190613 corraction copy for web tender for bimonthly ... office/utran gas based pow… · ``` 500/-...
TRANSCRIPT
Page 1 of 26
GUJARAT STATE ELECTRICITY CORPORATION LTD. CCPP-II, GBPS, Utran – 394 105
TENDER COPY
TECHNICAL BID
NAME OF THE WORK:-
Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran.
Tender No.:Web.05/2013/Mech-II
Page 2 of 26
INDEX
NAME OF WORK: Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran.(Web.05/13/Mech.II)
Sr. No.
Name of Document Page No.
Technical Bid
01 Tender notice. 3 02 Pre-qualification criteria 4
03 Scope of work (SCHEDULE-A) 5 04 Annexure-I (Terms & Conditions) 9
05 Annexure-II 14
06 Deviation sheet 15
07 Labour laws 16 08 General safety rules/norms to be observed by the contractor 20 PRICE BID 09 Tender Notice 22
10 Schedule-B 23
Page 3 of 26
GUJARAT STATE ELECTRICITY CORPORATION LTD. CCPP-II, UTRAN - 394105
TENDER NOTICE
(1) Tender is invited in accordance with the Tender No. Tender No.:Web.05/2013/Mech-II.
The tender Bid shall be furnished in two parts i.e. Technical Bid and price bid separately in 1+1
copies (Technical bid + Price bid) shall be submitted to this office on or before due date.
(2) Tender documents with technical specifications may be downloaded from our Web site
www.gseb.com & www.gsecl.in.
NON REFUNDABLE TENDER FEE
`̀̀̀ 500/-
EARNEST MONEY DEPOSIT
` ` ` ` 4945/-
Tender fee is acceptable in Cash or by Demand Draft favoring Gujarat State Electricity Corporation
Ltd. payable at Bank of Baroda at UTRAN.
1) Downloading end date : 05/07/2012 (Up to 15=00 Hour) 2) Date for submission of tender. : 05/07/2012 (15=30 Hour) 3) Date of opening of Tender (Technical Bid) : 05/07/2012 ( 15=30 Hour ) if possible.
4) Date of opening of Tender (Price bid) : Will be informed later.
Page 4 of 26
GUJARAT STATE ELECTRICITY CORPN. LTD. GAS BASED POWER STATION, UTRAN,DIST : SURAT-394 105.
PRE-QUALIFICATION REQUIREMENT
Name of work: Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran.(Web.05/13/Mech.II)
PRE-QUALIFICATION REQUIREMENT::
A. The bidder having work experienced of Servicing & Maintenance of Central Air
Conditions plants and Chiller Plant in any Govt. /non-Govt. reputed organization and
The bidder shall have to submit executed work order copies having Compressor
capacity above 70-Ton of Central Air Conditions plants /HVAC system /chiller plant
along with performance certificates for successful execution along with the technical bid.
B. The bidder shall have to submit detail of P.F. code number from appropriate authority
and Labour License.
C. The bidder shall have to submit PAN/TIN No. and IT Clearance Certificate along with
the Technical bid.
D. The bidder shall have to submit Solvency Certificate not older than 12 months from the
date of submission of tender of minimum 20% of the estimated cost from a Nationalized
Bank.
E. Copy of Service Tax registration.
F. Copy of Profile (List of tools & Tackles etc. required for subjected works)
G. Bidder shall have to mention the deviation if any into the Appendix No. 5 only enclosed herewith in technical bid.
H. Schedule, terms & conditions duly signed on each page of tender.
Technical Bid without above will not be qualified and liable for rejection
Signature of Contractor with Seal Additional Chief Engineer (Gen),
UGBPS, Utran
Page 5 of 26
GUJARAT STATE ELECTRICITY CORPN. LTD. GAS BASED POWER STATION, UTRAN,DIST : SURAT-394 105.
SCHEDULE-A
NAME OF WORK: Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran. (Web.05/13/Mech.II)
(1) SCOPE OF WORK:
The scope of work comprises following items but does not limit with matter, party might have to work as per site situation and instruction of EIC. The maintenance means the activity to be planned before failure as preventive, to monitor and repair wearing out components as schedule maintenance and to replace / repair and refit broken parts as breakdown maintenance such that the air conditioning plant should run at rated design condition.
(2) ROUTINE/PREVENTIVE MAINTENANCE OF AIR CONDITIONING PLANT ( FOR ITEM
SR. NO. A1, B1 & C1)
Routine maintenance of central A/C plant of ADM & ECB and SWAS Chiller Plant includes routine checking/rectification includes proper working of refrigeration compressors including gas charging/ Compressor Gas pressure checking, Greasing/Oiling Checking / filling, various accessories like Gas valves, Expansion Valves, Solenoid Valves, Micro-processor controller, Pressure Switches/gauges, thermostatic Control equipments, condensers and chillers cleaning & testing, chilled/Condenser Water pump’s valves. Routine checking of Air handling units & cooling Towers of ECB, ADM i.e. Belt checking & tensioning, Alignment, Greasing/Oiling Checking / filling, Cleaning of Cooling Tower, Bearing Checking, removal & application of insulation on pipe / auxiliaries, Air/ Water cleaning of Suction & Discharge Filters of AHUs, etc. Checking of SWAS chiller system with its accessories and cleaning suction filters and Micro Filters etc. so as to run the equipments to achieve design parameters. Taking set of reading and reporting the healthiness of the plant and suggesting improvement if any.
(3) OVERHAULING OF AC PLANT COMPRESSOR ( FOR ITEM SR. NO. A2, B2 & C2) Complete overhauling of VOLTAS make AC Plant (80 T capacity) Compressor model SRC-M-300 (2 Nos.) of Electric & Control Building (ECB) and VOLTAS make AC Plant (100 T capacity) compressor model 8591-140Y (2 Nos.) & SWAS chiller Unit KIRLOSKER Compressor. Compressor shall be overhaul in Power station Premises & if taking outside prior permission to be taken from EIC & should be dismantled in presence of Special Technical supervisor only. This includes, Complete Overhauling/servicing/ replacement of defective parts of AC compressors, various accessories like Gas valves, Expansion Valves, Solenoid Valves, Pressure Switches/gauges, Gasket, O-Ring, Sight Glass, thermostatic Control equipments, replacement/checking of Air Dryer/filter, condensers and chillers cleaning & testing, oil filling and re-commissioning of AC compressor by vacuum zing,
Page 6 of 26
Nitrogen Testing and gas charging to run at design parameters and if required replacement/servicing of copper tubing with its needle/angle valves. Seal Replacement includes rectification of leakage, pumping down of gas, attending the seal leakage and if required replacement so as to arrest leakages of gas as well as oil.
