33 KV SS Midjil
Location -
60 132 KV SS Marikal 2X31.5 63 5 --
Injection Points a) 132KV
SS Marikal
b) 33 KV SS Kondapur
c) 33 KV SS Deverkadra
d) 33 KV SS Sanginonipally e) 33 KV SS Nagaram Gate
f) 33 KV SS Eklaspur
g) 33 KV SS Waddeman
h) 33 KV SS Marikal
i) 33 KV SS Dhanwada
j) 33 KV SS Chinnajatram k) 33 KV SS Kotakonda
l) 33 KV SS Koukuntla
m) 33 KV SS Krishna MEDAK
Location -61
132 KV SS Sadasivapet 1X50+1X31.5
81.5 15 --
Injection Points a) 132KV
SS Sadasivapet
b) 33 KV SS Nizampur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 108
c) 33 KV SS Athmakur
d) 33 KV SS Jackwell
e) 33 KV SS Munipally
f) 33 KV SS Tatipally g) 33 KV SS Aroor
h) 33 KV SS Kamkole
i) 33 KV SS Sadasivpet j) 33 KV SS Kohir
k) 33 KV SS Bilalpur
Location -
62 132 KV SS Gajwal 2X50 100 10 --
Injection Points
a) 132KV SS
Gajwel
b) 33 KV SS Gowraram
c) 33 KV SS Wargal
d) 33 KV SS Markook
e) 33 KV SS Adavimajeedpally
f) 33 KV SS Karkapatla g) 33 KV SS Mulugu
h) 33 KV SS Wantimamidi
i) 33 KV SS B.V. Poor j) 33 KV SS Bejgam
k) 33 KV SS Ahmedipur
l) 33 KV SS Nimtoor
m) 33 KV SS Begumpet
n) 33 KV SS Wardharajpur
o) 33 KV SS Jagadevpur p) 33 KV SS Munigadapa
q) 33 KV SS Chatlapally
r) 33 KV SS Gajwel s) 33 KV SS Pregnapur
t) 33 KV SS Ganeshpally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 109
u) 33 KV SS Kodakandla
Location -
63 132 KV SS Kandi 2X50 100 5 --
Injection Points a) 132KV
SS Kandi
b) 33 KV SS Sangareddy - I
c) 33 KV SS Sangareddy - II
d) 33 KV SS Collector Complex
e) 33 KV SS Cheryal f) 33 KV SS Ismailkhan Pet
g) 33 KV SS Kondapur
h) 33 KV SS Malkapur i) 33 KV SS Gollapally
j) 33 KV SS Nandi gama
k) 33 KV SS T K Pur
l) 33 KV SS Gundla Machnoor
m) 33 KV SS Rudraram
Location -
64 132 KV SS Kowdipally 1X31.5+1X
16 47.5 5 --
Injection Points
a) 132KV SS
Kowdipally
b) 33 KV SS Kulcharam
c) 33 KV SS Amsanpally d) 33 KV SS Kowdipally
e) 33 KV SS Kanchanpally
f) 33 KV SS Rangampet g) 33 KV SS Venkatraopet
h) 33 KV SS Siripura
i) 33 KV SS Bujarampet j) 33 KV SS Rajipet
k) 33 KV SS Salabathpur
l) 33 KV SS Waddepally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 110
m) 33 KV SS Yenigandla
Location -
65 132 KV SS Manoharabad 1X50+1X31.5 81.5 15 --
Injection Points a) 132KV
SS Manoharabad
b) 33 KV SS Imampur
c) 33 KV SS Toopran
d) 33 KV SS Danthanpally
e) 33 KV SS Nagulapally f) 33 KV SS Sikindlapur
g) 33 KV SS Shivampet
h) 33 KV SS Chinna Gotti Mukkala
i) 33 KV SS Panbanda
j) 33 KV SS Manoharabad
k) 33 KV SS Kallakal l) 33 KV SS Nacharam
m) 33 KV SS Islampur
n) 33 KV SS Chetla Gowraram o) 33 KV SS Muppireddypally
Location -
66 132 KV SS Zaheerabad 2X31.5 63 10 --
Injection Points a) 132KV
SS Zaheerabad
b) 33 KV SS Zaheerabad Town
c) 33 KV SS Hadnoor
d) 33 KV SS Raikode
e) 33 KV SS Chalki
f) 33 KV SS Metal Kunta
g) 33 KV SS Nyalkal h) 33 KV SS Mamidgi
i) 33 KV SS Singitham
j) 33 KV SS Mohabathpur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 111
k) 33 KV SS Digwal
l) 33 KV SS Aligole
m) 33 KV SS Jharasangam
n) 33 KV SS Machnoor o) 33 KV SS Mannapur
p) 33 KV SS Malchelma
q) 33 KV SS Chota Hyderabad r) 33 KV SS Sathwar
Location -
67 132 KV SS Gummadiddala 1X50+1X31.5 81.5 5 --
Injection Points
a) 132KV SS
Gummadidala
b) 33 KV SS Kanukunta
c) 33 KV SS Vishal Projects
d) 33 KV SS Nallavally
e) 33 KV SS Bonthapally
f) 33 KV SS Solakpally
g) 33 KV SS Jinnaram h) 33 KV SS Dundigal
Location -
68 132 KV SS Narayanakhed 2X31.5 63 10 --
Injection Points
a) 132KV SS
Narayanakhed
b) 33 KV SS Bodagattu
c) 33 KV SS Shankarampet
d) 33 KV SS Nizampet e) 33 KV SS Burugupally
f) 33 KV SS Hanmanthraopet
g) 33 KV SS Narayankhed h) 33 KV SS Manoor
i) 33 KV SS Poosalpad
j) 33 KV SS Borancha
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 112
k) 33 KV SS Regode
l) 33 KV SS Karasgutti
m) 33 KV SS Wasar
n) 33 KV SS Thadkal o) 33 KV SS Kangti
p) 33 KV SS Ryakal
q) 33 KV SS Kalher r) 33 KV SS Bachepally
s) 33 KV SS Fathepur
t) 33 KV SS Sirgapoor
u) 33 KV SS Sanjeevraopet
Location -
69 132 KV SS Medak 2X31.5 63 10 --
Injection Points a) 132KV
SS Medak
b) 33 KV SS Pillikotyal
c) 33 KV SS NSF
d) 33 KV SS Ch.Ghanapur e) 33 KV SS B Bhoopathipur
f) 33 KV SS Wadi
g) 33 KV SS Thogita h) 33 KV SS Sardana
i) 33 KV SS Pathur
j) 33 KV SS Nagapur
k) 33 KV SS M.Bhupathipur
l) 33 KV SS Rajpally
m) 33 KV SS Ch.Shankarampet n) 33 KV SS Gavvalapally
o) 33 KV SS Suraram
p) 33 KV SS Shalipet Location -
70 132 KV SS Tukkapur 1X31.5+1X50 81.5 10 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 113
Injection Points a) 132KV
SS Tukkapur
b) 33 KV SS Mirdoddy
c) 33 KV SS Jangapally
d) 33 KV SS Khajipur e) 33 KV SS Pedda Chepyal
f) 33 KV SS Thukkapur
g) 33 KV SS Mettu h) 33 KV SS Gudikandula
i) 33 KV SS Lingapur
j) 33 KV SS Pallepahad k) 33 KV SS Thoguta
l) 33 KV SS Gurralasofa
m) 33 KV SS Raipole n) 33 KV SS Ramsagar
o) 33 KV SS Dommat
p) 33 KV SS Mubaraspur
q) 33 KV SS Doulthabad
r) 33 KV SS Mohd.Shapur
s) 33 KV SS Govindapur Location -
71 132 KV SS Chegunta 2X50 100 10 --
Injection Points a) 132KV
SS Chegunta
b) 33 KV SS Bonala c) 33 KV SS Narlapur
d) 33 KV SS Karnalpally
e) 33 KV SS Kalwakunta f) 33 KV SS Narsingi
g) 33 KV SS D.Dharmaram
h) 33 KV SS Chandaipet
i) 33 KV SS Masaipet
j) 33 KV SS Yeldurthy
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 114
k) 33 KV SS Ramaipally
l) 33 KV SS Chegunta
Location -
72 132 KV SS Narsapur 2X31.5 63 10 --
Injection Points a) 132KV
SS Narsapur
b) 33 KV SS Lingapur
c) 33 KV SS Reddypally
d) 33 KV SS Chippalthurthy e) 33 KV SS Kothapet
f) 33 KV SS Kagazmaddur
g) 33 KV SS Mangalparthy h) 33 KV SS Avancha
i) 33 KV SS Nasthipur
j) 33 KV SS Hathnoora
Location -
73 132 KV SS Habsipur 2X31.5 63 10 --
Injection Points a) 132KV
SS Habsipur
b) 33 KV SS Dubbak c) 33 KV SS Pedda Cheekode
d) 33 KV SS Chellapur
e) 33 KV SS Gambheerpur f) 33 KV SS Dharmajipet
g) 33 KV SS Raghothampally
h) 33 KV SS Chittapur i) 33 KV SS Pothareddypet
j) 33 KV SS Rudraram
k) 33 KV SS Habsipur Location -
74 132 KV SS Ramayapet 2X16 32 10 --
Injection a) 132KV Ramayampet
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 115
Points SS
b) 33 KV SS Zapthi Shivanur
c) 33 KV SS Nizampet
d) 33 KV SS Konapur e) 33 KV SS Naskal
f) 33 KV SS Katriyal
g) 33 KV SS Laxmapur Location -
75 132 KV SS Pedda Shankarampeta 1X16 16 10 --
Injection Points a) 132KV
SS Pedda Shankarampeta
Location -
76 132 KV SS Minpur 2X16 32 10 --
Injection Points a) 132KV
SS Minpur
b) 33 KV SS Podchan pally c) 33 KV SS Kothaipally
d) 33 KV SS Minpur
e) 33 KV SS Kodapak f) 33 KV SS Narsingi
g) 33 KV SS Tekmal
h) 33 KV SS Achnapally i) 33 KV SS P.Lingaipaly
j) 33 KV SS Palvancha (Dhanoora)
k) 33 KV SS Kaduloor
RANGA REDDY Location -
77 132 KV SS Medchal 1X31.5+2X50 131.5 5 --
Injection Points
a) 132KV SS
Medchal
b) 33 KV SS Kistapur
c) 33 KV SS Ravalkole
d) 33 KV SS Keshavaram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 116
e) 33 KV SS Kolthur
f) 33 KV SS Laxmapur
g) 33 KV SS Uddamarry
h) 33 KV SS ICICI
i) 33 KV SS Turkapally
j) 33 KV SS Medicity
k) 33 KV SS Athiwelly
l) 33 KV SS Yellempet
m) 33 KV SS Bandamadaram
n) 33 KV SS Gowdawelly
o) 33 KV SS GP Pally
p) 33 KV SS Deveryamjal
Location -
78 132 KV SS
Dharmasagar(Chervella) 2X31.5 63 10 --
Injection Points a) 132KV
SS Dharmasagar (Chevella)
b) 33 KV SS Kandawada
c) 33 KV SS Shabad
d) 33 KV SS Chandanvally
e) 33 KV SS Tallapally
f) 33 KV SS Bobbiligaon
g) 33 KV SS Aloor
h) 33 KV SS Kowkuntla
i) 33 KV SS Devunieravally
Location -79 132 KV SS Puttapahad 1x31.5+1x1
6 47.5 10 --
Injection Points a) 132KV
SS Puttapahad
b) 33 KV SS Chowdapur
c) 33 KV SS Marikal
d) 33 KV SS Puttapahad e) 33 KV SS Mohmmadabad
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 117
f) 33 KV SS Salkarpet
g) 33 KV SS Mumbapur
h) 33 KV SS Nancherla
i) 33 KV SS Veenuchedu j) 33 KV SS Dirsampally
k) 33 KV SS Gundal
l) 33 KV SS Doma m) 33 KV SS Mujahidpur
n) 33 KV SS Mothukuru
o) 33 KV SS Kulkacherla
Location -
80 132 KV SS Turkayamjal
(Hayatnagar) 2x31.5 63 10 --
Injection Points a) 132KV
SS Turkayamjal (Hayatnagar)
b) 33 KV SS Vanasthalipuram
c) 33 KV SS Turkayamzal
Location -
81 132 KV SS Pargi 2x31.5 63 10 --
Injection Points
a) 132KV SS
Pargi
b) 33 KV SS Manneguda
c) 33 KV SS Peddumenthol
d) 33 KV SS Siddalur
e) 33 KV SS Pargi
f) 33 KV SS Rapole g) 33 KV SS Rangampally
HYDERABAD Location -
82 132 KV SS Vikarabad Swt. Sn Swt. Sn 15 --
Injection Points
a) 132KV SS
Vikarabad
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 118
NALGONDA Location -
83 132 KV SS Nalgonda 1x50+2x31.5 113 15 --
Injection Points a) 132KV
SS Nalgonda
b) 33 KV SS Pole Centre c) 33 KV SS Panagal d) 33 KV SS SLBC e) 33 KV SS Velugupally f) 33 KV SS Mushampally g) 33 KV SS P.D.Pally h) 33 KV SS Narsingbatla i) 33 KV SS Appajipeta j) 33 KV SS Anneparthy k) 33 KV SS Indoor l) 33 KV SS Gollaguda m) 33 KV SS Rayanaguda n) 33 KV SS Pazzur o) 33 KV SS Rajupet p) 33 KV SS Ch.Mamidi q) 33 KV SS Gudapur r) 33 KV SS Kattangur s) 33 KV SS Aitipamula t) 33 KV SS Pamanagundla Location -
84 132 KV SS Alair (Kolanupak) 2x50 100 15 --
Injection Points a) 132KV
SS Alair(Kolanupak)
b) 33 KV SS Motakonduru
c) 33 KV SS Shaharajpeta
d) 33 KV SS Bhachannapeta
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 119
e) 33 KV SS Raghunathpuram
f) 33 KV SS Yadagirigutta
g) 33 KV SS Suddala
h) 33 KV SS Alair i) 33 KV SS Rajapeta
Location -
85 132 KV SS Wadapally 1x16+1x31.5 47.5 10 --
Injection Points
a) 132KV SS
Wadapally
b) 33 KV SS Dameracherla
c) 33 KV SS A.D.Pally(U.P)
d) 33 KV SS K.N.Konda e) 33 KV SS Janpahad
Location -
86 132 KV SS K.Mallepally 2x50+1x31.5 131.5 5 --
Injection Points
a) 132KV SS
K.Mallepally
b) 33 KV SS Pulicharla c) 33 KV SS Deverakonda
d) 33 KV SS K.M.Pally e) 33 KV SS Padmatipally
f) 33 KV SS Mudigonda
g) 33 KV SS Singarajpally h) 33 KV SS Palvai
i) 33 KV SS Junuthala
j) 33 KV SS Chandampet k) 33 KV SS Teldeverapally
l) 33 KV SS Cherkupally
m) 33 KV SS Yerraram n) 33 KV SS Chinthapally
o) 33 KV SS Madnapur
p) 33 KV SS Teededu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 120
q) 33 KV SS Nampally
r) 33 KV SS Mellavai
s) 33 KV SS Angadipet
t) 33 KV SS Ghanpur u) 33 KV SS Dugyala
v) 33 KV SS Puttamgandi
w) 33 KV SS Azmapur x) 33 KV SS Kothapally
Location -
87 132 KV SS Suryapet 2x80 160 20 --
Injection Points
a) 132KV SS
Suryapet
b) 33 KV SS Repala
c) 33 KV SS Mamillagudem
d) 33 KV SS Sirikonda
e) 33 KV SS Suryapet(Jammigadda)
f) 33 KV SS IndlEstate
g) 33 KV SS Penpahad h) 33 KV SS S.V.College
i) 33 KV SS Kasarabad
j) 33 KV SS Cheedella
k) 33 KV SS GTGiri
l) 33 KV SS Nuthankal
m) 33 KV SS Athmakur n) 33 KV SS Yerkaram
o) 33 KV SS Koduru
p) 33 KV SS Kandhagatla q) 33 KV SS Chandupatla
r) 33 KV SS Aipoor
s) 33 KV SS Tekumatla
t) 33 KV SS Kethepally
u) 33 KV SS Koppole(K)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 121
Location -
88 132 KV SS Ramannapet 2x50 100 10 --
Injection Points
a) 132KV SS
Ramannapet
b) 33 KV SS Narketpally
c) 33 KV SS Chityala
d) 33 KV SS Veliminedu
e) 33 KV SS Aregudem
f) 33 KV SS Urumadla g) 33 KV SS Ramannapet
h) 33 KV SS Yellanki
i) 33 KV SS Laxmapur j) 33 KV SS Yennram
k) 33 KV SS Iskilla
l) 33 KV SS Aroor
m) 33 KV SS Puligilla
n) 33 KV SS Valigonda
o) 33 KV SS Gollenepally Location -
89 132 KV SS
Huzurnagar(Matampally) 2x31.5 63 15 --
Injection Points a) 132KV
SS Huzurnagar (Mattampalli)
b) 33 KV SS Mattapally
c) 33 KV SS Mattamaplly
d) 33 KV SS Raghunadhapalerm
e) 33 KV SS Pedaveedu
f) 33 KV SS BheelayanaikThanda
Location -
90 132 KV SS Shaligouraram 1x50+1x31.
5 81.5 15 --
Injection Points
a) 132KV SS
Shaligouraram
b) 33 KV SS Akkenapally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 122
c) 33 KV SS Arvapally
d) 33 KV SS Nagaram
e) 33 KV SS Wangamarthy
f) 33 KV SS Nakrekal g) 33 KV SS Palem
h) 33 KV SS ChervuAnnaram
i) 33 KV SS Bairavonibanda j) 33 KV SS Akaram
k) 33 KV SS Eeduluru
l) 33 KV SS S.Gowraram
m) 33 KV SS Arlagaddagudem
n) 33 KV SS Marror
o) 33 KV SS Addaguduru p) 33 KV SS Azeempet Location -
91 132 KV SS Choutuppal 2x31.5 63 10 --
Injection Points
a) 132KV SS
Choutuppal
b) 33 KV SS Narayanpur c) 33 KV SS Jangam
d) 33 KV SS Survail e) 33 KV SS Choutuapapl
f) 33 KV SS D.Nagaram
g) 33 KV SS Varkatpally
Location -
92 132 KV SS Halia 1x16+1x31.5 47.5 5 --
Injection Points a) 132KV
SS Halia
b) 33 KV SS Nidmanoor c) 33 KV SS Haliya
d) 33 KV SS Rajavaram
e) 33 KV SS Pulimamidi
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 123
f) 33 KV SS Yacharam
g) 33 KV SS Peddavoora
h) 33 KV SS Pottichelma
i) 33 KV SS Nellikal j) 33 KV SS Velmagudem Location -
93 132 KV SS Kodad 1x31.5+1x16 47.5 10
Injection Points
a) 132KV SS
Kodad
b) 33 KV SS KodadIndoor c) 33 KV SS Bethovolu d) 33 KV SS Ananthagiri e) 33 KV SS N.B.Gudem
f) 33 KV SS Gondriyala
g) 33 KV SS Munagala
h) 33 KV SS Akupamula
i) 33 KV SS Nadigudem
j) 33 KV SS siripuram Location -
94 132 KV SS Tungathurthy 2x31.5 63 5 --
Injection Points a) 132KV
SS Tungathurthy
b) 33 KV SS Ravulapally c) 33 KV SS Reddygudem d) 33 KV SS Dirshanapally e) 33 KV SS Thungaturthy f) 33 KV SS Annaram g) 33 KV SS Gundepuri h) 33 KV SS Phanigiri i) 33 KV SS Thirumalagiri j) 33 KV SS Jalalpuram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 124
Location -95 132 KV SS Madugulapalli 1x31.5+1x1
6 47.5 5 --
Injection Points
a) 132KV SS
Madugulapalli
b) 33 KV SS Jalalpuram
c) 33 KV SS Thipparthy
d) 33 KV SS Chervupally
e) 33 KV SS Madugulapally
f) 33 KV SS Mamidala
g) 33 KV SS V.K.Palem h) 33 KV SS Settipalem
i) 33 KV SS Buggabaigudem
j) 33 KV SS Agamothkur k) 33 KV SS Thadakamalla
l) 33 KV SS Laxmideviguda
m) 33 KV SS Seetyathanda
n) 33 KV SS Cherukupally
Location -
96 132 KV SS Mothukur 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV
SS Mothukur
b) 33 KV SS Gundala
c) 33 KV SS Peddapatashala d) 33 KV SS Ambala e) 33 KV SS Paladugu
f) 33 KV SS Pallerla
g) 33 KV SS Chamapur h) 33 KV SS Athmakur
Location -
97 132 KV SS Marriguda 1x31.5+1x16 47.5 5 --
Injection Points
a) 132KV SS
Marriguda
b) 33 KV SS Chandur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 125
c) 33 KV SS Pullemla
d) 33 KV SS Gattuppal
e) 33 KV SS Marriguda
f) 33 KV SS Shivannaguda g) 33 KV SS D.B.Pally
Location -
98 132 KV SS Kanagal 1x31.5+1x16 47.5 5 --
Injection Points
a) 132KV SS
Kanagal
b) 33 KV SS G.Yedavelly
c) 33 KV SS Pagidimarry
d) 33 KV SS Thimmanaguda e) 33 KV SS Thoragal
f) 33 KV SS Gurrampode
g) 33 KV SS Pochampally
h) 33 KV SS Koppole
Location -
99 132 KV SS Guntipally 1x16 16 5
Injection Points a) 132KV
SS Guntipally
Location -
100 132 KV SS Dirsincherla 2x16 32 5 --
Injection Points
a) 132KV SS
Dirsincherlla
b) 33 KV SS Palakeedu c) 33 KV SS Alingapuram d) 33 KV SS Garidepally e) 33 KV SS Keethavarigudem
KHAMMAM Location -
101 132 KV SS Aswaraopet 1x31.5+1x1
6 47.5 10 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 126
Injection Points a) 132KV
SS Aswaraopeta
b) 33 KV SS Naramvarigudem
c) 33 KV SS Dammapeta
d) 33 KV SS Malkaram e) 33 KV SS Naidupeta
f) 33 KV SS Vinayakapuram
g) 33 KV SS Gangaram(B) Location -
102 132 KV SS Kusumanchi 1x31.5+1x1
6 47.5 10
Injection Points a) 132KV
SS Kusumanchi
b) 33 KV SS N.S.Gudem
c) 33 KV SS Bachodu
d) 33 KV SS Kakaravai
e) 33 KV SS Perikasingaram f) 33 KV SS Kusumanc hi
g) 33 KV SS Banapuram
h) 33 KV SS Vallabhi i) 33 KV SS Pammi
j) 33 KV SS Madhapuram
k) 33 KV SS N.K.Pally
l) 33 KV SS Buddaram
m) 33 KV SS R.J.Puram
n) 33 KV SS Jellacheruvu o) 33 KV SS Palair
p) 33 KV SS Patharlapadu
q) 33 KV SS Tippareddygudem r) 33 KV SS Sublaid
Location -
103 132 KV SS Penubaily 2x31.5 63 10 --
Injection Points a) 132KV
SS penubaily
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 127
b) 33 KV SS Gowravaram
c) 33 KV SS Maddukuru
d) 33 KV SS Chandrugonda e) 33 KV SS Brahmanakunta f) 33 KV SS Pedakorikondi g) 33 KV SS Kurnavalli h) 33 KV SS Kalluru i) 33 KV SS Enkoor j) 33 KV SS SS Palam k) 33 KV SS Raidupalam l) 33 KV SS Kandukuru m) 33 KV SS Vemsoor n) 33 KV SS Marlakunta o) 33 KV SS Guduru p) 33 KV SS Penubally q) 33 KV SS Sathupally r) 33 KV SS Gowrigudem Location -
104 132 KV SS Bhadrachalam 1x16+1x31.5 47.5 10 --
Injection Points
a) 132KV SS
Bhadrachalam
b) 33 KV SS Burgampadu c) 33 KV SS Sarapaka d) 33 KV SS Charla e) 33 KV SS S.N.Puram
f) 33 KV SS Wazeedu
g) 33 KV SS Dharamavaram h) 33 KV SS Venkatapuram
i) 33 KV SS Suraveedu
j) 33 KV SS Chintoor k) 33 KV SS Sarivella
l) 33 KV SS Nellipaka
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 128
m) 33 KV SS Dummugudem
n) 33 KV SS Kunavaram
Location -
105 132 KV SS Madhira 2x16 32 5
Injection Points a) 132KV
SS Madhira
b) 33 KV SS Bonakal
c) 33 KV SS K.I.Padu
d) 33 KV SS Siripuram e) 33 KV SS Yerrupalam
f) 33 KV SS Mamunoor
g) 33 KV SS Mulugumadu Location -
106 132 KV SS Gangaram 1x16+1x31.5 47.5 5
Injection Points a) 132KV
SS Gangaram
b) 33 KV SS Pakalagudem c) 33 KV SS Ankampalam
d) 33 KV SS Nagupally
e) 33 KV SS Gandugulapally f) 33 KV SS Mulakalapally
Location -
107 132 KV SS Yellandu 2x16 32 10 --
Injection Points
a) 132KV SS
Yellandu
b) 33 KV SS Garla
c) 33 KV SS Kothapeta d) 33 KV SS Bayyaram e) 33 KV SS ChallaSamudram f) 33 KV SS Mamakannu g) 33 KV SS Tekulapally h) 33 KV SS Karepally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 129
i) 33 KV SS Cheemalapadu j) 33 KV SS Komararam Location -
108 132 KV SS Nekkonda 1x31.5+1x50 81.5 5 --
Injection Points a) 132KV
SS Nekkonda
b) 33 KV SS Nagaram
c) 33 KV SS Teegalaveni
d) 33 KV SS Upparapalli
e) 33 KV SS Chennaraopet f) 33 KV SS Gudur
g) 33 KV SS Kesamudram
h) 33 KV SS Lingagiri i) 33 KV SS Nekkonda
j) 33 KV SS Rangapur
k) 33 KV SS Alankanipeta
l) 33 KV SS Choutapally
m) 33 KV SS Enugallu
n) 33 KV SS Parwathagiri o) 33 KV SS Redlawada
p) 33 KV SS Sangem
q) 33 KV SS Theegarajpally Location -
109 132 KV SS Mustyal 1x31.5+1x50 81.5 10 --
Injection Points a) 132KV
SS Mustyal
b) 33 KV SS Bachannapet c) 33 KV SS Laxmapur
d) 33 KV SS Padamati Keshavapur
e) 33 KV SS Ramchandrapuram
f) 33 KV SS Akunoor
g) 33 KV SS Bekkal
h) 33 KV SS Chityal
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 130
i) 33 KV SS Dhoolmitta
j) 33 KV SS Mustyal
k) 33 KV SS Guruvannapet
l) 33 KV SS Komuravelly
m) 33 KV SS Nagapuri
n) 33 KV SS Ankushapur
o) 33 KV SS Rebarthy
p) 33 KV SS Tharigoppula
q) 33 KV SS Veldanda
Location -
110 132 KV SS Chelpur 1x16+1x31.
