splost 2 forensic report
TRANSCRIPT
-
7/31/2019 SPLOST 2 Forensic Report
1/52
-
7/31/2019 SPLOST 2 Forensic Report
2/52
DeKalb County School SystemSPLOST Forensic Program Review
Table of Contents
Confidential 6/01/2006
Section
I
I-A
I-B
IV
IV-C
IV-D
IV-E
V
V-A
V-B
V-C
V-D
V-E
V-F
V-G
V-H
V-I
VI
2
3
4
5
Section Description
The SPLOST Program and PartiesThe Program and Budget Process
The Parties
Scope of Work
Findings and Conclusions-Executive Summary
Findings and Conclusions-Detailed Discussion
Perceptions of Problems with the SPLOST11Program-Change Orders and Management with Heery-Mitchell
Understated Needs Assessment Levels and Approval ofProjects by the Board
Heery Mitchell Contract Files and Performance
Allocations of Funding to Clusters and Projects
Southwest DeKalb High School-What Happened and How itCould Have Been Avoided
Other Observations
Selection of Individual to Run the SPLOST Program onBehalf of DCSS
Selection and Approval of Contracts
Audits
Close Outs
Punch List and Repair Work
Contract Administration
Change Order Review
Contract Administration
Other Contract Administration Issues
Recommendations
Criteria for Capital Expenditures
Needs Assessment Process
Priority of SPLOST Projects
Cluster Elementary School
DCSS Interface Representative for
Page
2
2
7
8
9
13
13
16
22
29
33
33
34
34
3 5
35
35
36
38
39
42
42
42
43
43
43
-
7/31/2019 SPLOST 2 Forensic Report
3/52
County School SystemSPLOST Forensic Program Review
Table of Contents
Confidential 6/01/2006
48
48
48
48
49
15
16
17
18
19
Budget and StatusReporting forMajorCapital Projects
MoreFormal ProjectApproval Process
EvaluationofExistingContract Language
Financial OversightbyDCSS
Best PracticesForum
-
7/31/2019 SPLOST 2 Forensic Report
4/52
Celebrating 25 Years
June 1,2006
Dr. LewisSuperintendentDeKalb County School System
3770 North Decatur RoadDecatur, Georgia 1099
Dear Dr. Lewis:
Rubino in conjunction with PMA Consultants
(hereinafter, has completed our effort related to those tasks
outlined in our proposal to County School System of
December 27, 2005 (as subsequently modified based on issues identified
and information gathered and reviewed) concerning SPLOST11
(or, theProgram). (This effort was described as Phase I in the proposal). In the
following pages and Attachments, we have presented our conclusions
based on the information reviewed and the discussions and interviews with
DCSS representatives and other individuals (identified further).
The report has been organized to include discussions relating to the
following issues and areas:
An overview of the SPLOST program;
An explanation of the various parties in the SPLOST
Program process;
A discussion of the work performed by including
a listing of the 16 construction projects sampled;
A summary of interviews conducted;
Summaries of budget and actual cost amounts for the SPLOST
11program;
A discussion of the growth in the SPLOST program from the
initial assessment timeframe to the current time,
and reasons for the increases;
Confidential Page 1 June 1,2006
Member, Worldwide Professional
-
7/31/2019 SPLOST 2 Forensic Report
5/52
County School System SPLOST Forensic Program Review
A summary of the provisions of the contract between the Program Manager (PM),
Heery-Mitchell, a Joint Venture (HM) and DCSS, and an assessment as to the
information contained in the HM files relating to its performance in accordance with
these provisions;
A discussion of the South West DeKalb High School (SWD) renovation project;
Comments as to the process used on SPLOST11 for professionals
selection and the results of the changes to the contracts for select contract
reviewed by
Recommendations arising from our review and conclusions.
I. THE SPLOST PROGRAM AND PARTIES
A-The Program and Budget Process
The Special Purpose Local Option Sales Tax ("SPLOST 11") program represents the
second phase of the one percent local sales and use tax levied within DeKalb County for twenty
quarters beginning on July 1, 2002. Under the passed by DeKalb County
voters on March 19, 2002, the sales and use tax proceeds are earmarked primarily for thefollowing DCSS Capital Outlay Projects:
a. Property acquisition, construction and equipping of eight new schools and two
new centers,
b. Renovations, modifications, additions, and equipment for existing county schools,
and
c. Acquisition and installation of information systems, hardware and infrastructure
at all schools and selected other facilities.
The SPLOST 11 budgeting process started with the program management firm
which had been engaged by DCSS for the SPLOST I program, conducting a comprehensive
Needs Assessment (NA). The purpose of the HM assessment was to evaluate and identify the
Confidential Page 2 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
6/52
County School System SPLOST Forensic Program Review
capital improvement, technology and transportation needs in the late time period for
evaluation purposes for the SPLOST11 In total, identified approximately $1.15
billion in capital requirements for the assessed areas. In contrast, at the time of the start of the
SPLOST11Program, the Sales and Use tax collections were estimated at plus Georgia
DOE funding and interest of another (after the use of of advanced funding for
SPLOST I projects), for a total of approximately This resulted in assessed needs that
were considerably in excess of anticipated SPLOST11collections.
Due to the variance between collections and total assessed needs, the School Board was
presented with a preliminary prioritization and budget for all potential SPLOST 11 projects on
June On June 10,2002, the Board of Education (BOE, or the Board):
Approved the SPLOST11Capital Outlay priority list of Phase projects totaling
$325,433,078 to allow for the immediate planning and development of new schools,
renovations, technology and transportation improvements.
Authorized the Superintendent and Staff to utilize funding in the amount of
to plan and develop new schools and centers, classroom additions,
renovations and property acquisitions described as Phase
In total, the June 10,2002 actions by the DCSS BOE approved funding in the amount of
$430,833,078 for those projects, prioritized as a part of the needs assessment as Phases and
(See attached Schedule I for summary of the amounts and dates of Board approval actions.)
In addition, DCSS had identified approximately of Program contingency4. The NA
estimates supporting the Board authorized amounts included costs of the following types:
SPLOST I Capital Improvements and Capital Improvements Needs Assessment - revised 18/01makes no comment as to the appropriateness of utilizing of SPLOST funding for SPLOST I projects
SPLOST Capital Improvements Preliminary Prioritization and Budget -MayA review of SPLOST Board actions does not indicate any direct Board action or consent item specifically
approving program contingency but contingency amounts are shown on documents supporting board minutesbeginning on September At the September Board meeting, the board approved the allocationfrom contingency to balance the cost increases incurred on several projects. The contingency balance prior to thataction was $24.6 million as listed above.
Confidential Page 3 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
7/52
County School System SPLOST Forensic Program Review
Architect and Engineering Fees
a Construction Cost for New Construction, Additions, and Renovations
Furniture, Fixtures Equipment
Land Costs
Program Management Fees
Technology Upgrades
Transportation Improvements
Other Miscellaneous Costs
The other miscellaneous cost category included a pool of costs that were estimated as a
part of the needs assessment process for individual project cost contingencies and estimated cost
escalation.
Contingencies were included in each of the projects that we reviewed at a rate of five
percent (5%)of all estimated project costs. Typically, cost contingencies are used for a variety
of purposes. Cost contingencies of this nature are typically used to address cost growth related
to design and scope changes, as well as expected and unforeseen change orders that occur during
the actual construction of the respective
An additional cost pool for escalation was included in the Other Miscellaneous cost
category. A seven and one half percent escalation factor was also added to all estimated costs.
Escalation allowances of this nature are normally used to plan for cost increases during the life of
a project or program primarily for price increases resulting from inflation. Generally speaking,
the size of the escalation factor largely depends on the duration gap between the time that a
project is being estimated and the construction mid-point. Obviously, the longer the time period
between the estimation date and the actual construction period, the higher the effective escalationrate will be.
The Construction Management Association ofAmerica's Standard ofpractice defines Contingency as"An amount ofmoney reserved by the Owner to pay for unforeseen changes in the work." ...