(4) CLEANING OF CONDENSER & CHILLER ( FOR ITEM SR. NO. A3,A4, B3 & B4) Condenser and Chiller cleaning/de-scaling and testing includes, Dismantling of Pipes/Component etc, cleaning of condenser by water jetting/Acid cleaning and after taking Hydro test, if required plugging of leaky tubes, box up of end covers and to assure no leakage after box-up.
(5) CLEANING OF SUCTION/OIL/LIQUID LINE FILTER ETC. ( FOR ITEM SR. NO. A5 & B5) Suction filter, Oil Filter, Filter Core, Liquid Line Filter etc. and Outside Cleaning of AC Compressor includes the work of Cleaning/replacement of Filters to remove debris and cleaning/replacement of AC Compressor, condenser, chiller, associated piping with removal & application of insulation etc. from outside so as to have aesthetic look of the equipment and system.
(6) GAS/REFRIGERANT LEAKAGE ATTENDING ( FOR ITEM SR. NO. A6,B6 & C3) Gas/ refrigerant leakage checking, attending and gas filling of AC Compressor System includes that During running of AC compressor, due to low/high gas pressure if AC compressor does not give satisfactory performance, gas leakage shall be checked by leak test and should be attended and required gas shall be filled up to run the AC compressor at design parameters.
(7) REPLACEMENT OF OIL ( FOR ITEM SR. NO. A7,B7 & C4) Oil replacement work of A/C Compressor includes pumping down of gas/refrigerant, topping up/replacement of Oil as per the requirement & in necessary Oil seal etc should be replaced.
(8) OVERHAULING OF AHU SYSTEM ( FOR ITEM SR. NO. A8 & B8) Complete AHU system Overhauling of ADM & ECB includes, Complete Overhauling/servicing/ replacement of defective parts of AHUs of ADM & ECB with its accessories like bearing, oil seal, pulleys etc. greasing/Oiling/replacement, belt adjustment/alignment, belt tension checking, leakage in heat exchanger attending, inlet outlet valves, cleaning/replacement of filters, Micro Filters, overhauling/ repairing of Discharge dampers & Bellow of ADM & ECB etc. so as to run the equipments to achieve design parameters and to maintain required temperature in Control Room.
(9) CHECKING OF COOLING TOWER-CT ( FOR ITEM SR. NO. A9 & B9)
Cooling Tower bearing greasing/Oiling/replacement, belt adjustment/alignment/ replacement, tension checking, Pulley checking etc. to avoid vibration. Cleaning /de-
Page 7 of 26
scaling of cooling tower fins by means of acid/water jetting, Cleaning of CT sumps, O/H / replacement of suction/discharge valves of CT and any other works to run the unit at design parameters.
(10) LOADING / UNLOADING OF COMPRESSOR / MOTORS OF AC PLANT of ECB & ADM: [For item Sr. No. A10 & B10]
(i) The lifting device like chain pulley block/ Hook-chook/Sealing etc will be given by the Corporation if available. However, same is to be collected by contractor from GSECL store on availability.
(ii) The complete, necessary, safe guard is to be prepared by the contractor with mounting of chain pulley block etc.
(iii) During lifting, shifting, loading/unloading for any damage to the man/material of GSECL or contractor; the contractor will be held responsible.
(iv) The work of loading/unloading should be completed within 10-days after clear cut instruction from Engineer in Charge of GSECL.
(v) Necessary arraignment of vehicle is to be arranged by contractor for shifting of defecting component to work site from ECB/ADM.
(11) CHECKING OF AHU SUSTEM ( FOR ITEM SR. NO. A11,B11 &C5)
Party has to report at site with in 04 Hrs. with technician/expert & helpers after receiving call from GSECL Engineer- in- Charge and shall have able to tackle/ resolve the problems. All the activities are to be carried out for put the plant in service as A/C plant is emergency in nature. Party has to leave the site only after prior permission of Engineer-in-charge.
(12) OVERHAULING OF VALVES ( FOR ITEM SR. NO. D1) Overhauling and servicing Cooling/ condenser Water and Chilled Water valves / NRVs size up to 200NB so as to have smooth operation of valves and proper isolation of the system/equipment.
13) OTHER TECHNICAL CONDITIONS: (i) The rates offered for each works are valid 11-Months from the date of issue of
order. (ii) The contractor has to inspect / check, service & attend our A.C. plant installation as
mentioned in schedule-B item Sr. No. A1, B1 & C1 of the contract, once in every 02 (two) Month i.e in first week of month and will ensure smooth running of plant. Any of the maintenance works as mentioned in schedule-B i.e. A2 to A11, B2 to B11, C2 to C5 and D1 will have to be carried out on “As and when required” basis. The payment will be made accordingly as per actual works carried out by the contractor
(iii) All the repairing and servicing work is to be carried out at site. One team of supervisor, skilled technicians and other required staff should be send by contractor in general shift as well as in extra hours for routine and planned schedule work. The defects which might come during odd hours or night time party shall have to arrange the staff. No extra charges shall be paid extra.
(iv) Contractor shall submit the list of required spares in advance at least before 1-2 months, which should be kept on hand at GSECL store. GSECL shall provide
Page 8 of 26
necessary spares to contractor. Although if the spares are not available during breakdown of plant, party has to arrange the spare in emergency with prior approval of authority, which shall be reimbursed to party after verifying reasonability of rates.
(v) Party has to keep the material account statement, and has to produce with each RA bill. The scrap items are to be credited to main store after prior approval, for which necessary documents shall be provided by GSECL.
(vi) Contractor shall keep the record of maintenance report in register and defects received from UGBPS, GSECL. This document has to be produce with each RA Bill.
(vii) The payment will be made accordingly as per actual works carried out by the contractor.
(viii) The rates are without supply of spares of Compressors, Condenser; AHU & Chiller unit requires to be replaced. Same will be supplied by GSECL free of cost. Mafron 22- Gas / Refron 22- Gas / R134a (Green series) for the system and Nitrogen Gas required for the system for flushing will be supplied by GSECL free of cost. Consumables required during the works will be supplied by GSECL free of cost.The contractor will have to arrange vacuum pump, compressor (to remove the gas from system), ice, copper tube, pressure/regulator gauge etc. at their own cost.
(ix) The contractor shall bring their own special tools and tackles for the required maintenance works. GSECL will not provide the same.
(x) The maintenance work of A.C plant is of emergency nature hence each & every defects shall be attended by working round the clock, if required to put the plant back in to service satisfactorily.
(xi) During maintenance work accommodation will be provided if available, on chargeable basis as per GSECL rules.
(xii) The Contractor has to clean the site before starting & completion of work. (xiii) After intimation party must to reach the site with in 04 Hrs at Utran power station.