5 47.5 5 --
Injection Points
a) 132KV SS
Chelpur
b) 33 KV SS Gudadpally
c) 33 KV SS Jadalpeta
d) 33 KV SS Bhoopalpally
e) 33 KV SS Nandigama
f) 33 KV SS Bagirthipeta
g) 33 KV SS Parkal(T)
h) 33 KV SS Regonda
i) 33 KV SS Repaka
Location -111 132 KV SS Waradannapet 1x31.5+1x5
0 81.5 10 --
Injection Points a) 132KV
SS Waradannapet
b) 33 KV SS Kondur
c) 33 KV SS Rayaparthy
d) 33 KV SS Dammanapet
e) 33 KV SS Kunoor f) 33 KV SS Venkatapur
g) 33 KV SS Zafferghad
h) 33 KV SS Annram Shariff
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 131
i) 33 KV SS Liabarthy
j) 33 KV SS Mylaram
k) 33 KV SS Ellanda
l) 33 KV SS Nandanam m) 33 KV SS Panthini
n) 33 KV SS Wadlakonda
Location -
112 132 KV SS Ayyagaripally 1x31.5+1x50 81.5 10 --
Injection Points
a) 132KV SS
Ayyagaripally
b) 33 KV SS Amangal
c) 33 KV SS Chenigapuram
d) 33 KV SS Chinnaguduru
e) 33 KV SS Inugurthy
f) 33 KV SS Kalwala
g) 33 KV SS Dornakal
h) 33 KV SS Jamandlapally
i) 33 KV SS Bodhugonda j) 33 KV SS Mogilicherla
k) 33 KV SS Nerada
l) 33 KV SS Edjerla m) 33 KV SS Giripuram
n) 33 KV SS Maripeda
o) 33 KV SS Gollacherla
p) 33 KV SS Mannegudem
q) 33 KV SS P'Sankeesa
r) 33 KV SS Upparagudem Location -
113 132 KV SS Madikonda
(Waddepalli) 2x31.5 63 10 --
Injection Points a) 132KV
SS Madikonda
b) 33 KV SS Dharmasagar
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 132
c) 33 KV SS Jayagiri
d) 33 KV SS Mallikudurla
e) 33 KV SS Narayanagiri
f) 33 KV SS Velair
g) 33 KV SS
Gopalpur
h) 33 KV SS KUC
i) 33 KV SS Madikonda
j) 33 KV SS West City
k) 33 KV SS REC
l) 33 KV SS Shayampet
Location -
114 132 KV SS Ghanpur 1x16+1x31.5 47.5 5 --
Injection Points
a) 132KV SS
Ghanpur
b) 33 KV SS Malkapur
c) 33 KV SS Peddapendyal
d) 33 KV SS Peechara
e) 33 KV SS Rajavaram
f) 33 KV SS Gudur (P)
g) 33 KV SS Ippagudem
h) 33 KV SS Namiligonda
i) 33 KV SS Suraram
j) 33 KV SS Thimmampet
k) 33 KV SS Thatikonda
Location -
115 132 KV SS Mulugu 3x16 48 10 --
Injection Points a) 132KV
SS Mulugu
b) 33 KV SS Mallampally
c) 33 KV SS Ramchandrapur d) 33 KV SS Abbapur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 133
e) 33 KV SS Gorikothapally
f) 33 KV SS Koppula
g) 33 KV SS Mulugu
h) 33 KV SS Govindraopet i) 33 KV SS Kasimdevipeta
j) 33 KV SS Medaram
k) 33 KV SS Pasra l) 33 KV SS Laxmidevipeta
m) 33 KV SS Peddapur
n) 33 KV SS Velthurlapally
Location -
116 132 KV SS Dharmasagar 2x50+1x16 116 10
Injection Points a) 132KV
SS Dharmasagar
Location -
117 132 KV SS Narsampet 1x31.5+1x1
6 47.5 5 --
Injection Points
a) 132KV SS
Narsampet
b) 33 KV SS Gangaram
c) 33 KV SS Kothaguda d) 33 KV SS Mangalavaripet
e) 33 KV SS Sadireddypally
f) 33 KV SS Dasaripally g) 33 KV SS Medapally
h) 33 KV SS Nallabelly
i) 33 KV SS Narsampet j) 33 KV SS Duggondi
k) 33 KV SS Elkurthy
l) 33 KV SS Mondrai m) 33 KV SS Rekhampally
Location -
118 132 KV SS Jangaon 2x16 32 10 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 134
Injection Points a) 132KV
SS Obulakeshapur
b) 33 KV SS Adavukeshapur
c) 33 KV SS Jangaon-I
d) 33 KV SS Jangaon-I e) 33 KV SS Jangaon-II
f) 33 KV SS Marigadi
g) 33 KV SS Jeedikal h) 33 KV SS Lingala Ghanpur
i) 33 KV SS Pemberthy
Location -
119 132 KV SS Chityala 2x16 32 5 --
Injection Points a) 132KV
SS Chityal
b) 33 KV SS Rangapur
c) 33 KV SS Ramakistapur d) 33 KV SS Tekumatla
Location -
120 132 KV SS Peddanagaram 2x16 32 5 --
Injection Points a) 132KV
SS Kousalyadevipally
b) 33 KV SS Kommulavancha
c) 33 KV SS Munigalaveedu
d) 33 KV SS Pedda Nagaram e) 33 KV SS Danthalapally
f) 33 KV SS Peddamupparam
g) 33 KV SS Reponi
h) 33 KV SS Yellampet
KARIMNAGAR Location -
121 132 KV SS Korutla 1x50+1x31.5 81.5 10 --
Injection Points a) 132KV
SS Korutla
b) 33 KV SS Ambaripeta
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 135
c) 33 KV SS Thandrial
d) 33 KV SS Manala
e) 33 KV SS Bhushanraopet
f) 33 KV SS Korutla Town g) 33 KV SS Paidimadugu
h) 33 KV SS Dharmaram
i) 33 KV SS Ailapur j) 33 KV SS Vempet
k) 33 KV SS Metpally
l) 33 KV SS Korutla Town-II
m) 33 KV SS Vellulla
n) 33 KV SS Athmakur
o) 33 KV SS Jaggasagar p) 33 KV SS Bommena
q) 33 KV SS Mannegudem
r) 33 KV SS Govindaram s) 33 KV SS Yakeenpur
Location -
122 132 KV SS Sircilla 2x50 100 15 --
Injection Points
a) 132KV SS
Sircilla
b) 33 KV SS Pedur
c) 33 KV SS Rallapeta
d) 33 KV SS Namapur
e) 33 KV SS Pegadapally
f) 33 KV SS Boanala
g) 33 KV SS Marthanapet h) 33 KV SS Nizamabad
i) 33 KV SS Textile Park
j) 33 KV SS Thangallapally k) 33 KV SS Shivanagar
l) 33 KV SS Nerella
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 136
m) 33 KV SS Avunoor
n) 33 KV SS Nampally
o) 33 KV SS Ramvaram
p) 33 KV SS Vankupally Location -
123 132 KV SS Jagityal 1x50+1x31.5 81.5 10 --
Injection Points a) 132KV
SS Jagityal
b) 33 KV SS Allipur c) 33 KV SS Kothakonda
d) 33 KV SS Itikyal
e) 33 KV SS Voddelingapur f) 33 KV SS Chelgal
g) 33 KV SS Venakatraopet
h) 33 KV SS Medipally
i) 33 KV SS Venkatapur
j) 33 KV SS Jagitial
k) 33 KV SS Polasa l) 33 KV SS Laxmipur
m) 33 KV SS Pegadapally
n) 33 KV SS T.R.Nagar Location -
124 132 KV SS Husnabad 2x31.5 63 5 --
Injection Points a) 132KV
SS Husnabad
b) 33 KV SS Gandipally c) 33 KV SS Gouravelly
d) 33 KV SS Vangara
e) 33 KV SS Potharam f) 33 KV SS Kothakonda
g) 33 KV SS Samudrala
h) 33 KV SS Indurthy
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 137
i) 33 KV SS Rekonda
Location -
125 132 KV SS Sultanabad
(Suglampally) 2x31.5 63 5 --
Injection Points a) 132KV
SS Sultanabad(Suglampally)
b) 33 KV SS Eligedu
c) 33 KV SS Julapally
d) 33 KV SS Kachapur
e) 33 KV SS Rangampally f) 33 KV SS Raghavapur
g) 33 KV SS Peddapally (T)
h) 33 KV SS Maredugonda i) 33 KV SS Bojannapet
j) 33 KV SS Jafferkhanpet
k) 33 KV SS Pegadapally
l) 33 KV SS Kolanur
m) 33 KV SS Pothkapally
n) 33 KV SS Chinnabonkur o) 33 KV SS Kanagarthy
p) 33 KV SS Odela
q) 33 KV SS Sultanabad Location -
126 132 KV SS Huzurabad 1x16+1x31.5 47.5 5 --
Injection Points a) 132KV
SS Huzurabad
b) 33 KV SS Godishala c) 33 KV SS Kothagattu
d) 33 KV SS Thadikal
e) 33 KV SS Uppal f) 33 KV SS Peddapapaiahpally
g) 33 KV SS Elkathurthy
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 138
Location -127 132 KV SS Mallaram 2x16 32 5 --
Injection Points
a) 132KV SS
Mallaram
b) 33 KV SS Baosaipet
c) 33 KV SS Mallaram
d) 33 KV SS Marrigadda
e) 33 KV SS Vemulawada
f) 33 KV SS Nimmapalli
g) 33 KV SS Sanugula h) 33 KV SS Bejjanki
Location -
128 132 KV SS Ellantakunta 1x31.5+1x16 47.5 10
Injection Points
a) 132KV SS
Ellantakunta
b) 33 KV SS Peddalingapur
c) 33 KV SS Kasimpet
d) 33 KV SS Somarampet Location -
129 132 KV SS Dharmapuri 2x16 32 5 --
Injection Points a) 132KV
SS Dharmapuri
b) 33 KV SS Sirikonda c) 33 KV SS Jaina
d) 33 KV SS Nerella
Location -
130 132 KV SS Pudur 2x16 32 5
Injection Points
a) 132KV SS
Pudur
b) 33 KV SS Thatipally
c) 33 KV SS Bathikepally
d) 33 KV SS Kodimyal
e) 33 KV SS Maddutla
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 139
f) 33 KV SS Burugupally
Location -
131 132 KV SS Yellareddypeta 1x25+1x16 41 5
Injection Points a) 132KV
SS Yellareddypeta
b) 33 KV SS Lingannapet
c) 33 KV SS Kothapally
d) 33 KV SS Gajasingaram
e) 33 KV SS Garjanapally f) 33 KV SS Rajannapet
g) 33 KV SS Yellareddypet
Location -
132 132 KV SS Manakondur 2x16 32 5
Injection Points a) 132KV
SS Manakondur
b) 33 KV SS Elbaka
c) 33 KV SS Pochampally d) 33 KV SS Chenjerla
Location -
133 132 KV SS Dharmaram 2x16 32 5
Injection Points
a) 132KV SS
Dharmaram
b) 33 KV SS Mallapur
c) 33 KV SS Yellapur
d) 33 KV SS Kothur e) 33 KV SS Velgatoor
f) 33 KV SS Basanthnagar
g) 33 KV SS Khilavanaparthy
f) 33 KV SS Chilvakodur
Location -
134 132 KV SS Shanigarm 2x16 32 5
Injection a) 132KV Shanigaram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 140
Points SS
b) 33 KV SS Thotapally
c) 33 KV SS Begumpet
d) 33 KV SS Koheda e) 33 KV SS Ramchandrapur
Location -
135 132 KV SS Godur 2x16 32 5 --
Injection Points
a) 132KV SS Godur
b) 33 KV SS Varshakonda
c) 33 KV SS Medipally
d) 33 KV SS Ragavapuram e) 33 KV SS Mallapur
Location -
136 132 KV SS Kataram 2x16 32 5 --
Injection Points
a) 132KV SS Kataram
b) 33 KV SS Maha Mutharam
c) 33 KV SS Mahadevpur
d) 33 KV SS Peddampet
e) 33 KV SS Kaleshwaram
f) 33 KV SS Koyyur
g) 33 KV SS Gangaram f) 33 KV SS V.V. Raopet
Location -
137 132 KV SS RTS 'B' Yellampalli 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV
SS RTS 'B' Yellampalli
Location -
138 132 KV SS Gangadhra (LIS) 1x50+1x25 75 5 --
Injection Points a) 132KV
SS Gangadhra(LIS)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 141
Location -139
132 KV SS Yellampally 2x16 32 5
Injection Points
a) 132KV SS
Yellampally
NIZAMABAD Location -
140 132 KV SS Kamareddy 1x50+1x31.
5 81.5 10
Injection Points
a) 132KV SS Kamareddy - I
b) 33 KV SS Siricilla Road-KMR
c) 33 KV SS Arepally
d) 33 KV SS Bhavanipet-M
e) 33 KV SS Issaipet
f) 33 KV SS Velupugonda g) 33 KV SS Brahmanpally
h) 33 KV SS Gandhari
i) 33 KV SS Sarvapoor j) 33 KV SS Adloor Yellareddy
k) 33 KV SS S.S.Nagar
l) 33 KV SS Padmajiwadi m) 33 KV SS Utnoor
n) 33 KV SS Housing Board-KMR
o) 33 KV SS Lingapoor
p) 33 KV SS Rajampet
q) 33 KV SS Chinnamallareddy
r) 33 KV SS Tadwai
s) 33 KV SS Aragonda
t) 33 KV SS Yerrapahad u) 33 KV SS Kondapur
v) 33 KV SS Posanipet
Location - 132 KV SS Renjal 1x31.5+1x1 47.5 10 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 142
141 6
Injection Points
a) 132KV SS
Renjal
b) 33 KV SS Navipet
c) 33 KV SS Dandigutta d) 33 KV SS Rampoor
e) 33 KV SS Kosli
f) 33 KV SS Yemcha
g) 33 KV SS Neela
h) 33 KV SS Tadbiloli
i) 33 KV SS Pegadapally
j) 33 KV SS Ch.Mavandi
k) 33 KV SS Saloora
l) 33 KV SS A.R.P.Camp
m) 33 KV SS Mangalpahad
n) 33 KV SS Yedapally
o) 33 KV SS Renjal
Location -
142 132 KV SS Jakhora 1x50+1x31.5 81.5 15 --
Injection Points a) 132KV
SS Jakhora
b) 33 KV SS Srinagar
c) 33 KV SS Chandoor
d) 33 KV SS Chinthakunta
e) 33 KV SS Mosra
f) 33 KV SS Jalalpur
g) 33 KV SS Kotagiri
h) 33 KV SS Pothangal i) 33 KV SS Jakhora (Varni)
j) 33 KV SS Nasrullabad
k) 33 KV SS Sangam
l) 33 KV SS Kalloor
m) 33 KV SS Kothapally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 143
n) 33 KV SS Ambam
o) 33 KV SS Rudrur
p) 33 KV SS Raikur
Location -
143 132 KV SS Nandipet 1x50+1x31.
5 81.5 5 --
Injection Points a) 132KV
SS Nandipet
b) 33 KV SS Degoam
c) 33 KV SS Manthani d) 33 KV SS Aloor
Location -
144 132 KV SS Domakonda 2x31.5 63 5
Injection Points
a) 132KV SS
Domakonda
b) 33 KV SS Kyasampally
c) 33 KV SS Muthyampet
d) 33 KV SS Domakonda e) 33 KV SS Laxmidevanpally
f) 33 KV SS Jangampally
g) 33 KV SS Thippaur h) 33 KV SS Talamadla
i) 33 KV SS Narsannapally
j) 33 KV SS Janagoan
k) 33 KV SS Mohommadapur
l) 33 KV SS Bibipet
m) 33 KV SS Issanagar
n) 33 KV SS Thujalpur
o) 33 KV SS Fareedpet
p) 33 KV SS Chukkapur
q) 33 KV SS Lachapet
r) 33 KV SS Annaram
s) 33 KV SS Yellampet
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 144
t) 33 KV SS Somavarpet
Location -
145 132 KV SS Armoor 1x31.5+1x16 47.5 5
Injection Points a) 132KV
SS Armoor
b) 33 KV SS Munipally
c) 33 KV SS Issapally
d) 33 KV SS Ankapoor
e) 33 KV SS Pipri
f) 33 KV SS Maggidi
g) 33 KV SS Komanpally
h) 33 KV SS Perkit i) 33 KV SS Govindpet
j) 33 KV SS Lakkora
k) 33 KV SS Fathepur
Location -
146 132 KV SS Bichkonda 2x16 32 5
Injection Points a) 132KV
SS Bichkunda
b) 33 KV SS Madnoor c) 33 KV SS Menoor
d) 33 KV SS Dongli
e) 33 KV SS Peddakodapgal f) 33 KV SS Kemrajkallali
g) 33 KV SS Somur
h) 33 KV SS Jukkal
i) 33 KV SS Pulkal
j) 33 KV SS Kathgoan
Location -
147 132 KV SS Lingapet 2x16 32 5
Injection Points
a) 132KV SS Lingampet
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 145
b) 33 KV SS Bhavanipet
c) 33 KV SS Gandimasanipet
d) 33 KV SS Mothe
e) 33 KV SS Parmalla
f) 33 KV SS Khannapur
g) 33 KV SS S.S.Reddy
h) 33 KV SS Malthummeda
i) 33 KV SS Ramalaxmanpally
Location -
148 132 KV SS Morthad 1x31.5+1x16 47.5 5
Injection Points
a) 132KV SS
Morthad
b) 33 KV SS Kammarpally
c) 33 KV SS Basheerabad
d) 33 KV SS Anksapur
e) 33 KV SS Kuknoor
f) 33 KV SS Donkal
g) 33 KV SS Morthad
h) 33 KV SS Palem
i) 33 KV SS Uploor
j) 33 KV SS Timmapur
Location -
149 132 KV SS Banswada 2x16 32 5 --
Injection Points a) 132KV
SS Banswada
b) 33 KV SS Damarancha
c) 33 KV SS Maddelcheru
d) 33 KV SS Shanthapoor
e) 33 KV SS Chillargi
f) 33 KV SS Birkur
g) 33 KV SS Mirzapur
h) 33 KV SS Konapur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 146
i) 33 KV SS Ibrahimpet
Location -150
132 KV SS Dharmora (Gutta LI scheme) 2x16 32 5 --
Injection Points a) 132KV
SS Dharmora(Gutta LI Scheme)
Location -151
132 KV SS C.H.Kondur (Gutta LI scheme) 2x16 32 5
Injection Points a) 132KV
SS C.H.Kondur(Gutta LI Scheme)
Location -
152 132 KV SS Bikanoor 2x16 32 5 --
Injection Points a) 132KV
SS Biknoor
b) 33 KV SS Baswapoor c) 33 KV SS Peddamallareddy
d) 33 KV SS Kachapoor
e) 33 KV SS Isannapaly
f) 33 KV SS Thippapur
g) 33 KV SS Talamadla
Location -
153 132 KV SS Reddypet 2x16 32 5
Injection Points
a) 132KV SS
Reddypet
b) 33 KV SS Shasodopur
c) 33 KV SS Ramreddy d) 33 KV SS Adloor
ADILABAD Location -
154 132 KV SS Adilabad 2x31.5 63 5
Injection Points a) 132KV
SS Adilabad
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 147
b) 33 KV SS Bukthapur
c) 33 KV SS Rampur
d) 33 KV SS G.S.Nagar
e) 33 KV SS Kailasnagar f) 33 KV SS Thamsi
g) 33 KV SS Talamadugu
h) 33 KV SS Arli i) 33 KV SS Ponnari
j) 33 KV SS Jainath
k) 33 KV SS Bhoraj
l) 33 KV SS Sathnala
m) 33 KV SS Bela
n) 33 KV SS Dasnapur
Location -155 132 KV SS Bellampally 1x15+1x16 31 5 --
Injection Points a) 132KV
SS Bellampally
b) 33 KV SS Andugulpet
c) 33 KV SS Kondapoor
d) 33 KV SS Nennel
e) 33 KV SS Bellampally (T)
f) 33 KV SS Rebbana
g) 33 KV SS Thandoor
h) 33 KV SS Kannepally
i) 33 KV SS Ginnedari
j) 33 KV SS Thiryani
k) 33 KV SS Asifabad
l) 33 KV SS Ippal Navegoam
m) 33 KV SS Wankidi
n) 33 KV SS Kerameri
o) 33 KV SS Jankapur
p) 33 KV SS Rechini
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 148
q) 33 KV SS Vankulam
r) 33 KV SS Shivalayam/Bellampaly Town
Location -156 132 KV SS Mancherial 1x31.5+1x1
6 47.5 5 --
Injection Points
a) 132KV SS
Mancherial
b) 33 KV SS ACC
c) 33 KV SS Ramnagar
d) 33 KV SS Jaipoor
e) 33 KV SS Kundaram
f) 33 KV SS Naspoor
g) 33 KV SS Hazipoor
h) 33 KV SS Ryali Gadpoor
i) 33 KV SS RKP
j) 33 KV SS Gudipet
k) 33 KV SS Awadam
l) 33 KV SS RK 6 Huts
Location -157 132 KV SS Sirpurkagaznagar 2x16 32 5
a) 132KV SS
Sirpurkagaznagar
b) 33 KV SS Kagaz nagar (t)
c) 33 KV SS Nazrool nagar
d) 33 KV SS jambuga
e) 33 KV SS Sirpur(t)
f) 33 KV SS Kowtala
g) 33 KV SS Ravindranagar
h) 33 KV SS Rebbena(B)
i) 33 KV SS Beejjur
j) 33 KV SS Elkapally
k) 33 KV SS Dahegam
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 149
Location -158 132 KV SS Bhainsa 2x31.5 63 5 --
a) 132KV
SS BHAINSA
b) 33 KV SS DEGAON
c) 33 KV SS WANALPAD
d) 33 KV SS LOHESRA
e) 33 KV SS PIPREE
f) 33 KV SS ABDULLAPUR
g) 33 KV SS MANMAD
h) 33 KV SS KALLUR
i) 33 KV SS KUNTALA
j) 33 KV SS Gollamada
k) 33 KV SS KUBEER
l) 33 KV SS Sonari
m) 33 KV SS Mudhole
n) 33 KV SS EDBID
o) 33 KV SS BRAHMAN GOAN
p) 33 KV SS THANOOR
q) 33 KV SS Beltharoda
Location -159 132 KV SS Luxettipeta 2x16 32 5 --
a) 132KV SS
Luxettipeta
b) 33 KV SS Suraram
c) 33 KV SS Jannaram
d) 33 KV SS Dandepally
e) 33 KV SS Velganoor
f) 33 KV SS Venkatraopet
g) 33 KV SS Kawal
h) 33 KV SS Thapalpur
Location -160 132 KV SS Ichoda 2x16 32 5 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 150
a) 132KV SS Ichoda
b) 33 KV SS Barampur
c) 33 KV SS Echoda
d) 33 KV SS Bazarhathnoor
e) 33 KV SS Pochera (Boath)
f) 33 KV SS Sonala
g) 33 KV SS Neradigonda
h) 33 KV SS Utnoor
i) 33 KV SS Pulimadugu
j) 33 KV SS Narnoor
k) 33 KV SS Lokari
l) 33 KV SS Jainoor
m) 33 KV SS Sirpur U
n) 33 KV SS Indervelly
o) 33 KV SS Dasnapur (Ivelly)
p) 33 KV SS Gudihathnoor
q) 33 KV SS Seethagondi
Location -161 132 KV SS Chennur 2x16 32 5 --
a) 132KV SS Chennur
b) 33 KV SS Kotapally
c) 33 KV SS Neelwai
d) 33 KV SS Bheemaram
e) 33 KV SS Devula Wada
f) 33 KV SS Chennor
g) 33 KV SS Kommera
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 151
FORMAT -6.12 –Format for Price Bid
PRICE BID
List of Identified Substations for Solar Power RfS
Location No. of
Transformers X capacity
Total Tr. Capacity
(MVA)
Maximum Solar
Capacity (MW)
Bidders offered
capacity in MW at
Injection points
Price offered by the Bidders in Rs./kwh
SRIKAKULAM Location -1
132 KV SS Chilakapalem 1X31.5 + 1X50 81.50 5 --
Injection Points a) 132KV SS Chilakapalem
b) 33 KV SS Tadivalasa
c) 33 KV SS Indoor
d) 33 KV SS A.S.N.COLONY
e) 33 KV SS AMADALAVALASA
f) 33 KV SS THOGARAM
g) 33 KV SS KINTALI
h) 33 KV SS PONDURU
i) 33 KV SS BUDUMURU
j) 33 KV SS LAVERU
k) 33 KV SS KS PALEM
l) 33 KV SS DHARMAVARAM
m) 33 KV SS ETCHERLA
n) 33 KV SS GUJARATHIPETA
o) 33 KV SS CHALLAPETA
p) 33 KV SS TULUGU
q) 33 KV SS ARASAVALLI
r) 33 KV SS SRIKAKULAM
s) 33 KV SS BHYRI
t) 33 KV SS RAGOLU
u) 33 KV SS Alikam
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 152
Location -2
132 KV SS Palakonda 1X31.5 + 1X16 47.50 5 --
Injection Points a) 132KV SS Palakonda
b) 33 KV SS BHAMINI
c) 33 KV SS GURANDI
d) 33 KV SS HIRAMANDALAM
e) 33 KV SS L.N.PETA S.S
f) 33 KV SS KOTTURU
g) 33 KV SS NIVAGAM
h) 33 KV SS SARUBUJJILI
i) 33 KV SS UNGARADAMETTA
j) 33 KV SS SANTHAKAVITY
k) 33 KV SS KOLLIVALASA
l) 33 KV SS NAVAGAM
m) 33 KV SS PALAKONDA
n) 33 KV SS SEETHAMPETA
o) 33 KV SS DONUBAI
p) 33 KV SS VANGARA
q) 33 KV SS VEERAGATTAM
r) 33 KV SS Parvateesam
peta
Location -3
132 KV SS Pydibheevaram 2X31.5 63.00 5 --
Injection Points a) 132KV SS Pydibheevar
am
b) 33 KV SS P.B.Varan
c) 33 KV SS Patharlapalli
d) 33 KV SS Ranasthalam
e) 33 KV SS Yerravaram
VIZIANAGARAM
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 153
Location -4 132 KV SS Vizianagaram 1X31.5 + 1X50 81.50 5 --
Injection Points
a) 132KV SS Vizianagaram
b) 33 KV SS Dharmapuri
c) 33 KV SS Denkada
d) 33 KV SS Nathavalasa
e) 33 KV SS Vontithadi
f) 33 KV SS B. koneru
g) 33 KV SS Indoor
h) 33 KV SS Phoolbagh
i) 33 KV SS Dasannapeta
j) 33 KV SS Ayyannapeta
k) 33 KV SS Collectrate
l) 33 KV SS Gajularega
m) 33 KV SS Gotlam
n) 33 KV SS Bondapalli