Confidential Page 4 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
8/52
County School System SPLOST Forensic Program Review
On May 12, 2003, the Board provided a second grouping of SPLOST 11 authorizations.
This Board action is known as the "Next Steps" funding allocation. Under the Next Steps
funding allocation, the Board authorized the Superintendent and staff to:
Utilize anticipated funding in the amount of $92,726,270 to bring the funding
allocation for each respective DeKalb County Cluster to 40%of the Cluster's ten year
assessed needs. In essence, the Clusters were given the 40% allocation, and given the
opportunity to decide how to spend those funds
Utilize anticipated funding from the State Reimbursement Program to develop the
following projects:
o Stephenson Large School Model-Additional project funding of $4,903,200
o New Peachtree Middle School Model - Additional Anticipated Funding
o New High School Career Technology Additions - Additional Funding of
o Renovate Restrooms at all schools beyond the funding already approved under
Phase 1-
Additional Funding $16,800,000
The Next Steps Board action added approximately $135.1 M to the Program, or a revised
total of approximately before Program contingency. The Board subsequently
approved certain other budget adjustments in June 2003, November 2003 and June based
on recommendations from the SPLOST team. These actions addressed the Model, the
Sexton Woods Relocation, and Emergency HVAC projects, and authorized an additional
in Board approved funding. As evidenced in Schedule I, the total Board
authorization for specific SPLOST projects totaled $586,527,543, before program
contingency. In addition to the amounts approved for specific projects, an additional
of SPLOST program contingency was identified6. During the 2003 through 2005
A review ofSPLOST Board actions does not indicate any direct Board action or consent item specifically
approving program contingency but contingency amounts are shown on documents supporting board minutes
Confidential Page 5 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
9/52
County School System SPLOST Forensic Program Review
time period, a number of additional SPLOST board actions addressed SPLOST project and
program budgets, with the majority of these actions geared toward the re-allocation of funding
from contingency to projects that were in an overrun status in comparison to the originally
approved project amounts. Accordingly, the total Board approved program budget at February
2006 stood at $61 (See Schedule I), and, as of December 6,2004, virtually the entire original
contingency amount of had been reallocated to projects with cost growth and overruns.
As mentioned above, anticipated SPLOST11 tax collections were estimated at
at the inception of the SPLOST program, which, with the Georgia DOE match, totaled
of total revenue. As of April 2006, total SPLOST tax collections and other revenue were
estimated at $494 million, or an amount in excess of $115M below the $61 that the Board had
approved for specific projects and contingency.
Given that the estimated available program funding was at levels less than the $61 of
approved projects and contingency, DCSS SPLOST 11 Program personnel separated the school
projects into"Above the Line" (AL) and "Below the Line" (BL) categories, with the schools
slated for implementation initially, and the BL schools only being implemented as funds would
allow. The DCSS Board minutes, however, do not clearly address the issue of the approved
projects being subject to funding, as discussed further. As of April 2006, the total wasapproximately while the BL total was As discussed further, changes were
often made from AL to BL to address growth in the AL projects in process, such that many of
the schools that were assuming completion of their new schools or renovation efforts have now
slipped to a BL category either in total, or with respect to certain deferred aspects of the work.
In reviewing the evolution of the budget process and amounts, the June 10, 2002 Board
Approved Phase projects (which totaled with contingency, as referenced
above) were within the total estimated revenue projection, and would have logically been viewed
at the time by the community and other interested parties as the AL projects, even though those
terms were not used at that juncture.
beginning on September At the September Board meeting, the board approved the allocationfrom contingency to balance the cost increases on several projects. The contingency balance prior to thataction was$24.6million as listed above.
Confidential Page 6 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
10/52
County School System SPLOST Forensic Program Review
B-The Parties
The SPLOST 11 Program oversight rests with the DCSS Board of Education. As such,
the Board is responsible for approving contracts and change orders in excess of certain limits,
approving new school and renovation projects, and for directing the prioritization of the various
projects.
DCSS designated Dr. Stanley Pritchett as the Associate Superintendent of Business
Affairs and Plant Services in 1996. In this capacity, Dr. Pritchett served as the DCSS
representative in charge of both the SPLOST I and SPLOST programs until October at
which time he was replaced by Mrs. Patricia Pope. Dr. Pritchett was the DCSS interface with
and was also responsible for the recommendations to the Superintendent with respect to
selection and, in conjunction with HM, for the selection of contractors to perform the
various school construction projects. Dr. Pritchett and HM were responsible for making
recommendations to the Board relating to project selection and prioritization. has been the
PM since January 1998.
During the performance of SPLOST 11, DCSS had the following Superintendents of the
School System:
Dr. James Hallford, from the start of SPLOST to June
Dr. Johnny Brown ,from July to October
Dr. Lewis, from October to the present
Approximately twenty five major Contractors and twenty one Architect
Engineering firms have received contracts for work on the SPLOST 11 Program, and many of
these contracts will be discussed further.
Confidential Page 7 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
11/52
County School System SPLOST Forensic Program Review
SCOPE OF WORK
The original scope of work was established in our discussions with DCSS,
and outlined in general in our proposal of December 27, 2005. The proposed areas of review
were incorporated into our contract with DCSS dated January 9, 2006. In summary, we were
asked to review the general issue of the growth of the SPLOST budget and resulting change
orders issued to contractors, in an attempt to determine and explain the reasons for increases in
the Program cost, which has led, in large part, to differences in the original Board-approved
project list and those projects actually scheduled to be completed. As part of our effort, the
County was interested in assessing the level and adequacy of documentation and support in the
PM's files for the entitlement and pricing aspects of various changes to the construction and
ARCHITECT contracts. In addition, we were asked to review the PM's files for information
with respect to reports and schedules for the Program that were required under the PM's contract.
As we commenced our work, we decided to conduct a broad range of interviews,
including Board members, other individuals suggested to us by DCSS, and individuals who
contacted us to give their perspective. Those interviews raised certain other issues not
specifically discussed and contemplated at the time of our original engagement, as discussed
further. More specifically, we conducted interviews with representatives, as well as withDCSS employees, legal representatives, and other interested parties. In Attachment A, we have
included a listing of the individuals that we held conversations with during the performance of
our work. All of the DCSS Board Members were invited to participate in our interview process.
In Attachment B, we have listed the information reviewed as part of our assignment, including
certain schools where we conducted site visits, and in Attachment C, we have included a
summary of certain references and publications that we have considered as part of our
conclusions and recommendations.
As part of the approach to the engagement, we realized that it was neither economically
feasible nor necessary to review every school project in the Program. Therefore, we selected all
Program projects with an underway budget of over These projects are listed in Attachment
D, along with information as to the ARCHITECT firm and contractor selected for the projects,
Confidential Page 8 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
12/52
County School System SPLOST Forensic Program Review
and the type of method guaranteed maximum price, lump sum, etc.) used
by the County for each construction contract.
As discussed further, our initial review or the HM files relating to the issue of the level of
documentation prepared and maintained for the individual projects resulted in our conclusion
that HM had not consistently documented its conclusions as to the entitlement as to most of the
change orders on the Program, nor had it consistently summarized the effort that it had
undertaken, or its basis for its recommendation as to the pricing and ultimate amount of the
subject changes. Instead of being in a position of reviewing conclusions and
determining, on a sample basis, our reactions to the level of support for those entitlement and
pricing reviews (as contemplated at the outset of our engagement), we concluded that there was
no Program-wide approach for such reviews by HM, and reviewed the sample project files
(discussed further) to confirm that this conclusion was appropriate. In conjunction with DCSS
representatives, we concluded that it was more beneficial to review all of the larger project files
during our Phase I effort rather than selecting just one or two contracts and reviewing the
entitlement and pricing basis for the individual change orders in more depth.