Penalty will be imposed Rs.200/- per Hour in case of late reporting. (xiv) Any works which are not specified in the contract which are to be carried out for put
the plant in service as A/C plant with out any extra cost.
(xv) Time Limit: This is rate contract to be awarded for a period of 11-Months. The Additional.C.E.(G)Utran GBPS reserves the right to extend this contract for further period of six months or any part thereof & it will be binding to the contractor. The rate & other terms & conditions will remain as per original order for extended period.
(xvi) GUARANTEE :- Contractor shall have to give one month performance guarantee for work carried out during contract period. In the event of any defect(s) noticed during guarantee period, contractor shall have to rectify the same as per instruction of concerned engineer with out any extra cost.
Additional Chief Engineer (Gen),
GSECL, GBPS, Utran
Seal & signature of contractor
Page 9 of 26
GUJARAT STATE ELECTRICITY CORPORATION LTD.
GAS BASED POWER STATION UTRAN
Name of work: Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran. (Web.05/13/Mech.II)
ANNEXURE-I
TERMS AND CONDITIONS:
1) The work shall be carried out according to the enclosed General Conditions, other conditions, Technical Specifications etc & such of the working drawings approved by the GSECL.
2) Tenders must be submitted in the enclosed schedule of work & quantities. Those received in any other form will not be accepted. They should be accompanied by a covering letter in which the bidder should give all information as called for in the specifications & any other point which he would like to be considered along with the tender.
3) EARNEST MONEY DEPOSIT (EMD) a. Bidders are requested to pay an earnest money deposit by demand draft only on Public
Sector Banks, or IDBI Bank / AXIS Bank / HDFC Bank / ICICI / The Kalupur Commercial Co-Operative Bank Limited Bank payable at Utran as specified in the tender notice. Payment of EMD in form of Cheque shall not be accepted.
b. The EMD shall be submitted along with submission of Technical bid only. Tenders not accompanied by EMD shall be rejected as non-responsive.
c. If during the tender validity period, i.e. 120 days, the tenderer withdraws his tender, the EMD shall be forfeited and the tenderer may be disqualified from tendering for further works.
d. The EMD will be returned promptly to the unsuccessful tenderer. The EMD will be returned to the successful tenderer after he furnishes the Security Deposit for performance and duly enters in to the contract. If he fails to furnish the SD or to execute the contract for the work offered to him, his EMD shall be forfeited and the tenderer may be disqualified from tendering for further work.
4) SECURITY DEPOSIT (SD): a. Successful bidder shall have to pay Security Deposit (SD) equivalent to 05% of the ordered
value in Advance. Any loss to the GSECL due to late start of work because of late payment SD shall be the contractor’s liability.
b. The amount of Security Deposit will be refunded after the satisfactory completion of the contract after certification by the concerned Suptd. Engineer and after deducting any dues of the GSECL.
5) AGREEMENT:
The contractor will have to execute agreement on Rs.100/- non judicial stamp paper purchased from Government treasury office/post office only before starting the work. In case of non execution of agreement the payment will be withheld.
6) BOND : You will have to execute Indemnity Bond on Rs. 100/- Non-judicial stamp paper purchased from Government treasury office/post office only for indemnity of the material issued by GSECL for the above work.
7) Any tender not bearing signature of the bidder & seal of the company on all the documents accompanying the tender is liable to rejection. Further it is specifically instructed that conditional tenders shall summarily be rejected.
8) The tenders received after time and date specified in the tender notice, will not be accepted. Once the offer submitted by the contractor before due date of submission, the contractor will not be allowed to submit revised / additional / modified / other even before due date. However, if the issue
Page 10 of 26
and receipt of tender is extended by the GSECL due to any reason, the contractor may submit the revised offer before due date of submission, if he wish to submit.
9) The bidders shall note that no deviations from the technical specifications or commercial conditions with this bid are acceptable & it will be presumed that the bidder agrees entirely with the specifications & General terms &conditions of the contract.
10) The work shall be completed within the period stipulated in the contract. In the event of any delay due to any other reason not attributable to the contractor, reasonable extension in the completing the work may be given at the discretion & as decided by the GSECL but no compensation or idle charges will be paid to the contractor under any circumstances.
11) The GSECL reserves the right to accept any tender irrespective of whether it is lowest or not or to reject all the tenders without assigning any reasons there of. Tenders departing from the technical Specification or the method of bidding in a radical manner may also be rejected.
12) On acceptance of the tender the name(s) of the accredited representative(s) of the tenderer who would be responsible for taking instructions from the Engineers of the GSECL shall be
communicated to the Additional Chief Engineer (GEN), Gujarat State Electricity Corporation Ltd,UGBPS, UTRAN.
13) This specification is intended as a general description of quality envisaged for materials & workmanship & of the finished work. It is not intended to cover minute details. The work shall be executed in accordance with the best modern practice & to the complete satisfaction of the GSECL. Special techniques approved by the GSECL shall be used if & where found necessary without any extra claim. This specification shall have precedence if any thing contrary to this is stated elsewhere in the contract documents, the GSECL’s decision shall be final & binding to the contractor on any issue arising out of such discrepancies
14) The contractor will observe all safety measures for his working persons. The Contractor will be responsible for his working personnel for any injuries or mishap caused/occurred to them during the execution of above work. GSECL will not pay any compensation in such case to Contractor’s persons.
15) The contractor will also be responsible for any damages caused to the GSECL property by his Personnel during the execution of above work. In such cases, the contractor will arrange to repair/rectify or will pay such amount to GSECL as may be decided by the competent authority of GSECL
16) The contractor will govern his working personnel with the labour laws and other prevailing laws in Gujarat State. Contractor shall arrange for all necessary insurance policies for labour, material, equipment etc
17) The work will have to be carried out as and when required, as per the instruction of Engineer-in-charge.
18) If any dispute arise during the execution of the work, the decision of Additional Chief Engineer, GSECL , Utran, shall be final & acceptable & binding to the contractor.
19) The contractor’s personnel will co-operate to the engineer-in-charge for execution and satisfactory completion of work.
20) GSECL reserves Right to forfeit the security deposit in case of any beach of Contract condition in
case of any dispute the decision of the under Additional Chief Engineer, GSECL UTRAN shall be final and acceptable & binding to contractor.
21) COMPENSATION FOR DELAY : The complete job as per schedule B is to be completed with time limit, failing which will be penalty at rate of ½ % or order value per day to the extend of 10% of the order value will be recovered from the bill.
22) If engineer–in-charge feels that work done by the contractor is not done in satisfactory no extra charge will be payable by the GSECL for such work if carried out again by Contractor, to complete the works as per the requirement.