o) 33 KV SS Gajapathinagaram
p) 33 KV SS Mentada
q) 33 KV SS Rajapulova
r) 33 KV SS Akkivaram
s) 33 KV SS Savaravalli
t) 33 KV SS Bhogapuram
u) 33 KV SS Mukkam
Location -5 132 KV SS Kothavalasa 1X16 + 1X31.5 47.50 5 --
Injection Points a) 132KV SS Kothavalasa
b) 33 KV SS L. Kota
c) 33 KV SS Malliveedu
d) 33 KV SS Kothavalasa
e) 33 KV SS Kantakapalli
f) 33 KV SS Vepada
g) 33 KV SS Ramalingapur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 154
am
VISAKHAPATNAM
Location -6 132 KV SS Koruprolu 1X16 + 1X31.5 47.50 5 --
Injection Points
a) 132KV SS Koruprolu
b) 33 KV SS Bhalighattam
c) 33 KV SS Darlapudi
d) 33 KV SS Kotavarutla
e) 33 KV SS Pamulawaka
f) 33 KV SS Narsipatnam
g) 33 KV SS Rolugunta
h) 33 KV SS Golugonda
i) 33 KV SS Chintapalli
j) 33 KV SS GK Veedhi (Unmanned)
k) 33 KV SS Duppiliwada (Unmanned)
l) 33 KV SS Etigyrampeta
m) 33 KV SS S.Rayavaram
n) 33 KV SS P Dharmavaram (Penugollu)
o) 33 KV SS Yelamanchili
p) 33 KV SS Koruprolu
q) 33 KV SS Upmaka
r) 33 KV SS Vempadu
s) 33 KV SS Lamsanghai
t) 33 KV SS K.D.peta
Location -7
132 KV SS Kasimkota 2X31.5 63.00 5
Injection Points a) 132KV SS Kasimkota
b) 33 KV SS Venkannapalem
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 155
c) 33 KV SS Chodavaram
d) 33 KV SS Cheedikada
e) 33 KV SS Koppaka SS
f) 33 KV SS Anakapalle
g) 33 KV SS Rajam
h) 33 KV SS Gadirai (Vommali)
i) 33 KV SS Madugula
j) 33 KV SS Waddadi
k) 33 KV SS Ravikamatham
l) 33 KV SS Kothakota SS
m) 33 KV SS Makavarapalem
n) 33 KV SS Anarak Aluminium
o) 33 KV SS Velagapudi Steels
p) 33 KV SS Bayyavaram
q) 33 KV SS Narasingabilli
r) 33 KV SS Toshali Cements
s) 33 KV SS Munagapaka (RECS)
Location -8
132 KV SS Payakaraopeta 1X16 + 1X31.5 47.50 5
Injection Points a) 132KV SS
Payakaraopeta
b) 33 KV SS Srirampuram
c) 33 KV SS Nathavaram
d) 33 KV SS Satyavaram
EAST GODAVARI Location -9 132 KV SS Peddapuram 2x31.5+1x15 78.00 5
Injection Points a) 132KV SS Peddaparum
b) 33 KV SS PITHAPURAM, ,
c) 33 KV SS KUMARAPURAM
d) 33 KV SS CHEBROLU
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 156
e) 33 KV SS B.PRATHIPADU
f) 33 KV SS DIVILI
g) 33 KV SS PEDDAPURAM IDA
h) 33 KV SS R.B.PATNAM
i) 33 KV SS SAMALKOT
j) 33 KV SS PEDDAPURAM
k) 33 KV SS MADHAVAPATNAM
l) 33 KV SS VETLAPALEM
m) 33 KV SS BORRAMPALEM
n) 33 KV SS JAGGAMPETA
o) 33 KV SS GANDEPALLI
p) 33 KV SS RANGAMPETA
Location -10
132 KV SS Ramachandrapuram 2x31.5 63.00 5
Injection Points a) 132KV SS Ramachandra
puram
b) 33 KV SS KUTUKULURU
c) 33 KV SS BICCAVOLU
d) 33 KV SS BB PURAM
e) 33 KV SS RANGAPURAM
f) 33 KV SS RAYAVARAM
g) 33 KV SS CHELLURU
h) 33 KV SS K.GANGAVARAM
i) 33 KV SS SEELAMVARI SAVARAM
j) 33 KV SS ALAMURU
k) 33 KV SS ANGARA
l) 33 KV SS SIVALA
m) 33 KV SS DRAKSHARAM
n) 33 KV SS INJARAM
o) 33 KV SS TALLAREVU
p) 33 KV SS R.C.PURAM
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 157
q) 33 KV SS ARYAVATAM
r) 33 KV SS KARAPA
Location -11 132 KV SS Rajanagaram 1X16 + 1X31.5 47.50 5 --
Injection Points
a) 132KV SS Rajanagaram
b) 33 KV SS G.DONTHAMU
RU
c) 33 KV SS PRC PURAM
d) 33 KV SS DIWANCHERU
VU
e) 33 KV SS KALAVACHARL
A
f) 33 KV SS RAJANAGARA
M
WEST GODAVARI
Location -12 132 KV SS Kamavorapukota 1x31.5+1x20 51.50 5 --
Injection Points
a) 132KV SS Kamavorapukota
b) 33 KV SS UPPALAPADU
c) 33 KV SS ANKALAMPADU
d) 33 KV SS EDAVALLI
e) 33 KV SS PERAMPETA
f) 33 KV SS RAJAVARAM
g) 33 KV SS KALLACHERUVU
h) 33 KV SS RANGAPURAM
i) 33 KV SS R.POTHEPALLI
j) 33 KV SS Adamilli
k) 33 KV SS G.G.KUNTA
l) 33 KV SS TADIKALAPUDI
Location -13 132 KV SS Jangareddygudem 2x31.5 63.00 5 --
Injection Points a) 132KV SS Jangareddygudem
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 158
b) 33 KV SS BUTTAIGUDEM
c) 33 KV SS RAMARAOPETA
d) 33 KV SS DHRABAGUDEM
e) 33 KV SS JILUGUMILLI
f) 33 KV SS MYSANNAGUDEM
g) 33 KV SS TADUVAI
h) 33 KV SS J.R.GUDEM
i) 33 KV SS LAKKAVARAM
j) 33 KV SS BAYYANAGUDEM
k) 33 KV SS KOYYALAGUDEM
l) 33 KV SS PAREDDYGUDEM
Location -14 132 KV SS Jangareddygudem 2x31.5+1x50 113.00 5 --
Injection Points
a) 132KV SS Pedatadepalli
b) 33 KV SS JAGANNAPETA
c) 33 KV SS KUNCHANAPALLI
d) 33 KV SS MODUGUNTA
e) 33 KV SS A.GOKAVARAM
f) 33 KV SS BADAMPUDI
g) 33 KV SS BHUVANAPALLI
h) 33 KV SS CHEBROL
i) 33 KV SS VARADARAJAPURAM
j) 33 KV SS NEELADRIPURAM
k) 33 KV SS VEERAMPALEM
l) 33 KV SS P.T.PALLI
m) 33 KV SS GOLLAGUDEM
n) 33 KV SS YERRAMALLA
o) 33 KV SS ARUGOLANU
p) 33 KV SS H.B.COLONY
q) 33 KV SS PENTAPADU
r) 33 KV SS TPG
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 159
KRISHNA
Location -15
132 KV SS Nuzivedu 3x50 150.00 10 --
Injection Points a) 132KV SS Nuzivedu
b) 33 KV SS Advainakkalam
c) 33 KV SS Agripalli
d) 33 KV SS katrenipadu
e) 33 KV SS Meerjapuram
f) 33 KV SS Morasapudi
g) 33 KV SS Gopavaram
h) 33 KV SS Gudipadu
i) 33 KV SS Musunuru
j) 33 KV SS Venkatapuram
k) 33 KV SS Ganapavaram
l) 33 KV SS Nuzivedu
m) 33 KV SS Chetlapalle
n) 33 KV SS Kotapadu
o) 33 KV SS Polavaram
p) 33 KV SS Thummalagudem
q) 33 KV SS Ramanakkapeta
r) 33 KV SS Janardhanapuram
s) 33 KV SS Vattigudipadu
t) 33 KV SS Chatrai
u) 33 KV SS Narasapuram
v) 33 KV SS Vissanapeta
w) 33 KV SS Kondaparava
x) 33 KV SS Annavaram
GUNTUR Location -16
132 KV SS Macherla 1X31.5 + 1X50 81.50 5 --
Injection Points
a) 132KV SS Macherla
b) 33 KV SS Veldurhy.1
c) 33 KV SS Kadlakunta
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 160
d) 33 KV SS Gangalakunta
e) 33 KV SS Sirigiripadu
f) 33 KV SS Macherla.II
g) 33 KV SS Koppunuru
h) 33 KV SS NSDsam
i) 33 KV SS Tallapalle
j) 33 KV SS Gurajala
k) 33 KV SS Retachintala
l) 33 KV SS Palvai
m) 33 KV SS Mutukuru
n) 33 KV SS Durgi
o) 33 KV SS Mandadi
p) 33 KV SS Bodiveddu
q) 33 KV SS Rayavaran
Location -17 132 KV SS Piduguralla 2X31.5 63.00 10 --
Injection Points a) 132KV SS Piduguralla
b) 33 KV SS Nakarikallu
c) 33 KV SS rompicherla
d) 33 KV SS Vipparlareddypalem
e) 33 KV SS Cherjerala
f) 33 KV SS PGPadu
g) 33 KV SS Brhamanapalle
h) 33 KV SS Macahvaram
i) 33 KV SS Srinagar
j) 33 KV SS Nadikudi
k) 33 KV SS Madinapadu
l) 33 KV SS Gadevaripalle
m) 33 KV SS Janapadu
n) 33 KV SS Piduguralla
o) 33 KV SS Kondamodu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 161
p) 33 KV SS Bellamkonda
q) 33 KV SS Rajupalem
r) 33 KV SS Papalpalem
s) 33 KV SS Sattenpalli
t) 33 KV SS Dulipalla
Location -18 132 KV SS Chilakaluripeta 1X50 + 1X31.5 81.50 5 --
Injection Points a) 132KV SS Chilakaluripeta
b) 33 KV SS Pollireddypalem
c) 33 KV SS Maddirala
d) 33 KV SS Santhamaguluru
e) 33 KV SS Purushothapatnam
f) 33 KV SS Kotappakonda
g) 33 KV SS Nandivardhana
h) 33 KV SS Nadendla
i) 33 KV SS Chilaluripeta
j) 33 KV SS R.Pasumarru
k) 33 KV SS Boppudi
l) 33 KV SS Ganapavaram
Location -19 132 KV SS Marripalem 1X31.5 + 1X16 47.50 5 --
Injection Points
a) 132KV SS Marripalem
b) 33 KV SS Edlapadu
c) 33 KV SS Boyapaolem
d) 33 KV SS Sakku
e) 33 KV SS Viswateja
f) 33 KV SS Vasundara
g) 33 KV SS Supriya
h) 33 KV SS Ananathalakshmi
i) 33 KV SS Ranganayaka
PRAKASHAM
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 162
Location -20 132 KV SS Cumbum 1X31.5 + 2X16 63.50 5 --
Injection Points
a) 132KV SS Cumbum
b) 33 KV SS Racherla
c) 33 KV SS Yerrabalem
d) 33 KV SS Akaveedu
e) 33 KV SS Mohiddinpuram
f) 33 KV SS Yachavaram
g) 33 KV SS Aradhaveedu
h) 33 KV SS Akkapalle
i) 33 KV SS Pitakayagulla
j) 33 KV SS Kandulapuram
k) 33 KV SS BVPeta
l) 33 KV SS Tarlupadu
m) 33 KV SS Ravipadu
n) 33 KV SS Ummareddypalle
o) 33 KV SS TRPalle
p) 33 KV SS Komatikunta
q) 33 KV SS Puchakayalapalle
r) 33 KV SS Thippayapalem
Location -21 132 KV SS Kanigiri 2X31.5 63.00 5 --
Injection Points
a) 132KV SS Kanigiri
b) 33 KV SS KKMitta
c) 33 KV SS Nandanamarella
d) 33 KV SS Chinnarikatla
e) 33 KV SS Gotlagattu
f) 33 KV SS TRPalle
g) 33 KV SS SRPuram
h) 33 KV SS Veligandla
i) 33 KV SS Rallapadu
j) 33 KV SS Tallur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 163
k) 33 KV SS P.Alavalapadu
l) 33 KV SS P.Eralapadu
m) 33 KV SS PCPalle
n) 33 KV SS Guravajipeta
o) 33 KV SS BPAddaroad
Location -22 132 KV SS Kandukuru 1X31.5 + 1X15 46.50 5 --
Injection Points a) 132KV SS Kandukuru
b) 33 KV SS Kandukuru Town
c) 33 KV SS East Kandukuru
d) 33 KV SS Pamur Road
e) 33 KV SS Kandukuru Rural
f) 33 KV SS Ponnalur
g) 33 KV SS Agraharam
h) 33 KV SS Lingasamudram
i) 33 KV SS VV Palem
j) 33 KV SS Chinnapavani
k) 33 KV SS Pokuru
l) 33 KV SS Naladalapur
m) 33 KV SS Gudlur
n) 33 KV SS Machavaram
o) 33 KV SS S.Konda
p) 33 KV SS Karedu
q) 33 KV SS Ulavapadu
r) 33 KV SS Tettu
s) 33 KV SS Pakala
t) 33 KV SS Narasingolu
u) 33 KV SS Kondepi
v) 33 KV SS Uppalapadu
w) 33 KV SS M.Nidamanur
x) 33 KV SS Jarugumalli
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 164
Location -23 132 KV SS Peddadornala 2X16 32.00 5 --
Injection Points
a) 132KV SS Peddadornala
b) 33 KV SS Dornala
c) 33 KV SS Sanikavaram
d) 33 KV SS B.Cherlopalli
e) 33 KV SS P.Bommanapuram
f) 33 KV SS Y.Cherlopalli
Location -24 132 KV SS Martur 2X31.5 63.00 5 --
Injection Points a) 132KV SS Martur
b) 33 KV SS Ballikurava
c) 33 KV SS Kommalapadu
d) 33 KV SS V.Kopperapadu
e) 33 KV SS Konanaki
f) 33 KV SS Dhramavaram
NELLORE
Location -25
132 KV SS Kavali 2X31.5 63.00 5 --
Injection Points a) 132KV SS Kavali
b) 33 KV SS Jaladanki
c) 33 KV SS Brahmanakraka
d) 33 KV SS Ananathapuram
e) 33 KV SS Ayyapreddypalem
f) 33 KV SS Basireddypalem
g) 33 KV SS Kaligiri
h) 33 KV SS Bogolu
i) 33 KV SS VRNagar
j) 33 KV SS Maddurupadu
k) 33 KV SS Pullaredynagar
l) 33 KV SS Annagaripalem
m) 33 KV SS Chowdawaram
n) 33 KV SS Kommi
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 165
o) 33 KV SS Kondapuram
Location -26 132 KV SS Chendodu 2X31.5 63.00 5 --
Injection Points a) 132KV SS Chendodu
b) 33 KV SS N.P.Kothapalem
c) 33 KV SS Kota
d) 33 KV SS Siddawaram
e) 33 KV SS Gunapadu
f) 33 KV SS Eswarawaka
g) 33 KV SS Mallam
h) 33 KV SS Kothagunta
i) 33 KV SS Vakadu
j) 33 KV SS BRPalem
k) 33 KV SS Konduru
l) 33 KV SS Ankulapaturu
m) 33 KV SS Chinthavaram
Location -27 132 KV SS Naidupet 2X31.5 63.00 5 --
Injection Points a) 132KV SS Naidupet
b) 33 KV SS Chillakuru
c) 33 KV SS Sirasmabedu
d) 33 KV SS KGKandriga
e) 33 KV SS Menskur
f) 33 KV SS Naidupeta
g) 33 KV SS Thummuru
h) 33 KV SS Annamedu
i) 33 KV SS Yakasini
j) 33 KV SS Puduru
CHITTOOR
Location -28 132 KV SS Palamaneur 1X31.5 + 1X50 81.50 5 --
Injection Points
a) 132KV SS Palamaneur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 166
b) 33 KV SS Bairedipalle
c) 33 KV SS Kolamasanpalle
d) 33 KV SS Kasturinagar
e) 33 KV SS Tekumanda
f) 33 KV SS Ragimanupenta
g) 33 KV SS Mogili
h) 33 KV SS Kadirimadugu
i) 33 KV SS Pathikonda
j) 33 KV SS Peddapurm
k) 33 KV SS Melmai
Location -29 132 KV SS Madanapally 1X50 + 1X31.5 81.50 10 --
Injection Points a) 132KV SS Madanapally
b) 33 KV SS Nimmanapalle
c) 33 KV SS Reddivaripalle
d) 33 KV SS Vengamavariapalle
e) 33 KV SS CTM
f) 33 KV SS Kantevaripalle
g) 33 KV SS Kotavuru
h) 33 KV SS Ammcheruvu mitta
i) 33 KV SS Nayanabavi
j) 33 KV SS Pothapolu
k) 33 KV SS Valasapalle
l) 33 KV SS Vemaplle
m) 33 KV SS Bommanacheruvu
n) 33 KV SS Kurabalakota
Location -30 132 KV SS Pakala 1X31.5 + 1X16 47.50 5 --
Injection Points a) 132KV SS Pakala
b) 33 KV SS Achamaagaraharam
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 167
c) 33 KV SS M.N.Palle
d) 33 KV SS Damaracheruvu
e) 33 KV SS Kalluru
f) 33 KV SS Pulicherla
g) 33 KV SS Ashoknagar
h) 33 KV SS Mangalamapeta
i) 33 KV SS Vallivedu
j) 33 KV SS Puthalapattu
k) 33 KV SS Petamitta
l) 33 KV SS M.Bandapalle
Location -31 132 KV SS Shanthipuram 1X50 + 1X31.5 81.50 5 --
Injection Points a) 132KV SS Shanthipuram
b) 33 KV SS Rallbuduguru
c) 33 KV SS Chinnabaldar
d) 33 KV SS Ramakuppam
e) 33 KV SS Aanikeri
f) 33 KV SS Suddalakuppam
g) 33 KV SS Sivaramanapuram
h) 33 KV SS Arimanupenta
i) 33 KV SS V.Kota
j) 33 KV SS Cheldiganipalle
Location -32 132 KV SS Nagiri 1X31.5 + 1X16 47.50 10 --
Injection Points
a) 132KV SS Nagiri
b) 33 KV SS Nethamkandriga
c) 33 KV SS M.Kothuru
d) 33 KV SS Pannuru
e) 33 KV SS Vijayapuram
f) 33 KV SS Kalikapuram
g) 33 KV SS Kosalanagaram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 168
h) 33 KV SS Netteri
i) 33 KV SS Mittakandriga
j) 33 KV SS Irruguvoi
Location -33
132 KV SS Kothapallimitta 1X50 + 1X31.5 81.50 10 --
Injection Points a) 132KV SS Kothapallimitta
b) 33 KV SS Katiripalle
c) 33 KV SS Chinnatayyuru
d) 33 KV SS Katikapalle
e) 33 KV SS SRPuram
f) 33 KV SS Nelavoi
g) 33 KV SS Kondakindpalle
h) 33 KV SS Vedurkuppam
i) 33 KV SS Mambedu
j) 33 KV SS NVPalle
k) 33 KV SS Allamadugu
l) 33 KV SS Penumuru
m) 33 KV SS Mattampalle
n) 33 KV SS Polavaram
o) 33 KV SS Bandarlapalle
p) 33 KV SS GDNellore
q) 33 KV SS Avulakonda
r) 33 KV SS SSKonda
s) 33 KV SS VRKuppam
t) 33 KV SS SBRpuram
u) 33 KV SS Vepamjeri
Location -34
132 KV SS Burakayalakota 2X31.5 63.00 10 --
Injection Points
a) 132KV SS Burakayalakota
b) 33 KV SS Rangasamudrum
c) 33 KV SS Nanbavi
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 169
d) 33 KV SS kandukuru
e) 33 KV SS Gopidinne
f) 33 KV SS Chowdasamudurm
g) 33 KV SS Burakayalakota
h) 33 KV SS Mulakalacherubu
i) 33 KV SS B.Kohakota
j) 33 KV SS PTM
k) 33 KV SS Varikasuvupalle
l) 33 KV SS Mallela
Location -35
132 KV SS Kuppam 2X31.5 63.00 10 --
Injection Points a) 132KV SS Kuppam
b) 33 KV SS Mallanuru
c) 33 KV SS Laskhmipuram
d) 33 KV SS Adivibuduguru
e) 33 KV SS Gudipalle
f) 33 KV SS Vasanadu
KADAPA Location -36
132 KV SS Badwel 2X16 32 5 --
Injection Points
a) 132KV SS Badvel
b) 33 KV SS Peddapolukunta
c) 33 KV SS Gangapenta
d) 33 KV SS Payalakunta
e) 33 KV SS B.Kodur
f) 33 KV SS Konduru
g) 33 KV SS Sidaout
h) 33 KV SS Venkatasettipalle
i) 33 KV SS D.Agraharam
j) 33 KV SS Badvel-II
Location - 132 KV SS Rayachoti 2X31.5 63 5 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 170
37
Injection Points
a) 132KV SS Rayachoti
b) 33 KV SS T.Sundupalli
c) 33 KV SS Rayavaram
d) 33 KV SS Gundlapalli
e) 33 KV SS Pujarivandlapalli
f) 33 KV SS Rayachoty
g) 33 KV SS Masapeta
h) 33 KV SS L.R.Pallif
i) 33 KV SS Ramapuram
j) 33 KV SS Veeraballi
k) 33 KV SS Matil
l) 33 KV SS Vangimalla
m) 33 KV SS Gadikota
n) 33 KV SS Galiveedu
o) 33 KV SS Madhavaram
p) 33 KV SS Nooliveedu
Location -38 132 KV SS Vontimitta 2x16 32 5 --
Injection Points
a) 132KV SS Vontimitta
b) 33 KV SS Peddapalle
c) 33 KV SS Mantapamapalle
Location -39 132 KV SS Jammalamadugu 2X16 32 5 --
Injection Points
a) 132KV SS Jammalamadugu
b) 33 KV SS Gundlakunta
c) 33 KV SS Diguvakalavatala
d) 33 KV SS Namalladinne
e) 33 KV SS Torivemula
f) 33 KV SS Thalamanchipatna
m
g) 33 KV SS Mylavaram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 171
h) 33 KV SS Dodlum
i) 33 KV SS Ambavaram
j) 33 KV SS Danavulapadu
Location -40
132 KV SS Sambepalli 2X16 32 5 --
Injection Points a) 132KV SS Sambepalle
b) 33 KV SS C.Mandam
c) 33 KV SS Pedamatikona
d) 33 KV SS Devapatla
e) 33 KV SS Mallur
ANANTHAPUR
Location -41 132 KV SS Kadri 1X50 + 1X31.5 81.5 5 --
Injection Points
a) 132KV SS Kadri
b) 33 KV SS Kondakamarla
c) 33 KV SS Amadugur
d) 33 KV SS Mohamadbad
e) 33 KV SS Nallacheruvu
f) 33 KV SS Tanakallu
g) 33 KV SS Chikatimanipalli
h) 33 KV SS Kokanti Cross
i) 33 KV SS Peddapalli
j) 33 KV SS N.P.Kunta
k) 33 KV SS Gajulavaripalli
l) 33 KV SS Gandlapenta
m) 33 KV SS Kadiri
n) 33 KV SS Kuttagulla
o) 33 KV SS N.S.G.Palli
p) 33 KV SS Malakavemula
q) 33 KV SS Mallepalli
r) 33 KV SS Mudigubba
s) 33 KV SS Kodavandla palli
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 172
t) 33 KV SS O.D.Cheruvu
u) 33 KV SS Pulagampalli
v) 33 KV SS Talapula
w) 33 KV SS Batrepalli
x) 33 KV SS Ganjivaripalli
Location -42 132 KV SS Tadipatri 2 X50 100 5 --
Injection Points a) 132KV SS Tadipatri
b) 33 KV SS Tadipatri Nandyala Road
c) 33 KV SS Rayalacheruvu
d) 33 KV SS Konauppalapadu
e) 33 KV SS Sajjaladinne
f) 33 KV SS Chukkalur
g) 33 KV SS P.Yekkaluru
h) 33 KV SS P.Pappuru
i) 33 KV SS Dharmapuram
j) 33 KV SS Kammavaripalli
k) 33 KV SS Nitturu
l) 33 KV SS Bugga
m) 33 KV SS AVT.Palli
n) 33 KV SS A.Kondapuram
o) 33 KV SS Maddipalli
p) 33 KV SS Yellutla
KURNOOL Location -43
132 KV SS Allagadda 2X31.5 63 5 --
Injection Points
a) 132KV SS Allagadda
b) 33 KV SS Uyyalawada,
c) 33 KV SS Perusomula,
d) 33 KV SS Nossam
e) 33 KV SS Chagalamarri,
f) 33 KV SS K. Kandukuru,
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 173
g) 33 KV SS P.Bodanam
h) 33 KV SS Chinthalacheruvu
i) 33 KV SS Alamuru (Allagada)
j) 33 KV SS Ahobilam,
k) 33 KV SS C T R Palli
l) 33 KV SS Muthylapadu,
m) 33 KV SS R.K.Puram,
n) 33 KV SS Rudravaram
o) 33 KV SS Yerraguntla
p) 33 KV SS Dornipadu,
q) 33 KV SS Kalugotla (Koilakuntla)
Location -44 132 KV SS Adoni 2X31.5 63 5 --
Injection Points a) 132KV SS Adoni
b) 33 KV SS S.K.D.Colony,
c) 33 KV SS Arts College
d) 33 KV SS Baichigiri
e) 33 KV SS Kamavaram,
f) 33 KV SS Kowthalam
g) 33 KV SS Halv i,
h) 33 KV SS Nadichagi
i) 33 KV SS Gulyam
j) 33 KV SS yellarthy
k) 33 KV SS Holagunda
l) 33 KV SS Chippagiri (Alternate)
m) 33 KV SS Molagavalli
n) 33 KV SS Basaladoddi,
o) 33 KV SS Vandagal,
p) 33 KV SS Kosigi
q) 33 KV SS Kolamanpeta
r) 33 KV SS Market yard
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 174
s) 33 KV SS santhakodur,
t) 33 KV SS Kallubavi
u) 33 KV SS Alur,
v) 33 KV SS Kammarachedu
w) 33 KV SS Nagaradona,
x) 33 KV SS Halaharvi
y) 33 KV SS Ganekal
z) 33 KV SS Pedda thumbalam
Location -45 132 KV SS Pathikonda 2X31.5 63 10 --
Injection Points
a) 132KV SS Pathikonda
b) 33 KV SS Devanakonda
c) 33 KV SS E.D.Banda,
d) 33 KV SS Yerrabadu,
e) 33 KV SS Kothiralla
f) 33 KV SS Gundlakonda
g) 33 KV SS Aspari,
h) 33 KV SS Dibbanakal,
i) 33 KV SS Devanabanda
j) 33 KV SS Maddikera,
k) 33 KV SS Tuggali,
l) 33 KV SS Jonnagiri
m) 33 KV SS Pathikonda,
n) 33 KV SS R.S.Pendekal
Location -46
132 KV SS Gudur 2X16 32 5 --
Injection Points a) 132KV SS Gudur
b) 33 KV SS Kothakota
c) 33 KV SS Gudur
d) 33 KV SS C.Belagal
e) 33 KV SS Polakal
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 175
f) 33 KV SS Gundrevula
g) 33 KV SS Kodumur,
h) 33 KV SS Pulakurthy
Location -47
132 KV SS Banaganapalli 2X16 32 5 --
Injection Points a) 132KV SS Banaganapalli,
b) 33 KV SS Yanakandla,
c) 33 KV SS Palukuru.