Our interface with DCSS was with the Superintendent of Schools, Dr. Lewis,
his administrative assistant, Ms. Deborah Loeb, and the Chief Financial Officer, Rick Cost. Wealso met on numerous occasions with Mrs. Patricia Pope, and received information from her and
her staff. Our work was performed independently, and our conclusions are not necessarily those
of the Superintendent or other DCSS employees. Since the time period for our Phase I review
was limited, our review was somewhat summary in nature, especially with respect to certain
issues arising out of the interview process that were not contemplated within our original scope
of work for Phase I.
FINDINGS AND CONCLUSIONS-EXECUTIVE SUMMARY
As mentioned above, the original budget for the SPLOST program was approved by
the Board in June of 2002, and outlined of specific projects in two groups, Phase and
Confidential Page 9 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
13/52
County School System SPLOST Forensic Program Review
Current projects approved to date total inclusive of contingency which was
originally established at a total of approximately and which has now been eroded with
cost overmns on existing contracts. Against this schedule of school projects that have been
approved is projected revenue of leaving a shortfall of over $1 if all projects on the
list are considered.
During the course of our review, the major problems identified to by DCSS
representatives and others interviewed were:
Overmns on the various projects, such that the contingency for the Program has
basically eroded in its entirety;
Constant requests by the SPLOST Group, including for the Board to approve
change orders to the construction contracts;
Shifting of priorities of the various programs, such that schools that were scheduled
for completion as part of the original budget will not be completed with SPLOST11
funds, and others that were not part of the originally approved budget have become
higher priority, and will be completed;
A lack of appropriate Program management and oversight by Group,
that may have caused or contributed to the aforementioned problems.
In summary, the following are our major conclusions relating to these and other issues
that arose during our review. In Sections and V of this report, a detailed discussion of each of
these issues, as well as comments relating to other findings and conclusions, is included. In
Section VI, we have included 19 specific recommendations for the Board to consider as part of
its improvements in its capital construction programs.
contract with DCSS was a comprehensive Program Management
contract and imposed many requirements on HM in terms of scope and
contract deliverables that are necessary to manage a program of the SPLOST11
size. Based on our review of the HM files and our conversations with and
DCSS personnel, it was apparent that HM did not, in many cases, fulfill its
Confidential Page 10 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
14/52
County School System SPLOST Forensic Program Review
contractual obligations nor manage the Program in accordance with the terms
of its contract. Details of these issues are presented in Sections and V.
Based on the records reviewed, DCSS did not properly oversee
performance. We did not observe written DCSS communication to of its
performance deficiencies until the middle of2004.
The selection of an individual with no construction experience prior to
SPLOST, to be the DCSS point person for the Program, (which included the
role of oversight of HM), was not in the best interests of DCSS. This role
should have been filled by someone with construction experience.
The DCSS Board should not have approved $61 in projects, as it gave the
public the sense that the projects listed would be completed with SPLOST
funds, which is clearly not the case. It is unclear as to whether or not the Board
was briefed in sufficient detail by and the DCSS staff when approving the
projects.
The original Needs Assessment (NA) estimates for the individual projects wereunderstated in relation to subsequent contract actions. Part of the reason for
the inadequacy appears to result from insufficient project contingency and
escalation factors.
and the DCSS staff should not have recommended, and the Board should
not have approved, an allocation of funds on a percentage basis to the
individual County clusters 40% of the total NA levels), as it allowed for a
mechanism that appears to deviate from overall County needs and contributed
to the impression of a capital allocation process that was political in nature.
Once original estimates were coming in higher than the budgeted levels
established in the NA, HM should have re-baselined the entire Program to
Confidential Page 11of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
15/52
County School System SPLOST Forensic Program Review
present a more realistic budget for the schools that were prioritized as part of
the original budgets. This would, in all probability, have avoided much of the
continuing controversy relating to the shifting of priorities for each school, the
deferral of certain work on existing projects, and the need to the Board to be
dealing regularly with changes to the construction contracts.
Under current Board policy, the selection decision for awarding contracts to
firms for SPLOST rests with the Superintendent, and
does not require Board approval. Until recently, there was no documentation
as to the basis for the evaluation and award of such contracts by the DCSS staff
assigned this task by the Superintendent. This approach was in accordance
with Board policy, but should be modified, as the level of contracts that
DCSS is awarding with the advent of SPLOST warranted a more formal
selection and approval process that is clearly disclosed, transparent to the
public and approved by the Board.
NeitherHM nor DCSS representatives have audited the contractors performing
work under cost type arrangements on the SPLOST program. In addition, it
appears, from theHM
files, that the approval of pay requisitions and changeorders was not, in many instances, a well documented or thorough process. If
change orders were based on actual or estimated costs, they should have been
scrutinized in more detail and should be reviewed by DCSS to see if they are
properly supported by the contractor's records and actual costs.
Based on the records reviewed, HM did not categorize the changes on the
projects in a Program-wide fashion such that any changes that might be
candidates for cost recovery from the firms for errors and omissions are
readily identified and pursued. We are not aware of any actions taken by HM
or DCSS as to pursue recovery against the firms for errors or omissions
until very recently, after the HM suspension. We have summarized, as part of
Confidential Page 12of49 June1,2006
-
7/31/2019 SPLOST 2 Forensic Report
16/52
County School System SPLOST Forensic Program Review
our detailed discussions, changes that have references to design issues that
need to be further investigated by DCSS for possible cost recovery.
Based on our review of the HM records there is a lack of a consistency with
respect to change order entitlement reviews. Our concern is not only with the
merit of the issue, but also with the increases in contract price and contract
time that have been granted without sufficient documented justification.
IV. FINDINGS AND CONCLUSIONS-DETAILED DISCUSSION
A-
Perceptions of Problems with the SPLOST Program-
Change Orders and
Management by Heery-Mitchell
During our initial meetings with DCSS representatives, and as part of the interviews with
many of the individuals involved with the Program, the perceptions of problems with SPLOST
centered on two main issues - the number and value of the change orders issued to the
construction projects, and the failure of the PM, HM, to monitor, control and meaningfully
manage the Program such that much of the cost growth was controlled or prevented. We havebeen informed by individuals that we interviewed that the Board has been frustrated with
requests to approve change orders at the various Board meetings, and with the inability to clearly
understand the current projected costs on many of the school projects, resulting in, among other
things, the fact that the Board, the Superintendent, and counsel to DCSS have lost confidence in
HM's ability to manage the Program and predict a meaningful estimate at completion for many
of the contracts in progress. There have been a number of letters written between DCSS (and its
counsel) and over the past year and a half outlining problems that DCSS believes to beHM's
responsibility, with HM responding with its defense of individual issues. The lack of confidence
by DCSS and its counsel with respect to performance has led to the recent suspension of
HM. In addition, based on our conversations with you and others, there is a sense that some of
the Public appears to have also lost confidence in the overall program management, as many
have seen projects in its jurisdictions be partially or wholly deferred, as they are moved from AL
Confidential Page 13 of49 June1,2006
-
7/31/2019 SPLOST 2 Forensic Report
17/52
County School System SPLOST Forensic Program Review
to BL status. According to some of our interviews and a review of certain records, the public, in
many instances, views the allocation of funds to specific projects as an overly politicized
process, and questions whether or not the expenditures are consistent with an independent needs
assessment review and prioritization.
Our review of the HM files for the 16 larger projects has led us to the conclusion that, at
present, the level of change orders was only a part of the issue for the Program growth on
SPLOST 11, as those increases explain only a portion of the growth in the construction project
levels. Based on our review of the Board minutes, it appears that the total change orders formally
approved by the Board through April 10, 2006 totals approximately $5M (see Schedule
which, on its face, would lead to the conclusion that the change orders are not that material in
relation to the overall budget. However, it should be noted that, since Ms. Patricia Pope has
assumed the primary DCSS Program responsibilities, she has taken in lead in identifying the
magnitude and extent of the pending, and approved change orders. This exercise
is in process, and has resulted in the preliminary identification of additional potential change
order exposure that was not evident in the HM files that we reviewed (see Schedule XIV). It
should also be noted that we reviewed the HM individual contract and Program files provided to
us by HM. We understand that, more recently, DCSS has discovered additional files that
individual HM employees keptin
their personal work space files and drawers that might nothave been part of the centralized HM filing system. We have not, unless specifically noted,
reviewed these materials as part of our Phase I effort.