Page 11 of 26
23) UNSATISFACTORY PROGRESS OF WORKS : If contractor fails to start the work in time specified or his work is found dissatisfactory or he
defaults In proper execution of work or he fails to improve his working in spite of instruction given
to him, GSECL reserves the right to terminate the contract by serving 7(seven) days notice. The
security deposit paid by the contractor in such case shall be forfeited. GSECL also reserves the
right to award the contract to any other party or may carry out the work departmentally at the risk
and cost of the contractor.
24) INCOME TAX : Income tax as applicable will be deducted from the bill as per I.T. act/Rules
25) GSECL will provide accommodation if available on chargeable basis as per GSECL’s rules & one quarter/Hostel room will be allocated to the contractor on request if available.
26) R.A./Final bill of this work will be prepaid after completion of work satisfactorily as per Engineer-in-charge.
27) Daily work progress report & labous’s presence will be submitted by Contractor to the Engineer-in –charge.
28) The penalty will be levied, if the contractor will leave the work un-completed. 29) All debris/dirt will be cleaned regularly from the work place, & the working place will be kept
cleaned by the contractor. 30) The contractor shall bring his own tools & tackles & cleaning material & consumable as may be
required for carrying out the job. 31) VALIDITY OF TENDERS:
All quotations shall be opened for acceptance by GSECL for a period of 120 days from the date of opening of the tenders and the Tenderer shall be bound to do so supply on such acceptance. All quotations submitted against this tender shall be deemed to comply with this condition, unless otherwise agreed to, by M/s GSECL.
32) QUOTATION a) The Tenderer must quote his rates per unit specified in the schedule, in figures as well as in
words. b) Any variation in the rates etc will not be allowed on any ground such as a mistake,
misunderstanding etc, after the tender has been submitted. The Tenderer rate must include in general.
c) Suppliers printed terms & conditions of the contract will not be considered as part of tender, if our standard terms are not acceptable they should specify deviation if any of the tender.
d) Tenderers are prohibited from making any addition or alteration in the description of articles mentioned in the Schedule. If they wish to quote for any similar items, they may do so, by adding such items at the end of
the Schedule.
e) All tenders must be submitted on this form and must be clearly and legibly filled in quotation and remarks must be either in ink or typewriting. Tenderers are requested to sign the form of tender and schedule of rates and if not so signed, the tender shall be rejected.
33) ACCEPTANCE OR REJECTION OF BID
(I) The GSECL reserves the right to accept any tender irrespective of whether it is lowest or not or to reject all the tenders without assigning any reasons thereof. Tenders departing from the stipulated technical specifications, commercial conditions or the method of bidding in a radical manner are liable to be rejected.
(II) The bid is liable for rejection, if it is
• Without payment of EMD / Tender Fee. • Not in prescribed form.
Page 12 of 26
• Not bearing signature of the bidder & seal of the company on all the documents accompanying the tender.
• Not confirming to specifications or conditional tender. • Received after expiry of the due date & time. • Received by telex or telegram or fax.
• Submitted by bidders who are listed under declaration of ineligibility for corrupt or fraudulent practices issued by GSECL, Govt. of Gujarat or other Public Sector under taking.
• Tender not fulfilling all the above conditions and those specified in the documents attached or incomplete in any respect are liable to rejection.
34) EARNEST MONEY OF UNSUCESSFUL TENDERS:
Earnest money deposited by unsuccessful tenders will be refund as soon as possible, after
the tender has been settled upon & the Tenderer has to return to the Addl Chief Engineer,
Utran, the original receipt for the Earnest money together with the advance stamped receipt.
35) DISREGARD OF TENDER CONDITIONS: M/s GSECL reserves the right to reject any tender which does not confirm to any of the above
conditions.
36) JURIDICTION: All quotations or differences arising our or in connection with the contract if concluded shall be
subject to the exclusive jurisdiction of the court within whose jurisdiction the place from which
the acceptance of tender issued, is situated.
37) Arbitration: { A }
“ All question, dispute or differences whatsoever which may at any time arise between the
parties to this agreement touching the agreement or subject matter thereof, arising out or in
relation thee to and whether as to construction or otherwise shall be referred to the decision
of the sole Arbitrator, appointed by the chairman & MD ,GSECL for that purpose, who shall be
retired High Court Judge or a retired District and Sessions Judge, and the decision of the said
Arbitrator shall be final and binding upon the parties, Reference to the Arbitrator shall be
governed by the provisions of the Arbitration and conciliation act-1996 as amended from time
to time and rules made there under. The Arbitration proceeding shall be conducted at HO,
GSECL, Vadodara or at such place as the sole Arbitrator may be determined. The award of
sole Arbitrator shall be final be final and binding upon the parties”
{ B }
“ All question, dispute or differences whatsoever which may at any time arise between the
parties to this contract in connection with the contract or any matter arising out of or in relation
thereto shall be referred to the Gujarat Public Works Contract Dispute Arbitration Tribunal as
per the provision of the Gujarat Public Works Contract Dispute Arbitration Tribunal act-1992”
“In case where divisible orders for supply and works are placed instead of indivisible supply
and works order, the arbitration clause for such divisible supply order shall be incorporated as
per Sr. A and for divisible work order the Arbitration clause shall be as per Sr no- B above.”
38 The contract or any part thereof shall not be subject to change without the written permission of
the Additional Chief Engineer (G), Gujarat State Electricity Corporation Ltd, Utran or his authorized representatives.
Page 13 of 26
35. Further information required, if any, can be had from the office of the Additional Chief Engineer (G), Gujarat State Electricity Corporation Ltd, Utran, during working hours. But it must be clearly understood that the tenders must be received complete in every respects by the due date & time.
36. The electric power, at site, will be made available at one mutually agreed point, free of cost (connection only) by Gujarat State Electricity Corporation Ltd, Utran Gas Based Power Station within GSECL premises only. Further distribution will have to be carried out by the contractor as per requirements at their own cost.
37. Bidders must quote firm price only, till completion of work under contract, & this is to be confirmed by bidder while submitting his offer.
38. No escalation towards labour and material / fuel shall be paid in this execution of contract. Price quoted shall be firm.
39. Each tender shall contain the name, residence & place of business of person or persons making the tender & shall be signed by the tenderer with his usual signature with seal of the company.
40. GSECL reserves the right to delete any item of Schedule-B for which contractor shall not have any right to claim on this account.
41. No idle charges shall be entertained by Gujarat State Electricity Corporation Ltd for any site conditions or any circumstances.
42. The contractor shall have a separate Provident Fund Code of RPFC in the name of company. The contractors, who do not posses such separate P.F. code, shall not be considered for acceptance of tender. The contractor has to submit such certificate showing P.F. code along with tender.