d) 33 KV SS Owk,
e) 33 KV SS Akumalla,
f) 33 KV SS I.K.Peta,
g) 33 KV SS Uppalapadu,
h) 33 KV SS Ramapuram. (Alternate)
i) 33 KV SS Gundla Singavaram
j) 33 KV SS Kolilakuntla,
k) 33 KV SS Gulladurthy,
l) 33 KV SS Sanjamala
m) 33 KV SS Pathapadu
Location -48 132 KV SS Gandikota 1X50 50 5 --
Injection Points a) 132KV SS Gandikota (LIS)
MAHABUBNAGAR
Location -49 132 KV SS Nagarkurnool 1X31.5+1X50 81.5 10 --
Injection Points
a) 132KV SS Nagarkurnool
b) 33 KV SS Ithole
c) 33 KV SS Tadoor
d) 33 KV SS Yangampally
e) 33 KV SS Kummera
f) 33 KV SS Bijnapally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 176
g) 33 KV SS Peddamudunoor
h) 33 KV SS Manganoor
i) 33 KV SS Mumaipally
j) 33 KV SS Waddeman
k) 33 KV SS Manthati
l) 33 KV SS Kollapur X Roads
m) 33 KV SS Telkapally
n) 33 KV SS Rakonda
o) 33 KV SS Peddur
p) 33 KV SS Tallapally
q) 33 KV SS Peddapur
r) 33 KV SS Kondareddypally
Location -
50 132 KV SS Wanaparthy 2X50 100 5 --
Injection Points a) 132KV SS Wanaparthy
b) 33 KV SS Kothakota
c) 33 KV SS Kurumurthy
d) 33 KV SS Madanapur
e) 33 KV SS Kothapally
f) 33 KV SS Ramanpad
g) 33 KV SS Peddamandadi
h) 33 KV SS Addakal
i) 33 KV SS Ponnakal
j) 33 KV SS Veltoor
k) 33 KV SS Solipur
l) 33 KV SS Buddaram
m) 33 KV SS Balijapally
n) 33 KV SS Kandur
o) 33 KV SS Mamidimada
p) 33 KV SS Gopalpet
q) 33 KV SS Revally
r) 33 KV SS P.K.Pally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 177
s) 33 KV SS Thudkurthy
t) 33 KV SS Chennaram
u) 33 KV SS Peddakarpamula
v) 33 KV SS Ayyavaripally
w) 33 KV SS Remaddula
x) 33 KV SS Rajapur
y) 33 KV SS Kodair
z) 33 KV SS Tirumalapur
a1) 33 KV SS Kethepally
a2) 33 KV SS Pangal
a3) 33 KV SS Pebbair
a4) 33 KV SS Williamkonda
a5) 33 KV SS Srinivasapuram
a6) 33 KV SS Nasanally
a7) 33 KV SS Sri Rangapur
Location -
51 132 KV SS Thimmapur 1X50+2X31.5 113 10 --
Injection Points a) 132KV SS Thimmapur
b) 33 KV SS Kothur
c) 33 KV SS Sangem
d) 33 KV SS Inmulnarva
e) 33 KV SS Kothapet
Location -52 132 KV SS Gadwal 2X50 100 10 --
Injection Points
a) 132KV SS Gadwal
b) 33 KV SS Veerapur
c) 33 KV SS Beechupally
d) 33 KV SS Kodandapur
e) 33 KV SS Gadwal
f) 33 KV SS Gadwal Town
g) 33 KV SS Alwalpad
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 178
h) 33 KV SS Dharoor
i) 33 KV SS Nandinne
j) 33 KV SS Dyagadoddi
k) 33 KV SS Maldakal
l) 33 KV SS Ieeza
m) 33 KV SS Mallamdoddi
n) 33 KV SS P.T.Pad
o) 33 KV SS Budidapad
p) 33 KV SS Bijjaram
q) 33 KV SS Amarchinta
r) 33 KV SS Atmakur
s) 33 KV SS Peddakadmoor
Location -
53 132 KV SS Makthal 1X50+1X31.5 81.5 5 --
Injection Points a) 132KV SS Makthal
b) 33 KV SS Jaklair
c) 33 KV SS Bijwar
d) 33 KV SS Narva
e) 33 KV SS Narayanpet
f) 33 KV SS Utkoor
g) 33 KV SS Pasupula
h) 33 KV SS Mushtipally
i) 33 KV SS Gudeballore
j) 33 KV SS Kolpur
k) 33 KV SS Maganoor
l) 33 KV SS Krishna
Location -
54 132 KV SS Kodangal 2X31.5 63 5 --
Injection Points
a) 132KV SS Kodangal
b) 33 KV SS Dudyal
c) 33 KV SS Kosigi
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 179
d) 33 KV SS Kodangal
e) 33 KV SS Ravulapally
f) 33 KV SS Doultabad
g) 33 KV SS Suraipally
h) 33 KV SS Sarjakhanpet
i) 33 KV SS Hamsanpally
Location -
55 132 KV SS Balanagar 1X50+2X31.5 113 10 --
Injection Points a) 132KV SS Balanagar
b) 33 KV SS Chinchode
c) 33 KV SS Peddarevally
d) 33 KV SS Thommidirekula
e) 33 KV SS Balanagar
f) 33 KV SS Rajapur
g) 33 KV SS Polepally
h) 33 KV SS Kollur
i) 33 KV SS Udityal
j) 33 KV SS Yedira
k) 33 KV SS Raikal
l) 33 KV SS Gantlavelly
m) 33 KV SS Dooskal
n) 33 KV SS Gundlapotlapally
Location -56 132 KV SS Achampet 2X31.5 63 5 --
Injection Points
a) 132KV SS Achampet
b) 33 KV SS Lingal
c) 33 KV SS Kondanagula
d) 33 KV SS Inole
e) 33 KV SS Amrabad
f) 33 KV SS Vankeshwaram
g) 33 KV SS Hajipur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 180
h) 33 KV SS Uppununthala
i) 33 KV SS Veltoor
j) 33 KV SS Mannewaripally
Location -
57 132 KV SS Amangal 2X31.5 63 10 --
Injection Points a) 132KV SS Amangal
b) 33 KV SS Madgul
c) 33 KV SS Nagilla
d) 33 KV SS Arkepally
e) 33 KV SS Polepally
f) 33 KV SS Irvin
g) 33 KV SS Akutotapally
h) 33 KV SS Amangal
i) 33 KV SS Kadthal
j) 33 KV SS Mudwin
k) 33 KV SS Karkalpad
l) 33 KV SS Talakondapally
m) 33 KV SS Chukapur
n) 33 KV SS Raviched
Location -58 132 KV SS Kalwakurthy 2X31.5+1X50 113 10 --
Injection Points
a) 132KV SS Kalwakurthy
b) 33 KV SS Sirsangandla
c) 33 KV SS Tandra
d) 33 KV SS Jajala
e) 33 KV SS Polkampally
f) 33 KV SS Gundoor
g) 33 KV SS Ellikal
h) 33 KV SS Totapally
i) 33 KV SS Dindichintapally
j) 33 KV SS Veldanda
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 181
k) 33 KV SS Peddapur
l) 33 KV SS Bollampally
m) 33 KV SS Rachur
n) 33 KV SS Madaram
o) 33 KV SS Marchala
p) 33 KV SS Jaknalpally
q) 33 KV SS Urkonda
r) 33 KV SS Gattuippalapally
s) 33 KV SS Juppally
t) 33 KV SS Vangoor
u) 33 KV SS Sarvareddypally
v) 33 KV SS Kalwakurthy
Location -
59 132 KV SS Midjil 2X16 32 5 --
Injection Points a) 132KV SS Midjil
b) 33 KV SS Velgomula
c) 33 KV SS Kothapally
d) 33 KV SS Kodgal
e) 33 KV SS Konded
f) 33 KV SS Avancha
g) 33 KV SS Donur
h) 33 KV SS Vemula
i) 33 KV SS Veljal
j) 33 KV SS Keshampet
k) 33 KV SS Midjil
Location -60 132 KV SS Marikal 2X31.5 63 5 --
Injection Points a) 132KV SS Marikal
b) 33 KV SS Kondapur
c) 33 KV SS Deverkadra
d) 33 KV SS Sanginonipally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 182
e) 33 KV SS Nagaram Gate
f) 33 KV SS Eklaspur
g) 33 KV SS Waddeman
h) 33 KV SS Marikal
i) 33 KV SS Dhanwada
j) 33 KV SS Chinnajatram
k) 33 KV SS Kotakonda
l) 33 KV SS Koukuntla
m) 33 KV SS Krishna
MEDAK
Location -61
132 KV SS Sadasivapet 1X50+1X31.5 81.5 15 --
Injection Points a) 132KV SS Sadasivapet
b) 33 KV SS Nizampur
c) 33 KV SS Athmakur
d) 33 KV SS Jackwell
e) 33 KV SS Munipally
f) 33 KV SS Tatipally
g) 33 KV SS Aroor
h) 33 KV SS Kamkole
i) 33 KV SS Sadasivpet
j) 33 KV SS Kohir
k) 33 KV SS Bilalpur
Locati on -62 132 KV SS Gajwal 2X50 100 10 --
Injection Points
a) 132KV SS Gajwel
b) 33 KV SS Gowraram
c) 33 KV SS Wargal
d) 33 KV SS Markook
e) 33 KV SS Adavimajeedpally
f) 33 KV SS Karkapatla
g) 33 KV SS Mulugu
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 183
h) 33 KV SS Wantimamidi
i) 33 KV SS B.V. Poor
j) 33 KV SS Bejgam
k) 33 KV SS Ahmedipur
l) 33 KV SS Nimtoor
m) 33 KV SS Begumpet
n) 33 KV SS Wardharajpur
o) 33 KV SS Jagadevpur
p) 33 KV SS Munigadapa
q) 33 KV SS Chatlapally
r) 33 KV SS Gajwel
s) 33 KV SS Pregnapur
t) 33 KV SS Ganeshpally
u) 33 KV SS Kodakandla
Location -63 132 KV SS Kandi 2X50 100 5 --
Injection Points a) 132KV SS Kandi
b) 33 KV SS Sangareddy - I
c) 33 KV SS Sangareddy - II
d) 33 KV SS Collector Complex
e) 33 KV SS Cheryal
f) 33 KV SS Ismailkhan Pet
g) 33 KV SS Kondapur
h) 33 KV SS Malkapur
i) 33 KV SS Gollapally
j) 33 KV SS Nandi gama
k) 33 KV SS T K Pur
l) 33 KV SS Gundla Machnoor
m) 33 KV SS Rudraram
Location -
64 132 KV SS Kowdipally 1X31.5+1X16 47.5 5 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 184
Injection Points a) 132KV SS Kowdipally
b) 33 KV SS Kulcharam
c) 33 KV SS Amsanpally
d) 33 KV SS Kowdipally
e) 33 KV SS Kanchanpally
f) 33 KV SS Rangampet
g) 33 KV SS Venkatraopet
h) 33 KV SS Siripura
i) 33 KV SS Bujarampet
j) 33 KV SS Rajipet
k) 33 KV SS Salabathpur
l) 33 KV SS Waddepally
m) 33 KV SS Yenigandla
Location -65 132 KV SS Manoharabad 1X50+1X31.5 81.5 15 --
Injection Points
a) 132KV SS Manoharabad
b) 33 KV SS Imampur
c) 33 KV SS Toopran
d) 33 KV SS Danthanpally
e) 33 KV SS Nagulapally
f) 33 KV SS Sikindlapur
g) 33 KV SS Shivampet
h) 33 KV SS Chinna Gotti Mukkala
i) 33 KV SS Panbanda
j) 33 KV SS Manoharabad
k) 33 KV SS Kallakal
l) 33 KV SS Nacharam
m) 33 KV SS Islampur
n) 33 KV SS Chetla Gowraram
o) 33 KV SS Muppireddypally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 185
Location -66 132 KV SS Zaheerabad 2X31.5 63 10 --
Injection Points
a) 132KV SS Zaheerabad
b) 33 KV SS Zaheerabad Town
c) 33 KV SS Hadnoor
d) 33 KV SS Raikode
e) 33 KV SS Chalki
f) 33 KV SS Metal Kunta
g) 33 KV SS Nyalkal
h) 33 KV SS Mamidgi
i) 33 KV SS Singitham
j) 33 KV SS Mohabathpur
k) 33 KV SS Digwal
l) 33 KV SS Aligole
m) 33 KV SS Jharasangam
n) 33 KV SS Machnoor
o) 33 KV SS Mannapur
p) 33 KV SS Malchelma
q) 33 KV SS Chota Hyderabad
r) 33 KV SS Sathwar
Location -67 132 KV SS Gummadiddala 1X50+1X31.5 81.5 5 --
Injection Points
a) 132KV SS Gummadidala
b) 33 KV SS Kanukunta
c) 33 KV SS Vishal Projects
d) 33 KV SS Nallavally
e) 33 KV SS Bonthapally
f) 33 KV SS Solakpally
g) 33 KV SS Jinnaram
h) 33 KV SS Dundigal
Location -
68 132 KV SS Narayanakhed 2X31.5 63 10 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 186
Injection Points a) 132KV SS Narayanakhed
b) 33 KV SS Bodagattu
c) 33 KV SS Shankarampet
d) 33 KV SS Nizampet
e) 33 KV SS Burugupally
f) 33 KV SS Hanmanthraopet
g) 33 KV SS Narayankhed
h) 33 KV SS Manoor
i) 33 KV SS Poosalpad
j) 33 KV SS Borancha
k) 33 KV SS Regode
l) 33 KV SS Karasgutti
m) 33 KV SS Wasar
n) 33 KV SS Thadkal
o) 33 KV SS Kangti
p) 33 KV SS Ryakal
q) 33 KV SS Kalher
r) 33 KV SS Bachepally
s) 33 KV SS Fathepur
t) 33 KV SS Sirgapoor
u) 33 KV SS Sanjeevraopet
Location -
69 132 KV SS Medak 2X31.5 63 10 --
Injection Points a) 132KV SS Medak
b) 33 KV SS Pillikotyal
c) 33 KV SS NSF
d) 33 KV SS Ch.Ghanapur
e) 33 KV SS B Bhoopathipur
f) 33 KV SS Wadi
g) 33 KV SS Thogita
h) 33 KV SS Sardana
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 187
i) 33 KV SS Pathur
j) 33 KV SS Nagapur
k) 33 KV SS M.Bhupathipur
l) 33 KV SS Rajpally
m) 33 KV SS Ch.Shankarampet
n) 33 KV SS Gavvalapally
o) 33 KV SS Suraram
p) 33 KV SS Shalipet
Location -70 132 KV SS Tukkapur 1X31.5+1X50 81.5 10 --
Injection Points
a) 132KV SS Tukkapur
b) 33 KV SS Mirdoddy
c) 33 KV SS Jangapally
d) 33 KV SS Khajipur
e) 33 KV SS Pedda Chepyal
f) 33 KV SS Thukkapur
g) 33 KV SS Mettu
h) 33 KV SS Gudikandula
i) 33 KV SS Lingapur
j) 33 KV SS Pallepahad
k) 33 KV SS Thoguta
l) 33 KV SS Gurralasofa
m) 33 KV SS Raipole
n) 33 KV SS Ramsagar
o) 33 KV SS Dommat
p) 33 KV SS Mubaraspur
q) 33 KV SS Doulthabad
r) 33 KV SS Mohd.Shapur
s) 33 KV SS Govindapur
Location -
71 132 KV SS Chegunta 2X50 100 10 --
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 188
Injection Points a) 132KV SS Chegunta
b) 33 KV SS Bonala
c) 33 KV SS Narlapur
d) 33 KV SS Karnalpally
e) 33 KV SS Kalwakunta
f) 33 KV SS Narsingi
g) 33 KV SS D.Dharmaram
h) 33 KV SS Chandaipet
i) 33 KV SS Masaipet
j) 33 KV SS Yeldurthy
k) 33 KV SS Ramaipally
l) 33 KV SS Chegunta
Location -
72 132 KV SS Narsapur 2X31.5 63 10 --
Injection Points a) 132KV SS Narsapur
b) 33 KV SS Lingapur
c) 33 KV SS Reddypally
d) 33 KV SS Chippalthurthy
e) 33 KV SS Kothapet
f) 33 KV SS Kagazmaddur
g) 33 KV SS Mangalparthy
h) 33 KV SS Avancha
i) 33 KV SS Nasthipur
j) 33 KV SS Hathnoora
Location -73
132 KV SS Habsipur 2X31.5 63 10 --
Injection Points a) 132KV SS Habsipur
b) 33 KV SS Dubbak
c) 33 KV SS Pedda Cheekode
d) 33 KV SS Chellapur
e) 33 KV SS Gambheerpur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 189
f) 33 KV SS Dharmajipet
g) 33 KV SS Raghothampally
h) 33 KV SS Chittapur
i) 33 KV SS Pothareddypet
j) 33 KV SS Rudraram
k) 33 KV SS Habsipur
Location -
74 132 KV SS Ramayapet 2X16 32 10 --
Injection Points a) 132KV SS Ramayampet
b) 33 KV SS Zapthi Shivanur
c) 33 KV SS Nizampet
d) 33 KV SS Konapur
e) 33 KV SS Naskal
f) 33 KV SS Katriyal
g) 33 KV SS Laxmapur
Location -75
132 KV SS Pedda Shankarampeta 1X16 16 10 --
Injection Points a) 132KV SS Pedda
Shankarampeta
Location -76 132 KV SS Minpur 2X16 32 10 --
Injection Points a) 132KV SS Minpur
b) 33 KV SS Podchan pally
c) 33 KV SS Kothaipally
d) 33 KV SS Minpur
e) 33 KV SS Kodapak
f) 33 KV SS Narsingi
g) 33 KV SS Tekmal
h) 33 KV SS Achnapally
i) 33 KV SS P.Lingaipaly
j) 33 KV SS Palvancha (Dhanoora)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 190
k) 33 KV SS Kaduloor
RANGA REDDY
Location -77 132 KV SS Medchal 1X31.5+2X50 131.5 5 --
Injection Points a) 132KV SS Medchal
b) 33 KV SS Kistapur
c) 33 KV SS Ravalkole
d) 33 KV SS Keshavaram
e) 33 KV SS Kolthur
f) 33 KV SS Laxmapur
g) 33 KV SS Uddamarry
h) 33 KV SS ICICI
i) 33 KV SS Turkapally
j) 33 KV SS Medicity
k) 33 KV SS Athiwelly
l) 33 KV SS Yellempet
m) 33 KV SS Bandamadaram
n) 33 KV SS Gowdawelly
o) 33 KV SS GP Pally
p) 33 KV SS Deveryamjal
Location -78 132 KV SS Dharmasagar(Chervella) 2X31.5 63 10 --
Injection Points
a) 132KV SS Dharmasagar (Chevella)
b) 33 KV SS Kandawada
c) 33 KV SS Shabad
d) 33 KV SS Chandanvally
e) 33 KV SS Tallapally
f) 33 KV SS Bobbiligaon
g) 33 KV SS Aloor
h) 33 KV SS Kowkuntla
i) 33 KV SS Devunieravally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 191
Location -79
132 KV SS Puttapahad 1x31.5+1x16 47.5 10 --
Injection Points a) 132KV SS Puttapahad
b) 33 KV SS Chowdapur
c) 33 KV SS Marikal
d) 33 KV SS Puttapahad
e) 33 KV SS Mohmmadabad
f) 33 KV SS Salkarpet
g) 33 KV SS Mumbapur
h) 33 KV SS Nancherla
i) 33 KV SS Veenuchedu
j) 33 KV SS Dirsampally
k) 33 KV SS Gundal
l) 33 KV SS Doma
m) 33 KV SS Mujahidpur
n) 33 KV SS Mothukuru
o) 33 KV SS Kulkacherla
Location -
80 132 KV SS Turkayamjal (Hayatnagar) 2x31.5 63 10 --
Injection Points a) 132KV SS
Turkayamjal (Hayatnagar)
b) 33 KV SS Vanasthalipuram
c) 33 KV SS Turkayamzal
Location -81 132 KV SS Pargi 2x31.5 63 10 --
Injection Points
a) 132KV SS Pargi
b) 33 KV SS Manneguda
c) 33 KV SS Peddumenthol
d) 33 KV SS Siddalur
e) 33 KV SS Pargi
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 192
f) 33 KV SS Rapole
g) 33 KV SS Rangampally
HYDERABAD
Location -82 132 KV SS Vikarabad Swt. Sn Swt. Sn 15 --
Injection Points
a) 132KV SS Vikarabad
NALGONDA Location -
83 132 KV SS Nalgonda 1x50+2x31.5 113 15 --
Injection Points
a) 132KV SS Nalgonda
b) 33 KV SS Pole Centre
c) 33 KV SS Panagal
d) 33 KV SS SLBC
e) 33 KV SS Velugupally
f) 33 KV SS Mushampally
g) 33 KV SS P.D.Pally
h) 33 KV SS Narsingbatla
i) 33 KV SS Appajipeta
j) 33 KV SS Anneparthy
k) 33 KV SS Indoor
l) 33 KV SS Gollaguda
m) 33 KV SS Rayanaguda
n) 33 KV SS Pazzur
o) 33 KV SS Rajupet
p) 33 KV SS Ch.Mamidi
q) 33 KV SS Gudapur
r) 33 KV SS Kattangur
s) 33 KV SS Aitipamula
t) 33 KV SS Pamanagundla
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 193
Location -84 132 KV SS Alair (Kolanupak) 2x50 100 15 --
Injection Points
a) 132KV SS Alair(Kolanupak)
b) 33 KV SS Motakonduru
c) 33 KV SS Shaharajpeta
d) 33 KV SS Bhachannapeta
e) 33 KV SS Raghunathpuram
f) 33 KV SS Yadagirigutta
g) 33 KV SS Suddala
h) 33 KV SS Alair
i) 33 KV SS Rajapeta
Location -85 132 KV SS Wadapally 1x16+1x31.5 47.5 10 --
Injection Points
a) 132KV SS Wadapally
b) 33 KV SS Dameracherla
c) 33 KV SS A.D.Pally(U.P)
d) 33 KV SS K.N.Konda
e) 33 KV SS Janpahad
Location -86
132 KV SS K.Mallepally 2x50+1x31.5 131.5 5 --
Injection Points
a) 132KV SS K.Mallepally
b) 33 KV SS Pulicharla
c) 33 KV SS Deverakonda
d) 33 KV SS K.M.Pally
e) 33 KV SS Padmatipally
f) 33 KV SS Mudigonda
g) 33 KV SS Singarajpally
h) 33 KV SS Palvai
i) 33 KV SS Junuthala
j) 33 KV SS Chandampet
k) 33 KV SS Teldeverapally
l) 33 KV SS Cherkupally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 194
m) 33 KV SS Yerraram
n) 33 KV SS Chinthapally
o) 33 KV SS Madnapur
p) 33 KV SS Teededu
q) 33 KV SS Nampally
r) 33 KV SS Mellavai
s) 33 KV SS Angadipet
t) 33 KV SS Ghanpur
u) 33 KV SS Dugyala
v) 33 KV SS Puttamgandi
w) 33 KV SS Azmapur
x) 33 KV SS Kothapally
Location -
87 132 KV SS Suryapet 2x80 160 20 --
Injection Points a) 132KV SS Suryapet
b) 33 KV SS Repala
c) 33 KV SS Mamillagudem
d) 33 KV SS Sirikonda
e) 33 KV SS Suryapet(Jammigadda)
f) 33 KV SS IndlEstate
g) 33 KV SS Penpahad
h) 33 KV SS S.V.College
i) 33 KV SS Kasarabad
j) 33 KV SS Cheedella
k) 33 KV SS GTGiri
l) 33 KV SS Nuthankal
m) 33 KV SS Athmakur
n) 33 KV SS Yerkaram
o) 33 KV SS Koduru
p) 33 KV SS Kandhagatla
q) 33 KV SS Chandupatla
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 195
r) 33 KV SS Aipoor
s) 33 KV SS Tekumatla
t) 33 KV SS Kethepally
u) 33 KV SS Koppole(K)
Location -88 132 KV SS Ramannapet 2x50 100 10 --
Injection Points a) 132KV SS Ramannapet
b) 33 KV SS NarketpallyIE
c) 33 KV SS Chityala
d) 33 KV SS Veliminedu
e) 33 KV SS Aregudem
f) 33 KV SS Urumadla
g) 33 KV SS Ramannapet
h) 33 KV SS Yellanki
i) 33 KV SS Laxmapur
j) 33 KV SS Yennram
k) 33 KV SS Iskilla
l) 33 KV SS Aroor
m) 33 KV SS Puligilla
n) 33 KV SS Valigonda
o) 33 KV SS Gollenepally
Location -89
132 KV SS Huzurnagar(Matampally) 2x31.5 63 15 --
Injection Points a) 132KV SS
Huzurnagar(Mattampalli)
b) 33 KV SS Mattapally
c) 33 KV SS Mattamaplly
d) 33 KV SS Raghunadhapalerm
e) 33 KV SS Pedaveedu
f) 33 KV SS BheelayanaikThanda
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 196
Location -90 132 KV SS Shaligouraram 1x50+1x31.5 81.5 15 --
Injection Points
a) 132KV SS Shaligouraram
b) 33 KV SS Akkenapally
c) 33 KV SS Arvapally
d) 33 KV SS Nagaram
e) 33 KV SS Wangamarthy
f) 33 KV SS Nakrekal
g) 33 KV SS Palem
h) 33 KV SS ChervuAnnaram
i) 33 KV SS Bairavonibanda
j) 33 KV SS Akaram
k) 33 KV SS Eeduluru
l) 33 KV SS S.Gowraram
m) 33 KV SS Arlagaddagudem
n) 33 KV SS Marror
o) 33 KV SS Addaguduru
p) 33 KV SS Azee mpet
Location -
91 132 KV SS Choutuppal 2x31.5 63 10 --
Injection Points
a) 132KV SS Choutuppal
b) 33 KV SS Narayanpur
c) 33 KV SS Jangam
d) 33 KV SS Survail
e) 33 KV SS Choutuapapl
f) 33 KV SS D.Nagaram
g) 33 KV SS Varkatpally
Location -92 132 KV SS Halia 1x16+1x31.5 47.5 5 --
Injection Points a) 132KV SS Halia
b) 33 KV SS Nidmanoor
c) 33 KV SS Haliya
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 197
d) 33 KV SS Rajavaram
e) 33 KV SS Pulimamidi
f) 33 KV SS Yacharam
g) 33 KV SS Peddavoora
h) 33 KV SS Pottichelma
i) 33 KV SS Nellikal
j) 33 KV SS Velmagudem
Location -93 132 KV SS Kodad 1x31.5+1x16 47.5 10
Injection Points a) 132KV SS Kodad
b) 33 KV SS KodadIndoor
c) 33 KV SS Bethovolu
d) 33 KV SS Ananthagiri
e) 33 KV SS N.B.Gudem
f) 33 KV SS Gondriyala
g) 33 KV SS Munagala
h) 33 KV SS Akupamula
i) 33 KV SS Nadigudem
j) 33 KV SS siripuram
Location -94 132 KV SS Tungathurthy 2x31.5 63 5 --
Injection Points
a) 132KV SS Tungathurthy
b) 33 KV SS Ravulapally
c) 33 KV SS Reddygudem
d) 33 KV SS Dirshanapally
e) 33 KV SS Thungaturthy
f) 33 KV SS Annaram
g) 33 KV SS Gundepuri
h) 33 KV SS Phanigiri
i) 33 KV SS Thirumalagiri
j) 33 KV SS Jalalpuram
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 198
Location -95
132 KV SS Madugulapalli 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV SS Madugulapalli
b) 33 KV SS Jalalpuram
c) 33 KV SS Thipparthy
d) 33 KV SS Chervupally
e) 33 KV SS Madugulapally
f) 33 KV SS Mamidala
g) 33 KV SS V.K.Palem
h) 33 KV SS Settipalem
i) 33 KV SS Buggabaigudem
j) 33 KV SS Agamothkur
k) 33 KV SS Thadakamalla
l) 33 KV SS Laxmideviguda
m) 33 KV SS Seetyathanda
n) 33 KV SS Cherukupally
Location -96 132 KV SS Mothukur 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV SS Mothukur
b) 33 KV SS Gundala
c) 33 KV SS Peddapatashala
d) 33 KV SS Ambala
e) 33 KV SS Paladugu
f) 33 KV SS Pallerla
g) 33 KV SS Chamapur
h) 33 KV SS Athmakur
Location -97 132 KV SS Marriguda 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV SS Marriguda
b) 33 KV SS Chandur
c) 33 KV SS Pullemla
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 199
d) 33 KV SS Gattuppal
e) 33 KV SS Marriguda
f) 33 KV SS Shivannaguda
g) 33 KV SS D.B.Pally
Location -98 132 KV SS Kanagal 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV SS Kanagal
b) 33 KV SS G.Yedavelly
c) 33 KV SS Pagidimarry
d) 33 KV SS Thimmanaguda
e) 33 KV SS Thoragal
f) 33 KV SS Gurrampode
g) 33 KV SS Pochampally
h) 33 KV SS Koppole
Location -
99 132 KV SS Guntipally 1x16 16 5
Injection Points
a) 132KV SS Guntipally
Location -100 132 KV SS Dirsincherla 2x16 32 5 --
Injection Points a) 132KV SS Dirsincherlla
b) 33 KV SS Palakeedu
c) 33 KV SS Alingapuram
d) 33 KV SS Garidepally
e) 33 KV SS Keethavarigudem
KHAMMAM Location -
101 132 KV SS Aswaraopet 1x31.5+1x16 47.5 10 --
Injection Points a) 132KV SS Aswaraopeta
b) 33 KV SS Naramvarigudem
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 200
c) 33 KV SS Dammapeta
d) 33 KV SS Malkaram
e) 33 KV SS Naidupeta
f) 33 KV SS Vinayakapuram
g) 33 KV SS Gangaram(B)
Location -102 132 KV SS Kusumanchi 1x31.5+1x16 47.5 10
Injection Points a) 132KV SS Kusumanchi
b) 33 KV SS N.S.Gudem
c) 33 KV SS Bachodu
d) 33 KV SS Kakaravai
e) 33 KV SS Perikasingaram
f) 33 KV SS Kusumanchi
g) 33 KV SS Banapuram
h) 33 KV SS Vallabhi
i) 33 KV SS Pammi
j) 33 KV SS Madhapuram
k) 33 KV SS N.K.Pally
l) 33 KV SS Buddaram
m) 33 KV SS R.J.Puram
n) 33 KV SS Jellacheruvu
o) 33 KV SS Palair
p) 33 KV SS Patharlapadu