As the program cost growth was not fully explained by the extent and magnitude of the
identified change orders, we believe that it is more appropriate to define and assess the growth of
the SPLOST 11 program by looking at the original NA amount, and comparing it to the current
status of the individual projects that we selected for review. The reason for our conclusion to
look to the original NA instead of the construction contracts as the measuring points is that, in
many instances, the level of change orders on a contract does not always address the true
problem in terms of Program growth or public perception of project re-prioritization from to
BL. This is true because the initial construction contract value was often established at a point
when many cost growth risk issues were already discovered, and, in many cases, addressed
Confidential Page 14 of 49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
18/52
County School System SPLOST Forensic Program Review
through the contracting process. What is driving the issue, in our opinions, is the differential
between the NA levels from 200212003 until the current time-frame, which, of course, also
includes the volume of change orders actually issued.
In Schedules through we have summarized our comparison of the current
Budget to that which was prepared and published in June 2002, as well as the Budget
published through June 2003 (the budget authority that incorporated the 'Next Steps' and other
additions and re-prioritizations, including the 40% allocation to Clusters for their determination
as to use for those funds). As can be see from the chart, the current expenditures on the 16
schools that we reviewed is anywhere from 21% to 37% above the amounts from the
timeframe (inclusive of contingency and escalation allocation), depending on how the data is
viewed in terms of projects not contemplated as Phase I in 2002. As an example, in reviewing
the schedule, it can be seen that the New Peachtree Middle School (MS) was not included in the
original 2002 budget total of However, once the 40% allocation was made to Clusters,
individuals in the Cluster decided to build a new Middle School, and so this project
was added at a level of in mid 2003. By adding this project, the overall funds for AL
requirements had to be adjusted, meaning that either this project drew from certain other projects
that were scheduled to be priority O.E.C. North High School North), O.E.C.
Central (Warren Tech), Woodridge Elementary School, Stone Mountain Elementary School, andHigh School), or eliminating (along with the other additions at the same time) the overall
Program contingency. Therefore, the absolute growth of these 16 projects from the original NA
budget to their current status is 37%; however, even if you factor in the addition of the budgets in
2003, and view them as the baseline for measurement, the additions are still approximately 21%
of the revised budget totals. These increases are in addition to the 7.5% escalation and 5%
individual project contingency amounts originally included by in each of the original budget
totals.
The information in Schedules11 through IV relates to the overall budget for the SPLOST
11 Program projects, inclusive of construction, and furniture and fixtures. We were not
asked to review the information relating to the furniture and fixture contracts, nor certain other
budget items beyond the construction and areas. However, in analyzing the construction
Confidential Page 15 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
19/52
County School System SPLOST Forensic Program Review
and contracts, we did conclude that each of these expenditure areas had similar increases in
terms of budget growth from the original NA to the current actual or projected levels. In
Schedules V and VI, we have provided certain examples of contracts that had large increases in
the actual expenditures in comparison to that contemplated at the time of the NA and original
budgeting process. As can be seen from this analysis, the conclusion is consistent for both the
construction and design component of the expenditure comparison.
Given this data, it is clear that the growth of the Program is at levels that are beyond what
might have been anticipated, and, as discussed further, are not merely attributable to escalation
of labor and materials in the Atlanta area over the last four years. Determining the exact cause
for the increases is a much more complicated undertaking, however, and will be explored further
in this report. At the outset, however, it is important to stress that, based on our document
reviews and interviews, the original NA levels were determined by the PM, HM, and the
responsibility for monitoring the increases and reporting those to DCSS and the Board also rests
with in its role as the overall PM, as outlined under the terms of its contract with DCSS, as
discussed further.
B-Understated Needs Assessment (Na) Levels And Approval Of ProjectsBy The
Board
As mentioned above, the NA process, which led to the establishment of budgets for
various schools and the overall Program, understated the costs needed to accomplish the
objectives of the Program. Our understanding was that HM performed the NA review for the
County, and used an approach whereby it estimated costs based on a square foot (SF) or unit
price approach, and then added a cost contingency factor of5% and an escalation factor of7.5%
to the estimated amounts for all project costs contemplated by the NA. As an example, for new
school construction, HM apparently applied a graduated square foot pricing amount for various
types of schools Elementary Schools, Middle Schools and High Schools), and then added
the contingency and escalation factors.
Confidential Page 16 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
20/52
County School System SPLOST Forensic Program Review
In analyzing the issue of planned versus actual costs, we have summarized the actual
costs per square foot for certain of the new school projects that we had reviewed. This
information is presented in Schedule VII, and reflects an average total cost per foot of $126.86.
The $126.86 is based on change orders approved, as well as those recommended by HM for
approval and pending as of April 12, 2006, per the Change Order Log (COR Log) that HM
provided to DCSS. The $126.86 does not include any changes for issues
on active projects as of April 12, 2006, even though some amounts have been reserved by HM
for such potential issues. As a result, the $126.86 cost per foot may, in fact, be higher when the
projects are all closed out. In comparison, those same schools had a planned cost per square
foot, inclusive of contract contingency and escalation, of $111.83 (See Schedule or an
increase of almost $15 per foot of new construction (a 13% increase), beyond budgeted
escalation and contingencies (assuming no additional changes are executed).
To assess the reasonableness of the contingency component of NA levels, we
looked to SPLOST I new school construction data to see if trends for that part of the program
were properly considered by HM. As shown in Schedule the increases in the new school
construction contract values for SPLOST I, as of June 2001 (near to the NA timeframe) were
tracking at approximately 15%. This percentage compares to 5% individual contract
contingency thatit
used for the SPLOST program. It would appear that, even assuming thatthe original starting points for the graduated costs per SF were reasonable (albeit perhaps a little
understated), the contingency for changes, based on the SPLOST I experience, should have been
higher.
The other area that we reviewed relating to the NA study undertaken by HM was the
escalation rate of 7.5% used across the board and applied to the totals. To understand the 7.5%
factor, it must be remembered that this is really an average for the 5 year SPLOST program,
and should be viewed, in a summary fashion, as an approximate 3% per year escalation for 5
years, which would mid point out at around It should be noted that we did not see any
analysis by HM as to the timing of the actual construction to see if a simple application of one
escalation rate made sense in terms of the timing of the projects, and we believe that a
driven escalation analysis should have been undertaken as part of the NA. Without such an
Confidential Page 17 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
21/52
County School System SPLOST Forensic Program Review
analysis, it is virtually impossible to determine if the mid-point of a Program schedule actually
translates into the mid-point of the construction expenditures. As an example, if a Program is
scheduled to span a 5 year period, it may be that, with planning and design, the actual
construction expenditures will be weighted more heavily towards the later part of the 5 year
period. If so, even using a 3% per year estimate, the overall factor would be higher than the
7.5% result the used (and, perhaps, calculated) for the Program.
From a review of the RS data for the late time frame, we
observed that the use of an annual escalation factor of 3% (if that was, in fact, the manner in
which HM approached its estimate) was not apparently unreasonable. (See Schedule X)
However, escalation rates increased rather markedly in 2004 and 2005, contributing to the more
recent rise in costs for SPLOST11 in relation to the original NA. This escalation has been caused
by a number of factors, including increases in steel and concrete prices nationally, increases in
construction materials due to the hurricane issues in the South over the last two years, and
increases in Atlanta due to competition for resources due to the multiple SPLOST programs in
the various counties. It is difficult, in hindsight, to determine how much of this increase for
and 2005 should have been contemplated by HM. The rising escalation in these years does not,
however, explain the Project growth for schools bid and awarded early in the Program, such as
New Miller Grove, New Tucker, and New
Another increase between the NA and the final actual costs relates to scope growth in
terms of size of the facility. Of the new school construction in our sample, six of the projects
included changes in square footage, and this total scope growth equates to approximately
SF, or approximately $7 million. But for this scope growth, other projects that were originally
scheduled to be might have been able to be completed with SPLOST11funds.