43. Effect and validity of Bid: The submission of any bid connected with these documents and specification shall constitute on agreement that bidder shall have no cause of action or claim against the owner for rejection of his bid. The GSECL shall always be at liberty to reject or accept, split any bid or bids at his sole discretion and any action will not be called into question and the bidder shall have no claim in that regards against the owner.
44. Site visit: The bidder may visit the site for all information that may be necessary for quoting the tender bid and entering in to contract. All cash and liabilities arising out of the site visit shall be at bidder account.
45. Recoveries: (I) In case of any damage to equipment/machinery or structure/building of GSECL or any public
property due to negligence’s of contractor or any other reasons attributed to contractor the decision of E.I.C. regarding the amount of recovery shall be final.
(II) If the contractor fails to execute the work as per direction of E.I.C. within the time frame given by GSECL time to time, shall get the work done through any other contractor at the risk and cost of the contractor and the cost of execution of such work along with 15% overhead charges shall be deducted from contractor bill over and above recovery as per rules.
46. The notice inviting tender, general instruction to bidders and all other documents of this tender shall form part of the contract.
47. Tenders who do not fulfill all the above conditions & those specified in the documents attached with this contract document or incomplete in any respect are liable to rejection.
Additional Chief Engineer (Gen),
GBPS, Utran
Seal & signature of contractor
Page 14 of 26
ANNEXURE-II
Name of work: Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran. (Web.05/13/Mech.II)
Detail Specification Of HVACs Plant::
Sr No
Location Equipment No. of Unit
Model No Capaci
ty Make
Power Consumptio
n
Motor Ratin
g Type
No Of Capacity
Controlled Steps
1
ECB (Electrical & Control; Building)
Main Unit 2
(1W+1S) WCDRO8
ORMN 80 Tr. EACH
VOLTAS 75 KW 90 KW
Compressor 2
(1W+1S) SRC-M-
300 80 Tr. EACH
REFCOMP, ITALY
75 KW 90 KW
Semi-Hermetic/
Reciprocating
3 steps(100 %/67 %/33
%)
Condenser 2
(1W+1S) 9076 VOLTAS
Chiller 2
(1W+1S) 10076 VOLTAS
AHU 2
(1W+1S) V-500H VOLTAS
Cooling Tower
2 (1W+1S)
3853 PAHARPUR
2
ADM (SERVICE BUILDING):
Main Unit 2
(1W+1S)
GSWCDXR 100-1(green series)
100 Tr. Each
Voltas Limited
80KW 115K
W
Compressor 2
(1W+1S) 8591-140Y
100 Tr. Each
Bitzer, Germany
80KW 115K
W Semi-Hermetic / Screw Type
Stepless Control
from 100% to 25 %
Condenser 2
(1W+1S) 9126
Voltas Limited
Chiller 2
(1W+1S) ERDX105-
2P 1M
Voltas Limited
AHU 2
(1W+1S) VOLTAS
Cooling Tower
2 (1W+1S)
3861 PAHARPUR
3
SWAS SAMPLE Chiller unit
Main Unit 2
(1W+1S) 5 Tr.
FORBES MARSHELL
Vapour Compression Type, Water
Cooled Chiller
Compressor
2 (1W+1S)
Kirlosker
Semi-Hermetic/
Screw Type
Page 15 of 26
GUJARAT STATE ELCTRICITY CORPORATION LIMITED GAS BASED POWER STATION UTRAN –SURAT
Name of work: Name of work: Bimonthly services & maintenance of equipments and systems
on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran. (Web.05/13/Mech.II)
Deviation sheet
Sr. No. DEVIATION Ref. Page
No.
Tender Document
Ref.
Proposal of contractor
Remarks
Date: Place: Seal & signature of contractor
Page 16 of 26
TERMS AND CONDITIONS REGARDING INDUSTRIAL LAWS AND OTHER RELATED MATTERS:
1. WAGES TO BE PAID, TIME OF PAYMENT, ETC. BY THE CONTRACTOR :
The Monthly payment of wages to the contract labourers will be compulsorily made through
bank. The Contractor shall supply copy of Bank Statement duly stamped by the concern Bank
as a Token of Proof towards payment of wages to HR Dept. If any problem may arise for
payment of wages through bank, same may inform to Additional.Chief Engineer (G) and after
approval the payment shall be disbursed in presence of the GSECL representative i.e. HR
officer during the working hours in the factory premises and the contractor shall get the entries
certified in the register of wages by the representative of the GSECL. Any default will result in
cancellation of contract forthwith or else the contractor shall be punishable to the extend of Rs.
100/- per day by way of fine. The contractor shall give his telephone number, address to the
GSECL, so that in case of labour unrest etc. the contractor can be contracted.
2. Labour Laws:
a. The labour laws applicable and amended from time to time have to be followed scrupulously. A
few of them for information are as under:
b. Person below the age of eighteen years shall not be employed for the works
c. No female worker shall be employed in the night shift between 19:00 hrs and 06:00 hrs.
d. Contractor shall maintain a valid labour license under the Contract Labour (Regulation &
Abolition) Act for employing necessary manpower to be required by him. In the absence of
such license, the contract shall be liable to be terminated without assigning any reasons
thereof.
e. The contractor shall, at his own expense, comply with all labour laws and keep the GSECL
indemnified in respect thereof. Some of the major liabilities under various labour and industrial
laws, which the contractor shall comply with, are as under:
f. Payment of contribution of employees (contract labour) as well as employer’s (contractor’s)
contribution towards provident fund, family pension scheme, deposit linked insurance scheme,
administration charges, inspection charges, etc., at the rates applicable from time to time by the
Government of Gujarat/Government of India or other statutory authorities.
g. Payment of deposit and License fee in respect of each contract labour at the rate as revised by
the Government from time to time with the Office of the Commissioner of Labour as per the
Contract Labour (R&A) Act. License fee as prescribed under the Contract Labour (R&A) Act
and rules framed therein, depending upon the number of workers employed by the contractor.
h. Paid leave facility and wages as per the provision of the Factories Act at the rate of one day for
every 20 days of working.
i. No laboures are allowed to enter in power station premises that don’t Identity cards as
prescribed under the Factories Act or by the Thermal power station with photograph affixed
thereon, for identification of workers.
Page 17 of 26
j. Payment of retrenchment compensation, notice pay and other liabilities as per Industrial
Disputes Act, 1947. Any payment to the contractor’s employees arising out of any claim or
disputes under the Industrial Disputes Act, 1947 or any other labour laws.
k. Payment of compensation in case of accidental injury, under Workmen’s Compensation Act.
l. Provision of crèche if the female labour employed is more than 30.
m. Maternity leave as per the provision of the Maternity Benefits Act.
n. If any workmen engage by contractor / agency meets with fatal or non fatal accident while on
duty, then contractor / agency shall be liable to pay compensation to legal hair or to the
workman as case may be as per workman compensation act.