q) 33 KV SS Tippareddygudem
r) 33 KV SS Sublaid
Location -103 132 KV SS Penubaily 2x31.5 63 10 --
Injection Points a) 132KV SS penubaily
b) 33 KV SS Gowravaram
c) 33 KV SS Maddukuru
d) 33 KV SS Chandrugonda
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 201
e) 33 KV SS Brahmanakunta
f) 33 KV SS Pedakorikondi
g) 33 KV SS Kurnavalli
h) 33 KV SS Kalluru
i) 33 KV SS Enkoor
j) 33 KV SS SS Palam
k) 33 KV SS Raidupalam
l) 33 KV SS Kandukuru
m) 33 KV SS Vemsoor
n) 33 KV SS Marlakunta
o) 33 KV SS Guduru
p) 33 KV SS Penubally
q) 33 KV SS Sathupally
r) 33 KV SS Gowrigudem
Location -104 132 KV SS Bhadrachalam 1x16+1x31.5 47.5 10 --
Injection Points a) 132KV SS Bhadrachalam
b) 33 KV SS Burgampadu
c) 33 KV SS Sarapaka
d) 33 KV SS Charla
e) 33 KV SS S.N.Puram
f) 33 KV SS Wazeedu
g) 33 KV SS Dharamavaram
h) 33 KV SS Venkatapuram
i) 33 KV SS Suraveedu
j) 33 KV SS Chintoor
k) 33 KV SS Sarivella
l) 33 KV SS Nellipaka
m) 33 KV SS Dummugudem
n) 33 KV SS Kunavaram
Location - 132 KV SS Madhira 2x16 32 5
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 202
105
Injection Points
a) 132KV SS Madhira
b) 33 KV SS Bonakal
c) 33 KV SS K.I.Padu
d) 33 KV SS Siripuram
e) 33 KV SS Yerrupalam
f) 33 KV SS Mamunoor
g) 33 KV SS Mulugumadu
Location -106 132 KV SS Gangaram 1x16+1x31.5 47.5 5
Injection Points
a) 132KV SS Gangaram
b) 33 KV SS Pakalagudem
c) 33 KV SS Ankampalam
d) 33 KV SS Nagupally
e) 33 KV SS Gandugulapally
f) 33 KV SS Mulakalapally
Location -107 132 KV SS Yellandu 2x16 32 10 --
Injection Points
a) 132KV SS Yellandu
b) 33 KV SS Garla
c) 33 KV SS Kothapeta
d) 33 KV SS Bayyaram
e) 33 KV SS ChallaSamudram
f) 33 KV SS Mamakannu
g) 33 KV SS Tekulapally
h) 33 KV SS Karepally
i) 33 KV SS Cheemalapadu
j) 33 KV SS Komararam
Location -108 132 KV SS Nekkonda 1x31.5+1x50 81.5 5 --
Injection a) 132KV SS Nekkonda
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 203
Points
b) 33 KV SS Nagaram
c) 33 KV SS Teegalaveni
d) 33 KV SS Upparapalli
e) 33 KV SS Chennaraopet
f) 33 KV SS Gudur
g) 33 KV SS Kesamudram
h) 33 KV SS Lingagiri
i) 33 KV SS Nekkonda
j) 33 KV SS Rangapur
k) 33 KV SS Alankanipeta
l) 33 KV SS Choutapally
m) 33 KV SS Enugallu
n) 33 KV SS Parwathagiri
o) 33 KV SS Redlawada
p) 33 KV SS Sangem
q) 33 KV SS Theegarajpally
Location -109 132 KV SS Mustyal 1x31.5+1x50 81.5 10 --
Injection Points
a) 132KV SS Mustyal
b) 33 KV SS Bachannapet
c) 33 KV SS Laxmapur
d) 33 KV SS Padamati Keshavapur
e) 33 KV SS Ramchandrapuram
f) 33 KV SS Akunoor
g) 33 KV SS Bekkal
h) 33 KV SS Chityal
i) 33 KV SS Dhoolmitta
j) 33 KV SS Mustyal
k) 33 KV SS Guruvannapet
l) 33 KV SS Komuravelly
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 204
m) 33 KV SS Nagapuri
n) 33 KV SS Ankushapur
o) 33 KV SS Rebarthy
p) 33 KV SS Tharigoppula
q) 33 KV SS Veldanda
Location -110 132 KV SS Chelpur 1x16+1x31.5 47.5 5 --
Injection Points a) 132KV SS Chelpur
b) 33 KV SS Gudadpally
c) 33 KV SS Jadalpeta
d) 33 KV SS Bhoopalpally
e) 33 KV SS Nandigama
f) 33 KV SS Bagirthipeta
g) 33 KV SS Parkal(T)
h) 33 KV SS Regonda
i) 33 KV SS Repaka
Location -111 132 KV SS Waradannapet 1x31.5+1x50 81.5 10 --
Injection Points a) 132KV SS Waradannapet
b) 33 KV SS Kondur
c) 33 KV SS Rayaparthy
d) 33 KV SS Dammanapet
e) 33 KV SS Kunoor
f) 33 KV SS Venkatapur
g) 33 KV SS Zafferghad
h) 33 KV SS Annram Shariff
i) 33 KV SS Liabarthy
j) 33 KV SS Mylaram
k) 33 KV SS Ellanda
l) 33 KV SS Nandanam
m) 33 KV SS Panthini
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 205
n) 33 KV SS Wadlakonda
Location -112 132 KV SS Ayyagaripally 1x31.5+1x50 81.5 10 --
Injection Points a) 132KV SS Ayyagaripally
b) 33 KV SS Amangal
c) 33 KV SS Chenigapuram
d) 33 KV SS Chinnaguduru
e) 33 KV SS Inugurthy
f) 33 KV SS Kalwala
g) 33 KV SS Dornakal
h) 33 KV SS Jamandlapally
i) 33 KV SS Bodhugonda
j) 33 KV SS Mogilicherla
k) 33 KV SS Nerada
l) 33 KV SS Edjerla
m) 33 KV SS Giripuram
n) 33 KV SS Maripeda
o) 33 KV SS Gollacherla
p) 33 KV SS Mannegudem
q) 33 KV SS P'Sankeesa
r) 33 KV SS Upparagudem
Location -113
132 KV SS Madikonda (Waddepalli) 2x31.5 63 10 --
Injection Points a) 132KV SS Madikonda
b) 33 KV SS Dharmasagar
c) 33 KV SS Jayagiri
d) 33 KV SS Mallikudurla
e) 33 KV SS Narayanagiri
f) 33 KV SS Velair
g) 33 KV SS
h) 33 KV SS KUC
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 206
i) 33 KV SS Madikonda
j) 33 KV SS West City
k) 33 KV SS REC
l) 33 KV SS Shayampet
Location -114 132 KV SS Ghanpur 1x16+1x31.5 47.5 5 --
Injection Points a) 132KV SS Ghanpur
b) 33 KV SS Malkapur
c) 33 KV SS Peddapendyal
d) 33 KV SS Peechara
e) 33 KV SS Rajavaram
f) 33 KV SS Gudur (P)
g) 33 KV SS Ippagudem
h) 33 KV SS Namiligonda
i) 33 KV SS Suraram
j) 33 KV SS Thimmampet
k) 33 KV SS Thatikonda
Location -
115 132 KV SS Mulugu 3x16 48 10 --
Injection Points
a) 132KV SS Mulugu
b) 33 KV SS Mallampally
c) 33 KV SS Ramchandrapur
d) 33 KV SS Abbapur
e) 33 KV SS Gorikothapally
f) 33 KV SS Koppula
g) 33 KV SS Mulugu
h) 33 KV SS Govindraopet
i) 33 KV SS Kasimdevipeta
j) 33 KV SS Medaram
k) 33 KV SS Pasra
l) 33 KV SS Laxmidevipeta
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 207
m) 33 KV SS Peddapur
n) 33 KV SS Velthurlapally
Location -116 132 KV SS Dharmasagar 2x50+1x16 116 10
Injection Points
a) 132KV SS Dharmasagar
Location -
117 132 KV SS Narsampet 1x31.5+1x16 47.5 5 --
Injection Points
a) 132KV SS Narsampet
b) 33 KV SS Gangaram
c) 33 KV SS Kothaguda
d) 33 KV SS Mangalavaripet
e) 33 KV SS Sadireddypally
f) 33 KV SS Dasaripally
g) 33 KV SS Medapally
h) 33 KV SS Nallabelly
i) 33 KV SS Narsampet
j) 33 KV SS Duggondi
k) 33 KV SS Elkurthy
l) 33 KV SS Mondrai
m) 33 KV SS Rekhampally
Location -118 132 KV SS Jangaon 2x16 32 10 --
Injection Points
a) 132KV SS Obulakeshapur
b) 33 KV SS Adavukeshapur
c) 33 KV SS Jangaon-I
d) 33 KV SS Jangaon-I
e) 33 KV SS Jangaon-II
f) 33 KV SS Marigadi
g) 33 KV SS Jeedikal
h) 33 KV SS Lingala Ghanpur
i) 33 KV SS Pemberthy
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 208
Location -119 132 KV SS Chityala 2x16 32 5 --
Injection Points
a) 132KV SS Chityal
b) 33 KV SS Rangapur
c) 33 KV SS Ramakistapur
d) 33 KV SS Tekumatla
Location -
120 132 KV SS Peddanagaram 2x16 32 5 --
Injection Points
a) 132KV SS Kousalyadevipally
b) 33 KV SS Kommulavancha
c) 33 KV SS Munigalaveedu
d) 33 KV SS Pedda Nagaram
e) 33 KV SS Danthalapally
f) 33 KV SS Peddamupparam
g) 33 KV SS Reponi
h) 33 KV SS Yellampet
KARIMNAGAR
Location -121
132 KV SS Korutla 1x50+1x31.5 81.5 10 --
Injection Points a) 132KV SS Korutla
b) 33 KV SS Ambaripeta
c) 33 KV SS Thandrial
d) 33 KV SS Manala
e) 33 KV SS Bhushanraopet
f) 33 KV SS Korutla Town
g) 33 KV SS Paidimadugu
h) 33 KV SS Dharmaram
i) 33 KV SS Ailapur
j) 33 KV SS Vempet
k) 33 KV SS Metpally
l) 33 KV SS Korutla Town-II
m) 33 KV SS Vellulla
n) 33 KV SS Athmakur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 209
o) 33 KV SS Jaggasagar
p) 33 KV SS Bommena
q) 33 KV SS Mannegudem
r) 33 KV SS Govindaram
s) 33 KV SS Yakeenpur
Location -122 132 KV SS Sircilla 2x50 100 15 --
Injection Points a) 132KV SS Sircilla
b) 33 KV SS Pedur
c) 33 KV SS Rallapeta
d) 33 KV SS Namapur
e) 33 KV SS Pegadapally
f) 33 KV SS Boanala
g) 33 KV SS Marthanapet
h) 33 KV SS Nizamabad
i) 33 KV SS Textile Park
j) 33 KV SS Thangallapally
k) 33 KV SS Shivanagar
l) 33 KV SS Nerella
m) 33 KV SS Avunoor
n) 33 KV SS Nampally
o) 33 KV SS Ramvaram
p) 33 KV SS Vankupally
Location -123
132 KV SS Jagityal 1x50+1x31.5 81.5 10 --
Injection Points
a) 132KV SS Jagityal
b) 33 KV SS Allipur
c) 33 KV SS Kothakonda
d) 33 KV SS Itikyal
e) 33 KV SS Voddelingapur
f) 33 KV SS Chelgal
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 210
g) 33 KV SS Venakatraopet
h) 33 KV SS Medipally
i) 33 KV SS Venkatapur
j) 33 KV SS Jagitial
k) 33 KV SS Polasa
l) 33 KV SS Laxmipur
m) 33 KV SS Pegadapally
n) 33 KV SS T.R.Nagar
Location -124 132 KV SS Husnabad 2x31.5 63 5 --
Injection Points
a) 132KV SS Husnabad
b) 33 KV SS Gandipally
c) 33 KV SS Gouravelly
d) 33 KV SS Vangara
e) 33 KV SS Potharam
f) 33 KV SS Kothakonda
g) 33 KV SS Samudrala
h) 33 KV SS Indurthy
i) 33 KV SS Rekonda
Location -125 132 KV SS Sultanabad (Suglampally) 2x31.5 63 5 --
Injection Points
a) 132KV SS Sultanabad(Suglampally)
b) 33 KV SS Eligedu
c) 33 KV SS Julapally
d) 33 KV SS Kachapur
e) 33 KV SS Rangampally
f) 33 KV SS Raghavapur
g) 33 KV SS Peddapally (T)
h) 33 KV SS Maredugonda
i) 33 KV SS Bojannapet
j) 33 KV SS Jafferkhanpet
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 211
k) 33 KV SS Pegadapally
l) 33 KV SS Kolanur
m) 33 KV SS Pothkapally
n) 33 KV SS Chinnabonkur
o) 33 KV SS Kanagarthy
p) 33 KV SS Odela
q) 33 KV SS Sultanabad
Location -126 132 KV SS Huzurabad 1x16+1x31.5 47.5 5 --
Injection Points a) 132KV SS Huzurabad
b) 33 KV SS Godishala
c) 33 KV SS Kothagattu
d) 33 KV SS Thadikal
e) 33 KV SS Uppal
f) 33 KV SS Peddapapaiahpally
g) 33 KV SS Elkathurthy
Location -127
132 KV SS Mallaram 2x16 32 5 --
Injection Points
a) 132KV SS Mallaram
b) 33 KV SS Baosaipet
c) 33 KV SS Mallaram
d) 33 KV SS Marrigadda
e) 33 KV SS Vemulawada
f) 33 KV SS Nimmapalli
g) 33 KV SS Sanugula
h) 33 KV SS Bejjanki
Location -128
132 KV SS Ellantakunta 1x31.5+1x16 47.5 10
Injection Points a) 132KV SS Ellantakunta
b) 33 KV SS Peddalingapur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 212
c) 33 KV SS Kasimpet
d) 33 KV SS Somarampet
Location -129 132 KV SS Dharmapuri 2x16 32 5 --
Injection Points
a) 132KV SS Dharmapuri
b) 33 KV SS Sirikonda
c) 33 KV SS Jaina
d) 33 KV SS Nerella
Location -
130 132 KV SS Pudur 2x16 32 5
Injection Points
a) 132KV SS Pudur
b) 33 KV SS Thatipally
c) 33 KV SS Bathikepally
d) 33 KV SS Kodimyal
e) 33 KV SS Maddutla
f) 33 KV SS Burugupally
Location -131 132 KV SS Yellareddypeta 1x25+1x16 41 5
Injection Points
a) 132KV SS Yellareddypeta
b) 33 KV SS Lingannapet
c) 33 KV SS Kothapally
d) 33 KV SS Gajasingaram
e) 33 KV SS Garjanapally
f) 33 KV SS Rajannapet
g) 33 KV SS Yellareddypet
Location -132 132 KV SS Manakondur 2x16 32 5
Injection Points
a) 132KV SS Manakondur
b) 33 KV SS Elbaka
c) 33 KV SS Pochampally
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 213
d) 33 KV SS Chenjerla
Location -133 132 KV SS Dharmaram 2x16 32 5
Injection Points a) 132KV SS Dharmaram
b) 33 KV SS Mallapur
c) 33 KV SS Yellapur
d) 33 KV SS Kothur
e) 33 KV SS Velgatoor
f) 33 KV SS Basanthnagar
g) 33 KV SS Khilavanaparthy
f) 33 KV SS Chilvakodur
Location -134 132 KV SS Shanigarm 2x16 32 5
Injection Points a) 132KV SS Shanigaram
b) 33 KV SS Thotapally
c) 33 KV SS Begumpet
d) 33 KV SS Koheda
e) 33 KV SS Ramchandrapur
Location -135 132 KV SS Godur 2x16 32 5 --
Injection Points a) 132KV SS Godur
b) 33 KV SS Varshakonda
c) 33 KV SS Medipally
d) 33 KV SS Ragavapuram
e) 33 KV SS Mallapur
Location -136 132 KV SS Kataram 2x16 32 5 --
Injection Points
a) 132KV SS Kataram
b) 33 KV SS Maha Mutharam
c) 33 KV SS Mahadevpur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 214
d) 33 KV SS Peddampet
e) 33 KV SS Kaleshwaram
f) 33 KV SS Koyyur
g) 33 KV SS Gangaram
f) 33 KV SS V.V. Raopet
Location -137 132 KV SS RTS 'B' Yellampalli 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV SS RTS 'B' Yellampalli
Location -
138 132 KV SS Gangadhra (LIS) 1x50+1x25 75 5 --
Injection Points
a) 132KV SS Gangadhra(LIS)
Location -
139 132 KV SS Yellampally 2x16 32 5
Injection Points
a) 132KV SS Yellampally
NIZAMABAD
Location -140 132 KV SS Kamareddy 1x50+1x31.5 81.5 10
Injection Points a) 132KV SS Kamareddy - I
b) 33 KV SS Siricilla Road-KMR
c) 33 KV SS Arepally
d) 33 KV SS Bhavanipet-M
e) 33 KV SS Issaipet
f) 33 KV SS Velupugonda
g) 33 KV SS Brahmanpally
h) 33 KV SS Gandhari
i) 33 KV SS Sarvapoor
j) 33 KV SS Adloor Yellareddy
k) 33 KV SS S.S.Nagar
l) 33 KV SS Padmajiwadi
m) 33 KV SS Utnoor
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 215
n) 33 KV SS Housing Board-KMR
o) 33 KV SS Lingapoor
p) 33 KV SS Rajampet
q) 33 KV SS Chinnamallareddy
r) 33 KV SS Tadwai
s) 33 KV SS Aragonda
t) 33 KV SS Yerrapahad
u) 33 KV SS Kondapur
v) 33 KV SS Posanipet
Location -141 132 KV SS Renjal 1x31.5+1x16 47.5 10 --
Injection Points a) 132KV SS Renjal
b) 33 KV SS Navipet
c) 33 KV SS Dandigutta
d) 33 KV SS Rampoor
e) 33 KV SS Kosli
f) 33 KV SS Yemcha
g) 33 KV SS Neela
h) 33 KV SS Tadbiloli
i) 33 KV SS Pegadapally
j) 33 KV SS Ch.Mavandi
k) 33 KV SS Saloora
l) 33 KV SS A.R.P.Camp
m) 33 KV SS Mangalpahad
n) 33 KV SS Yedapally
o) 33 KV SS Renjal
Location -142 132 KV SS Jakhora 1x50+1x31.5 81.5 15 --
Injection Points a) 132KV SS Jakhora
b) 33 KV SS Srinagar
c) 33 KV SS Chandoor
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 216
d) 33 KV SS Chinthakunta
e) 33 KV SS Mosra
f) 33 KV SS Jalalpur
g) 33 KV SS Kotagiri
h) 33 KV SS Pothangal
i) 33 KV SS Jakhora (Varni)
j) 33 KV SS Nasrullabad
k) 33 KV SS Sangam
l) 33 KV SS Kalloor
m) 33 KV SS Kothapally
n) 33 KV SS Ambam
o) 33 KV SS Rudrur
p) 33 KV SS Raikur
Location -143 132 KV SS Nandipet 1x50+1x31.5 81.5 5 --
Injection Points a) 132KV SS Nandipet
b) 33 KV SS Degoam
c) 33 KV SS Manthani
d) 33 KV SS Aloor
Location -144 132 KV SS Domakonda 2x31.5 63 5
Injection Points
a) 132KV SS Domakonda
b) 33 KV SS Kyasampally
c) 33 KV SS Muthyampet
d) 33 KV SS Domakonda
e) 33 KV SS Laxmidevanpally
f) 33 KV SS Jangampally
g) 33 KV SS Thippaur
h) 33 KV SS Talamadla
i) 33 KV SS Narsannapally
j) 33 KV SS Janagoan
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 217
k) 33 KV SS Mohommadapur
l) 33 KV SS Bibipet
m) 33 KV SS Issanagar
n) 33 KV SS Thujalpur
o) 33 KV SS Fareedpet
p) 33 KV SS Chukkapur
q) 33 KV SS Lachapet
r) 33 KV SS Annaram
s) 33 KV SS Yellampet
t) 33 KV SS Somavarpet
Location -145 132 KV SS Armoor 1x31.5+1x16 47.5 5
Injection Points a) 132KV SS Armoor
b) 33 KV SS Munipally
c) 33 KV SS Issapally
d) 33 KV SS Ankapoor
e) 33 KV SS Pipri
f) 33 KV SS Maggidi
g) 33 KV SS Komanpally
h) 33 KV SS Perkit
i) 33 KV SS Govindpet
j) 33 KV SS Lakkora
k) 33 KV SS Fathepur
Location -146
132 KV SS Bichkonda 2x16 32 5
Injection Points
a) 132KV SS Bichkunda
b) 33 KV SS Madnoor
c) 33 KV SS Menoor
d) 33 KV SS Dongli
e) 33 KV SS Peddakodapgal
f) 33 KV SS Kemrajkallali
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 218
g) 33 KV SS Somur
h) 33 KV SS Jukkal
i) 33 KV SS Pulkal
j) 33 KV SS Kathgoan
Location -147 132 KV SS Lingapet 2x16 32 5
Injection Points a) 132KV SS Lingampet
b) 33 KV SS Bhavanipet
c) 33 KV SS Gandimasanipet
d) 33 KV SS Mothe
e) 33 KV SS Parmalla
f) 33 KV SS Khannapur
g) 33 KV SS S.S.Reddy
h) 33 KV SS Malthummeda
i) 33 KV SS Ramalaxmanpally
Location -148
132 KV SS Morthad 1x31.5+1x16 47.5 5
Injection Points a) 132KV SS Morthad
b) 33 KV SS Kammarpally
c) 33 KV SS Basheerabad
d) 33 KV SS Anksapur
e) 33 KV SS Kuknoor
f) 33 KV SS Donkal
g) 33 KV SS Morthad
h) 33 KV SS Palem
i) 33 KV SS Uploor
j) 33 KV SS Timmapur
Location -149 132 KV SS Banswada 2x16 32 5 --
Injection Points a) 132KV SS Banswada
b) 33 KV SS Damarancha
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 219
c) 33 KV SS Maddelcheru
d) 33 KV SS Shanthapoor
e) 33 KV SS Chillargi
f) 33 KV SS Birkur
g) 33 KV SS Mirzapur
h) 33 KV SS Konapur
i) 33 KV SS Ibrahimpet
Location -150
132 KV SS Dharmora (Gutta LI scheme) 2x16 32 5 --
Injection Points a) 132KV SS Dharmora(Gutta
LI Scheme)
Location -151
132 KV SS C.H.Kondur (Gutta LI scheme) 2x16 32 5
Injection Points a) 132KV SS C.H.Kondur(Gutta
LI Scheme)
Location -152 132 KV SS Bikanoor 2x16 32 5 --
Injection Points a) 132KV SS Biknoor
b) 33 KV SS Baswapoor
c) 33 KV SS Peddamallareddy
d) 33 KV SS Kachapoor
e) 33 KV SS Isannapaly
f) 33 KV SS Thippapur
g) 33 KV SS Talamadla
Location -153 132 KV SS Reddypet 2x16 32 5
Injection Points
a) 132KV SS Reddypet
b) 33 KV SS Shasodopur
c) 33 KV SS Ramreddy
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 220
d) 33 KV SS Adloor
ADILABAD
Location -154 132 KV SS Adilabad 2x31.5 63 5
Injection Points a) 132KV SS Adilabad
b) 33 KV SS Bukthapur
c) 33 KV SS Rampur
d) 33 KV SS G.S.Nagar
e) 33 KV SS Kailasnagar
f) 33 KV SS Thamsi
g) 33 KV SS Talamadugu
h) 33 KV SS Arli
i) 33 KV SS Ponnari
j) 33 KV SS Jainath
k) 33 KV SS Bhoraj
l) 33 KV SS Sathnala
m) 33 KV SS Bela
n) 33 KV SS Dasnapur
Location -
155 132 KV SS Bellampally 1x15+1x16 31 5 --
Injection Points
a) 132KV SS Bellampally
b) 33 KV SS Andugulpet
c) 33 KV SS Kondapoor
d) 33 KV SS Nennel
e) 33 KV SS Bellampally (T)
f) 33 KV SS Rebbana
g) 33 KV SS Thandoor
h) 33 KV SS Kannepally
i) 33 KV SS Ginnedari
j) 33 KV SS Thiryani
k) 33 KV SS Asifabad
l) 33 KV SS Ippal Navegoam
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 221
m) 33 KV SS Wankidi
n) 33 KV SS Kerameri
o) 33 KV SS Jankapur
p) 33 KV SS Rechini
q) 33 KV SS Vankulam
r) 33 KV SS Shivalayam/Bellampaly Town
Location -156
132 KV SS Mancherial 1x31.5+1x16 47.5 5 --
Injection Points a) 132KV SS Mancherial
b) 33 KV SS ACC
c) 33 KV SS Ramnagar
d) 33 KV SS Jaipoor
e) 33 KV SS Kundaram
f) 33 KV SS Naspoor
g) 33 KV SS Hazipoor
h) 33 KV SS Ryali Gadpoor
i) 33 KV SS RKP
j) 33 KV SS Gudipet
k) 33 KV SS Awadam
l) 33 KV SS RK 6 Huts
Location -
157 132 KV SS Sirpurkagaznagar 2x16 32 5
a) 132KV SS Sirpurkagaznagar
b) 33 KV SS Kagaz nagar (t)
c) 33 KV SS Nazrool nagar
d) 33 KV SS jambuga
e) 33 KV SS Sirpur(t)
f) 33 KV SS Kowtala
g) 33 KV SS Ravindranagar
h) 33 KV SS Rebbena(B)
i) 33 KV SS Beejjur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 222
j) 33 KV SS Elkapally
k) 33 KV SS Dahegam
Location -158 132 KV SS Bhainsa 2x31.5 63 5 --
a) 132KV SS BHAINSA
b) 33 KV SS DEGAON
c) 33 KV SS WANALPAD
d) 33 KV SS LOHESRA
e) 33 KV SS PIPREE
f) 33 KV SS ABDULLAPUR
g) 33 KV SS MANMAD
h) 33 KV SS KALLUR
i) 33 KV SS KUNTALA
j) 33 KV SS Gollamada
k) 33 KV SS KUBEER
l) 33 KV SS Sonari
m) 33 KV SS Mudhole
n) 33 KV SS EDBID
o) 33 KV SS BRAHMAN GOAN
p) 33 KV SS THANOOR
q) 33 KV SS Beltharoda
Location -
159 132 KV SS Luxettipeta 2x16 32 5 --
a) 132KV SS Luxettipeta
b) 33 KV SS Suraram
c) 33 KV SS Jannaram
d) 33 KV SS Dandepally
e) 33 KV SS Velganoor
f) 33 KV SS Venkatraopet
g) 33 KV SS Kawal
h) 33 KV SS Thapalpur
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 223
Location -160 132 KV SS Ichoda 2x16 32 5 --
a) 132KV SS Ichoda
b) 33 KV SS Barampur
c) 33 KV SS Echoda
d) 33 KV SS Bazarhathnoor
e) 33 KV SS Pochera (Boath)
f) 33 KV SS Sonala
g) 33 KV SS Neradigonda
h) 33 KV SS Utnoor
i) 33 KV SS Pulimadugu
j) 33 KV SS Narnoor
k) 33 KV SS Lokari
l) 33 KV SS Jainoor
m) 33 KV SS Sirpur U
n) 33 KV SS Indervelly
o) 33 KV SS Dasnapur (Ivelly)
p) 33 KV SS Gudihathnoor
q) 33 KV SS Seethagondi
Location -161
132 KV SS Chennur 2x16 32 5 --
a) 132KV SS Chennur
b) 33 KV SS Kotapally
c) 33 KV SS Neelwai
d) 33 KV SS Bheemaram
e) 33 KV SS Devula Wada
f) 33 KV SS Chennor
g) 33 KV SS Kommera
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 224
Format 6.13 – Format for Contract Performance Bank Guarantee
(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)
In consideration of the ----------- [Insert name of the Bidder] (hereinafter referred to as selected Solar Power Developer') submitting the response to RfS inter alia for selection of the project of the capacity of ______ MW, at …………[Insert name of the place], for supply of power there from on long term basis, in response to the RfS dated ………….issued by APTRANSCO/DISCOM and APTRANSCO/DISCOM considering such response to the RfS of ………[insert the name of the selected Solar Power Developer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Solar Power Project of the Developer and issuing Letter of Intent No ------- to (Insert Name of selected Solar Power Developer) as per terms of RfS and the same having been accepted by the selected SPD resulting in a Power Purchase Agreement (PPA) to be entered into, for purchase of Power [from selected Solar Power Developer or a Project Company, M/s --------- ---- {a Special Purpose Vehicle (SPV) formed for this purpose}, if applicable ]. As per the terms of the RfS, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to APTRANSCO/DISCOM at [Insert Name of the Place from the address of the APTRANSCO/DISCOM] forthwith on demand in writing from APTRANSCO/DISCOM or any Officer authorised by it in this behalf, any amount up to and not exceeding Rupees------ [Total Value] only, on behalf of M/s [Insert name of the selected Solar Power Developer / Project Company]
This guarantee shall be valid and binding on this Bank up to and including and shall not be terminable by notice or any change in the constitution of the Bank or the term of contract or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective agreement.