Based on our conversations and interviews, and our review of the files, it appears
that did not include local representatives in its discussions and analysis of the NA
levels. Later, the firms were often unable to design to the NA levels. We believe that the
RS Means is a leading supplier of construction cost information. A product line of Reed Construction Data, RSMeans provides cost information that helps owners, developers, architects, engineers, contractors and others toproject and control the cost of both new building construction and renovation projects.
Confidential Page 18 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
22/52
County School System SPLOST Forensic Program Review
inclusion of these professionals in the process of establishing the budgets for the individual
projects, (a process which was used for SPLOST I), may have resulted in a more meaningful
planning and budgeting process, as these professionals would have had to reconcile their
participation in the NA process with their current budget estimates.
Based on our review, we also observed that the County did not appear to have in place a
written model spelling out the Criteria for Capital Allocation within the school system. This type
of model, or Master Plan, is important in that is sets out the criteria no children in portable
schools by a certain date, no school without operating air conditioning and heat systems by a
certain date, number of classroom goals per planned enrollment levels in various areas of the
county, etc.) by which decisions are made for individual schools and projects across the County.
Without such criteria, the allocation of funds among the various schools becomes difficult to
defend in some instances, and can be viewed by the public as an overly-political process. In
addition, studies have shown that School Systems that use effective Master Planning strategies
have lower incidents of scope creep and change order impact in comparison with school systems
that do not employ effective master planning strategies8. Although did perform detailed
work in arriving at estimated enrollments and other needs-driven requirements, there appeared to
be a subsequent disconnect between that analysis and the actual prioritization and approval of
projects. This is especially true after the"
Next Steps"
approval process in 2003 and theassignment of the 40% factor to each Cluster for determination of the use of the funds. This 40%
assignment approach contributed to the movement of projects between and BL, and, as
discussed further, appeared to lead to decisions for new school construction or additions that
were at odds with the overall NA effort originally undertaken. As such, we believe that the
process of assigning the 40% allocation to each Cluster and effectively allowing community
members and school officials in those areas to determine how to use those funds, without making
sure that the Cluster determination is consistent with the prioritization of the NA study, was not
appropriate.
As discussed above, the DCSS had assessed needs of at least $1.15 billion dollars based
on the results of the SPLOST needs assessment. Relative to the SPLOST Needs
FMUCMAAK-12Public School Construction Management Survey Report, 2005.
Confidential Page 19 of 49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
23/52
County School System SPLOST Forensic Program Review
Assessment, and as summarized in Schedule I, the Board approved $61 1 million of projects
based on the SPLOST team's recommendations (See Schedule I). The projects authorized for
construction by the DCSS BOE exceeds the current funding amount of (inclusive of an
additional $9M of estimated revenue recently added to the Program) by approximately
and is even in excess of what the funding levels supported at the time of the commencement of
the SPLOST Program. Due to this issue, and as it became apparent that there would not be
sufficient funding to complete approved projects with the SPLOST funds, the "above and
below the line" classifications were established by SPLOST individuals in the August
timeframe. Based on a review of BOE records and minutes, as well as the information conveyed
to us in interviews, it appears that the AL and BL issue, and the subsequent result that not all of
the projects would be built with SPLOST 11 funds, was never fully understood by the school
communities. The public believed that the Board's approval of their projects translated to the
fact that they would be built under the SPLOST program. Some staff internal to the SPLOST
and DCSS program concede that the communication of the above the line and below the line
issue, as well as the approval process for projects, could have been handled in a more clear and
transparent nature. In our opinion, the SPLOST team should not have recommended, and the
Board should not have approved $61 in projects under SPLOST 11, as it gave a false sense of
a promise that it now clearly can not keep. It is not clear from the records reviewed, however,
what information the Board was presented with by and Dr. Pritchett in reaching its decisionto approve the projects in the fashion that they did.
Compounding the understated NA budget issue, was a failure by and DCSS to
proactively manage the budgeting aspects of design and development, and re-baseline all of the
projects once the estimates were coming in with indications that the NA levels were either
unrealistic or inaccurate. As an example, the New Miller Grove High School Project was one of
the first new construction projects built under the SPLOST program. From the beginning of
the design development and estimating process for Miller Grove, the project exceeded
construction cost estimate from the SPLOST Needs Assessment. In fact, the estimates
provided HM by the Miller Grove architect early in the design process also exceeded the fully
loaded construction budget of $25.6 million plus 5% contingency and 7.5% escalation).
The Miller Grove GMP amount was set at $28 million for a SF facility, an effective cost
Confidential Page 20 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
24/52
County School System SPLOST Forensic Program Review
per square foot of$117. As the new construction sequence of the SPLOST program progressed
(New Tucker MS, New Peachtree MS, New Chamblee MS, New Stone Mountain MS), the cost
per square foot numbers continued to increase beyond what had been
adversely impacting the budgetary status of the SPLOST11program.
The direction given to the SPLOST11 firms from the outset was to design to the NA
budgets. However, with New Miller Grove, as with several other schools, the firms came
back early with indications that the budget was inadequate to meet the intended scope. At this
point, DCSS had the option of either reducing scope to stay within the NA budget, or moving
forward and re-baselining the entire Program to address more realistic budgets and scope. If HM
and DCSS would have re-baselined the Program and revised all of the budgets to reflect the
results of more current information, it might have avoided many of the problems that now exist
in terms of deferring project scope and certain projects in their entirety, and the related lack of
confidence and trust by the public in HM, DCSS and the Board. Instead, the program moved
forward with outdated budget estimates, and each award in excess of the NA level resulted
further depletion of the overall Program contingency and eroding confidence in the overall
Program plan.
In summary, we believe that errors were made under the SPLOST 11 Program in thefollowing areas:
In using a 40%allocation approach to Cluster funding;
In recommending and approving $61 of projects in light of the funding estimates;
In failing to clearly communicate that certain projects were subject to future funding,
and, therefore, would probably not be completed with SPLOST11funds;
In understating the NA levels for possible contingencies that might occur with the
Program;
In failing to proactively manage the budgeting aspects of the
process;
In estimating escalation for a five year program without schedule-phasing the projects
and the timing of the incurrence of costs relating to those projects; and
Confidential Page 21of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
25/52
County School System SPLOST Forensic Program Review
In failing to re-baseline the Program and project estimates once it was apparent that
the NA levels were inadequate.
C- Mitchell (HM) Contract Files And Performance
The HM contract for overall PM services is a comprehensive document that outlines the
duties that HM would perform and the fees that it would be paid for such effort. In Article 3 of
the agreement, role as the owner's agent is outlined, and language is included whereby
agrees to perform its duties "at a level and to a standard of care, consistent with the
standards and quality prevailing among first class, nationally recognized program and
construction management firms of superior skill and experience engaged in programs of similar
size and complexity."
In Article 4 of that agreement, the exact duties of HM were outlined. The following
summarizes certain obligations of HM pursuant to Article 4 of the agreement (References are to
Article 4 of the contract):
- Program Analysis-
The PM shall provide DCSS with a detailed written report, the Program Analysis.The Program Analysis"shall evaluate the Owner's program objectives and make
recommendations and proposals with respect to achieving such objectives or
modifying same."