The above are some of the major liabilities of the contractor in addition to other liabilities prescribed
under the various labour laws in force from time to time by the statutory authorities, like State
Government/Government of India, which the contractor shall have to comply with.
3. PROVIDENT FUND AND FAMILY PENSION SCHEME:
The contractor shall submit along with his bill ( month – wise ) a statement regarding deductions
against employees Provident Fund ( EPF ) and Family Pension Scheme ( FPS ) in respect of
each concerned employee at the rate of 12% or at the rates made applicable by the government
from to time of wages. The contractor’s contribution and the worker’s contribution towards PF
and FPS shall be deposited by the contractor with the Regional Provident Fund Commissioner,
Ahmedabad, or to the authority prescribed under the Act along with the other charges.
4. DEPOSIT LINKED INSURANCE SCHEME : The contractor shall have to deposit 0.50% ( half percent ) or the rate applicable from time to
time of the wages in respect of employees who are members of the PF , as the contribution to
the Deposit Linked Insurance Scheme, with the Regional Provident Fund Commissioner.
5. MINIMUM WAGES ACT : The contractor shall pay prevailing minimum wages as applicable from time to time to the
laborers engaged by him as per the Minimum Wages Act, in presence of the GSECL’s officer or
representative.
6. ADMINISTRATIVE CHARGES : Administrative charges for maintaining Provident Fund account shall be deposited by the
contractor with the Regional Provident Fund Commissioner, Ahmedabad, at the rates
applicable.
7. PAID LEAVE FACILITY :
Page 18 of 26
Paid leave facility at the rate of one day for every twenty days of actual work by the contract
labour shall be provided by the contractor to his workers. He shall maintain leave record /
verified and approved / certified by the authorized officer of the GSECL.
8. E.S.I. Act: The contractors shall comply with the provisions of E.S.I. Act wherever applicable as per the
prevailing provisions of the Act and as amended from time to time.
9. Safety: The contractor shall strictly observe all safety rules and provide safety equipment to the
contract labourers as per the Factories Act, 1948, and whatever amendments made from time
to time to avoid any chance of accident. The contractor shall strictly observe all instructions of
Safety Officer and Factory Inspector to avoid any chance of accident.
10. LABOUR LICENSE FOR LABOUR CONTRACT : : The Contractor / Agency shall have to obtain the copy of Labour Contract
License under contract Labour (Regulation & Abolition) Act from the appropriate authorities
before commencement of work.
11. WORKMEN’S COMPENSATION FUND AND EMPLOYER’S LIABILITY INSURACE:
Insurance shall be affected for all the contract employees engaged in the performance of this
contract. If any of the work is sublet after due permission in writing from the GSECL, the
contractor shall require the sub – contractor to provide workmen’s compensation and
employer’s liability insurance for the later employees, unless such employees are covered under
the contractor’s insurance. It shall be the liability of contractor for employees of his sub –
contractor. The contractor must insure that all the laborers may cover before starting the works
12. SUBMISSION OF RETURNS & MAINTENANCE OF RECORDS : The contractor shall submit the returns under the Contract Labour Act, payment of Bonus Act,
Payment of Gratuity Act etc. and shall have to maintain all up to date records / registers in
respect his employee as prescribed under various Labour Laws and produce the same as and
when demanded by GSECL’s or Govt. appropriate authorities.
13. CONTRACTOR TO INDEMNIFY THE GSECL : The contractor shall indemnify and keep indemnified the GSECL and every member, officer and
employees of the GSECL, including Engineer – in – Charge and his staff, against all actions.
Proceedings, claims, demands, costs and expenses whatever arising out of or in connection
with the matters referred in above clauses and elsewhere and against all actions, claims,
demands, Costa and expenses which may be made against the GSECK, by any workman /
Page 19 of 26
employee of the contractor or sub – contractor or any other person under any law, rules or
regulations having the force of law, including, but not limited to, claims against the owner under
Workmen’s Compensation Act, 1970. The force of law, including, but not be liable for or in
respect of or in consequence of any accident or injury to any workman or other person in the
employment of the contractor. The contractor shall indemnify and keep indemnified.
The GSECL against all such damages and compensation and against all claims, demands,
proceeding costs, charges and expenses whatever in respect thereof or in relation thereto.
The contractor shall also indemnify GSECL in all respect against any liability due to breach of
legal provisions contained in any of the Labour Laws.
The Contractor shall also indemnify GSECL for injury or damage to third party other than
employees of the GSECL contractor or sub – contractor.
14. Contractor / Agency shall have to issue the contractual appointment letter for a specific period to their Labour engaged during the contract period each and every instance & should narrated clear out terms & conditions for the liabilities of the concerned employees.
15. As a contractor, the contractor shall be responsible and liable to pay difference in wages, if any, and / or observe the revised service conditions that may be awarded by the Honorable Industrial Tribunal effective from the date directed in the award.
16. The contractor must be maintaining regular Labour record and should be paying all acquired benefits to Labour force and contractor should obtain certificates to this effect from HR Officer of GSECL.
17. The contractor will make arrangements at his own cost to insure all men, materials and equipment employed for this work. The GSECL will to be responsible for any loss or damage either to the contractor’s personnel or his equipment.
18. Dispute, if any, taking place between the contractor and laborers must be intimated to IRO, GBPS, Utran, immediately.
19. Any casualty will also have to be borne by the contractor for the period the contract continues.
20. The Contractor shall deposit 15 days salary at the rate of last drawn salary for every completed one year of services for each worker for the liabilities of Gratuity.
21. The Contractor / Agency shall have to produce / submit the copy of Wage Register, Muster Roll, PF Deposition Challan, PF Schedule, Copy of Bank Statement duly stamped by the concern Bank and
Page 20 of 26
relevant records under various Labour Laws for the contract work to HR Department to ensure compliance to provisions of various legislations.
22. Attendance of contract labourers will be through punching machines for which
Punching machines shall installed to facilitate the contractors by GSECL for
Which monthly charges of Rs. 10/- will be levied on contractor as administrative
Charges.
Additional Chief Engineer (Gen),
GBPS, Utran
Seal & signature of contractor
Page 21 of 26
GUJARAT STATE ELECTRICITY CORPORATION LTD.