Our liability under this Guarantee is restricted to Rs. (Rs. only) ------. Our Guarantee shall remain in force until _[Insert date] APTRANSCO/DISCOM shall be entitled to invoke this Guarantee till [Insert date]
The Guarantor Bank hereby agrees and acknowledges that the APTRANSCO/DISCOM shall
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 225
have a right to invoke this BANK GUARANTEE in part or in full, as it may deem fit. The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written demand by APTRANSCO/DISCOM, made in any format, raised at the above mentioned address of the Guarantor Bank, in order to make the said payment to APTRANSCO/DISCOM.
The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and notwithstanding any objection by -------------[Insert name of the selected Solar Power Developer / Project Company as applicable] and/or any other person. The Guarantor Bank shall not require APTRANSCO/DISCOM to justify the invocation of this BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against APTRANSCO/DISCOM in respect of any payment made hereunder
This BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at Andhra Pradesh shall have exclusive jurisdiction.
The Guarantor Bank represents that this BANK GUARANTEE has been established in such form and with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.
This BANK GUARANTEE shall not be affected in any manner by reason of merger, amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.
This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly APTRANSCO/DISCOM shall not be obliged before enforcing this BANK GUARANTEE to take any action in any court or arbitral proceedings against the selected Solar Power Developer / Project Company, to make any claim against or any demand on the selected Solar Power Developer / Project Company or to give any notice to the selected Solar Power Developer / Project Company or to enforce any security held by APTRANSCO/DISCOM or to exercise, levy or enforce any distress, diligence or other process against the selected Solar Power Developer / Project Company .
The Guarantor Bank acknowledges that this BANK GUARANTEE is not personal to APTRANSCO/DISCOM and may be assigned, in whole or in part, (whether absolutely or by way of security) by APTRANSCO/DISCOM to any entity to whom APTRANSCO/DISCOM is entitled to assign its rights and obligations under the PPA.
Notwithstanding anything-contained hereinabove, our liability under this Guarantee is
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 226
restricted to Rs. (Rs. only) and it shall remain in force until with an additional claim period of thirty (30) days thereafter. We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if APTRANSCO/DISCOM serves upon us a written claim or demand.
Signature
Name
Power of Attorney No. For
[Insert Name of the Bank]
Banker's Stamp and Full Address.
Dated this day of , 20 Witness: 1. ……………………………………. Signature Name and Address 2. …………………………………..
Signature Name and Address
Notes:
The Stamp Paper should be in the name of the Executing Bank. The Bank Guarantee shall be executed by any of the Bank from the List of Banks enclosed.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 227
Format 6.14 – Format for Earnest Money Deposit (EMD) (To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)
In consideration of the ----------- [Insert name of the Bidder] (hereinafter referred to as selected Solar Power Developer') submitting the response to RfS inter alia for selection of the project of the capacity of ______ MW, at …………[Insert name of the place], for supply of power there from on long term basis, in response to the RfS dated ………….issued by APTRANSCO and APTRANSCO considering such response to the RfS of ………[insert the name of the selected Solar Power Developer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Solar Power Project of the Developer and issuing Letter of Intent No ------- to (Insert Name of selected Solar Power Developer) as per terms of RfS and the same having been accepted by the selected SPD resulting in a Power Purchase Agreement (PPA) to be entered into, for purchase of Power [from selected Solar Power Developer or a Project Company, As per the terms of the RfS, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to APTRANSCO at [Insert Name of the Place from the address of the APTRANSCO] forthwith on demand in writing from APTRANSCO or any Officer authorised by it in this behalf, any amount up to and not exceeding Rupees------ [Total Value] only, on behalf of M/s [Insert name of the selected Solar Power Developer / Project Company]
This guarantee shall be valid and binding on this Bank up to and including and shall not be terminable by notice or any change in the constitution of the Bank or the term of contract or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective agreement.
Our liability under this Guarantee is restricted to Rs. (Rs. only). Our Guarantee shall remain in force until _[Insert date] APTRANSCO shall be entitled to invoke this Guarantee till [Insert date]
The Guarantor Bank hereby agrees and acknowledges that the APTRANSCO shall have a right to invoke this BANK GUARANTEE in part or in full, as it may deem fit.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 228
The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written demand by APTRANSCO, made in any format, raised at the above mentioned address of the Guarantor Bank, in order to make the said payment to APTRANSCO
The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and notwithstanding any objection by -------------[Insert name of the selected Solar Power Developer / Project Company as applicable] and/or any other person. The Guarantor Bank shall not require APTRANSCO to justify the invocation of this BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against APTRANSCO in respect of any payment made hereunder
This BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at Andhra Pradesh shall have exclusive jurisdiction.
The Guarantor Bank represents that this BANK GUARANTEE has been established in such form and with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.
This BANK GUARANTEE shall not be affected in any manner by reason of merger, amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.
This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly APTRANSCO shall not be obliged before enforcing this BANK GUARANTEE to take any action in any court or arbitral proceedings against the selected Solar Power Developer / Project Company, to make any claim against or any demand on the selected Solar Power Developer / Project Company or to give any notice to the selected Solar Power Developer / Project Company or to enforce any security held by APTRANSCO or to exercise, levy or enforce any distress, diligence or other process against the selected Solar Power Developer / Project Company .
The Guarantor Bank acknowledges that this BANK GUARANTEE is not personal to APTRANSCO and may be assigned, in whole or in part, (whether absolutely or by way of security) by APTRANSCO to any entity to whom APTRANSCO is entitled to assign its rights and obligations under the PPA.
Notwithstanding anything-contained hereinabove, our liability under this Guarantee is restricted to Rs. (Rs. only) and it shall remain in force
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 229
until with an additional claim period of thirty (30) days thereafter. We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if APTRANSCO serves upon us a written claim or demand.
Signature
Name
Power of Attorney No. For
[Insert Name of the Bank]
Banker's Stamp and Full Address.
Dated this day of , 20 Witness: 1. ……………………………………. Signature Name and Address 2. …………………………………..
Signature Name and Address
Notes:
The Stamp Paper should be in the name of the Executing Bank. The EMD shall be executed by any of the Bank from the List of Banks enclosed.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 230
Appendix – A CHECK LIST FOR BANK GUARANTEES/DDs
Sl.No. Details of checks YES/NO.
a) Bid Processing fee Rs. 2 Lakhs in the form of DD or by online payment through RTGS .
b) Is the EMD in the form of BG. C) Whether date, purpose of purchase of stamp paper and name of the
purchaser are indicated on the back of Stamp paper under the Signature of Stamp vendor? (The date of purchase of stamp paper should be not later than the date of execution of BG and the stamp paper should be purchased either in the name of the executing Bank or the party on whose behalf the BG has been issued. Also the Stamp Paper should not be older than six months from the date of execution of BG).
d) In case of BGs from Banks abroad, has the BG been executed on Letter Head of the Bank endorsed by SBI, India.
e) Has the executing Officer of BG indicated his name, designation and Power of Attorney No./Signing Power no. on the BG?
f) Is each page of BG duly signed / initialed by executants and whether stamp of Bank is affixed thereon? Whether the last page is signed with full particulars including two witnesses under seal of Bank as required in the prescribed proforma?
g) Does the Bank Guarantees compare verbatim with the Proforma prescribed in the Bid Documents?
h) Are the factual details such as Bid Document No. / Specification No., / LoI No. (if applicable) / Amount of BG and Validity of BG correctly mentioned in the BG
i) Whether overwriting/cutting if any on the BG have been properly authenticated under signature & seal of executant?
j) Whether the BG has been issued by a Bank in line with the provisions of Bidding documents?
k) In case BG has been issued by a Bank other than those specified in Bidding Document, is the BG confirmed by a Bank in India acceptable as per Bidding documents?
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 231
Annexure1
Technical Qualification requirement in case of Solar Project The following are some of the technical measures required to ensure quality of the PV modules used in grid connected Solar Power Projects.
1. PV Module Qualification
1.1 The PV modules used in the grid connected Solar Power Projects must qualify to
the latest edition of any of the following IEC PV module qualification test or equivalent BIS standards.
Crystalline Silicon Solar Cell Modules IEC 61215
Thin Film Modules IEC 61646
Concentrator PV modules IEC 62108
1.2 In addition, PV modules must qualify to IEC 61730 for safety qualification testing.
For the PV modules to be used in a highly corrosive atmosphere throughout their
lifetime, they must qualify to IEC 61701.
2 Solar Thermal Qualification
2.1 Only new plant & machinery to be used.
2.2 Any of the Concentrated Solar Power (CSP) technology, such as, Parabolic
Trough Collectors, Solar Dish Stirling (or any other prime mover), Linear Fresnel
Reflector, Central Tower with heliostats, or their any other combination could
be used. 3. Authorized Test Centers
The Solar plant equipment must be tested and approved by one of the IEC/
Accredited authorized test centers as per norms. In addition a PV module
qualification test certificate as per IEC standard, issued by Solar Energy Centre,
MNRE, New Delhi will also be valid.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 232
4. Warranty
The mechanical structures, electrical works and overall workmanship of the grid solar power plants must be warranted for a minimum of 5 years.
The plant equipment used for solar Power generation in grid connected solar
power plants must be warranted for output wattage, which should not be less
than 90% at the end of 10 years and 75% at the end of 20 years. 5. Identification and Traceability
Each equipment used in any Solar power Project must use a RF identification tag (RFID). The following information must be mentioned in the RFID used on each module (This can be inside or outside the laminate, but must be able to withstand state harsh environmental conditions.)
(i) Name of the manufacturer of each equipment. (ii) Month and year of the manufacture (separately for solar cells and module) of
each apparatus. (iii) Country of origin (separately for solar cells and module). (iv) I-V curve for the module and generator. (v) Wattage, Im, Vm and FF for the module for the installed equipment. (vi) Unique Serial No and Model No of the module. (vii) Date and year of obtaining qualification certificate from appropriate
authority as per Indian/Global standards. (viii) Name of the test lab issuing IEC/qualification certificate. (ix) Other relevant information on traceability of solar cells and module as per ISO
9000.
All grid connected Solar Power Projects must install necessary equipment to
continuously measure solar radiation, ambient temperature, and other weather
parameters and simultaneously measure the generation of DC power as well as AC
power generated from the plant besides measuring Electrical Parameters. It is
also required that suitable SCADA system with facilities for remote monitoring must
be installed. They will be required to provide remote access to the above data to
SLDCas well as submit the same through a monthly report for the entire duration of
Power Purchase Agreement.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 233
Annexure 2 List of Banks
A. SBI AND ASSOCIATES 1. State Bank of India 2. State Bank of Bikaner & Jaipur 3. State Bank of Hyderabad 4. State Bank of Indore 5. State Bank of Mysore 6. State Bank of Patiala 7. State Bank of Travancore
B. NATIONALISED BANKS 1. Allahabad Bank 2. Andhra Bank 3. Bank of India 4. Bank of Maharashtra 5. Canara Bank 6. Central Bank of India 7. Corporation Bank 8. Dena Bank 9. Indian Bank 10. Indian Overseas Bank 11. Oriental Bank of Commerce 12. Punjab National Bank 13. Punjab & Sind Bank 14. Syndicate Bank of India 15. Union Bank of India 16. United Bank of India 17. UCO Bank 18. Vijaya Bank 19. Bank of Baroda
C. SCHEDULED FOREIGN BANKS 1. Bank of America N.A. 2. Bank of Tokyo Mitsubishi UFJ Ltd. 3. BNP Paribas 4. Citi Bank N.A. 5. Deutsche Bank A.G 6. The Hongkong and Shanghai Banking Corp. Ltd. 7. Standard Charted Bank 8. Societe General 9. Barclays Bank 10. ABN Amro Bank N.V. 11. Bank of Nova Scotia 12. Development Bank of Singapore(DBS, Bank Ltd.)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 234
Annexure 3 Checklist of Documents to be submitted:
a. Demand Draft/Receipt of cash payment made towards cost of the RfS. b. RfS document duly signed and stamped on every page. c. Covering Letter as per Format 6.1 d. Power of Attorney/Board Resolution as per Format 6.2 e. Earnest Money Deposit (EMD) in the form of Demand Draft in Format 6.14 f. Processing fee in the form of Demand Draft g. Submission of bid document and all other relevant documents in English
language only. h. Board Resolution as per Format 6.4 i. Consortium Agreement as per Format 6.5 j. Financial Requirements criteria as per Format 6.6 k. Technical Criteria as per Format 6.7 l. Letter from Developer confirming connectivity as per Format 6.8 m. Disclosure Statement as per Format 6.9 n. Technological Tie Up as per Format 6.10 o. Checklist of Bank Guarantee as per Appendix-A p. Data Sheet as per Format 6.11 q. Tariff Bid as per Format 6.12 r. Calculation of Net worth s. Memorandum and Articles of Association t. Certificate of Incorporation u. Annual audited accounts for the financial year 2011-12 and also for relevant years as per RfS. All
financial documents submitted along with the RfS must be signed on all pages by the Chartered Accountant.
v. Shareholding pattern indicating the controlling shareholding certified by chartered accountant. w. Shareholding pattern statement of the Foreign Company, duly certified by competent authority. x. Proof of listing in the Stock Exchange if a public limited company. y. Any other document mentioned in the RfS or PPA. NOTE: All the above items in the check list are to be submitted as per the requirements under the RfS.
Response to RfS that are incomplete, which do not substantially meet the requirements prescribed in this RfS, will be liable for rejection by APTRANSCO.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 235
Annexure-B
A. Charges to be paid by the bidder
a) Processing fee of Rs. 2 Lakh per location at the time of submission of RfS
(Non-refundable) to APPCC/DISCOM.
b) Bid security: EMD in the form of BG as follows:
Rs 2 lakhs/MW BG in favor of Chief Engineer/IPC/APPCC/APTRANSCO,for
Validity period of 90 days from the date of bid submission and c laim period
of one more month over and above validity period.
Insufficient Bid submitted by the bidders will be rejected without any prior notice.
B. Charges to be paid by the Developer/Successful Bidder
a) Contract performance Bank Guarantee (if applicable) as specified in Clause
3.17.
b) Performance Bank Guarantee as specified in Clause 3.17.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 236
ANNEXURE –C (for RTGS)
RTGS Particulars
Sl.No. Particulars
1 Bank's name and branch name State Bank of Hyderabad, Gunfoundry Branch, Abids Hyderabad.
2 Bank address Gunfoundry Branch, Abids, Hyderabad.
3 Name of City Hyderabad.
4 Bank Telephone Number 23387334/23387837 (F)/23387551 (F)
5 Bank IFSC code for NEFT SBHY0020066
6 Bank IFSC code for RTGS SBHY0020066
7 Bank MICR code 50000401900049011
8 Beneficiary name AP Power Distribution companies pool account
9 Beneficiaries Bank Account No. 52117479223
10 Type of account current account
11 Telephone No. of Beneficiary off 23369000, Extn. 3663, Fx-23395370, Mobile-9440816306
Note for bidder: Bidder has to ensure that the address of the bidder is correctly reflected in the RTGS transaction for technical bid evaluation.
Bidders declaration form: ____________Bidder has to ensure the payment of processing fee through RTGS by submitting the relevant details i.e., they have paid the processing fee through transaction number_______________date:_______ for an amount of Rs._______________ from_____________ Bank, ___________Branch. The same is required to be uploaded along with the other required documents/Formats, failing which the bid is liable for rejection.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 237
Power Purchase Agreement
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 238
Draft PPA
POWER PURCHASE AGREEMENT BETWEEN
__________ POWER DISTRIBUTION COMPANY OF ANDHRA PRADESH LIMITED AND
M/s. _____________________________________
NCE SOLAR PPA No.______________
1. This Power Purchase Agreement ( “Agreement”) entered into this ____ day of ____________ between ___________Power Distribution Company of Andhra Pradesh Limited
(DISCOM), incorporated by the Government of Andhra Pradesh in accordance with the Andhra Pradesh Electricity Reform Act 1998 (Act No.30 of 1998), under the provisions of Companies Act, 1956, having its office at ______________________ Andhra Pradesh, India, hereinafter referred to as the “DISCOM” (which expression shall, unless repugnant to the
context or meaning thereof, include its successors and assigns) as first party, and ____________________, having registered office at ____________________________________ hereinafter referred to as the “Solar Power Developer” (which expression shall, unless repugnant to the context or meaning thereof,
include its successors and assigns) as second party;
2. WHEREAS, the Solar Power Developer is setting up the Solar Power Project of ____MW capacity at ________________(Village/Mandal) ______ District, Andhra Pradesh (hereafter called the Project,) with a proposal of _________ MW for Sale to DISCOM as detailed in Schedule 1 attached herewith.
3. WHEREAS, APTRANSCO/DISCOM has no obligation to recommend any department to grant
permissions /sanctions for the Solar Power Project. The Solar Power Developer shall obtain permissions/sanctions from Govt authorities, if any required for establishing the project.
4. And where as Solar Power Developer desires to sell entire solar energy from the Contracted Capacity to DISCOM in accordance with the Policy announced by GoAP vide G.O.
Ms. No.46, dated: 27.11.2012.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 239
5. WHEREAS, the Solar Power Developer shall achieve Commercial Operation Date within 12 months from the date of signing of this Agreement, default of which, the
Agreement is liable for termination as provided in Clause 10.5.
The PPA will continue to be in force for a period of 20 years from the Date of Commercial Operation (COD) subject to the approval of Andhra Pradesh Electricity Regulatory Commission (“APERC”).
6. WHEREAS, it has been agreed that the Project will be designed, engineered and constructed and operated by or on behalf of the Solar Power Developer or its successors with reasonable diligence subject to all applicable Indian laws, rules, regulations and orders
having the force of law;
7. Whereas, the Project proposed at ____________________(Village/Mandal), ______(District) will be connected to ________ (insert 132/33 kV or 33/11 kV) grid substation for easy power evacuation within the time frame stipulated in this Agreement. The injection of power from the Project to the grid is to be limited to the already
technically approved capacity.
8. This Agreement is enforceable subject to approval of APERC as per Section 86 of Electricity Act 2003;
9. The terms and conditions of this Agreement are subject to the provisions of the Act and also subject to relevant regulations, if any, issued by the APERC from time to time.
10. NOW THEREFORE, in consideration of the foregoing premises and their mutual covenants herein, and for other valuable consideration, the receipt and sufficiency of which
are acknowledged, the parties hereto, intending to be legally bound hereby agree as follows:
11. The Solar Power Developer shall deploy commercially established technologies for generation of Solar Power.
12. The Solar Power Developer shall not be eligible for obtaining RECs, as per prevailing regulations issued by CERC and APERC, for energy generated from this Project and supplied
to DISCOMs.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 240
ARTICLE 1 DEFINITIONS
Unless the context otherwise expressed in this Agreement, the following terms shall have the meanings set forth herein below. Defined terms of singular number shall include the plural and vice-versa.
“Act” shall mean the Electricity Act, 2003 and include any modifications, amendments and substitution from time to time;
“Agreement” shall mean this Power Purchase Agreement in accordance with Government policy vide G.O. Ms. No.46, dated:27.11.2012 through competitive bidding route, including the articles, schedules, amendments, modifications and supplements made in writing by the parties from time to time.
“APTRANSCO” shall mean Transmission Corporation of Andhra Pradesh Limited, incorporated under the Company Act 1956.
“Performance Bank Guarantee (BG)” shall mean any bank guarantee (BG) furnished by the developer to APTRANSCO/DISCOM, to assure timely and satisfactory completion of a Project by a developer as described in the RfS.
“Billing Date” shall mean the fifth (5th) Working day after the Meter Reading Date.
“Billing Month” shall mean the period commencing from 25th of the calendar month and ending on the 24th of the next calendar month.
“Capacity Utilization factor” (“CUF”) shall have the same meaning as provided by APERC from time to time. Till such time, it shall have the same meaning as provided in CERC (Terms and Conditions for the Tariff determination from Renewable Energy Sources) Regulations, 2012 and as amended from time to time.
“CERC” shall mean Central Electricity Regulatory Commission formed under Section 76 of the Electricity Act 2003.
“Commercial Operation Date”/ “Date of Commercial Operation” (“COD”) shall mean, with respect to each Generating unit, the date on which such Generating unit is declared by the Solar Power Developer to be operational, provided that the Solar Power
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 241
Developer shall not declare a Generating unit to be operational until such Generating unit has met the conditions of the Clause 3.9.
“Consultation Period” shall mean the period of sixty (60) days or such other longer period as the parties may agree, commencing from the date of issuance of a Solar Power Developer Preliminary Default Notice or DISCOM Preliminary Default Notice as provided in Article 10 of this Agreement, for consultation between the parties to mitigate the consequence of the relevant event having regard to all the circumstances;
“Contract Performance Bank Guarantee” (“CPBG”) shall refer to the bank guarantee to be produced by successful bidder to the concerned distribution licensees on the difference of L1 Tariff and Committee decided benchmark price to the tune of amount of rupees equivalent to the energy that would be generated for 3 [three] years at CUF (capacity utilization factor) of 25% from the plant if the technology used is Solar PV and 25% CUF for STP (Solar Thermal plant) provided to the L1 Tariff is lesser than the benchmark price.
“Change in Law” shall mean any change in the, provision of electricity law in force, regulations, directions, notifications issued by the competent authorities and GoI/GoAP from time to time.
"Contracted Capacity" shall mean ……[Insert capacity] MW contracted with DISCOM for supply by the Solar Power Developer to DISCOM at the Interconnection Point from the Project.
“Delivered Energy” shall mean, with respect to any Billing Month, the kilo watt hours (kWh) of electrical energy generated by the Project and delivered to the DISCOM at the Interconnection Point, as measured by both energy meters at the Interconnection Point during that Billing Month at the designated substation of APTRANSCO/DISCOM.
Explanation 1: For the purpose of clarification, Delivered Energy, excludes all energy consumed in the Project, by the main plant and equipment, lighting and other loads of the Project from the energy generated and as recorded by energy meter at Interconnection Point.
Explanation 2: The Delivered Energy in a Billing Month shall be limited to the energy calculated based on the Contracted Capacity multiplied with number of hours and
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 242
fraction thereof the Project is in operation during that Billing Month. In case, energy will be procured at L1 Tariff up to 25% CUF for this location, beyond the same, the energy will be purchased at a flat rate of Rs 3.00 / commercial (kWh) unit (without escalation) for the entire agreement period.
“Due Date of Payment” shall mean the date on which the amount payable by the DISCOM to the Solar Power Developer hereunder for Delivered Energy, if any, supplied during a Billing Month becomes due for payment, which date shall be thirty (30) days from the Meter Reading Date provided the bill is received by DISCOM within 5 working days from Meter Reading Date, and in the case of any supplemental or other bill or claim, if any, the Due Date of Payment shall be thirty (30) days from the date of the presentation of such bill or claim to the designated officer of the DISCOM. If the last date of payment falls on a holiday, the next working day shall be considered as last date.
“Financial Year” shall mean, with respect to the initial Financial Year, the period beginning on the Commercial Operation Date and ending at 12.00 midnight on the following March 31. Each successive Financial Year shall begin on April 1 and end on the following March 31, except that the final Financial Year shall end on the date of expiry of the term or on termination of this Agreement as per the provisions of Clauses 9.2, 10.4.4 and 10.5 whichever is earlier.
“Financing Agreement” shall mean the agreement pursuant to which the Solar Power Developer has sought financing for the Project including the loan agreements, security documents, notes, indentures, security agreements, letters of credit and other documents, as may be amended, modified, or replaced from time to time, but without in anyway increasing the liabilities of APTRANSCO/ DISCOM;
“Grid Code” shall mean the Indian Electricity Grid Code issued by CERC vide notification No. L-1/18/2010-CERC, New Delhi, 28-04-2010 including any amendments and modifications thereto and/ or AP Grid Code, as amended from time to time.
“Installed Capacity” shall mean the name plate capacity of all the Units of the Project.
“Interconnection Facilities” shall mean all the equipment and facilities, including, but not limited to, all metering facilities, switchgear, substation facilities, transmission lines and related infrastructure, to be installed at the Voltage of Delivery at the Solar
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 243
Power Developer's expense from time to time throughout the Term of the Agreement, necessary to enable the DISCOM to economically, reliably and safely receive Delivered Energy from the Project in accordance with the terms of this Agreement. The Solar Power Developer has to bear entire expenditure of Interconnection Facilities for power evacuation as per the sanctioned estimate by the field officers.
“Interconnection Point” shall mean the point or points where the Project and the grid system of APTRANSCO/ DISCOM are interconnected at the grid substation of APTRANSCO/DISCOM. The metering for the Project will be provided at the interconnection point as per Clause 4.1.
“Interconnection Substation” shall mean the substation where the Project and the APTRANSCO/ DISCOM grid system are interconnected.
“Metering Code” shall mean Central Electricity Authority (“CEA”) (Installation and Operation of Meters) Regulations, 2006 , as amended from time to time.
“Meter Reading Date” shall mean the 25th (twenty fifth) day of each calendar month, at 00:00 hours, at the Interconnection Point.
“Metering Point” shall mean points where metering shall be provided for Project and shall be as follows:
(i) Both meters (main & check) provided at the Interconnection Point for purposes of recording of Delivered Energy of the Project;
(ii) Additionally, a standby meter shall be provided as per CEA norms on the dedicated feeder at grid Substation.
(iii) Metering point shall include three separate sets of 0.2s class accuracy ABT meters as specified in Clause 4.1, main meter, check and standby meter installed by the Solar Power Developer and all meters sealed by the DISCOM, having facilities to record both export and import of electricity to / from the grid.
“Project” shall mean the solar power generation facility of Installed Capacity of ………..[Insert capacity ] MW, located at ……………. [Insert name of the place] in ….
[Insert name of the District and State];
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 244
Which includes all units and auxiliaries such as water supply, treatment or storage facilities; bay/s for transmission system in the switchyard, and all the other assets, buildings/structures, equipments, plant and machinery, facilities and related assets required for the efficient and economic operation of the power generation facility;
whether completed or at any stage of development and construction or intended to be developed and constructed for the purpose of supply of power as per this Agreement;
“Prudent Utility Practices” shall mean those practices, methods, techniques and standards, that are generally accepted for use in electric utility industries taking into account conditions in India, and commonly used in prudent electric utility engineering and operations to design, engineer, construct, test, operate and maintain equipment lawfully, safely, efficiently and economically as applicable to power stations of the size, service and type of the Project, and that generally conform to the manufacturers'
operation and maintenance guidelines.
“RfS” shall mean the document to request for selection of solar power projects for purchase of solar energy by DISCOMs, issued by Transmission Corporation of Andhra Pradesh Limited floated in accordance with the Policy issued by GoAP vide G.O. Ms No.46, dated: 27.11.2012
“Scheduled COD” shall mean 12 months from the date of signing of this Agreement.