- Monthly reports-
The PM shall prepare and submit to the Owner's representative and the Owners
Counsel a monthly report "summarizing the progress of the program during the
preceding month." Such report shall set forth, in detail satisfactory to the owner,
significant facts and events occurring during the preceding month. The report shall
also describe any problems or obstacles which may adversely impact the budget or
schedule of the Program or any Project. The monthly report shall include without
limitation the following:
Confidential Page 22 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
26/52
County School System SPLOST Forensic Program Review
The PM shall prepare an update of Program Schedule identifying any delays
to the Program or any Project including the cause and extent of the delays;
The PM shall provide DCSS with recommendations to mitigate schedule
delays;
The PM shall provide and analysis of budget and cash flow subdivided
between design and construction;
The PM shall provide a Month by month projection and forecast of future
anticipated costs and payments by Owner;
The PM shall provide a Summary of all change orders approved for each
Project during the preceding month, indicating cost and cause, and;
The PM shall tabulate the cumulative total cost of all change orders approved
for each project as percentage of the construction contract.
- At every meeting the Program Manager attends, the PM shall prepare and
distribute meeting minutes;
- The PM shall prepare a Program schedule that establishes and shows milestones
for critical phases and events in the design and construction of each Project in the
Program. The PM shall continually update this schedule throughout the duration of
the Program;
The PM shall provide, in writing, notice of delays to Program Schedule and
should make recommendations for eliminating or minimizing such delays;
- The PM shall provide and continually update throughout the duration of the
project a budget and anticipated cash flow analysis for the Program that segregates
costs into design and construction phases for each project;
.10 communication between the PM and DCSS shall be in writing to Dr.
Pritchett;- The PM shall implement a Manager or equal computerized system for
management and control of documents and information, with owner having
continuous access;
.13 - The PM shall prepare written design criteria and standards for the project and
should assist the Owner in the preparation of detailed education specifications;
Confidential Page 23 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
27/52
County School System SPLOST Forensic Program Review
.14 - The PM shall prepare design schedules. PM shall also monitor all design
schedules and notify the Owner in writing of any delays in the Design phase
including recommendations for minimizing delays;
.15 - The PM shall provide program reviews with Project Architects during which the
PM and Architect review the design criteria, project budget, design schedule, program
schedule, communication channels and applicable laws affecting the project;
.17 - The PM shall attend twice monthly meetings on each project with architects to
review the progress of the design and address issues impacting the design and
constructability of the project;
17.1 - The PM shall evaluate the potential cost savings and the cost effectiveness of
the construction and installation;
17.2-
ThePM shall provide a written report within three days of these meetings
noting the progress and any issues with respect to the design process;
20 - The PM shall review pay applications of Project Architect and certify to owner
that the Architect is due such payment as required under the applicable contract;
1.1 - The PM shall perform a review of the Preliminary design and prepare written
report to owner noting any areas of concern or any deviations from the Project or
Program requirements. Such report shall contain estimate and shall identify
any deviations from the original Project budget and the cause of the same. The reportshall make recommendations for eliminating or minimizing such deviations;
- The PM shall perform a review of the design for construction and prepare a
written report to the Owner after review of design for construction. Such report shall
identify any problems or areasof concern. The report will also include estimate
and shall identify any deviations from the original Project budget and the cause of the
same. The report shall make recommendations for eliminating or minimizing such
deviations;
.24 - The PM shall negotiate with bidders when bids are in excess of budget;
.26 - The PM shall conduct preconstruction conferences and prepare written minutes
of the conference;
.28 - Unless otherwise directed by the Owner, PM shall coordinate with Owner to
schedule, coordinate, assist with and facilitate the performance of all Owners duties
Confidential Page 24of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
28/52
County School System SPLOST Forensic Program Review
under each construction contract. The PM shall also perform all of the duties of the
Owner's Representative as defined in any Design Build contracts. PM shall
coordinate with Owner to schedule and coordinate the procurement, delivery, and
security of any materials, furnishings, and equipment to be furnished to the Program
or any Project by Owner;
.29 - PM shall confirm that all Contractors obtain all permits, licenses required by the
contract or law;
.31 - The PM shall review Contractor prepared construction schedules verifying that
schedules are reasonable, practical and in conformance with contract terms and
conditions. PM shall furnish the Owner with a summary of the schedules showing
the Contractors critical path logic;
.32-
The PM shall obtain and review all monthly updates to construction schedules
verifying that updates are consistent with actual progress. PM shall notify Owner in
writing if schedule shows slippage or delays to project;
.33 - The PM shall examine and approve the Contractors schedule of values (SOV) to
protect the owner against an unbalanced SOV;
.39 - The PM shall review each contractor payment request and shall certify to the
owner that in professional judgment that the requested amount is due the
Contractor. certification of the Contractor pay request shall be a representationto the Owner that the amount requested is properly due to the Contractor and the PM
has no reason why any portion of the requested amount should not be withheld;
.40 - The PM shall review all change order request or proposals submitted and advise
the Owner in writing as to the cause, likely cost, likely schedule impact and all other
potential impacts related to the request. PM shall negotiate on Owner's behalf cost
increases and decreases and time extensions resulting from each request. PM shall
maintain a log of all change order requests or proposals, all actions taken and the
dates of any such actions;
.41 - The PM shall be responsible for maintaining a daily log.
As evidenced by this detailed listing, roles and responsibilities under the terms of
its agreement with DCSS were very broad and comprehensive, and required detailed reporting
Confidential Page 25 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
29/52
County School System SPLOST Forensic Program Review
and schedule management. Based on our review of the files maintained by HM, the following
observations were made:
It appears that no comprehensive Program Schedule was maintained and routinely
updated for the project. Interviews with HM personnel revealed that relied
upon the construction schedules prepared by the various Contractors involved in
the program. The individual construction project schedules are not adequate for
managing the specific project components (design, construction and
let alone the overall Program.
It appears that there was no consistent and coordinated approach to the review and
summarization of change orders on the projects. As an example, we expected to
see, for each project, a categorization of change orders among various types
design changes, differing site conditions, added scope, etc.) and a up of this
information into overall Program summaries of the same information. Any such
sporadic summaries found in the HM files reviewed by appeared to
have been prepared by the individual project manager for an individual contract,
but not updated and systematically summarized on a Program basis or put into
any format that could be meaningful to DCSS.
There was no documented evidence in the files reviewed by of any
attempt to go back to the firms for possible errors or omissions related to
design changes or issues that came up.
There was little documented evidence of steps HM took in analyzing the
entitlement and pricing aspect of the change orders on the sampled projects, nor
were there summaries of the change order negotiation process and conclusions
relating to why a particular change should be approved. Further it appears that
increases in Contract Time were granted without adequate documented schedule
justification. (This is commonly referred to as a record of negotiation (RON) or
Confidential Page 26 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
30/52
County School System SPLOST Forensic Program Review
some other similar term, depending on the firm or organization performing the
effort.)
As a response to some correspondence from Dr, Pritchett citing breakdowns on
several projects, HM indicated, in August 2004, that it was going to undertake
quality type audits of its various projects on a quarterly basis.
These audits were to be performed by Don Green, a project manager. Our
review of the HM general program files, as well as the 16 sampled project files,
has not provided any indication of the results or performance of these audits.
Additionally, documentation requests were made by to related to
these audits, but no documentation was provided in response to these requests.
The monthly reports required by the contract were not consistently prepared.
When prepared, the format and content included within the reports appear to be
somewhat less than the format envisioned in the contract language cited above.
There is little documented evidence that HM performed detailed reviews of the
contractor's payment applications or requested actual cost information for those
contracts or changes that were being performed on a cost plus(GMP)contractbasis. In deposition testimony on the Carolina Casualty Insurance Company
versus R. L. Brown Associates, Inc., Construction Company, et. al, Mr.
Steven P. Kimsey, Program Coordinator for the Program, testified that he
believed that he had no responsibility to review the payment applications of the
contractors beyond making sure that the and others had signed off on the
request and that the budget authority existed to make the payment requested under
the requisition. Mr. Kimsey also testified that had no responsibility to look at
the conformity of the work with respect to the payment requisitions. Mr.
Kimsey's assessment appears to be inconsistent with the terms of the HM contract
with DCSS. (See, for example, Article 4.39.)