UTRAN GAS BASED POWER STATION
“GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTORS. All contractors working at Utran GBPS shall have to strictly observe the following Safety Rules. Contractors are responsible to inform these rules to their staff & see that it is implemented by them as well as the employees of Agencies/Sub-Contractors engaged by them for work contract awarded to them. Prior to commencement of the work, Contractor shall have to submit a written assurance on their letterhead to the concerned Sectional Head/Engineer-in-charge that they have thoroughly gone through these Rules, have educated their employees/employee of their sub contractor and will strictly observe the said Rules while execution of work under work contract awarded to them. They shall indemnify the Corporation for any loss/damage of properties or accident/injury to the Corporation’s employee or employee of their own in default of non - observing these rules. 01 Only qualified, trained, experienced & conversant persons are to be engaged/ employed for execution of the
work awarded to them. 02 The contractor shall take all the required safety measures prior to commencement of work on dangerous
substances, machineries or area at which cautionary notice is displayed and obtain “Line Clear” or “Work Permit” through the concerned Department / Section.
03 Prior to welding, cutting, heating or any other hot work job, remove all the inflammable material lying at or nearby worksite or cover it properly by suitable protective covering. Also, special care shall be taken before carrying out such job & see that all possible contributing factors to set fire shall be removed/vanished prior to commencement of the work. Advance intimation shall be given to concern section/fire section to commence the work in fire prone areas. Necessary Fire Extinguishers/equipments & fire extinguishing media/material like sand/water buckets or other appropriate equipment shall also be kept ready at such place.
04 Prior to commencement of the work inside confined space/vessel, obtain necessary “Confined Space/Vessel Entry Permit” from concerned department. Properly guarded & BIS approved 24-volt hand lamp shall be used for lighting in such areas. Competent supervisor/person at entry point shall be kept for taking care of person(s) working inside confined space/vessel who will keep constant watch on person(s) working inside, assist them or arrange for outside assistance incase of emergency. While working inside sewage, trench or in-depth, either a person, to warn outsiders/entrants/passers etc, shall remain available near entry point or the entry point shall be cordoned by a barricaded tape with a cautionary notice. After completion of the works, all the lids/covers/grills/grits opened, shall be re-fixed/re-placed in the original position as it were prior to commencement of the work and leave the work place in safe condition in all respect, so as to prevent accident to fellow workers.
05 Do not work on or block (by stacking material/spare-parts/tools-tackles/equipments etc) any passages/walkways/staircases/lifts/platforms or any other approaches/roads leading to plants or its auxiliaries, on which there is movement or possibility of movement/traffic in emergency. Such passages are for safe escape in emergency. In unavoidable circumstances if it is utmost necessary to carryout any work in such area, either obtain prior permission of competent authority/Engineer in charge of this area, demarcate/declare area as UNSAFE by cordoning it using barricading tape with a suitable cautionary notice displayed on it or deploy a person to restrict the traffic on this route & divert it through other safe passage.
06 Prior to make use of any power/electrically operated hand tools/equipments/machines like welding/cutting machine/hand grinder/hand drill etc, ensure for its safe operation & use it only if it is found safe to use. Do not use defective, unsafe or improperly maintained equipments. The electrical power supply required to run such equipments shall not be connected directly at their own but it shall be obtained through Electrical Department by their authorized person or under their supervision/guidance. The Electrical Section will provide temporary electrical connection up to contractor’s Mains Board on which it is compulsory to install mains switch, ELCB & fuses of adequate capacity. All such equipments shall invariably be earthed adequately to prevent electrical shock/sparking/short-circuit etc. Power cord/cable used shall be of adequate capacity, joint less & having earth wire. It is compulsory to use 3-wire power cord for single & 4/5-wire power cord for three phase power connections. The plugs, receptacles, pins, holders etc shall be of standard make, adequate capacity & safe to use.
07 It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) while at work as per the job requirement. If your staff found working without P.P.Es., the ongoing work will be stopped at your risk & cost. List of P.P.Es. to be used for various works/worksites is as under. 01 Industrial Safety Helmet. For head protection against falling objects or during fall of person from
height.
02 Safety Goggles(Grinding, Welding, Panorama etc).
For protection of eyes against flying particles / dust, chemical splash, spark, arc, flashover etc.
03 Face shield (Half or full). For protection of face against flying particles /dust, chemical splash, spark,
Page 22 of 26
arc, flashover etc.
04 Earplug / Ear muffs. For ear / hearing system protection while working in high noise level area.
05 Apron (Rubber / PVC / Asbestos / Leather / Cotton).
For body protection against chemicals, oils, sharp edged objects, heat, hot objects etc.
06 Gloves (Rubber/PVC, Asbestos, Leather, shock proof).
For protection of hands against chemicals, oils, sharp edged objects, heat, hot metals/objects, electricity etc.
07 Safety / Leather / Asbestos shoes, Gum Boots etc.
For protection of leg/feet against falling objects, sharp edged objects, heat, hot metals/objects, electricity etc..
08 Safety Belt / Rope / Life line / Fall prevention system etc.
For fall prevention while working at heights or in depth, working in vessel or in confined space.
09 Dust Respirator / Scarf. Protection of respiratory system against dust.
10 Chemical Cartridge Respirator
Protection against chemical fume / vapor etc.
11 Canister Gas mask. Protection against toxic/poisonous fumes/gases.
12 Air supply respirators. Working in oxygen deficient zone.
08 Before using lifting machines/tackles (CPBs./Hook-chooks/winch/forklift/mobile-crane/EOT-crane etc) & its attachments (D-shackles/slings/U-clamps/Eye-bolts etc) or any fixtures, check it & use only if found safe-to-use, ensure that these statutorily tested, examined & certified by Competent Person & is valid. Further, it shall be fixed properly and firmly prior to lifting the weight.
09 Scaffoldings for working at height shall be of adequate size & capacity. It is compulsory to use helmet with fastened chinstrap and safety belt with anchored rope While climbing on such scaffolding or working on any structure at height.
10 All electrical & mechanical equipments/tools-tackles like welding-cutting machine, Grinder, Drill, Chain Pulley Blocks, Hook chooks etc used during work execution shall be of standard make & ISI marked. The consumables like welding electrodes, grinding wheels/discs etc which has specific prescribed life span shall not be used in any case after its expiry date is over.
11 Either contractor or their employee shall not interfere in routine plant activities/works except work assigned to them, leave their work jurisdiction & loiter in other area and temper/operate/disturb the machineries/equipments/auxiliaries not concerned to their work. Contractor shall not allow their staff to sit or take rest at/near/below running plants/auxiliaries/systems or any place which is dangerous/hazardous & prone to accident.
12 In case of noticing smoke or fire during their work execution, they shall make immediate efforts to extinguish / control it and simultaneously inform the Fire Brigade on phone No. 200 or 300.
13 Poisonous/toxic/flammable/explosive gas cylinders (O2/H2/NH3/Cl2/ CO2/LPG/ Acetylene etc) shall be handled safely taking due care. It shall never be rolled but handled/shifted using a special trolley.