“SLDC” shall mean the State Load Dispatch Center as notified by the State Government under the provisions of the Electricity Act 2003.
“Solar Power” shall mean power generated from the SPV or STP.
“Solar Power Project” shall mean either an SPV or STP Project.
“Solar Photovoltaic Project” or “Solar PV” or “SPV” shall mean the solar photovoltaic power project that uses sunlight for conversion into electricity and that is being set up by the Solar Power Developer to provide Solar Power to DISCOM as per the terms and conditions of this Agreement.
“Solar Thermal Project” or “STP” shall mean the solar thermal power project that uses sunlight through Concentrated Solar Power Technology (based on either line
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 245
focus or point focus principle) for conversion into heat/steam which can be used for producing electricity.
“System Emergency” means a condition affecting the APTRANSCO/ DISCOM electrical system including grid which threatens the safe and reliable operation of such system or which is likely to result in the disruption of safe, adequate and continuous electric supply by the APTRANSCO/ DISCOM, or which endangers life or property, which condition is affected or aggravated by the continued delivery of Delivered Energy from the Project.
“Solar Power Developer” shall mean a company registered under Indian companies Act, a partnership firm registered under partnership Act or a society registered under A.P. society Registration Act.
“Tariff” shall have the same meaning as provided for in Clause 2.2 of this Agreement.
“Term of the Agreement” shall have the same meaning as provided for in Article 7 of this Agreement
“Unit”, when used in relation to the solar generating equipment, shall mean the set of solar panels multiplied by their name plate capacity in MW in case of Solar PV Project and set of parabolic troughs, turbo plant and connected equipment along with related auxiliary equipment in case of Solar Thermal Project and facilities forming part of the Project and when used in relation to electrical energy, means Kilo Watt Hour (kWh).
“Voltage of Delivery” shall mean the voltage at which the electrical energy generated by the Project is required to be delivered to the APTRANSCO/DISCOM grid substation at the Interconnection Point. Any modifications or procedures or changes in arranging Interconnection Facilities for power evacuation rest with APTRANSCO and DISCOM.
All other words and expressions used herein and not defined herein but defined in AP Electricity Reform Act, 1998 and the Electricity Act, 2003 and rules and Regulations made there under shall have the meanings respectively assigned to them in the said laws, as amended from time to time.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 246
ARTICLE 2 PURCHASE OF DELIVERED ENERGY AND TARIFF
2.1 All the Delivered Energy, as mentioned in Schedule 1, at the Interconnection Point for sale to DISCOM will be purchased at the Tariff provided for in Clause 2.2 from and after the Date of Commercial Operation of the Project and limited to capacity of project only and title to Delivered Energy purchased shall pass from the Solar Power Developer to the DISCOM at the Interconnection Point.
2.2 The DISCOM shall pay a Tariff of Rs. _____ / Unit (“Tariff”) arrived through competitive bidding for this particular location based on the bidding guidelines issued and RfS floated in accordance with the Policy issued by GoAP vide G.O. Ms No.46, dated: 27.11.2012.
2.3 The Tariff payable by the DISCOM will be inclusive of all taxes, duties and levies, to be borne by the Solar Power Developer.
2.4 All future increase in taxes, duties and levies on energy generated will have to be borne by the Solar Power Developer.
2.5 DISCOM, at any time during a contract year will purchase electricity at the Tariff from the Solar Power Developer up to the CUF of 25%, beyond the said quantum, the electricity will be purchased at a flat rate of Rs 3.00 / Unit for the entire agreement period.
2.6 The Solar Power Developer, at any time during validity of this Agreement, shall not add any extra solar modules/equipment more than the Contracted Capacity.
2.7 The solar Developer is entitled to draw the power for its auxiliary consumption the limit of which is specified in schedule-1 from DISCOM. The energy supplied by the DISCOM to the Solar Power Developer through a bilateral arrangement, to maintain the Auxiliaries of the power plant in situations of non-generation of power, in any billing month shall be adjusted from the delivered energy, as indicated below:
Net off Energy= Deliveed energy by the developer at interconnection point- Energy drawl from DISCOM for auxiliaries.
Explanation: The Solar plants during the plant shut down/non-generation periods shall draw the energy from DISCOM only for the essential loads not exceeding auxiliary consumption.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 247
ARTICLE 3 INTERCONNECTION FACILITIES, SYNCHRONIZATION, COMMISSIONING AND COMMERCIAL
OPERATIONS
3.1 Upon receipt of a requisition from the Solar Power Developer, APTRANSCO/ DISCOM
will prepare an estimate for arranging Interconnection Facilities for power evacuation at the Voltage of Delivery. The Solar Power Developer has to bear the entire cost of the Interconnection Facilities as per the sanctioned estimate.
3.2 APTRANSCO and DISCOM may also permit the Solar Power Developer to execute the Interconnection Facilities for power evacuation as per the sanctioned estimate at its discretion duly collecting the supervision charges as per procedure in vogue.
3.3 The Solar Power Developer shall own, operate and maintain Interconnection Facilities from Project to grid sub-station from time to time and necessary
expenditure shall have to be borne by the Solar Power Developer. The maintenance work at the grid sub-station and connected bay and equipment has to be done in coordination with the APTRANSCO and DISCOM authorities. If APTRANSCO/DISCOM carryout the O&M work, the power producer shall pay such expenses to
APTRANSCO/DISCOM as applicable.
3.4 Any modifications or procedures or changes in arranging Interconnection Facilities for
power evacuations rest with APTRANSCO and DISCOM.
3.5 DISCOM reserves the right to add any additional loads on the feeder without
detriment to the existing generator /solar plants on the same feeder.
3.6 The Solar Power Developer shall be responsible to operate the Project as envisaged
under this Agreement & to provide appropriate facility/ instrumentation/ metering arrangement as per Clause 4.1.
3.7 The Solar Power Developer shall deploy components/ equipment for the STP/SPV complying with approved/ minimum technical standards as per International Electrotechnical Commission (“IEC”) & Bureau of Indian Standards (“BIS”) or
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 248
technical standards that are as specified by Ministry of New and Renewable Energy (“MNRE”) as amended from time to time at the cost of the Solar Power Developer.
3.8 Any modifications or procedures or changes in arranging Interconnection Facilities for power evacuation shall be at the discretion of APTRANSCO and DISCOM.
3.9 Acceptance/Performance Test
Prior to synchronization of the Project as per Clause 3.11, the Solar Power Developer
shall be required to get the Project certified for the requisite
acceptance/performance test as may be laid down by CEA/ APERC/APTRANSCO or an
agency identified by APTRANSCO/DISCOM to carry out testing and certification for
the Solar Power Projects.
3.10 Verification by APTRANSCO/DISCOM
3.10.1 The Solar Power Developer shall be further required to provide entry to the site of
the Project free of all encumbrances at all times during the Term of the Agreement
to APTRANSCO/ DISCOM for inspection and verification of the works being carried out
by the Solar Power Developer at the site of the Project.
3.10.2 The APTRANSCO/DISCOM may verify the construction works/operation of the Project
being carried out by the Solar Power Developer and if it is found that the
construction works/operation of the Project is not as per the Prudent Utility
Practices, it may seek clarifications from Solar Power Developer or require the works
to be stopped or to comply with the instructions of such third party.
3.11 Synchronization, Commissioning and Commercial Operation
3.11.1 The Solar Power Developer shall give the concerned SLDC and DISCOM at least sixty
(60) days advance of preliminary written notice and at least thirty (30) days advance
of final written notice, of the date on which it intends to synchronize the Project to
the grid system.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 249
3.11.2 The Project may be synchronized by the Solar Power Developer to the grid system
when it meets all the connection conditions prescribed in applicable Grid Code then
in effect and otherwise meets all other Indian legal requirements for synchronization
to the grid system.
3.11.3 The synchronization equipment shall be installed by the Solar Power Developer at its
generation facility of the Project at its own cost. The Solar Power Developer shall
synchronize its system with the Grid System only after the approval of
synchronization scheme is granted by the head of the concerned sub-station/grid
system and checking/verification is made by the concerned authorities of the grid
system.
3.11.4 The Solar Power Developer shall immediately after synchronization/ tripping of
generator, inform the sub-station of the grid system to which the Project is
electrically connected in accordance with applicable Grid Code.
3.11.5 The Solar Power Developer shall commission the Project within twelve (12) Months of
the date of signing of this Agreement, and delayed commissioning of the same is
subject to the penalties and incentives stated in Clause 3.12 and Clause 10.5.
3.12 Incentives for early commissioning
The Solar Power Developer will be paid an incentive by DISCOM for early
commissioning. The incentive will be paid as follows:
iv. Commissioning between 30 days and 59 days before Scheduled COD: Rs 1 lakh/MW
of capacity commissioned.
v. Commissioning between 60 days and 89 days before Scheduled COD: Rs 2 lakh/MW
of capacity commissioned.
vi. Commissioning before 90 days of the Scheduled COD: Rs 3 lakh/MW of capacity
commissioned.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 250
ARTICLE 4
METERING AND PROTECTION
4.1 The Solar Power Developer shall install main meter, check meter of static type 0.2
class accuracy of ABT Meters at the Interconnection Point. Also Solar Power Developer shall install stand by meter of same accuracy as per norms fixed by CEA/APERC/APTRANSCO. The main meter, check meter and stand by meter will each consist of a pair of export and import parameters with facility for recording
meter readings using meter recording instrument. For the purpose of uniformity, the Solar Power Developer shall follow metering specifications as developed by the DISCOM from time to time and as per Metering Code. The Solar Power Developer shall be responsible to enable remote monitoring of generation (providing of AMR modules
to the billing meters by Solar Power Developer).
4.2 All of the meters required to be installed pursuant to Clause 4.1 above shall be
jointly inspected and sealed on behalf of both parties and shall not be interfered with, tested or checked except in the presence of representatives of both parties and as per Metering Code.
4.3 The meter readings from the main meters will form the basis of billing. If any of the meters required to be installed pursuant to Clause 4.1 above are found to be
registering inaccurately the affected meter will be immediately be replaced.
4.4 Where the half yearly meter check indicates an error in one of the main
meter/meters beyond the limits for such meter but no such error is indicated in the corresponding check meter/meters, billing for the month will be done on the basis of the reading on the check meter/meters and the main meter will be replaced immediately. If both the main and check meters indicate an error beyond the limits,
billing for the month will be reconciled on the basis of the reading on the standby meter/meters, and the main and check meters will be replaced immediately.
4.5 If during the half yearly test checks, all the main meters and the corresponding check meters and standby meters are found to be beyond permissible limits of error, all the meters shall be immediately replaced and the correction applied to the
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 251
consumption registered by the main meter to arrive at the correct Delivered Energy for billing purposes for the period of one month up to the time of such test check,
computation of Deliv ered Energy for the period thereafter till the next monthly meter reading shall be as per the replaced main meter.
4.6 Corrections in Delivered Energy billing, whenever necessary, shall be applicable to the period between the previous monthly meter reading and the date and time of the test calibration in the current month when the error is observed and this
correction shall be for the full value of the absolute error. For the purpose of determining the correction to be applied to any meter registering inaccurately, the meter shall be tested under conditions simulating 100, 50, 20 and 10 percent load at unity power factor and 0.5 power factor. Of these eight values, the error at the load
and power factor nearest the average monthly load served at the Interconnection Point during the applicable period shall be taken as the error to be applied for correction.
4.7 If all the main, check and standby meters fail to record or if all/ any of the PT fuses are blown out, then the energy will be computed on a mutually agreeable basis for that period of defect.
4.8 The main, check and standby meters shall be tested and calibrated once in a
financial year utilizing a standard meter of 0.02 class accuracy testing meter
(“Standard Meter”). The Standard Meter shall be calibrated once in every year at the approved Laboratory by Government of India / Government of Andhra Pradesh, as per Terms and Conditions of supply. The testing of meters shall be carried out as per T.O.O (CE/Comml/APTRANSCO) Rt.No.537, dated.23.03.2010 (which is available in
APTRANSCO Website) issued by APTRANSCO scrupulously.
4.9 All main, check and stand by meter tests shall be jointly conducted by the authorized representatives of both the parties and the results and correction so arrived at mutually will be applicable and binding on both the parties.
4.10 On the Meter Reading Date of each month, meter readings shall be taken (and an acknowledgement thereof signed) by the authorized representatives of both parties.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 252
4.11 Within six (6) months, following the execution of this Agreement, the Solar Power
Developer and the APTRANSCO/DISCOM shall mutually agree to technical and
performance specifications (including, but not limited to, the metering configuration for the Project) concerning the design and operation of the facilities required to be installed by the Solar Power Developer in order for the Solar Power Developer to operate in parallel with the grid. Thereafter, any change in such specifications shall
be subject to mutual agreement of the parties.
4.12 The Project shall be operated and maintained in accordance with good and generally accepted fraudulent utility standards with respect to synchronizing, voltage, frequency and reactive power control.
4.13 Voltage regulation shall be such as to enable continued paralleling and synchronization with the network voltage at the point of interconnection.
4.14 The equipment of the Solar Power Developer shall be designed for fluctuations in the
frequency within limits of -5% and +3% of the standard frequency of 50 cycles per second.
4.15 The Solar Power Developer shall ensure that the power factor of the power delivered
to the DISCOM is maintained at or above the Minimum Power Factor as per Tariff Notification, or otherwise pay Surcharge as per Tariff Notification in force.
4.16 Any change in rupturing capacity of switch-gear, settings of the relays, etc., shall be subject to approval of the APTRANSCO/DISCOM.
4.17 As the Solar Project's plant may carry fault currents that may occur on the grid, the
Solar Power Developer shall provide adequate switchgear protection against such faults. The APTRANSCO/DISCOM is not responsible for damage, if any, caused to the Project’s plant and allied equipment during parallel operation of the plant with the
grid.
4.18 The Solar Power Developer shall make bonafied effort to operate the Project in such a manner so as to avoid fluctuations and disturbances to the APTRANSCO / DISCOM network due to parallel operation with the network.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 253
4.19 The Solar Power Developer shall control and operate the Project as per Prudent
Utility Practices. The APTRANSCO/DISCOM shall only be entitled to request the Solar
Power Developer to reduce electric power and energy deliveries from the Project during a System Emergency, and then only to the extent that in the APTRANSCO/ DISCOM’s reasonable judgment such a reduction will alleviate the emergency. The DISCOM shall give the Solar Power Developer as much advance notice of such a
reduction as is practicable under the circumstances and shall use all reasonable efforts to remedy the circumstance causing the reduction as soon as possible. Any reduction required of the Solar Power Developer hereunder shall be implemented in a manner consistent with safe operating procedures.
4.20 SLDC may instruct the Solar plant to back down generation on consideration of grid safety and security or safety of any equipment or personnel is endangered and solar plant shall comply with the same. For this, the Solar Power Developer shall provide Data Acquisition System (“DAS”) facility in compatible to SLDC Supervisory Control
and Data Acquisition (“SCADA”) system in consultation with SLDC for transfer of online information to concerned SLDC as per the clause No. 5.2.U of APERC Grid Code and IEGC 2010 & APERC Grid Code.
(i) SLDC may direct the Solar Power Developer to curtail its VAR /injection incase the security of grid or safety of any equipment or personnel is endangered.
(ii) During the Project start-up, the Solar Power Developer shall ensure that the reactive power drawl (inrush currents in case of induction plants) shall not affect the grid performance.
4.21 The Solar Power Developer shall ensure the connectivity standards applicable to the
solar generating stations as per the Central Electricity Authority (CEA) Regulations and its amendments thereto are adhered to.
4.22 The Project proponent will install necessary current limiting devices such as thyristors etc, if required. The project proponent shall provide protection system in compliance to grid code requirement for short circuit level, neutral grounding, current unbalance, limiting of harmonics, fault- clearing time etc. A generating unit
may be synchronized to the state grid system, when the project proponent has obtained permission for synchronization after meeting system requirements and such generating unit complies with Prudent Utility Practices.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 254
ARTICLE 5 BILLING AND PAYMENT
5.1 For the Delivered Energy purchased, Solar Power Developer shall furnish a bill to the DISCOM calculated at the Tariff provided for in Article 2, in such form as may be
mutually agreed between the DISCOM and the Solar Power Developer, for the billing month on or before the 5th working day following the Meter Reading Date.
5.2 The DISCOM shall be entitled to get a rebate of 1% of the total amount billed in any billing month for payments made before the Due Date of Payment. Any payment made beyond the Due Date of Payment, DISCOM shall pay interest at prevailing SBI bank rate and in case this rate is reduced, such reduced rate is applicable from the
date of reduction.
5.3 The DISCOM shall pay the bill on monthly basis as per Clause 5.1, by opening a one
month revolving Letter of Credit in favour of Solar Power Developer.
5.4 Letter of Credit: Not later than 30 days prior to the Scheduled COD of the
Generating Unit, DISCOM shall cause to be in effect an irrevocable revolving Letter of Credit issued in favour of Solar Power Developer by a Scheduled Bank (the “Letter of Credit”). Each Letter of Credit shall
(a) on the date it is issued, have a term of one month;
(b) be payable upon the execution and presentation by an officer of Solar Power Developer of a sight draft to the issuer of such Letter of Credit supported by a meter reading statement accepted and signed by both parties or a certification from Solar Power Developer that the DISCOM failed to sign the
meter reading statements within five days of the Meter Reading Date or that a supplemental bill has been issued and remains unpaid until the Due Date of Payment;
(c) In the absence any dispute regarding the claim provide that Solar Power Developer shall have the right to draw upon such Letter of Credit notwithstanding any failure by the DISCOM to reimburse the issuer thereof for
any draw made under; and
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 255
(d) not less than 7 days prior to the expiration of any Letter of Credit, the DISCOM shall provide a new or replacement Letter of Credit. Each monthly bill or
supplemental bill shall be presented at the said Scheduled Bank for payment under the Letter of Credit and shall become payable there under. The opening charges for Letter of Credit and Letter of Credit negotiation charges will be borne by the beneficiary Solar Power Developer.
(e) Letter of Credit should not be invoked for any disputed bill amount.
5.5 Direct Payment: Notwithstanding the fact that a Letter of Credit has been opened, in the event that through the actions of the DISCOM, Solar Power Developer is not able to make a draw upon the Letter of Credit for the full amount of any bill, Solar
Power Developer shall have the right to require the DISCOM to make direct payment of any bill by cheque or otherwise on or before the Due Date of Payment by delivering to the DISCOM on or prior to the Due Date of Payment of such bill a notice requiring payment in the foregoing manner. Without prejudice to the right of Solar
Power Developer to draw upon the Letter of Credit if payment is not received in full, the DISCOM shall have the right to make direct payment by cheque or otherwise of any bill such that within 30 days after the date of its presentation to the designated officer of the DISCOM, Solar Power Developer shall receive payment in full for such
bill. When either such direct payment is made, Solar Power Developer shall not present the same bill to the Scheduled Bank for payment against the Letter of Credit.
5.6 Billing disputes: The DISCOM shall pay the bills of Solar Power Developer promptly subject to the Clauses 5.1 and 5.2.
The DISCOM shall notify Solar Power Developer in respect of any disallowed amount on account of any dispute as to all or any portion of the bill. Solar Power Developer shall immediately take up issue with all relevant information with DISCOM which
shall be rectified by the DISCOM, if found satisfactory. Otherwise notify its (DISCOM’s) rejection of the disputed claim within reasonable time with reasons therefore. The dispute may also be decided by mutual agreement. If the resolution of any dispute requires the DISCOM to reimburse Solar Power Developer, the amount
to be reimbursed shall bear interest at prevailing SBI bank rate (Prime Lending Rate)
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 256
and in case this rate is reduced, such reduced rate is applicable from the date of reduction from the date of disallowance to the date of reimbursement.
5.7 All payments by the DISCOM to Solar Power Developer hereunder shall be made to such address as may be designated by Solar Power Developer to the DISCOM in writing from time to time.
5.8 Notwithstanding anything stated in this Article, the dispute of correctness or otherwise of the applicable Tariff, shall not be considered as billing dispute. Further
in the event, the Solar Power Developer is found due of any amount to the DISCOM either under this agreement or under any other transaction, the DISCOM/first party is entitled to recover the said due amount by adjusting from the bill amount payable to the Solar Power Developer .
Address : M/s. _________
Telephone : ______________
Fax : ______________
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 257
ARTICLE 6 UNDERTAKING
6.1 The Solar Power Developer shall be responsible:
(i) for proper maintenance of the Project in accordance with established Prudent Utility Practices.
(ii) for operation, maintenance, overhaul of the plant, equipment, works, switch yard and transmission lines and equipment up to the Interconnection Point of the Project in coordination with the APTRANSCO/DISCOM officials.
(iii) to furnish the generation and maintenance schedules every year, during peak and non-peak season.
(iv) for making all payments on account of any taxes, cess, duties or levies imposed by any government or competent statutory authority on the land, equipment, material or works of the Project or on the energy generated or
consumed by the Project or the Solar Power Developer or on the income or assets of the Solar Power Developer.
(v) for obtaining necessary approvals, permits or licences for operation of the Project and sale of energy to DISCOM there from under the provision of the relevant laws.
(vi) to comply with the provisions of the Grid Code. Notwithstanding any provision in this Agreement, the Solar Power Developer shall comply with the state Grid Code, dispatch practices, performance standard, protection
& safety as required as per the rules & regulations in force as applicable from time to time in the State of AP.
(vii) for achieving Commercial Operation Date within 12 months from the date of signing of the Agreement.
(viii) for seeking approval of APTRANSCO and DISCOM in respect of Interconnection Facilities with grid substation and synchronization of the Project with grid.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 258
(ix) to install new machinery/modules in the plant.
(x) The Solar Power Developer shall not dismantle and take away Project machinery and Interconnection Facilities during the Term of the Agreement.
(xi) To share Clean Development Mechanism (“CDM”) benefit with DISCOM as provided in CERC (Terms and Conditions for the Tariff determination from Renewable Energy Sources) Regulations, 2012, and as amended from time to
time, as indicated below:
(1) The proceeds of carbon credit from approved CDM Project shall be
shared between Solar Power Developer and DISCOM in the following manner, namely
a) 100% of the gross proceeds on account of CDM benefit to be retained by the Solar Power Developer in the first year after the date of commercial operation of the generating station;
b) In the second year, the share of the beneficiaries shall be 10% which shall be progressively increased by 10% every year till it reaches
50%, where after the proceeds shall be shared in equal proportion, by the Solar Power Developer and the DISCOM.
6.2 The DISCOM agrees:
(i) to make all reasonable efforts for making arrangements for evacuation of
power from the Project to be completed prior to the COD of the Project subject to Article 3.
(ii) for purchase of Delivered Energy from the Project as per Clause 2.2.
(iii) to co-ordinate with APTRANSCO and guide the Solar Power Developer in
obtaining approval for the interconnection facilities where the interconnection is at 33 kV or above voltages, for synchronization, commercial operation, regular operation etc., as required by the Solar Power Developer.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 259
ARTICLE 7 DURATION OF AGREEMENT
This Agreement is subject to para (5) of the Preamble and shall be effective upon its
execution and delivery thereof between parties hereto and shall continue in force from the
Commercial Operation Date (COD) and until the 20th anniversary that is for a period of
twenty years from the Commercial Operation Date (COD) or any mutually agreed time
period from the date of Commercial Operation (COD) subject to the approval of APERC
(“Term of the Agreement”). This Agreement may be renewed for such further period of
time and on such terms and conditions as may be mutually agreed upon by the parties, 90
days prior to the expiry of the said period, subject to the consent of the APERC. Any and
all incentives/conditions envisaged in the Articles of this Agreement are subject to
modification from time to time as per the directions of APERC. It is agreed that they are
bound by the competitive least Tariff that may be consented by APERC, at the request of
either or both the parties.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 260
ARTICLE 8 NOTICES
8.1 Except as otherwise expressly provided in this Agreement, all notices or other communications which are required or permitted hereunder shall be in writing and sufficient if delivered personally or sent by registered or certified mail, telecopy, telex or telegram addressed as follows:
If to the Solar Power Developer:
Attention : Mr. [Insert details of Solar Power Developer] : M/s. [Insert details of Solar Power Developer]
Telephone : [Insert details of Solar Power Developer] Fax : [Insert details of Solar Power Developer]
If to the DISCOM:
Attention : [Insert details of DISCOM] Fax No. : [Insert details of DISCOM] Telephone No. : [Insert details of DISCOM]
8.2 All notices or communications given by telecopy, telex or telegram shall be confirmed by depositing a copy of the same in the post office in an envelope properly addressed to the appropriate party for delivery by registered or certified mail. All notices shall be deemed delivered upon receipt, including notices given by
telecopy, telex or telegram regardless of the date the confirmation of such notice is received.
8.3 Any party, may by written notice, change the address and/or addresses to which such notices and communications to it are to be delivered or mailed.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 261
ARTICLE 9
FORCE MAJEURE 9.1 Definition of Force Majeure:
(a) “Force Majeure” shall mean any event or circumstance or combination of events or circumstances that materially and adversely affects the performance by either party (the “Affected Party”) of its obligations pursuant to the terms of this Agreement (including by preventing, hindering or delaying such performance), but only if and to
the extent that such events and circumstances are not within the Affected Party’s reasonable control and were not reasonably foreseeable and the effects of which the Affected Party could not have prevented by Prudent Utility Practices or, in the case of construction activities, by the exercise of reasonable skill and care. Any events or
circumstances meeting the description of Force Majeure which have the same effect upon the performance of any of the Solar Power Project setup in accordance with solar policy announced by GoAP under competitive bidding route and which therefore materially and adversely affect the ability of the Project or, as the case may be, the
DISCOM to perform its obligations hereunder shall constitute Force Majeure with respect to the Solar Power Developer or the DISCOM, respectively.
(b) Force Majeure circumstances and events shall include the following events to the extent that they or their consequences satisfy the above requirements.
i. Non Political Events such as acts of GOD including but not limited to any storm,
flood, Drought, Lightning, Earthquake or other natural, fire, accident,
equipment failure, explosion, strikes, labour difficulties, epidemic, plague or
quarantine, air crash, shipwreck, train wrecks or failure (“Non Political
Events”).
ii. Indirect Political Events such as acts of war sabotage, terrorism or act of public
enemy, blockades, embargoes, civil disturbance, revolution or radioactive
contamination (“Indirect Political Events”).
iii. Direct Political Events such as any Government Agencies’ or the DISCOM’s
unlawful or discriminatory delay, modification, denial or refusal to grant or
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 262
renew, or any revocation of any required permit or Change in Law (Direct
Political Events).
9.2 In the event of a delay in COD due to:
a) Force Majeure Events affecting the Solar Power Developer; or
b) any DISCOM Event of Default,
the COD and the date of expiry of the Agreement shall be deferred, subject to a limit of 12 months from the Scheduled COD, for a reasonable period but not less than ‘day for day’ basis, to permit the Solar Power Developer or DISCOM through the use of due diligence, to
overcome the effects of the Force Majeure events affecting the Solar Power Developer or DISCOM, or till such time such event of default is rectified by DISCOM.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 263
ARTICLE 10
EVENTS OF DEFAULT AND TERMINATION
10.1 Solar Power Developer Event of Default
10.1.1 The occurrence and continuation of any of the following events, unless any such
event occurs as a result of a Force Majeure event or a breach by DISCOM of its
obligations under this Agreement, shall constitute a Solar Power Developer Event of
Default (“Solar Power Developer Event of Default”):
(i) if (a) the Solar Power Developer assigns, mortgages or charges or purports to
assign, mortgage or charge any of its assets or rights related to the Project in
contravention of the provisions of this Agreement; or (b) the Solar Power Developer
transfers or novates any of its rights and/ or obligations under this Agreement, in a
manner contrary to the provisions of this Agreement; except where such transfer
• is in pursuance of a law; and does not affect the ability of the transferee to
perform, and such transferee has the financial capability to perform, its
obligations under this Agreement or
• is to a transferee who assumes such obligations under this Agreement and
the Agreement remains effective with respect to the transferee;
(ii) if (a) the Solar Power Developer becomes voluntarily or involuntarily the subject
of any bankruptcy or insolvency or winding up proceedings and such proceedings
remain uncontested for a period of thirty (30) days, or (b) any winding up or
bankruptcy or insolvency order is passed against the Solar Power Developer, or (c)
the Solar Power Developer goes into liquidation or dissolution or has a receiver or
any similar officer appointed over all or substantially all of its assets or official
liquidator is appointed to manage its affairs, pursuant to law,
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 264
Provided that a dissolution or liquidation of the Solar Power Developer will not be a
Solar Power Developer Event of Default if such dissolution or liquidation is for the
purpose of a merger, consolidation or reorganization and where the resulting
company retains creditworthiness similar to the Solar Power Developer and expressly
assumes all obligations of the Solar Power Developer under this Agreement and is in a
position to perform them; or
(iii) the Solar Power Developer repudiates this Agreement and does not rectify such
breach within a period of thirty (30) days from a notice from DISCOM in this regard;
or
(iv) except where due to any DISCOM’s failure to comply with its material
obligations, the Solar Power Developer is in breach of any of its material obligations
pursuant to this Agreement, and such material breach is not rectified by the Solar
Power Developer within thirty (30) days of receipt of first notice in this regard given
by DISCOM.