Confidential Page 27 of 49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
31/52
County School System SPLOST Forensic Program Review
HM did not implement the Manager (or equivalent) system required under
the terms of its contract with DCSS. The Manager system would have
been an effective tool to monitor Submittals, Correspondence and Change
Orders.
The above deficiencies are not intended to be all-inclusive, and other areas where HM's
performance was questionable are referenced in other sections of this report. In discussing the
above with HM representatives, we were informed that HM worked very closely with Dr.
Pritchett in determining his needs under the Program, and that DCSS, through Dr. Pritchett, was
not always requiring those deliverables from the contract. Dr. Pritchett does not believe that he
relaxed the contract requirements for HM. Based on our review of the contract files of both Dr.
Pritchett and HM, there is no correspondence that conveys either a relaxation of the contract
requirements nor an expressed dissatisfaction with the HM reporting process until well into the
SPLOST Program, and after the involvement of legal representatives and construction
personnel of DCSS replacing Dr. Pritchett.
As mentioned above, DCSS personnel, the Board, and counsel to DCSS had lost
confidence with HM commencing in 2004. There are a number of letters and memorandum
between HM and DCSS and its counsel that outline areas that DCSS believed were theresponsibility of HM, along with responses to these issues. It was not the purpose of our
scope of work under this engagement to make determinations as to whether or not DCSS or HM
is, in each of the areas cited, responsible for the management issues identified in these letters.
However, we did observe the foregoing HM contract issues, some of which overlap with the
DCSS complaints, have made certain other conclusions relating to HM's performance in other
areas of this report, and have also concluded that HM had apparently participated in the
of change orders for items such as compensation for weather delays, that are
not generally considered compensable in the construction industry and/or under the subject
DCSS contracts with its contractors.
As a result of these and other issues, DCSS has suspended HM from its contract for PM
services.
Confidential Page 28 of49 June1,2006
-
7/31/2019 SPLOST 2 Forensic Report
32/52
County School System SPLOST Forensic Program Review
D-Allocations Of Funding To Clusters And Projects
As stated above, we believe that the allocation to clusters based on a 40% overall
percentage of needs assessments was not appropriate. This decision, coupled with a movement
of projects from BL to AL, contributed to the impression in the County that the approach was
overly political in nature. Although we were not tasked specifically with assessing the
appropriateness of the allocation of funds among the Clusters and school projects, we did
observe that there were some decisions made in the selection and scope of schools for
construction and renovation that are questionable in terms of a review of actual and projected
enrollments. These include questionsas to why:
A new McNair Cluster Elementary School is being planned to replace the Leslie J.
Steele ES at a cost of to allow for over 900 students, when the current enrollment is 305
and the capacity of the existing facility is In addition, other elementary schools in the same
cluster also have under-utilized capacity Peachcrest with a capacity of 902, and a
current enrollment of 289). In contrast, the Fairington Elementary School has a design capacity
of 748 students and a current enrollment of 1,417 with portable classrooms and transportation to
other clusters being utilized for the excess students. On the surface, these statistics raise the
question as to why DCSS would construct a new elementary school in the cluster.
A new Middle School is being built at Peachtree Middle School at a cost of
with a Design Capacity for 1,150 students, when the current capacity of the existing school is
1,342 and the current enrollment is
These questions are not meant to be all-inclusive nor a conclusion that those decisions
were inappropriate; however, they do highlight the need for County-wide criteria for the
expenditure of funds on school projects to assure that the overall County needs of the community
and students are being addressed.
Confidential Page 29 of 49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
33/52
County School System SPLOST Forensic Program Review
E-Southwest DeKalb High School-What Happened And How Could It Have
Been Avoided
The Southwest DeKalb High School (SWD) project was a particularly troublesome
project. Issues related to excessive change orders, delays, lack of budget control and value for
the amounts expended were identified of particular concern. In an attempt to understand these
concerns, we undertook a more extensive review of the project, and the following are our
preliminary findings.
The project was included in the SPLOST Needs Assessment program with a
value of $12,502,363 for the overall project. The project scope at the NA stage involved the
demolition and renovation of a portion of the existing high school and the construction of a new
wing.
DCSS contracted with Brown as the architect on April 22,2003. The contract
included a provision requiring a design to a stated construction cost limitation of
The contract value was $561,480, including Preliminary Consultation, Examination andReport, Preliminary Design and Price Estimate, Construction Documents and Final Price
Estimate and Contract Administration associated with the construction of an 18,000 sf new
addition, and the complete floor to ceiling renovation of sf of the existing facility. In
July 2003, DCSS increased the scope of the project by requiring the design of a 10,000 sf Career
Tech Classroom addition.
RL Brown's contract value was increased in December 2004 to reflect a fee adjustment
based on a $16 million construction contract, using the original contract fee rate (6% of
construction cost). This fee adjustment was to account for the increase in construction value
related to the scope increase resulting from the addition of a Multi-purpose classroom,
administrative offices and the extension of the trailer village.
Confidential Page 30 of 49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
34/52
County School System SPLOST Forensic Program Review
In October 2003, provided DCSS a preliminary estimate of probable cost of
$10,500,489. Depending on whether the scope of this estimate included the Career Tech
addition, it would still be in line with contractual stated cost limitation requirement. In
April 2004, prepared a 75% Construction Document phase estimate in the amount of
$13,703,999.
HJ Russell was awarded a GMP Construction Management contract in May
The contract provided for design phase services support in the amount of $9,750. Although there
was an uncertain project cost, and the preliminary estimates were in excess of amounts that the
DCSS budgeted, HJR was given the approval to commence demolition of the existing facility in
June 2004. It appears that the decision to allow demolition to commence with out final
drawings, permits or pricing was due partly to community pressure to initiate work on the
facility.
Amendment to the Contract, executed in July 2004, established a $7,278,050
GMP, setting in place a phased approach to the work, with a March 31,2005 required
completion date. The initial phase involved interior demo, site clearing,
temporary learning center, surveying, and temporary support of existing electrical, structural and
miscellaneous steel.
Later in 2004, provided its first GMP estimate in excess of $19 million. This set in
motion a series of Value Engineering (VE) studies in an attempt to reduce the cost. Several
recommendations were adopted and certain portions of the work was deferred. Amendment
to Contract, executed in March 2005, set the GMP at $16.5 million.
Schedule XII provides a summary of the schedule of values as reflected in the Russell
payment requisitions on the SW DeKalb HS project. A review of Schedule XII provides some
insight into the allegations that DCSS was not getting value for the work performed under the
contract. Renovation projects by nature include types of work that not readily apparent at
the completion of the project. Examples of this effort include the replacement of Plumbing,
HVAC and electrical systems, the demolition of existing building space to ready the structure for
Confidential Page 31 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
35/52
County School System SPLOST Forensic Program Review
its new construction activities, and the or re-routing of site utility services
to accommodate the demands of the new facility. Additionally, other costs during the
construction process relate to the general conditions costs of the Contractor. Accordingly,
persons unfamiliar with the intricacies of construction renovation projects may not see the value
in a particular project if it is not apparent to the naked eye.
visited the Southwest DeKalb site on two occasions to walk the project in an
effort to better understand the nature of the project. During these site visits, and while analyzing
the payment requisitions, we have had occasion to notice extensive amounts of work above the
acoustic ceilings in the hallways and classrooms, as well as general conditions type costs that
could explain the perception gap between the community representatives that we met and the
construction team on SW DeKalb. A more detailed analysis of the project would be
required to make a determination as to whether DCSS received value under the construction at
SW DeKalb.
Although HJR completed the interior demolition in late October 2004, the renovation and
new addition work could not proceed until HJR received the Land Disturbance Permit and the
Building Permit. Approval of these documents was delayed pending final design review
with the Fire Marshall's office and the Building Department. The permits were finally receivedin February and March resulting in a six month delay to the contract schedule.