14 On completion of the work, cotton waste, spilled oil / grease, pieces of welding rod & other waste material shall be removed from work site and the area shall be left safe, neat & clean.
15 In case of any injury/accident while working, it shall immediately be reported through concerned Sectional Head / Engineer in the prescribed Form No. 21 available at TK office.
16 Contractor shall to provide standard make (ISI approved) P.P.Es./Safety Gadgets, suitable to give sufficient protection against hazards involved in their work/job, to their staff looking to the job requirement and insist/enforce them to use it compulsorily while at works.
17 Over & above these, contractor shall have to observe, follow & comply with all safety related requirements/rules & regulations/norms and legal provisions laid down in various statutes. Particularly the provisions of The Factories Act-1948 & The Gujarat State Factories Rules-1963 (Amended up to date) shall be followed strictly. The contractor shall also obey the rules / regulations / instructions of the local Competent Authority for safety requirements.
18 The above rules shall be scrupulously followed. Contact Safety Officer, if required, in case of any ambiguity or further guidance in this regard.
Seal & signature of contractor Additional Chief Engineer (Gen),
GBPS, Utran
Page 23 of 26
GUJARAT STATE ELECTRICITY CORPORATION LTD.
CCPP-II, GBPS, Utran – 394 105
TENDER COPY
PRICE BID
NAME OF THE WORK:-
Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran. (Web.05/13/Mech.II)
Tender No.:Web.05/2013/Mech-II
Page 24 of 26
GUJARAT STATE ELECTRICITY CORPN. LTD.
GAS BASED POWER STATION, UTRAN,DIST : SURAT-394 105.
Name of work: Bimonthly services & maintenance of equipments and systems on as & when required basis for Central Air Condition plants of ADM, ECB and SWAS Chiller Plant of 370 MW CCPP-II, GSECL, Utran. (Web.05/13/Mech.II)
SCHEDULE –B
Sr. No.
Description Qty UOM Rate (Rs.) Amount
A A/C Plant of Electricals & Control Building (ECB):-
1
Routine/ Preventive maintenance of central A/C plant of ECB (1 Job =02 Nos. central A/C plant Unit i.e. 02 Nos. Main Unit, 02 Nos. Chiller, 02 Nos. Condenser, 02 Nos. AHU & 02 Nos. cooling Tower etc.)
6 Job 10010.00 60060.00
2 Overhauling of AC Compressors 2 Number 10010.00 20020.00
3 Condenser cleaning and testing 4 Number 2502.50 10010
4 Chiller Cleaning and testing 4 Number 2502.50 10010
5 Suction filter, Oil Filter, Liquid Line Filter and Outside Cleaning of AC Compressor.
4 Number 4004.00 16016
6 Leakage checking, attending and gas filling of AC Compressor System.
4 Number 5005.00 20020
7 Oil replacement work of AC Compressor 2 Number 1001.00 2002
8 Complete AHU system Overhauling of ECB 4 Number 2002.00 8008
9 Cleaning, de-scaling, preventive-routine Maintenance cooling Tower
2 Number 10010.00 20020
10 Removal, Unloading, loading and refitting AC Compressor -Motor of ECB.
2 Number 2002.00 4004
Page 25 of 26
Sr. No.
Description Qty UOM Rate (Rs.) Amount
11 AS & When required / EMERGENCY on Call Basis for above work
10 Call 2502.50 25025
B A/C Plant of Administrative Building::-
1
Routine maintenance of central A/C plant of Unit of ADM 1 Job =02 Nos. central A/C plant Unit i.e. 02 Nos. Main Unit, 02 Nos. Chiller, 02 Nos. Condenser, 02 Nos. AHU & 02 Nos. cooling Tower etc.)
6 Job 10010.00 60060
2 Overhauling of AC Compressors 2 Number 10010.00 20020
3 Condenser cleaning and testing 4 Number 2502.50 10010
4 Chiller Cleaning and testing 4 Number 2502.50 10010
5 Suction filter, Oil Filter, Liquid Line Filter and Outside Cleaning of AC Compressor.
4 Number 4004.00 16016
6 Leakage checking, attending and gas filling of AC Compressor System.
4 Number 5005.00 20020
7 Oil replacement work of AC Compressor 2 Number 1001.00 2002
8 Complete AHU system Overhauling of ADM 4 Number 2002.00 8008
9 Cleaning, de-scaling, preventive-routine Maintenance cooling Tower
2 Number 10010.00 20020
10 Removal, Unloading, loading and refitting AC Compressor -Motor of ADM.
2 Number 2002.00 4004
11 AS & When required/ EMERGENCY on Call Basis for above work
10 Call 2502.50 25025
C SWAS CHILLER UNIT:-
1 Routine maintenance of Chiller plant of Unit 6 Job 10010.00 60060
2 Overhauling of AC Compressors 1 Number 10010.00 10010
3 Leakage checking, attending and gas filling of AC Compressor System.
4 Number 3003.00 12012
4 Oil replacement work of AC Compressor 2 Number 1001.00 2002
5 AS & When required/ EMERGENCY on Call Basis for above work
6 Call 2502.50 15015
Page 26 of 26
Sr. No.
Description Qty UOM Rate (Rs.) Amount
D Common for ECB, ADM & SWAS Chiller Plant:-
1 Cooling Water and Chilled Water valves & NRV overhauling of Size up to 200NB Size of ADM, ECB & SWAS Chiller Plant.
10 Number 500.50 5005
Total estimate amount ::Rs. 494494.00
(TOTAL ESTIMATE AMOUNT Rs. FOUR LAC NINETY FOUR THOUSAND FOUR THOUSAND
NINETY FOUR ONLY)
NOTE:-
1. The above rates are exclusive of service tax. The same will be paid @rate prevailing. Bills shall be raised accordingly as per Govt. rules time to time.
Any other taxes if applicable, Contractor has to pay the same.
2. The contractor has to inspect / check, service & attend our A.C. plant installation as mentioned in schedule-B item Sr. No. A1, B1 & C1 of the contract, once in every 02 (two) Month i.e in first week of month and will ensure smooth running of plant. Any of the maintenance works as mentioned in schedule-B i.e. A2 to A11, B2 to B11, C2 to C5 and D1 will have to be carried out on “As and when required” basis. The above quantities are approximate & actual execution may be part thereof. The payment will be made for the actual quantity executed.
3. The unexecuted quantity may be treated as cancelled. 4. Percentage higher or lower shall be written in figure as well as in words also. 5. The contractor shall deploy qualified and experienced personal. 6. Please submit details of RTGS/NEFT.
Additional Chief Engineer (Gen), GBPS, Utran
Our Offer is___________________% higher OR ___________________% lower.
Net Amount in Rs.______________________________________________________
In words______________________________________________________________
Sign of contractor With seal & date