(v) the Solar Power Developer delays the commissioning of the Project by more than
4 months from the Scheduled COD, in which case the procedures of Clause 10.5 shall
be followed.
(vi) occurrence of any other event which is specified in this Agreement to be a
material breach/ default of the Solar Power Developer.
10.2 DISCOM Event of Default
10.2.1 The occurrence and the continuation of any of the following events, unless any such
event occurs as a result of a Force Majeure event or a breach by the Solar Power
Developer of its obligations under this Agreement, shall constitute the Event of
Default on the part of defaulting DISCOM (“DISCOM Event of Default”):
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 265
(i) DISCOM fails to pay (with respect to payments due to the Solar Power Developer
according to Article 5), for a period of ninety (90) days after the Due Date of Payment
and the Solar Power Developer is unable to recover the amount outstanding to the
Solar Power Developer through the Letter of Credit,
(ii) DISCOM repudiates this Agreement and does not rectify such breach even within a
period of thirty (30) days from a notice from the Solar Power Developer in this regard;
or
(iii) except where due to any Solar Power Developer’s failure to comply with its
obligations, DISCOM is in material breach of any of its obligations pursuant to this
Agreement, and such material breach is not rectified by DISCOM within thirty (30)
days of receipt of notice in this regard from the Solar Power Developer to DISCOM; or
(iv) if :-
• DISCOM becomes voluntarily or involuntarily the subject of any bankruptcy or
insolvency or winding up proceedings and such proceedings remain uncontested for a
period of thirty (30) days, or
• any winding up or bankruptcy or insolvency order is passed against DISCOM, or
• DISCOM goes into liquidation or dissolution or a receiver or any similar officer is
appointed over all or substantially all of its assets or official liquidator is appointed to
manage its affairs, pursuant to law,
Provided that it shall not constitute a DISCOM Event of Default, where such
dissolution or liquidation of DISCOM or DISCOM is for the purpose of a merger,
consolidation or reorganization and where the resulting entity has the financial
standing to perform its obligations under this Agreement and has creditworthiness
similar to DISCOM and expressly assumes all obligations of DISCOM and is in a position
to perform them;
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 266
or;
(v) If DISCOM is subject to any of the above defaults and DISCOM does not designate
another DISCOM for purchase of Solar Power.
(vi) occurrence of any other event which is specified in this Agreement to be a
material breach or default of DISCOM.
10.3 Procedure for cases of Solar Power Developer Event of Default
10.3.1 Upon the occurrence and continuation of any Solar Power Developer Event of Default
under Clause 10.1, DISCOM shall have the right to deliver to the Solar Power
Developer, with a copy to the representative of the lenders to the Solar Power
Developer with whom the Solar Power Developer has executed the Financing
Agreements, a notice stating its intention to terminate this Agreement (“DISCOM
Preliminary Default Notice”), which shall specify in reasonable detail, the
circumstances giving rise to the issue of such notice.
10.3.2 Within a period of seven (7) days following the expiry of the Consultation Period
unless the parties shall have otherwise agreed to the contrary or the Solar Power
Developer Event of Default giving rise to the Consultation Period shall have ceased to
exist or shall have been remedied, DISCOM may terminate this Agreement by giving a
written Termination Notice of thirty (30) days to the Solar Power Developer.
10.3.3 Subject to the terms of this Agreement, upon occurrence of a Solar Power Developer
Event of Default under this Agreement, the lenders may exercise their rights, if any,
under Financing Agreements, to seek substitution of the Solar Power Developer by a
selectee for the residual period of the Agreement, for the purpose of securing the
payments of the total debt amount from the Solar Power Developer and performing
the obligations of the Solar Power Developer.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 267
Provided that any substitution under this Agreement can only be made with the
condition that the selectee meets the eligibility requirements of RfS issued by
DISCOM.
10.3.4 The lenders may seek to exercise right of substitution under Clause 10.3.3 by an
amendment or novation of the Agreement in favour of the selectee. The Solar Power
Developer shall cooperate with the lenders to carry out such substitution and shall
have the duty and obligation to continue to operate the Project in accordance with
this Agreement till such time as the substitution is finalized.
10.4 Procedure for cases of DISCOM Event of Default
10.4.1 Upon the occurrence and continuation of any DISCOM Event of Default specified in
Clause 10.2 the Solar Power Developer shall have the right to deliver to DISCOM, a
Solar Power Developer Preliminary Default Notice, which notice shall specify in
reasonable detail the circumstances giving rise to its issue.
10.4.2 Following the issue of a Solar Power Developer Preliminary Default Notice, the
Consultation Period of sixty (60) days or such longer period as the parties may agree,
shall apply and it shall be the responsibility of the parties to discuss as to what steps
shall be taken with a view to mitigate the consequences of the relevant DISCOM Event
of Default having regard to all the circumstances.
10.4.3 During the Consultation Period, the parties shall continue to perform their respective
obligations under this Agreement.
10.4.4 After a period of seven (7) days following the expiry of the Consultation Period and
unless the parties otherwise agreed to the contrary or DISCOM Event of Default giving
rise to the Consultation Period shall have ceased to exist or shall have been
remedied, the Solar Power Developer shall be free to sell the Contracted Capacity to
any third party of the Solar Power Developer’s choice.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 268
Provided further that at the end of three (3) months period from the period
mentioned in this Clause 10.4.4, this Agreement may be terminated by the Solar
Power Developer.
10.5 Penalties in case of Delayed Commissioning
Under normal circumstances the Project has to be commissioned within 12 months
from the date of signing of this Agreement. In case of failing to achieve this
milestone, DISCOM shall encash the Bank Guarantee in the following manner:
a) Delay up to one month from Scheduled COD: 2 lakhs/MW of capacity not
commissioned.
b) Delay of more than one month up to two months from Scheduled COD: 3
lakhs/MW of capacity not commissioned.
c) Delay of more than two months up to four months from Scheduled COD: 5
lakhs/MW of capacity not commissioned.
d) Delay of more than 4 months:
i. In case of part commissioning, the Agreement shall be amended to reflect
the capacity that has been commissioned.
ii. Else, the Agreement stands terminated for unfulfilled obligation. For all
other cases of Solar Power Developer Event of Default, procedure as
provided in Clause 10.3 shall be applicable.
CPBG will be returned on COD. If commissioning does not happen within 15 months of signing this Agreement, the CPBG will be encashed.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 269
ARTICLE 11
DISPUTE RESOLUTION
11.1 Each party shall designate in writing to the other party a representative who shall be authorized to resolve any dispute arising under this Agreement in an equitable manner.
11.2 Following notice by one party to the other setting out the particulars of the dispute, if the designated representatives are unable to resolve a dispute under this Agreement within 15 days, such dispute shall be referred by such representatives to a senior officer designated by the Solar Power Developer and a senior officer designated by the DISCOM, respectively, who shall attempt to resolve the dispute within a further period of 15 days.
11.3 The parties hereto agree to use their best efforts to attempt to resolve all disputes arising hereunder promptly, equitably and in good faith and further agree to provide each other with reasonable access during normal business hours to any and all non-privileged records, information and data pertaining to any such dispute.
11.4 Failing resolution of the dispute in terms of the above provisions or even otherwise, any party may approach the APERC to resolve the dispute in terms of Section 86 (1) (f) of Electricity Act, 2003.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 270
ARTICLE 12
SPECIAL PROVISIONS
12.1 The waiver of any breach or failure to enforce any of the terms, covenants or conditions of this Agreement shall not in any way affect, limit, modify or waive the future enforcement of such terms, covenants or conditions.
12.2 No oral or written modification of this Agreement either before or after its execution shall be of any force or effect unless such modification is in writing and signed by the duly authorized representatives of the Solar Power Developer and the APTRANSCO/DISCOM, subject to the condition that any further modification of the Agreement shall be done only with the prior approval of APERC. However, the amendments to the Agreement as per the respective orders of APERC from time to time shall be carried out. All the conditions mentioned in the Agreement are with the consent of APERC.
12.3 However, in respect of power evacuation, the voltage levels for interfacing with grid will be as per Voltage of Delivery. The cost of Interconnection Facilities has to be borne by the Solar Power Developer as per Article 3.
12.4 The invalidity or unenforceability for any reason of any provision of this Agreement shall not prejudice or affect the validity or enforceability of any other provision of this Agreement.
12.5 The failure of any party to insist in one or more instances upon the strict performance of any of the provisions of this Agreement or to take advantage of any of its rights hereunder shall not be construed as a waiver of any such provisions or relinquishment of any such rights but the same shall continue in full force and effect.
12.6 Unless the context otherwise requires, every arrangement, procedure or any other matter which is, under any of the provisions of this Agreement, required to be mutually agreed upon between the parties, shall be concluded by a written Agreement between the parties not later than the date specified in the concerned clause of this Agreement, subject to the consent of the APERC.
12.7 This Agreement, including Schedule 1 attached hereto, constitute the entire agreement between the parties with respect to the subject matter hereof, and there are no oral or written understandings, representations or commitments of any kind, express or implied, not set forth herein.
12.8 The headings contained herein are included solely for the convenience of the parties and are not to be used as a basis for interpreting the various sections of this Agreement.
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 271
12.9 The parties each agree to act in good faith in implementing the terms and conditions of this Agreement and in carrying out their respective obligations hereunder.
12.10 In the event of the merger or re-organization of DISCOM, if the resulting entity is able to perform DISCOM’s obligations hereunder in no less a manner than DISCOM, the resulting entity shall take the right and responsibility for performance of DISCOM’s obligations.
12.11 In the event of the merger or re-organization of Solar Power Developer if the resulting entity is able to perform Solar Power Developer’s obligations hereunder in no less a manner than Solar Power Developer, the resulting entity shall take the right and responsibility for performance of Solar Power Developer’s obligations.
12.12 Assignment and Financing: Neither party shall assign this Agreement or any portion thereof to any third party without the prior written consent of the other party which consent shall not be unreasonably withheld.
IN WITNESS WHEREOF, the Solar Power Developer and the DISCOM have caused this Agreement to be executed as on the date and the year first set forth above.
For and behalf of
_________POWER DISTRIBUTION COMPANY
OF ANDHRA PRADESH LIMITED
WITNESS
1. By:
2. Its:
For and behalf of
M/s. WITNESS 1. By:
2. Its:
SOLAR RFS BID DOCUMENT
TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 272
SCHEDULE 1
Particulars of the Project
(referred to in the Preamble to the Agreement)
* Out of ______ MW, _____ is for Auxiliary Consumption and _______MW is for export to grid for sale to DISCOM.
*Note: Auxiliary Consumption of 0.1% is for for Solar PV and 10% is for Solar Thermal
SCHEDULE 2
Attach copy of Solar Power Policy announced by GoAP by competitive bidding route vide G.O.Ms No. 46 dated 27.11.2012.
SCHEDULE 3 Attach sanction copies of Solar Power plant, if any, from government authorities.
NAME OF THE PROJECT AND ADDRESS
LOCATION /EHT
SUBSTATION
33/11 kV SUBSTATION (IF
APPLICABLE)
TYPE OF PROJECT CAPACITY OF THE PROJECT (MW)
M/s. Solar Photo Voltaic/
Solar Thermal
1 | P a g e
Clarifications to the bidders for the queries on the “MODEL RFS BID
DOCUMENT” for grid connected solar power projects issued by APTransco
Issue Bidder Queries Response
No of bids that a
company can
participate in/Max
capacity that can be
bid
Can any company send in single RFS
for more than one station?
What is the maximum No. of
applications by a company?
The bidder can bid for any
number of locations.
The bidder should submit a
different bid for each location.
But, the bidder cannot submit
more than one bid for a particular
location.
What is the maximum capacity that
can be bid by a bidder?
The maximum capacity for a
bidder shall be limited to the
capacities specified for each
location.
The „Maximum Cumulative
Capacity that any bidder can bid
across locations should not exceed
200 MW
Bidder Selection Methodology of L1 computation. The lowest quoted tariff for each
location shall be considered as L1
for that particular location. Other
bids in that location shall not be
considered.
A single tariff for the entire
agreement period should be
quoted by the project developer
and no escalation shall be given.
Bidders should not be asked to match
the L1 price but power contracted at
the quoted tariff
L1 will be the successful bidder
for the location.
No other bidders in that location
will be considered
2 | P a g e
Will the tariff be modified later The tariff will not change over the
entire agreement period
Processing
Fee/EMD
When will the EMD of successful/
unsuccessful bidders be returned?
EMD will be returned to all
unsuccessful bidders within 15
days of issue of LOI.
For all successful bidders, EMD
will be adjusted against the
Performance Bank Guarantee
What is the EMD Amount? What is
the format for EMD BG?
EMD format will be enclosed in
the modified RfS
When should the processing fee be
paid? Is the processing fee applicable
to each bid or each bidder?
The project developer shall submit
non refundable processing fee of
Rs. 2 Lakh along with RfS for
each bid.
The processing fee will have to be
paid separately for each bid.
Performance Bank
Guarantee to be
replaced with
‘Bank Guarantee’
When should the performance bank
guarantee be submitted by the bidder?
The Bank Guarantee of Rs. 10
Lakh /MW has to be submitted at
the time of signing of PPA. Three
separate BG's shall be submitted
in the amounts of Rs. 2, 3 and 5
lakh /MW.
The bank guarantee is to ensure
timely completion of the project.
When should the contract
performance bank guarantee (CPBG)
be submitted by the bidder? When is
CPBG not required?
CPBG has to be submitted before
the LOI issue date.
If difference in price is less than
5%, then CPBG is not required.
The CPBG is to safeguard
APTransco against any non-
realistic bids.
3 | P a g e
When will the CPBG be encashed or
returned?
CPBG will be returned on the date
of commissioning.
It will be encashed if the plant is
not commissioned within 15
months from the signing of PPA
Should the bidder then submit
multiple BG's for various locations or
one BG amounting to the total
requirement? What about the
processing fee
Yes. The bidder has to submit
multiple bids for multiple
locations. The bidder also has to
submit multiple BG's and separate
processing fee for each bid.
Benchmark Price Mechanism and time schedule
associated with determination of
Benchmark Price - When shall the
benchmark price be announced?
Benchmark price shall be decided
after opening the bids. This price
will be determined by the
committee. This will be uniform
across all the locations.
Payment Security
Mechanism
Payment Security Mechanism has not
been included in the RfS Bid
Document.
One month revolving Letter of
Credit
Technology Can the SPD change PV technology
after signing PPA?
Yes - Change of technology is
allowed subject to CUF ceiling for
only solar related technology -
after signing the PPA
Local Content Mandate? No such provision exists
Are trackers allowed?
The PLF of 25% for solar PV with
trackers
Yes
4 | P a g e
CUF A ceiling CUF of 25% shall be
considered for PV modules.
A ceiling CUF of 25% CUF shall
be considered for Solar Thermal.
For the energy generation within
the ceiling CUF, the tariff
finalized for a location shall be
payable. For any energy
generation over and above the
ceiling CUF, a flat tariff of Rs 3
per unit for the entire period of the
agreement irrespective of the
location shall be payable.
Shareholding Change in shareholding pattern? Yes.
Can 4 companies form a consortium
with 25% stake each and in such case
who will be considered as lead
member?
Yes. It is for bidders to decide
about the lead member.
5 | P a g e
Penalty The Damages towards delay in
commissioning is for the Total
Capacity or the Capacity not
commissioned.
Damages are on the capacity not
commissioned
<1 month : Rs 2 lakh/MW of
capacity not commissioned
>1 month and <2 months :
Rs 3 lakh/MW of capacity
not commissioned
>2 month and <4 month: Rs
5 lakh/MW of capacity not
commissioned
>4 months :
In case of part
commissioning, the PPA
shall be amended to reflect
the capacity that has been
commissioned
Else, the PPA stands
terminated for unfulfilled
obligation
What is the penalty in case of less
than 80% of expected generation
No penalties for under generation
If shortfall in supply of electricity is
due to grid unavailability, developer
should not be penalized
In case of shortfall in supply due
to grid unavailability, the
developer will not be penalized
Performance
Acceptance
In page no 12, regarding COD it is
mentioned performance acceptance
tests, will you declare what are those
tests, who had to do, what are the
related standard clause?
Standard procedures of COD shall
be followed
Plant
Commissioning
Who will issue the Plant
Commissioning Certificate
Concerned SE/CE
6 | P a g e
PV based power plant should be
commissioned within 6 months of
signing PPA which is too aggressive
PV Plant should be commissioned
within 12 months of signing the
PPA.
However, there will be incentives
provided for early commissioning.
The incentive to be paid is as
follows:
9 to 10 months : Rs 3
lakh/MW of capacity
commissioned
10 to 11 months : Rs 2
lakh/MW of capacity
commissioned
11 to 12 months : Rs 1
lakh/MW of capacity
commissioned
Plant commissioning proof to be
submitted to DISCOMS,
APTRANSCO one month before the
Commissioning date
Notice for readiness of the plant
for commissioning shall be given
at least one month before the
COD.
PPA Draft PPA to be provided along with
invitation for RfS
Yes. A copy of draft PPA shall be
provided along with invitation for
submission of RfS
Is the PPA for 25 years irrevocable? Yes, PPA holds good for entire
agreement period. The agreement
period will be for 20 years.
After termination of PPA, can the
developer still be connected to the
grid and sell power on a merchant
basis
No mid-course termination of
PPA is allowed. However, on
expiration of PPA, the First right
of refusal of the power shall
remain with Discoms
Land and Water Water Requirement not asked for Responsibility of water lies with
the developer.
7 | P a g e
When should details of land
ownership be provided
No land details are required to be
submitted.
Financial Criteria Ambiguity prevails regarding the
submission of audited financial
records is for the last 4 years or 1
year.
The company is required to
submit annual audited accounts
for the last four financial years (or
if the period of existence of the
Company is less than four Years,
then starting from the year of
incorporation) indicating the year
which should be considered for
evaluation along with a net worth
certificate from a Chartered
Accountant
Evacuation and
Connectivity
Shall developer bear the cost related
to transmission, evacuation etc
Yes. The bidder shall bear all
responsibilities and costs
associated with transmission,
evacuation, right of way, bay
extensions etc.
Financial Closure Too optimistic to expect financial
closure within 60 days of signing
PPA
Financial closure within 180 days
from the date of signing of PPA
Timelines RfS states technical and financial bid
would be opened on the same day but
financial bids of only shortlisted
bidders would be opened
Technical bid will be opened first
and the financial bids will be
opened subsequently for the
successful technical bids
What is the date of bid submission 30 days from the modified RfS
date
Miscellaneous Payment to bidder in case grid
network is unavailable to accept the
power
Maximum care will be taken by
APTRANSCO for availability of
transmission network. Since
APTRANSCO is not levying any
penalty for under-generation, no
penalty shall be paid by
APTRANSCO in case of non
availability of grid network.
8 | P a g e
Allocation in case of two bidders
quoting same price, both L1
Bidders shall both be awarded the
project subject to maximum
capacity per location.
In case the maximum capacity at
the location is exceeded, then the
prorated capacity shall be awarded
in the ratio of offered capacity by
the bidders.
Taxes, Duties, Cess, Accelerated
Depreciation and other Special
Incentives/Costs
It is the bidder‟s responsibility to
account for all incentives/costs
granted to renewable energy
projects.
Connectivity at the 11 KV level is
allowed?
No.List of substations has been
provided and connection is only
allowed to substations in the list
Can a bid be made for locations other
than those specified?
No
Does the bidder pay for the
connectivity application processing
fee also?
No
Is the project capacity mentioned an
AC capacity or DC capacity?
The capacity is considered as AC
capacity
What are the statutory clearances
required to be obtained by the bidder?
List of necessary clearances
should be obtained and
responsibility lies with the
Developer.
Is the interconnection point at
substation the bus bar or C&R panel?
Busbar
Is the developer allowed to take a
separate auxiliary power connection
for the project?
No.
9 | P a g e
Why is number of responses limited
only for a “Company” and not for
“firm/society/association”? Does this
mean that a firm/society/association
can submit alternate bids in the same
location?
Can one person float a company and a
firm and bid in the name of company
and firm for the same location?
Wouldn‟t that be alternate bids for
same location and violate the spirit?
The bid criteria will applicable to
all bidders. Please refer modified
RFS
If for suppose at a substation if before
the bidding process, if there is a
private developer who is setting up a
power plant on the rec mechanism,
who would be given the first
preference to inject the power in to
the grid, is it going to be the
successful bidder or the private
developer on the rec route.
Both are independent schemes and
will not be linked with each other.
This bidding process is meant for
selection of developers for setting
up solar capacity under the PPA
route under competitive bidding
route with APDiscoms for each
location
What if separation of State happens
after PPA
It will be accordingly addressed
then in the PPA
The capacity mentioned to generate
solar power as per annexure - A is it
installed capacity or solar power
generated capacity which is about
20% PLF on installed capacity.
Installed Capacity
10 | P a g e
It has been understood that at a given
substation, even if I am the lowest
bidder, my bid price is higher than the
bench mark figure I have to go with
the bench mark figure or have to quit.
In this case will I be refunded my BG
and application fees as I was the
lowest bidder in this scenario but was
not happy with the bench mark figure.
Yes I understand that if multiple
bidders are there then I would be
automatically refunded the amount
but here what if I am the only
bidder at that substation?
Processing fee will not be
refunded.
As per Section 2, under the definition
of COD, it is stated that “Solar Power
Producer shall not declare a
generating unit to be operationalize
until such generating unit has
completed its performance acceptance
test as per standard prescribed”. What
is the standard since it has not been
prescribed anywhere?
Procedures of COD will be
applicable.
As per clause 3.5-C, The bidder is
required to undertake to furnish
evidence of meeting commercially
established solar PV technology.
What sort of evidence required in
this?
Evidence of one year completion
of successful operation in India
will have to be provided.
11 | P a g e
The Rajasthan Electricity Regulatory
Commission (RERC) had tried to
bring in regulations for RE based
Power Projects for competitive
bidding. The Commission backed out
on this front as it was in conflict with
the provisions of Electricity Act,
2003, Section 63 which is as given
below. You may have a look at the
RERC website for the order issued by
the RERC on this issue.
This is an order issued by the
RERC. APDiscoms will file with
APERC
What would be the legal status of the
Committee who will decide the tariffs
for awards as only the Commission
has the right to award the tariff as per
regulations. Even, the Government
does not have the authority to
determine the tariff as per Electricity
Act, 2003. So, how come tariffs
decided by the Committee will be
accepted as it does not have any legal
authority or the legal sanctity.
The benchmark tariffs to be
determined by the committee will
be used only for comparison of
competitiveness of the tariffs
received in the bid process
Does capacity limit at a substation
refer to Transformer Capacity of
“Proposed Anticipated Generation”?
This limit is the maximum
injectable capacity of the
particular sub station as per
system studies.
What are the provisions for
Compensation/Termination in case of
Force Majeure?
This will be as per the PPA
12 | P a g e
In sub-clause (b) it is mentioned that
the Developer has to do O&M of
power evacuation line also. Does this
mean that if a developer chooses to
build the transmission line on his own
then he need not pay any supervision
charges? In our limited knowledge we
understand that supervision charges
are collected as certain % of capital
cost because once the line is built the
line is handed over to concerned
licensee and the O&M is then taken
care of licensee. Please clarify if our
understanding is incorrect.
The SPD has to pay all relevant
charges according to procedures
of APTRANSCO/ DISCOM
GOVERNMENT OF ANDHRA PRADESH ABSTRACT
Energy Department - Purchase of solar power by DISCOMs Policy- orders – Issued.
ENERGY (RES-A1) DEPARTMENT G.O.Ms. No. 46 Dt.27-11-2012. Read the following.
1. G.O.Ms. No. 39, Energy (RES-A1) Department, Dt. 26-09-2012.
2. G.O. Rt. No.1663, G.A (Cabinet) Deptt, dt 16-04-2012. *******
ORDER: State Government have issued policy guidelines vide G.O 1st read above for production of Solar Power by Private developers for captive use and sale to third party within the state and also for sale of Solar Power to DISCOMs at pooled cost. However, there was no provision for sale of solar power to DISCOMs at regulated price.
2. Group of Ministers was constituted vide G.O 2nd read above to suggest ways to encourage the generation of Power through non- Conventional sources including Solar in view of the prevailing power deficit in the State. Group of Ministers after detailed deliberations has recommended various actions and one of the recommendations regarding encouraging generation of solar power is purchase of solar power by APDISCOMs from the developers at a price to be determined through a process of competitive bidding. Group of Ministers also recommended that State should plan for setting up of 2000 MW of solar power plants under this route with a condition that 1000 MW plants will be set up before June, 2013. DISCOMs would list out industries who are willing to purchase solar power at the rate decided through the process of competitive bidding. However, incase all the procured solar power is not utilized by the willing industries, the State Government would bear the financial burden arising out of purchase of such solar power.
3. Government after careful examination of the recommendations of the Group of Ministers order as follows:
(i) DISCOMs will ensure that 1,000 MW of Solar Power Plants is set up before June,2013.
(ii) DISCOMs shall select Solar Power developers through the process of competitive bidding.
(iii) DISCOMs should include the cost of Solar Power in their filing with APERC. To the extent not covered by tariff the extra cost to be recovered through sale to the industries at the rate at which it is procured.
(iv) DISCOMs will prepare the list of industries willing to purchase such solar power at the rate arrived through process of competitive bidding. State Government will finance the differential cost over and above the rate fixed by APERC (or pooled cost till the rate is decided by APERC) for the purchase of solar power by DISCOMs over and above power not purchased by the Industries.
Cntd. P.2
-2-
4. CMD, APTRANSCO will conduct bidding process duly notifying 132/33/11 KV sub-station near which developers can develop their solar power unit to facilitate easy evacuation. Solar developers would be required to offer their bids and quantum of power proposed to be sold to the DISCOMs at the notified locations. 5. CMD, APTRANSCO will develop bidding document for selection of developers through the process of competitive bidding. The bidding document should contain provision to check non- serious bidding or frivolous bids. The bidding time should be appropriately decided to ensure wider participation and there shall be a pre- bid conference to hear the points or difficulties of potential bidders for addressing them in a suitable manner before final bid is received.
6. Chairman, APPCC, CMD, APTRANSCO are requested to take necessary action accordingly.
7. This issues with the concurrence of Finance Department vide their U.O.No 213/PF.I/2012: dt. 24-11-2012. (BY ORDER AND IN THE NAME OF THE GOVERNOR OF ANDHRA PRADESH) MRUTUNJAY SAHOO
PRINCIPAL SECRETARY TO GOVERNMENT
To
The C&MD AP TRANSCO, Hyderabad. The C&MD of All DISCOMs The VC&MD, NREDCAP. The MD. AP GENCO The Secretary to APERC The PFS/ PFS(IF)/PFS(R& E) Copy to: P.S to Secretary to Hon’ble C.M. P.S to Hon’ble Minister for Finance. P.S to Principal Secretary to Government, Energy. P.A to Special Secretary to Government, Energy. S.F/SC ( C.No.4244/RES-A1/2012)
// FORWARDED: BY ORDER//
SECTION OFFICER