Once received the permits, it argued that its work was further delayed for several
other reasons including late RFI, submittal and shop drawing reviews. Later issues arose
concerning the kitchen grease traps. In June 2005, commenced the demolition of the
kitchen. This demolition started even though all shop drawings were not approved and design
was not complete. The Fire Marshall initially insisted that HJR install a large grease trap that
would have necessitated installation of new sanitary lines. This would have resulted in a large
dollar value change and the Fire Marshall ultimately permitted a relaxation of its requirement.
Although the requirement was relaxed, it still created a delay to the kitchen construction. The
school kitchen phase of the work was finally completed in January 2006.
Confidential Page 32of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
36/52
County School System SPLOST Forensic Program Review
submitted a delay analysis explaining its position with respect to the delays
described above. The files showed no response from or
As with other projects reviewed by us, the significant cost growth from the initial
estimates necessitated redesigns from RLB. These redesigns likely contributed to the delay in
obtaining the and the resulting construction contract delay. Despite assurances from
that it would have construction drawings ready and approved by the time the demolition
was complete, the redesigns were of such a magnitude that approval was no longer a
formality.
In hindsight, perhaps a better strategy would have been to suspend construction work
once the construction cost estimates were showing a significant deviation from the budgeted
amount. At this point, a re-baseline of the SPLOST11 program may have been warranted as
significant overall Program contingency was going to be used, and funds allocated to other
planned projects may have been needed to fund the SWD contract work. While the suspension
may not have been well received in the community, it would probably have made sense from an
overall program perspective. Because the final cost of the SWD project will greatly exceed theinitial Needs Assessment value, the program will experience the ripple effect of the decisions to
proceed with the work.
V. OTHER OBSERVATIONS
Based on our review of project records and interviews of key project personnel, we have
made some additional observations and have reached some additional conclusions relating to the
SPLOST Program. These observations and conclusions are presented below.
A) Selection of Individual to Run the SPLOST11 on behalf of DCSS - as
mentioned above, DCSS selected Dr. Stanley Pritchett to head up the SPLOST Program and to
Confidential Page 33of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
37/52
County School System SPLOST Forensic Program Review
act as the interface with HM, the firms, and other contractors and vendors dealing with
DCSS on the Program. Dr. Pritchett had no background or experience with construction prior to
his selection for this role. The County would likely have benefited from someone with
Construction Management or Construction experience in such a critical role, as this experience is
necessary for someone in the role assigned to Dr. Pritchett, especially considering that he had the
oversight responsibility HM PM contract.
B) Selection and Avvroval of Contracts - According to Board policy, the
Superintendent is responsible for selecting architects, and he accepted recommendations from his
staff as part of that process. For SPLOST Dr. Stanley Pritchett was heavily involved in the
recommendation and selection process for contracts. Our review to date of DCSS files
revealed no documentation of the process for selection and award. We understand from Dr.
Pritchett that he could consult with others in his department, but there was no written policy
established within the Superintendent's office or the SPLOST organization for the evaluation
criteria and selection process for firms. We observed that the Architects contracts were not
approved by the Board, and such approval was not required under existing Board policy. It
should be noted that the current evaluation and award process for construction contracts includes
the types of checks and balances that we recommend be considered for the architect selection
process. For information purposes, we have summarized the total SPLOST payments to thefirms as of February 2,2006 in Schedule XI.
Audits - although many of the SPLOST contracts were of a cost reimbursable
nature, and many change orders were based on cost representations by contractors,
noted no documentation evidencing the performance of audits by HM or other DCSS
representatives of the books and records of the contractors. (In addition, we understand that
some of the SPLOST I contracts may also be of a cost reimbursable nature, and may not have
been audited to date.) Typically, on a program of this size, the PM or the County itself would
have an audit arm to provide assist-audits of contractor data. By doing so, contractors are
sensitive to the data submitted, and there tends to be long term savings in terms of a deterrent
value when an audit environment is contemplated as part of the billing or negotiation process.
Confidential Page 34 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
38/52
County School System SPLOST Forensic Program Review
D) Close outs- it appears that DCSS has not implemented a close out process for the
various construction and architect contracts, and that many of these contracts have been
completed, but still not closed out, for years.
E) Punch list and work-
based on discussions with select individuals and our
site visits to a few schools, it appears that there is still fairly substantial repair or punch list work
to be completed at certain schools. As an example, at the Miller Grove High School, we
observed stained ceiling tiles at several locations that may be the result of roof leaks, a large
gutter drain had fallen down and had not been repaired, and several doors were difficult to open
because of conflicts with the slab concrete. At the SW DeKalb School, we also noted several
stained ceiling tiles that may be the result of roof leaks.
F) Contract Administration - The Construction Management at Risk (CMR)
contracts were, in many instances, administered like they were Lump Sum contracts. Under a
CMR contract (or, a Guaranteed Maximum Price (GMP) contract), there is normally a ceiling
price established early enough in the process to motivate a contractor, through cost sharing
incentives, to work towards that ceiling and realize savings that it can share in with the owner.
On the SPLOST program, ceiling amounts were established too late in the program, thereby
creating a delivery method which was,in
essence, a cost type contract without a ceiling amountof any significance.
Those contracts that were administered as CMR deviated from the traditional
contracting that may have contributed to the issuance of change orders. In the traditional
contracting method, the contractor is permitted to include in its GMP price contingency amounts
to cover estimating variances and scope that is not clearly defined on the contract drawings. In
our brief review of the DCSS CMR contracts, we noted that many of the contracts did not
include such contingency amounts. Therefore, in many instances, as design was finalized, the
contractor submitted change order requests for items that would have normally been included in
the line item contingency amount.
Confidential Page 35 of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
39/52
County School System SPLOST Forensic Program Review
G) Change Order Review - We undertook a more detailed review of two Change
Orders; our findings are as follows:
a) Towers High School, Change Order Rock Excavation
The contract documents indicate that the contractor should expect to
encounter rock during the excavation for the storm sewer system. The
contract also notes that the contractor should assume that all excavation will
be earth material and that the contract sum shall be adjusted by change order if
rock is encountered during construction. Expectantly, the contractor,
encountered rock during the excavation for the Storm Sewer system
construction as was noted on the contract drawings. submitted its
claim for approximately $75,000 for costs incurred through September 22,
2005; in its proposal, also indicated that it was having difficulty
removing the rock with conventional means and was stopping work to explore
alternate means of removal. The Architect, Sy Richards, recommended
approval of claim in the amount proposed which was later approved
by the Board. Later, revised its claim, increasing the proposed amount
to approximately including a 29 day time extension request. We
understand that has not executed the Board approved change order,probably because it does not want to compromise its rights to recover
additional costs and time pursuant to its latest proposal.
We have several concerns with this issue as follows:
It appears that the contract is being administered as if the contractor is due
an increase in contract price and contract time for encountering rock that
was clearly detected during the design phase. It seems that a more
appropriate contracting strategy would have been to make the contractor
responsible for rock removal in its contract price and time and only allow
for increases in contract price and time if the nature of the rock
encountered was materially different than represented by the contract
Confidential Page 36of49 June 1,2006
-
7/31/2019 SPLOST 2 Forensic Report
40/52
County School System SPLOST Forensic Program Review
documents. This is a customary contracting strategy that can be
implemented with the use of a differing site condition clause. While the
contract does include a differing site condition clause, the change order is
being administered as if the excavation clause overrides the differing site
condition clause.
If it is determined that the contractor is entitled to a change for this issue,
we would suggest that the contract file include documentation setting forth
the nature of the change and indicating that an evaluation of the proposed
costs was undertaken. While there are references in the change order file
to estimates done by for this issue, the file did not include the
estimate or cost evaluation.
With respect to the request for an increase in contract time, we would also
have expected to see some level of schedule analysis to demonstrate that
the contractor was or was not entitled to any such adjustment. We did not
find any such evaluation in the change order file.
b) Miller Grove High